A22_W912EK25BA004 Solicitation and Specifications.pdf

SOLICITATION NO.: W912EK25BA004

B5IWPROJ202404

US Army Corps of Engineers Rock Island District

ILLINOIS RIVER BASIN

PEORIA AND LAGRANGE DAMS

PEORIA AND BROWN COUNTY, ILLINOIS

WICKET BULKHEAD – FIRST AND LAST

WICKETS

Supply Solicitation and Specifications

JUNE 2025

Peoria and LaGrange Dams Wicket Bulkhead SOLICITATION NO: W912EK25BA004

B5IWPROJ202404

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 14 00 WORK RESTRICTIONS

01 20 00 PRICE AND PAYMENT PROCEDURES

01 30 00 ADMINISTRATIVE REQUIREMENTS

01 32 16 FABRICATION PROGRESS SCHEDULES

01 33 00 SUBMITTAL PROCEDURES

01 45 00 RESIDENT MANAGEMENT SYSTEM (RMS)

01 45 04 FABRICATOR QUALITY CONTROL

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 05 - METALS

05 59 20 FABRICATION OF HYDRAULIC STEEL STRUCTURES

DIVISION 09 - FINISHES

09 97 02 PAINTING: HYDRAULIC STRUCTURES

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

REQUEST FOR QUOTATION

US Army Corps of Engineers ILLINOIS RIVER BASIN

PEORIA AND LAGRANGE DAMS

PEORIA AND BROWN COUNTY, ILLINOIS

WICKET BULKHEAD – FIRST AND LAST

WICKETS - W912EK25BA004

PLEASE RETURN TO:

US Army Corps of Engineers Attn: Kate Behrens 1500 Rock Island Drive Rock Island, Illinois 61201 Email: Katherine.D.Behrens@usace.army.mil

PLEASE INCLUDE THE FOLLOWING INFORMATION:

1. Complete blocks 15 through 18 on the SF33. All amendments should be acknowledged either by filling out block 14 of the SF33 or by filling out blocks 8 and 15A-C on each individual amendment.

2. Complete Offeror Representations and Certifications (Clause 52.212-3) in SAM and include in bid if your company has not previously completed the Representations and Certifications located with your company’s SAM record (https://www.sam.gov). Otherwise, simply mark FAR provision 52.204-8 with an “X” in paragraph (b)(2) where it states “( ) Paragraph (d) applies.”

3. Please fill out the the below information completely and include this cover page with your offer, along with the above items that need to be filled out.

4. Include the Solicitation Number on the subject line of your email when you submit your bids.

Bids shall be submitted via email to the following points of contact:

To: Katherine.D.Behrens@usace.army.mil cc: Jeffrey.R.Voss@usace.army.mil

Contractors must be current in their registration in the System for Award Management (SAM) Database before a Government Contract award can be made. Go to https://www.sam.gov/ to complete registration or renew registration if needed.

Please provide: Taxpayer ID Number: ____________________________ Point of Contact: _________________________________ Phone & Email: __________________________________

FOR ADDITIONAL INFORMATION,

CONTACT: Kate Behrens

Email: Katherine.D.Behrens@usace.army.mil

SECTION

15A. NAME AND

ADDRESS

OF OFFEROR

SOLICITATION, OFFER, AND AWARD 1. This Contract is a Rated Order under the Defense Priorities and Allocations System (DPAS) - Code of Federal Regulations - at 15 CFR 700.

CODE7. ISSUED BY 8. ADDRESS OFFER TO (If other than item 7)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

9. Sealed offers in original and copies for furnishings the supplies or services in the Schedule will be received at the place specified in item 8, or if hand carried, in the depository located in until local time

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision Number 52.214-7 or 52.215-1. All offers are subject to all terms and conditions contained in this solicitation.

10. FOR

INFORMATION

CALL:

A. NAME B. TELEPHONE (NO COLLECT CALLS)

AREA CODE NUMBER EXTENSION

C. EMAIL ADDRESS

11. TABLE OF CONTENTS

(X) DESCRIPTION PAGE(S) (X) SECTION PAGE(S)DESCRIPTION

I

J

K

L

M EVALUATION FACTORS FOR AWARD

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND OTHER

STATEMENTS OF OFFERORS

PART IV - REPRESENTATIONS AND INSTRUCTIONS

LIST OF ATTACHMENTS

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

CONTRACT CLAUSES

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

OFFER (Must be fully completed by offeror)

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause Number 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the SOLICITATION for offerors and related documents numbered and dated):

10 CALENDAR DAYS (%) 20 CALENDAR DAYS (%) 30 CALENDAR DAYS (%) CALENDAR DAYS (%)

DATEAMENDMENT NUMBERAMENDMENT NUMBER DATE

CODE FACILITY 16. NAME AND THE TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

15B. TELEPHONE NUMBER

AREA CODE NUMBER EXTENSION

15C. CHECK IF REMITTANCE ADDRESS IS

DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

17. SIGNATURE 18. OFFER DATE

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL OPEN COMPETITION UNDER THE

UNITED STATES CODE AT:

10 U.S.C. 3204(a) ( )41 U.S.C. 3304(a)

24. ADMINISTERED BY (If other than Item 7)

26. NAME OF CONTRACTING OFFICER (Type or print)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition is unusable

23. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

25. PAYMENT WILL BE MADE BY

27. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

28. AWARD DATE

CODE

ITEM

STANDARD FORM 33 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.214 (c)

(Hour) (Date)

PART I - THE SCHEDULE PART II - CONTRACT CLAUSES

1 52

W912EK25BA004 01 AUG 2025

W07V ENDIST ROCK ISLAND

KO CONTRACTING DIVISION, 1 ROCK ISLAND ARSENAL

ROCK ISLAND, IL 61299-5001

UNITED STATES

KATHERINE BEHRENS, EMAIL: KATHERINE.D.BEHRENS@USACE.ARMY.MIL TELEPHONE: (309) 794-5909

W912EK

10:00 AM 03 SEP 2025

KATHERINE BEHRENS

309 794-5909 KATHERINE.D.BEHRENS@USACE.ARMY.MIL

Section A - Solicitation/Contract Form

Peoria/LaGrange Dams, Peoria and Brown County, Illinois, Wicket Bulkhead - First and Last Wickets

W912EK25BA004

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

SCHEDULE OF PRICES

QUESTION AND ANSWER VIA PROJNET

ALL SUBMITTED QUESTIONS FOR THIS PROJECT AND THE ANSWERS PROVIDED SHALL BE VIEWED IN BIDDER INQUIRY IN PROJNET AT (https://www.projnet.org).

Technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at (https://www. projnet.org) No Later Than (NLT) 15 August 2025, at 2:00 PM Central Time. To submit or review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email. Another email to the same address will notify the prospective vendor once the reply is available for viewing.

The Bidder Inquiry Key is:

Specific Instructions for First Time ProjNet Bid Inquiry Access: F67X7T-SPT7TT

1. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

2. Identify the Agency. This should be marked as USACE.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Email. Enter the email address you would like to use for communication.

5. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

6. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

7. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Specific Instructions for Future ProjNet Bid Inquiry Access:

1. For future access to ProjNet, you will not be provided any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. From the ProjNet home page linked above, click on Quick Add on the upper right side of the screen.

3. Identify the Agency. This should be marked as USACE.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Email. Enter the email address you used to register previously in ProjNet.

6. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

7. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

INSTRUCTIONS TO BIDDERS

The Rock Island District has implemented the below procedures for all current bid openings.

Electronic Submission of Bids:

For this IFB Solicitation, the Rock Island District is requesting only electronic bids be submitted via email to the Contracting Officer and Contract Specialist. No hard copy bids will be accepted.

Contracting Officer - Jeff Voss: jeffrey.r.voss@usace.army.mil

Contract Specialist - Kate Behrens: katherine.d.behrens@usace.army.mil

In the subject of the e-mail - the solicitation and Project Name shall be provided.

The Contracting Officer or Contract Specialist will send an email acknowledging receipt. Please note, the Firewall can cause a delay in receipt of email, so be sure to allow time for the delay.

The Bid Opening is currently scheduled for Wednesday, 03 September 2025 at 11:00 AM CST.

The Contracting Officer and Contract Specialist will begin downloading bids ONE HOUR BEFORE BID OPENING TIME, which is the bid receipt cutoff time.

All bids received after 10:00 AM CST on Wednesday, 03 September 2025 will be considered late.

Audio Teleconference Bid Opening Information:

Bid Opening will be held on Wednesday, 03 September 2025 at 11:00 AM CST. Please use the following call-in information to attend the meeting:

Toll-Free: 601-262-2433

Phone conference ID: 542 246 202#

Following the conclusion of the bid opening, the Bid Abstract will be uploaded to SAM website under this solicitation, within 24 hours.

Bid Bonds (Offer Guarantee) should be submitted electronically with the Bid Package as per the scheduled Bid Opening on Amendment.

Per Class Deviation 2020-O0016, Electronic signatures and electronic, mechanically-applied, or printed dates may be used and shall be considered original signatures and dates. In addition, a Corporate Seal is not required, the SF 28 need not be sworn and notarized and a written authorization of the release signed by the surety is acceptable in lieu of the notarized authorization of release by the surety. Original Certified Bonds need not be submitted at time of bid.

HOWEVER, the Rock Island District reserves the right to request the Original Certified Bonds, if deemed necessary to verify their authenticity.

The following deviation clauses now apply, in lieu of the corresponding FAR clauses:

52.228-11, Pledges of Assets (DEVIATION 2020-O0016), which removes the requirement for the Standard Form 28 to be sworn and notarized.

52.228-15, Performance and Payment Bonds--Construction (DEVIATION 2020-O0016), which removes the requirements for seals on Standard Forms.

52.228-16, Performance and Payment Bonds--Other than Construction (DEVIATION 2020-O0016), which removes requirements for seals on Standard Forms.

For any Questions please contact:

Contracting Officer - Jeff Voss at Jeffrey.R.Voss@usace.army.mil

Contract Specialist - Kate Behrens at Katherine.D.Behrens@usace.army.mil

Item Supplies/Service Quantity Unit Unit Price Amount

Illinois River Basin - Peoria and LaGrange Dams - Peoria and Brown County, Illinois - Wicket Bulkhead - First and Last Wickets

Equipment Type: Bulkhead Product Service Code: 9999 Pricing Arrangement: Firm Fixed Price

1 Job

Section C - Description/Specifications/Statement of Work

Requirements The work includes, but is not limited to, the fabrication, assembly, painting, and delivery of a steel bulkhead

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.246-2 Inspection of Supplies-Fixed-Price. Aug 1996 52.246-16 Responsibility for Supplies. Apr 1984

Section F - Deliveries or Performance

Delivery Period From 29 Aug 2025 to 25 Feb 2027

Line Item Delivery Schedule Quantity Address and POC Special Handling/Notes

Delivery Period From 29 Aug 2025 to 25 Feb 2027

1 Job Place of Performance DoDAAC: 965149 CountryCode: USA

ARMY CORPS OF ENGINEERS

CIVIL WORKS

LAGRANGE LOCK, RURAL ROUTE

NO 1

VERSAILLES, IL 62378

UNITED STATES

FoB Details

Party to Pay Transportation Cost:

Contractor

Point Type: Destination

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.211-18 Variation in Estimated Quantity. Apr 1984 52.242-15 Stop-Work Order. Aug 1989 52.242-17 Government Delay of Work. Apr 1984 52.247-34 F.o.b. Destination. Nov 1991

Additional Regulation or Supplemental Clauses Incorporated by Full Text

5152.211-9001 VARIATIONS IN ESTIMATED QUANTITIES — SUB LINE ITEMS (Dec 2019)

This variation in estimated quantities clause is applicable only to item Nos. 0002.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent subline item or elimination of all work under such a second or subsequent subline item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for item Nos. 0002 is less than 85% of the quantity of the first subline item listed under such item, the contractor will be paid at the contract unit price for that subline item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause at Federal Acquisition Regulation (FAR) 52.211-18, Variation in Estimated Quantities.

(c) If the actual quantity of work performed under item Nos. 0002 exceeds 115% or is less than 85% of the total estimated quantity of the subline item under that item and/or if the quantity of the work performed under the second subline item or any subsequent subline item under item Nos. 0002 exceeds 115% or is less than 85% of the estimated quantity of any such subline item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18,Variation in Estimated Quantities.

(End of clause)

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative. Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.202-1 Definitions. Jun 2020 52.203-3 Gratuities. Apr 1984 52.203-5 Covenant Against Contingent Fees. May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government. Jun 2020 52.203-7 Anti-Kickback Procedures. Jun 2020

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

May 2014

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. Jun 2020 52.203-13 Contractor Code of Business Ethics and Conduct. Nov 2021 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. Jun 2020 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities.

Dec 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

Jan 2025

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. Oct 2018 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.210-1 Market Research. Nov 2021 52.211-5 Material Requirements. Aug 2000 52.214-29 Order of Precedence-Sealed Bidding. Jan 1986 52.215-2 Audit and Records-Negotiation. Jun 2020 52.215-8 Order of Precedence-Uniform Contract Format. Oct 1997 52.215-14 Integrity of Unit Prices. Nov 2021 52.219-6 Notice of Total Small Business Set-Aside. Nov 2020 52.219-33 Nonmanufacturer Rule. Sep 2021 52.222-1 Notice to the Government of Labor Disputes. Feb 1997 52.222-19 Child Labor-Cooperation with Authorities and Remedies. Jan 2025 52.222-20 Contracts for Materials, Supplies, Articles, and Equipment. Jun 2020 52.222-21 Prohibition of Segregated Facilities. Apr 2015 52.222-35 Equal Opportunity for Veterans. Jun 2020 52.222-36 Equal Opportunity for Workers with Disabilities. Jun 2020 52.222-37 Employment Reports on Veterans. Jun 2020 52.222-50 Combating Trafficking in Persons. Nov 2021 52.222-54 Employment Eligibility Verification. Jan 2025 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving. May 2024 52.227-1 Authorization and Consent. Jun 2020 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement. Jun 2020 52.228-2 Additional Bond Security. Oct 1997 52.228-11 Pledges of Assets (DEVIATION 2020-O0016) Feb 2021 Deviation 2020-O0016 Apr 2020 52.229-3 Federal, State, and Local Taxes. Feb 2013 52.229-12 Tax on Certain Foreign Procurements. Feb 2021 52.232-17 Interest. May 2014 52.232-23 Assignment of Claims. May 2014 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Mar 2023 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.242-13 Bankruptcy. Jul 1995 52.243-1 Changes-Fixed-Price. Aug 1987 52.244-6 Subcontracts for Commercial Products and Commercial Services. Jan 2025 52.246-24 Limitation of Liability-High-Value Items. Feb 1997 52.249-2 Termination for Convenience of the Government (Fixed-Price). Apr 2012 52.249-8 Default (Fixed-Price Supply and Service). Apr 1984 52.253-1 Computer Generated Forms. Jan 1991

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

Jan 2023

252.203-7003 Agency Office of the Inspector General. Aug 2019 252.203-7004 Display of Hotline Posters. Jan 2023 252.204-7003 Control of Government Personnel Work Product. Apr 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. Jan 2023 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. May 2024 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. Jan 2023

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

Jan 2023

252.204-7020 NIST SP 800-171 DoD Assessment Requirements. Nov 2023 252.205-7000 Provision of Information to Cooperative Agreement Holders. Oct 2024

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

May 2019

252.211-7008 Use of Government-Assigned Serial Numbers. Sep 2010 252.225-7001 Buy American and Balance of Payments Program. Feb 2024 252.225-7021 Trade Agreements. Feb 2024 252.225-7048 Export-Controlled Items. Jun 2013 252.232-7004 DoD Progress Payment Rates (DEVIATION 2020-O0010) Oct 2014 Deviation 2020-O0010 Mar 2020 252.232-7010 Levies on Contract Payments. Dec 2006 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.243-7002 Requests for Equitable Adjustment. Dec 2022 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Nov 2023

FAR Clauses Incorporated by Full Text

52.204-27 Prohibition on a ByteDance Covered Application. (Jun 2023)

Prohibition on a ByteDance Covered Application (Jun 2023)

(a) Definitions. As used in this clause-

Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)-

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use-

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L. 117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, "No TikTok on Government Devices" Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor's employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23- 13.

(c) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for the acquisition of commercial products or commercial services.

(End of clause)

52.211-8 Time of Delivery. (Jun 1997)

Time of Delivery (June 1997)

(a) The Government requires delivery to be made according to the following schedule:

Within 545 consecutive calendar days after receipt of order

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

Offeror's Proposed Delivery Schedule

Item No. Quantity Within Days After Date of Contract

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. (Sep 2000)

Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000)

If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of (a) actual damages, pay to the Government liquidated damages of $ per calendar day of delay.1000

If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for (b) liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault (c) or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

52.219-14 Limitations on Subcontracting (DEVIATION 2021-O0008) (Oct 2022) Deviation 2021-O0008 (Feb 2023)

LIMITATIONS ON SUBCONTRACTING (FEB 2023) (DEVIATION 2021-O0008)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Definition. Similarly situated entity, as used in this clause, means a first-tier subcontractor, including an independent contractor, that--

(1) Has the same small business program status as that which qualified the prime contractor for the award (e.g., for a small business set-aside contract, any small business concern, without regard to its socioeconomic status); and

(2) Is considered small for the size standard under the North American Industry Classification System (NAICS) code the prime contractor assigned to the subcontract.

(c) Applicability. This clause applies only to--

(1) Contracts that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(2) Part or parts of a multiple-award contract that have been set aside for any of the small business concerns identified in 19.000(a)(3);

(3) Contracts that have been awarded on a sole-source basis in accordance with subparts 19.8, 19.13, 19.14, and 19.15;

(4) Orders expected to exceed the simplified acquisition threshold and that are--

(i) Set aside for small business concerns under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F); or

(ii) Issued directly to small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii);

(5) Orders, regardless of dollar value, that are--

(i) Set aside in accordance with subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 8.405-5 and 16.505(b)(2)(i)(F);

or

(ii) Issued directly to concerns that qualify for the programs described in subparts 19.8, 19.13, 19.14, or 19.15 under multiple-award contracts, as described in 19.504(c)(1)(ii); and

(6) Contracts using the HUBZone price evaluation preference to award to a HUBZone small business concern unless the concern waived the evaluation preference.

(d) Independent contractors. An independent contractor shall be considered a subcontractor.

(e) Limitations on subcontracting. By submission of an offer and execution of a contract, the Contractor agrees that in performance of a contract assigned a North American Industry Classification System (NAICS) code for--

(1) Services (except construction), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding certain other direct costs and certain work performed outside the United States (see paragraph (e)(1)(i)), to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both services and supplies, the 50 percent limitation shall apply only to the service portion of the contract. The following services may be excluded from the 50 percent limitation:

(i) Other direct costs, to the extent they are not the principal purpose of the acquisition and small business concerns do not provide the service.

Examples include airline travel, work performed by a transportation or disposal entity under a contract assigned the environmental remediation NAICS code 562910), cloud computing services, or mass media purchases.

(ii) Work performed outside the United States on awards made pursuant to the Foreign Assistance Act of 1961, or work performed outside the United States required to be performed by a local contractor.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), it will not pay more than 50 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 50 percent subcontract amount that cannot be exceeded. When a contract includes both supplies and services, the 50 percent limitation shall apply only to the supply portion of the contract;

(3) General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 85 percent subcontract amount that cannot be exceeded; or

(4) Construction by special trade contractors, it will not pay more than 75 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractor’s 75 percent subcontract amount that cannot be exceeded.

(f) The Contractor shall comply with the limitations on subcontracting as follows:

(1) For contracts, in accordance with paragraphs (c)(1), (2), (3) and (6) of this clause--

[Contracting Officer check as appropriate.]

[ ] By the end of the base term of the contract and then by the end of each subsequent option period; or

[ ] By the end of the performance period for each order issued under the contract.

(2) For orders, in accordance with paragraphs (c)(4) and (5) of this clause, by the end of the performance period for the order.

(g) A joint venture agrees that, in the performance of the contract, the applicable percentage specified in paragraph (e) of this clause will be performed by the aggregate of the joint venture participants.

(1) In a joint venture comprised of a small business protégé and its mentor approved by the Small Business Administration, the small business protégé shall perform at least 40 percent of the work performed by the joint venture. Work performed by the small business protégé in the joint venture must be more than administrative functions.

(2) In an 8(a) joint venture, the 8(a) participant(s) shall perform at least 40 percent of the work performed by the joint venture. Work performed by the 8(a) participants in the joint venture must be more than administrative functions.

(End of clause)

52.219-28 Postaward Small Business Program Rerepresentation. (Jan 2025)

Postaward Small Business Program Rerepresentation (Jan 2025)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern-

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (d) of this clause.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13 CFR 121.103.

(b) If the Contractor represented that it was any of the small business concerns identified in 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, upon occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) If the Contractor represented its status as any of the small business concerns identified at 19.000(a)(3) prior to award of this contract, the Contractor shall rerepresent its size and socioeconomic status according to paragraph (f) of this clause or, if applicable, paragraph (h) of this clause, for the NAICS code assigned to an order (except that paragraphs (c)(1) through (3) of this clause do not apply to an order issued under a Federal Supply Schedule contract at subpart 8.4)-

(1) Set aside exclusively for a small business concern identified at 19.000(a)(3) that is issued under an unrestricted multiple-award contract, unless the order is issued under the reserved portion of an unrestricted multiple-award contract ( e.g., an order set aside for a woman-owned small business under a multiple-award contract that is not set-aside, unless the order is issued under the reserved portion of the multiple-award contract);

(2) Issued under a multiple-award contract set aside for small businesses that is further set aside for a specific socioeconomic category that differs from the underlying multiple-award contract ( e.g., an order set aside for a HUBZone small business concern under a multiple-award contract that is set aside for small businesses);

(3) Issued under the part of the multiple-award contract that is set aside for small businesses that is further set aside for a specific socioeconomic category that differs from the underlying set-aside part of the multiple-award contract ( e.g., an order set aside for a WOSB concern under the part of the multiple-award contract that is partially set aside for small businesses); and

(4) When the Contracting Officer explicitly requires it for an order issued under a multiple-award contract, including for an order issued under a Federal Supply Schedule contract (see 8.405-5(b) and 19.301-2(b)(2)).

(d) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code(s) assigned to this contract. The small business size standard corresponding to this NAICS code(s) can be found at https://www.sba.gov/document/support--table-size-standards.

(e) The small business size standard for a Contractor providing an end item that it does not manufacture, process, or produce itself, for a contract other than a construction or service contract, is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition-

(1) Was set aside for small business and has a value above the simplified acquisition threshold;

(2) Used the HUBZone price evaluation preference regardless of dollar value, unless the Contractor waived the price evaluation preference; or

(3) Was an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(f) Except as provided in paragraph (h) of this clause, the Contractor shall make the representation(s) required by paragraphs (b) and (c) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting officer in writing within the timeframes specified in paragraph (b) of this clause, or with its offer for an order (see paragraph (c) of this clause), that the data have been validated or updated, and provide the date of the validation or update.

(g) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (f) or (h) of this clause.

(h) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

(1) The Contractor represents that it [ ] is, [ ] is not a small business concern under 332312NAICS Code assigned to ____contract number.

(2) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1001.

(3) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause.] The Contractor represents that it [ ] is, [ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(5) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The Contractor represents that it [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __ .]

(6) [Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that it [ ] is, [ ] is not a veteran-owned small business concern.

(7) [Complete only if the Contractor represented itself as a veteran-owned small business concern in paragraph (h)(6) of this clause.] The Contractor represents that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern.

(8) Service-disabled veteran-owned small business (SDVOSB) joint venture eligible under the SDVOSB Program. The Contractor represents that it [ ] is, [ ] is not an SDVOSB joint venture eligible under the SDVOSB Program that complies with the requirements of 13 CFR 128.402. [____The Contractor shall enter the name and unique entity identifier of each party to the joint venture: __.]

(9) [ Complete only if the Contractor represented itself as a small business concern in paragraph (h)(1) of this clause. ] The Contractor represents that-

(i) It [ ] is, [ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ] is, [ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (h)(8)(i) of this clause is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [____The Contractor shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

[____Contractor to sign and date and insert authorized signer's name and title.]

(End of clause)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (Dec 2010)

Notification of Employee Rights Under the National Labor Relations Act (Dec 2010)

(a) During the term of this contract, the Contractor shall post an employee notice, of such size and in such form, and containing such content as prescribed by the Secretary of Labor, in conspicuous places in and about its plants and offices where employees covered by the National Labor Relations Act engage in activities relating to the performance of the contract, including all places where notices to employees are customarily posted both physically and electronically, in the languages employees speak, in accordance with 29 CFR471.2 (d) and (f).

(1) Physical posting of the employee notice shall be in conspicuous places in and about the Contractor's plants and offices so that the notice is prominent and readily seen by employees who are covered by the National Labor Relations Act and engage in activities related to the performance of the contract.

(2) If the Contractor customarily posts notices to employees electronically, then the Contractor shall also post the required notice electronically by displaying prominently, on any website that is maintained by the Contractor and is customarily used for notices to employees about terms and conditions of employment, a link to the Department of Labor's website that contains the full text of the poster. The link to the Department's website, as referenced in (b)(3) of this section, must read, "Important Notice about Employee Rights to Organize and Bargain Collectively with Their Employers."

(b) This required employee notice, printed by the Department of Labor, may be-

(1) Obtained from the Division of Interpretations and Standards, Office of Labor-Management Standards, U.S. Department of Labor, 200 Constitution Avenue, NW., Room N-5609, Washington, DC 20210, (202) 693-0123, or from any field office of the Office of Labor-Management Standards or Office of Federal Contract Compliance Programs;

(2) Provided by the Federal contracting agency if requested;

(3) Downloaded from the Office of Labor-Management Standards Web site at http://www.dol.gov/olms/regs/compliance/EO13496.htm; or

(4) Reproduced and used as exact duplicate copies of the Department of Labor's official poster.

(c) The required text of the employee notice referred to in this clause is located at Appendix A, Subpart A, 29 CFR Part 471.

(d) The Contractor shall comply with all provisions of the employee notice and related rules, regulations, and orders of the Secretary of Labor.

(e) In the event that the Contractor does not comply with the requirements set forth in paragraphs (a) through (d) of this clause, this contract may be terminated or suspended in whole or in part, and the Contractor may be suspended or debarred in accordance with 29 CFR 471.14 and subpart 9.4.

Such other sanctions or remedies may be imposed as are provided by 29 CFR part 471, which implements Executive Order 13496 or as otherwise provided by law.

(f) Subcontracts.

(1) The Contractor shall include the substance of this clause, including this paragraph (f), in every subcontract that exceeds $10,000 and will be performed wholly or partially in the United States, unless exempted by the rules, regulations, or orders of the Secretary of Labor issued pursuant to section 3 of Executive Order 13496 of January 30, 2009, so that such provisions will be binding upon each subcontractor.

(2) The Contractor shall not procure supplies or services in a way designed to avoid the applicability of Executive Order 13496 or this clause.

(3) The Contractor shall take such action with respect to any such subcontract as may be directed by the Secretary of Labor as a means of enforcing such provisions, including the imposition of sanctions for noncompliance.

(4) However, if the Contractor becomes involved in litigation with a subcontractor, or is threatened with such involvement, as a result of such direction, the Contractor may request the United States, through the Secretary of Labor, to enter into such litigation to protect the interests of the United States.

(End of clause)

52.228-14 Irrevocable Letter of Credit. (Nov 2014)

Irrevocable Letter of Credit (Nov 2014)

(a) "Irrevocable letter of credit" (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit.

(b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used.

(c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and-

(1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period;

(2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be:

(i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of-

(A) Oneyear following the expected date of final payment;

(B) For performance bonds only, until completion of any warranty period; or

(C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment.

(ii) For contracts not subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of-

(A) 90 days following final payment; or

(B) For performance bonds only, until completion of any warranty period.

(d)

(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC.

(2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year.

(3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC.

(4) The current rating for a financial institution is available through any of the following rating services registered with the U.S.