A06 Specifications.pdf

U.S. Department of the Interior Bureau of Land Management

Fire Station Remodel Fillmore & Little Sahara, Utah

April 2020

TABLE OF CONTENTS

SPECIFICATIONS ............................................................................................................... # OF PAGES

DIVISION 01 - GENERAL REQUIREMENTS

01009 GENERAL REQUIREMENTS

012973 SCHEDULE OF VALUES

013200 CONSTRUCTION PROGRESS DOCUMENTATION

013300 SUBMITTAL PROCEDURES

DIVISION 02

024119 SELECTIVE DEMOLITION

DIVISION 02-05 (NOT USED)

DIVISION 06 – WOOD, PLASTICS, AND COMPONENTS

061000 ROUGH CARPENTRY

DIVISION 07 – (NOT USED)

DIVISION 08 - OPENINGS

081416 FLUSH WOOD DOORS

087100 DOOR HARDWARE

DIVISION 09 – FINISHES

092900 GYPSUM BOARD

096519 RESILIENT TILE FLOORING

099123 INTERIOR PAINTING

DIVISION 10 – SPECIALTIES

10801 TOILET AND BATH ACCESSORIES

DIVISION 11 (NOT USED)

DIVISION 12 – FURNISHINGS

06601 SOLID SURFACE COUNTERTOPS

12356 CASEWORK

122113 HORIZONTAL LOUVER BLINDS

DIVISION 13-21 (NOT USED)

DIVISION 22 – PLUMBING

15400 PLUMBING SYSTEMS

224100 RESIDENTAL PLUMBING FIXTURES

223400 FUEL FIRED DOMESTIC-WATER HEATERS

DIVISION 23 – HEATING VENTILATING AND AIR CONDITIONING

15010 BASIC MECHANICAL REQUIREMENTS

230923.12 CONTROL DAMPERS

233813 COMMERCIAL KITCHEN HOODS

235416.13 GAS_FIRED FURNACES

238146.13 WATER-TO-AIR HEAT PUMPS

DIVISION 24 - 25 (NOT USED)

DIVISION 26 – ELECTRICAL

16010 BASIC ELECTRICAL

265119 LED INTERIOR LIGHTING

DIVISION 27 – 33 (NOT USED)

END OF TABLE OF CONTENTS

JANUARY 2020 GENERAL REQUIREMENTS

FILLMORE AND LITTLE SAHARA FIRE REMODEL 01009-1

SECTION 01009

GENERAL INFORMATION AND REQUIREMENTS

PART 1: GENERAL

1.1 SUMMARY

A. Description of Work: Furnishing labor, equipment, supplies, and materials, to remodel the Fillmore Fire Station, Little Sahara Fire Station and the Little Sahara Recreation Bunkhouse. All work shall meet current codes and comply with the local requirements.

B. Location: Work under this Contract is in Millard & Juab Counties, Utah. The work site is at the Fillmore Interagency Center, Fillmore, Utah, Little Sahara Interagency Center, Little Sahara, Utah and the Little Sahara Recreation Bunkhouse.

1.2 REFERENCES

A. Referenced Specifications/Standards with Abbreviations and/or Acronyms: Wherever the following acronyms are used in these specifications or on the drawings, they are to be construed the same as the respective expressions represented.

B. Referenced Codes with Abbreviations and Acronyms: Wherever the following acronyms are used in these specifications or on the drawings, they are to be construed the same as the respective expressions represented.

1.3 DEFINITIONS

A. Approvals: Approval of the submittals is an indication that the Contractor's submittals have been reviewed and that there are no objections, except as noted. Approval of deviations shall apply only to those deviations or omissions from the requirements of the drawings and specifications brought to the Contracting Officer's attention in writing. After approval of an item, submit a substitute for approval when the approved item cannot be purchased or delivered in time to avoid delay in completion of the project.

1.4 SUBMITTALS

A. Scope: Submittals include design computations, shop drawings, manufacturers' literature, as-built drawings, samples, and maintenance manuals.

B. Requirements: Refer to specifications for submittals required. Allow at least 5 working days for review. Submittals shall be delivered to the Contracting Officer.

C. Identification of Submittals: Completely identify each submittal by showing at least the following information:

1. Name and address of submitter, plus name and telephone number of the individual to contact for further information.

2. Name of project as it appears in these specifications.

FILLMORE AND LITTLE SAHARA FIRE REMODEL 01009-2

3. Contract number, drawing number, and specification section number to which the submittal applies.

4. Whether this is an original submittal or resubmittal.

5. Each item shall clearly note the manufacturer's name and address, trade name, product, lot, style, color, catalog designation or model number, and locations of use.

1.6 QUALITY ASSURANCE

A. Codes and Standards: The work shall comply with codes and standards applicable to each type of work and as listed in the individual sections of these specifications. This Contract incorporates materials, applications, and tests by reference, with the same force and effect as when they were given in full text.

B. Conflict: Where a conflict occurs between reference documents and project specifications, the project specifications shall govern.

C. Measurements: Where approved manufacturer's diagrams and shop drawings give specific measurements or rough-in dimensions for equipment, these dimensions shall take precedence over dimensions indicated on the drawings.

D. Equipment: Prior to ordering equipment, verify dimensions and functions of equipment proposed for use including the electrical service requirements. Be certain the equipment is compatible with the structural and architectural features of the work, avoids conflicts with equipment of other crafts, and that it will fit in the space provided.

1.7 DELIVERY, STORAGE, AND HANDLING

A. Delivery: Protect products incorporated into the work from damage while in transit to the site.

Products must be delivered in original unopened containers with manufacturer's name, brand designation, and contents legibly indicated.

B. Storage: Provide temporary storage facilities for products. Storage shall comply with the manufacturer's instructions. The storage area shall permit access for inspection and handling.

C. Handling: Load and unload products protecting them from damage.

1.8 PROJECT/SITE CONDITIONS

A. Access to the site is via state highways.

1.9 SEQUENCING AND SCHEDULING

A. Work Schedule: The schedule shall be submitted at the pre-work conference. When requested, submit an updated schedule within 3 calendar days. As a minimum, the estimated start and completion dates shall be shown in the estimate.

B. Work in the public visitor areas will only be allowed on Tuesdays and Wednesdays when the Visitor Center is closed to the public. Work in the electrical room, mechanical rooms, exterior is allowed Monday through Friday.

FILLMORE AND LITTLE SAHARA FIRE REMODEL 01009-3

PART 2: PRODUCTS

(There are no applicable requirements.)

PART 3: EXECUTION

3.1 PROJECT MEETINGS

A. Pre-Work Conference:

1. Will be held prior to the start of work. The Contractor will be notified in advance of meeting time, date and place. The purpose will be to review required work, project drawings and specifications, construction schedules, payroll and payments, and administrative provisions of the Contract.

2. The Contractor, subcontractors and the persons responsible for coordination of the work shall be present at the meeting.

3. Be prepared to summarize and explain procedures planned for the project.

B. Progress Meetings:

1. To be held at the project site, or as determined by the Contracting Officer.

2. May be called by either the Contracting Officer or the Contractor. Request shall state who should attend and include an agenda.

C. Final Inspection:

1. To be held at the project site, or as determined by the Contracting Officer.

2. Notify the Contracting Officer in writing at least 3 working days before the completion date so the Government can schedule final inspection.

3. The superintendent shall be present during this inspection.

3.2 PREPARATION

A. Work Layout: As shown on the drawings.

3.3 PROJECT MONUMENT

A. Requirements: None.

3.4 SALVAGEABLE ITEMS

A. Requirements: None

3.5 DISPOSAL OF DEBRIS

A. Requirements: Demolition material shall become the property of the Contractor. Disposal of materials in a legal manner and payment of fees required is the Contractor's responsibility.

3.6 PROJECT IDENTIFICATION

A. Requirements: None.

FILLMORE AND LITTLE SAHARA FIRE REMODEL 01009-4

3.7 AS-BUILT DRAWINGS

A. General Requirements: A complete set of full-sized prints, furnished by the Contracting Officer for this purpose only, shall be kept at the site. As the job progresses, continuously maintain as-built drawings of the work. The changes shall be noted legibly in red pencil or red ink. These drawings shall be submitted to the Contracting Officer prior to final inspection.

B. Installation Changes: Records shall be maintained of actual installations where at variance with the work shown, where changed, or where not otherwise located by dimension, elevation or other reference on the Contract drawings. Actual locations and elevations of equipment and components (such as pipe, conduits and ducts) occurring within concealed areas shall be recorded by actual dimensions referenced from readily accessible and permanent structures or monuments.

3.8 WARRANTY

A. Requirements: Materials and equipment furnished under this Contract shall be covered by the most favorable commercial warranties given to customers for such materials or equipment. The rights or remedies provided herein are in addition to and do not limit rights afforded to the Government by other clauses of this Contract. With respect to warranties, expressed or implied, from manufacturers or suppliers for materials or equipment furnished under the Contract the Contractor shall:

1. Obtain warranties that would be given in normal commercial practices.

2. Require warranties to be executed, in writing, for the benefit of the Government.

3. Submit warranties to the Contracting Officer prior to the final inspection.

END OF SECTION

JAMUARY 2020 SCHEDULE OF VALUES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 012973-1

SECTION 012973 – SCHEDULE OF VALUES

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements to prepare schedule of values.

1.2 SCHEDULE OF VALUES

A. Coordination: Coordinate preparation of the Schedule of Values with preparation of Contractor's Construction Schedule. Cost-loaded CPM Schedule may serve to satisfy requirements for the Schedule of Values.

1. Correlate line items in the Schedule of Values with other required administrative forms and schedules, including Application for Payment forms with Continuation Sheets Submittals Schedule and Contractor's Construction Schedule.

2. Submit the Schedule of Values to Contracting Officer at earliest possible date but no later than ten (10) calendar days after the Notice to Proceed.

B. Format and Content: Use the Project Manual table of contents as a guide to establish line items for the Schedule of Values. Provide at least one-line item for each Specification Section.

1. Identification: Include the following Project identification on the Schedule of Values:

a. Project name and location.

b. Name of Contracting Officer.

c. Contractor's name and address.

d. Date of submittal.

2. Provide a breakdown of the Contract Sum in enough detail to facilitate continued evaluation of Applications for Payment and progress reports. Coordinate with the Project Manual table of contents. Provide several line items for principal subcontract amounts, where appropriate. Include separate line items under required principal subcontracts for operation and maintenance manuals, punch list activities, Project Record Documents, and demonstration and training in the amount of 5 percent of the Contract Sum.

3. Round amounts to nearest whole dollar; total shall equal the Contract Sum.

4. Provide a separate line item in the Schedule of Values for each part of the Work where

Applications for Payment may include materials or equipment purchased or fabricated and stored, but not yet installed.

5. Provide separate line items in the Schedule of Values for initial cost of materials, for each subsequent stage of completion, and for total installed value of that part of the Work.

6. Each item in the Schedule of Values and Applications for Payment shall be complete.

Include total cost and proportionate share of general overhead and profit for each item.

FILLMORE AND LITTLE SAHARA FIRE REMODEL 012973-2

a. Temporary facilities and other major cost items that are not direct cost of actual work-in-place may be shown either as separate line items in the Schedule of Values or distributed as general overhead expense, at Contractor's option.

7. Schedule Updating: Update and resubmit the Schedule of Values before the next Applications for Payment when Modifications or Construction Change Directives result in a change in the Contract Sum.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

BID SCHEDULE

FILLMORE AND LITTLE SAHARA FIRE REMODEL

BASIS FOR AWARD:

Bids will be received on the Schedule below. No bid will be considered for only a part of the schedule. Award will be made based on the unit price quoted.

Division Description Quantity Unit Total

Division 00 Mobilization 1 Ea

Division 01 GENERAL REQUIREMENTS 1 Ea

Division 06 Wood & Plastics 1 Ea

Division 08 Doors & Windows 1 Ea

Division 09 Finishes 1 Ea

Division 10 Specialties & Plumbing 1 Ea

Division 12 Furnishings 1 Ea

Division 15 Mechanical 1 Ea

Division 16 Electrical 1 Ea

Division 22 Plumbing 1 Ea

1 Ea

1 Ea

FILLMORE AND LITTLE SAHARA FIRE REMODEL 012973-3

Total Bid Schedule:

END OF SECTION 012973

APRIL 2020 CONSTRUCTION PROGRESS DOCUMENTATION

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-1

SECTION 013200 – CONSTRUCTION PROGRESS DOCUMENTATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for documenting the progress of construction during performance of the Work, including the following:

1. Contractor's Construction Schedule.

2. Submittals Schedule.

3. Daily construction reports.

4. Field condition reports.

B. See Division 01 Section "Schedule of Values" for submitting the Schedule of Values.

C. See Division 01 Section "Photographic Documentation" for submitting construction photographs.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

C. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

D. Float: The measure of leeway in starting and completing an activity.

E. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

F. Major Area: A story of construction, a separate building, or a similar significant construction element.

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-2

1.3 SUBMITTALS

A. Submittals Schedule: Submit electronic (pdf) copy of schedule. Arrange the following information in a tabular format:

1. Scheduled date for first submittal.

2. Specification Section number and title.

3. Submittal category (action or informational).

4. Name of subcontractor.

5. Description of the Work covered.

6. Scheduled date for Contracting Officer's final release or approval.

B. Preliminary Network Diagram: Submit electronic (pdf) copy, large enough to show entire network for entire construction period. Show logic ties for activities.

C. Contractor's Construction Schedule: Submit electronic (pdf) copy of initial schedule, large enough to show entire schedule for entire construction period.

1. Submit an electronic copy of schedule, using software indicated, labeled to comply with requirements for submittals. Include type of schedule (Initial or Updated) and date on label.

D. CPM Reports: Concurrent with CPM schedule, submit electronic (pdf) copy of each of the following computer-generated reports. Format for each activity in reports shall contain activity number, activity description, cost and resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity Report: List of all activities sorted by activity number and then early start date, or actual start date if known.

2. Logic Report: List of preceding and succeeding activities for all activities, sorted in ascending order by activity number and then early start date, or actual start date if known.

3. Total Float Report: List of all activities sorted in ascending order of total float.

E. Daily Construction Reports: Submit electronic (pdf) copy at [weekly] [monthly] intervals.

F. Field Condition Reports: Submit electronic (pdf) copy at time of discovery of differing conditions.

1.4 COORDINATION

A. Coordinate preparation and processing of schedules and reports with performance of construction activities and with scheduling and reporting of separate contractors.

B. Coordinate Contractor's Construction Schedule with the Schedule of Values, list of subcontracts, Submittals Schedule, progress reports, payment requests, and other required schedules and reports.

1. Secure time commitments for performing critical elements of the Work from parties involved.

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-3

2. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

1.5 SUBMITTALS SCHEDULE

A. Preparation: Submit a schedule of submittals, arranged in chronological order by dates required by construction schedule. Include time required for review, resubmittal, ordering, manufacturing, fabrication, and delivery when establishing dates.

1. Coordinate Submittals Schedule with list of subcontracts, the Schedule of Values, and Contractor's Construction Schedule.

2. Submit concurrently with the first complete submittal of Contractor's Construction Schedule.

1.6 CONTRACTOR'S CONSTRUCTION SCHEDULE, GENERAL

A. Time Frame: Extend schedule from date established for the Notice to Proceed to date of Final Completion.

1. Contract completion date shall not be changed by submission of a schedule that shows an early completion date, unless specifically authorized by Modification.

B. Activities: Treat each story or separate area as a separate numbered activity for each principal element of the Work. Comply with the following:

1. Activity Duration: Define activities so no activity is longer than 20 days, unless specifically allowed by Contracting Officer.

2. Procurement Activities: Include procurement process activities for the following long lead items and major items, requiring a cycle of more than 60 days, as separate activities in schedule. Procurement cycle activities include, but are not limited to, submittals, approvals, purchasing, fabrication, and delivery.

3. Submittal Review Time: Include review and resubmittal times indicated in Division 01 Section "Submittal Procedures" in schedule. Coordinate submittal review times in Contractor's Construction Schedule with Submittals Schedule.

4. Startup and Testing Time: Include not less than 7 days for startup and testing.

5. Substantial Completion: Indicate completion in advance of date established for Substantial

Completion, and allow time for Contracting Officer's administrative procedures necessary for certification of Substantial Completion.

C. Constraints: Include constraints and work restrictions indicated in the Contract Documents and as follows in schedule, and show how the sequence of the Work is affected.

1. Work by Government: Include a separate activity for each portion of the Work performed by Government.

2. Work Restrictions: Show the effect of the following items on the schedule:

a. Coordination with existing construction.

b. Limitations of continued occupancies.

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-4

c. Uninterruptible services.

d. Partial occupancy before Substantial Completion.

e. Use of premises restrictions.

f. Provisions for future construction.

g. Seasonal variations.

h. Environmental control.

3. Work Stages: Indicate important stages of construction for each major portion of the Work.

4. Other Constraints: Possibility of tenants living in the quarters.

D. Milestones: Include milestones indicated in the Contract Documents in schedule, including, but not limited to, the Notice to Proceed, Substantial Completion, and Final Completion.

E. Contract Modifications: For each proposed contract modification and concurrent with its submission, prepare a time-impact analysis using fragnets to demonstrate the effect of the proposed change on the overall project schedule.

F. Contractor's Construction Schedule Updating: At monthly intervals, update schedule to reflect actual construction progress and activities. Issue schedule one week before each regularly scheduled progress meeting.

1. Revise schedule immediately after each meeting or other activity where revisions have been recognized or made. Issue updated schedule concurrently with the report of each such meeting.

2. Include a report with updated schedule that indicates every change, including, but not limited to, changes in logic, durations, actual starts and finishes, and activity durations.

3. As the Work progresses, indicate Actual Completion percentage for each activity.

G. Distribution: Distribute copies of approved schedule to Contracting Officer, separate contractors, testing and inspecting agencies, and other parties identified by Contractor with a need-to-know schedule responsibility.

1. Post copies in Project meeting rooms and temporary field offices.

2. When revisions are made, distribute updated schedules to the same parties and post in the same locations. Delete parties from distribution when they have completed their assigned portion of the Work and are no longer involved in performance of construction activities.

1.7 CONTRACTOR'S CONSTRUCTION SCHEDULE (GANTT CHART)

A. Gantt-Chart Schedule: Submit a comprehensive, fully developed, horizontal Gantt-chart-type, Contractor's Construction Schedule within 30 days of date established for the Notice to Proceed.

Base schedule on the Preliminary Construction Schedule and whatever updating and feedback was received since the start of Project.

B. Preparation: Indicate each significant construction activity separately. Identify first workday of each week with a continuous vertical line.

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-5

1. For construction activities that require 3 months or longer to complete, indicate an estimated completion percentage in [10] <Insert number> percent increments within time bar.

1.8 CONTRACTOR'S CONSTRUCTION SCHEDULE (CPM SCHEDULE)

A. General: Prepare network diagrams using AON (activity-on-node) format.

B. Preliminary Network Diagram: Submit diagram within 14 days of date established for [commencement of the Work] [the Notice to Proceed] [the Notice of Award]. Outline significant construction activities for the first 60 days of construction. Include skeleton diagram for the remainder of the Work and a cash requirement prediction based on indicated activities.

C. CPM Schedule: Prepare Contractor's Construction Schedule using a computerized, cost- and resource-loaded, time-scaled CPM network analysis diagram for the Work.

1. Develop network diagram in sufficient time to submit CPM schedule so it can be accepted for use no later than 30 days after date established for the Notice to Proceed.

a. Failure to include any work item required for performance of this Contract shall not excuse Contractor from completing all work within applicable completion dates, regardless of Contracting Officer's approval of the schedule.

2. Establish procedures for monitoring and updating CPM schedule and for reporting progress. Coordinate procedures with progress meeting and payment request dates.

3. Use "one workday" as the unit of time. Include list of nonworking days and holidays incorporated into the schedule.

D. CPM Schedule Preparation: Prepare a list of all activities required to complete the Work. Using the preliminary network diagram, prepare a skeleton network to identify probable critical paths.

1. Activities: Indicate the estimated time duration, sequence requirements, and relationship of each activity in relation to other activities. Include estimated time frames for the following activities:

a. Preparation and processing of submittals.

b. Mobilization and demobilization.

c. Purchase of materials.

d. Delivery.

e. Fabrication.

f. Utility interruptions.

g. Installation.

h. Work by Government that may affect or be affected by Contractor's activities.

i. Testing and commissioning.

2. Critical Path Activities: Identify critical path activities, including those for interim completion dates. Scheduled start and completion dates shall be consistent with Contract milestone dates.

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-6

3. Processing: Process data to produce output data on a computer-drawn, time-scaled network. Revise data, reorganize activity sequences, and reproduce as often as necessary to produce the CPM schedule within the limitations of the Contract Time.

4. Format: Mark the critical path. Locate the critical path near center of network; locate paths with most float near the edges.

a. Subnetworks on separate sheets are permissible for activities clearly off the critical path.

E. Initial Issue of Schedule: Prepare initial network diagram from a list of straight "early start-total float" sort. Identify critical activities. Prepare tabulated reports showing the following:

1. Contractor or subcontractor and the Work or activity.

2. Description of activity.

3. Principal events of activity.

4. Immediate preceding and succeeding activities.

5. Early and late start dates.

6. Early and late finish dates.

7. Activity duration in workdays.

8. Total float or slack time.

9. Average size of workforce.

F. Schedule Updating: Concurrent with making revisions to schedule, prepare tabulated reports showing the following:

1. Identification of activities that have changed.

2. Changes in early and late start dates.

3. Changes in early and late finish dates.

4. Changes in activity durations in workdays.

5. Changes in the critical path.

6. Changes in total float or slack time.

7. Changes in the Contract Time.

1.9 REPORTS

A. Daily Construction Reports: Prepare a daily construction report recording the following information concerning events at Project site:

1. List of subcontractors at Project site.

2. Equipment at Project site.

3. Material deliveries.

4. High and low temperatures and general weather conditions.

5. Accidents.

6. Stoppages, delays, shortages, and losses.

7. Meter readings and similar recordings.

8. Orders and requests of authorities having jurisdiction.

9. Services connected and disconnected.

10. Equipment or system tests and startups.

FILLMORE & LITTLE SAHARA FIRE REMODEL 013200-7

B. Field Condition Reports: Immediately on discovery of a difference between field conditions and the Contract Documents, prepare and submit a detailed report. Submit with a request for interpretation. Include a detailed description of the differing conditions, together with recommendations for changing the Contract Documents.

PART 2 - PRODUCTS (Not used)

PART 3 - EXECUTION (Not used)

END OF SECTION 013200

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-1

SECTION 013300 – SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for submitting Shop Drawings, Product Data, Samples, Design Computations, and other submittals.

B. See Division 01 Section "Construction Progress Documentation" for submitting schedules and reports, including Contractor's Construction Schedule.

C. See Division 01 Section "Photographic Documentation" for submitting construction photographs.

D. See Division 01 Section "Quality Requirements" for submitting test and inspection reports. See Division 01 Section "Closeout Procedures" for submitting warranties.

E. See Division 01 Section "Project Record Documents" for submitting Record Drawings, Record Specifications, and Record Product Data.

F. See Division 01 Section "Operation and Maintenance Data" for submitting operation and maintenance manuals.

G. See Division 01 Section "Demonstration and Training" for submitting video of demonstration of equipment and training of Government personnel.

1.2 DEFINITIONS

A. Action Submittals: Written and graphic information that requires Contracting Officer's responsive action.

B. Informational Submittals: Written information that does not require Contracting Officer's responsive action. Submittals may be rejected for not complying with requirements.

C. File Transfer Protocol (FTP): Communications protocol that enables transfer of files to and from another computer over a network and that serves as the basis for standard Internet protocols. An FTP site is a portion of a network located outside of network firewalls within which internal and external users are able to access files.

D. Portable Document Format (PDF): An open standard file format licensed by Adobe Systems used for representing documents in a device-independent and display resolution-independent fixed-layout document format.

1.3 SUBMITTAL PROCEDURES

A. Coordination: Coordinate preparation and processing of submittals with performance of construction activities.

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-2

1. Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals, and related activities that require sequential activity.

2. Coordinate transmittal of different types of submittals for related parts of the Work so processing will not be delayed because of need to review submittals concurrently for coordination.

a. Contracting Officer reserves the right to withhold action on a submittal requiring coordination with other submittals until related submittals are received.

B. Submittals Schedule: Comply with requirements in Division 01 Section "Construction Progress Documentation" for list of submittals and time requirements for scheduled performance of related construction activities.

C. Processing Time: Allow enough time for submittal review, including time for resubmittals, as follows. Time for review shall commence on Contracting Officer's receipt of submittal. No extension of the Contract Time will be authorized because of failure to transmit submittals enough in advance of the Work to permit processing, including resubmittals.

1. Initial Review: Allow 14 calendar days for initial review of each submittal. Allow additional time if coordination with subsequent submittals is required. Contracting Officer will advise Contractor when a submittal being processed must be delayed for coordination.

2. Intermediate Review: If intermediate submittal is necessary, process it in same manner as initial submittal.

3. Resubmittal Review: Allow 14 calendar days for review of each resubmittal.

D. Paper Submittals:

1. Place a permanent label or title block on each submittal for identification; include name of firm or entity that prepared each submittal on label or title block.

2. Provide a space approximately 6 by 8 inches Insert size on label or beside title block to record Contractor's review and approval markings and action taken by Contracting Officer.

3. Include the following information on label for processing and recording action taken:

a. Project name.

b. Date.

c. Name and address of Architect.

d. Name and address of Contractor.

e. Name and address of subcontractor.

f. Name of firm or entity that prepared submittal.

g. Name and address of supplier.

h. Name of manufacturer.

i. Submittal number or other unique identifier, including revision identifier.

1) Submittal number shall use Specification Section number followed by a decimal point and then a sequential number (e.g., 061000.01). Resubmittals shall include an alphabetic suffix after another decimal point (e.g., 061000.01.A). Work schedule and value schedules shall be numbers

01000.01 and 01000.02.

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-3

j. Number and title of appropriate Specification Section.

k. Drawing number and detail references, as appropriate.

l. Location(s) where product is to be installed, as appropriate.

m. Other necessary identification.

E. Cover Sheet: Use Cover Sheet Submittal-Bureau of Land Management at end of this Section.

1. Ensure that cover sheet includes following information:

a. Submittal Number

b. Contract Number

c. Specification section number and title, paragraph, and complete description of item being submitted. Be specific and clearly identify what is being submitted. When appropriate, reference a specific sheet and detail of the Drawings. Note multiple items individually.

d. Signature and date.

e. Name and telephone number of individual to contact for further information, if other than Contractor.

2. Submitted Information: Link submittal to cover sheet by contract number, project name, and submittal number. Stamp is recommended but may be hand-written on each copy;

ensure submittal stamp includes project name and contract number and blank space in which to write submittal number. Stamp or write this information on all copies.

F. Mechanical and Electrical: Deliver catalogs or pages and tables for mechanical and electrical items in one complete mechanical package and one complete electrical package. Incomplete packages will be retained until all items are received. Shop drawings may be submitted separately.

Submit the following additional data:

1. Rough-in data and dimensions.

2. Motor characteristics and wiring diagrams.

3. Performance curves and rated capacities.

4. Operation characteristics.

G. Deviations: Highlight, encircle, or otherwise specifically identify deviations from the Contract Documents on submittals.

H. Approved Equals:

1. For each item proposed as an “or approved equal,” submit supporting data, including:

a. Drawings and samples as appropriate.

b. Comparison of the characteristics of the proposed item with that specified.

c. Changes required in other elements of the work because of the substitution.

d. Name, address, and telephone number of vendor.

e. Manufacturer’s literature regarding installation, operation, and maintenance, including schematics for electrical and hydraulic systems, lubrication requirements, and parts lists. Describe availability of maintenance service, and state source of replacement materials.

2. A request for approval constitutes a representation that Contractor:

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-4

a. Has investigated the proposed item and determined that it is equal or superior in all respects to that specified.

b. Will provide the same warranties for the proposed item as for the item specified.

c. Has determined that the proposed item is compatible with interfacing items.

d. Will coordinate the installation of an approved item and make all changes required in other elements of the work because of the substitution.

e. Waives all claims for additional expenses that may be incurred as a result of the substitution.

I. Electronic Submittals: Prepare submittals as PDF package, incorporating complete information into each PDF file. Name PDF file with submittal number.

J. Submittals for Web-Based Project Software: Prepare submittals as PDF files, or another format indicated by Project software website.

K. Additional Copies: Unless additional copies are required for final submittal, and unless Contracting Officer observes noncompliance with provisions in the Contract Documents, initial submittal may serve as final submittal.

L. Transmittal: Package each submittal individually and appropriately for transmittal and handling.

Transmit each submittal using a transmittal form. Contracting Officer will return submittals, without review received from sources other than Contractor.

1. Transmittal Form: Use form as directed by Contracting Officer.

M. Resubmittals: Make resubmittals in same form and number of copies as initial submittal.

1. Note date and content of previous submittal.

2. Note date and content of revision in label or title block and clearly indicate extent of revision.

3. Resubmit submittals until they are marked "<Insert approval notation from Contracting

Officer's action stamp>."

N. Distribution: Furnish copies of final submittals to manufacturers, subcontractors, suppliers, fabricators, installers, authorities having jurisdiction, and others as necessary for performance of construction activities. Show distribution on transmittal forms.

O. Use for Construction: Use only final submittals with mark indicating "“Approved” or “Approved with notations”. taken by Contracting Officer.

1.4 ACTION SUBMITTALS

A. Prepare and submit Action Submittals required by individual Specification Sections.

B. Product Data: Collect information into a single submittal for each element of construction and type of product or equipment.

1. If information must be specially prepared for submittal because standard printed data are not suitable for use, submit as Shop Drawings, not as Product Data.

2. Mark each copy of each submittal to show which products and options are applicable.

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-5

3. Include the following information, as applicable:

a. Manufacturer's written recommendations.

b. Manufacturer's product specifications.

c. Manufacturer's installation instructions.

d. Manufacturer's catalog cuts.

e. Wiring diagrams showing factory-installed wiring.

f. Printed performance curves.

g. Operational range diagrams.

h. Compliance with specified referenced standards.

i. Testing by recognized testing agency.

j. Standard color charts

k. Availability and delivery time information

l. Clearances required to other construction, if not indicated on accompanying Shop

Drawings

4. Number of Copies: Submit three copies of Product Data, unless otherwise indicated.

Contracting Officer will return two copies. Mark up and retain one returned copy as a Project Record Document.

C. Shop Drawings: Prepare Project-specific information, drawn accurately to scale. Do not base Shop Drawings on reproductions of the Contract Documents or standard printed data, unless submittal of Architect's CAD Drawings is otherwise permitted.

1. Preparation: Fully illustrate requirements in the Contract Documents. Include the following information, as applicable:

a. Dimensions.

b. Identification of products.

c. Fabrication and installation drawings.

d. Roughing-in and setting diagrams.

e. Wiring diagrams showing field-installed wiring, including power, signal, and control wiring.

f. Shopwork manufacturing instructions.

g. Templates and patterns.

h. Schedules.

i. Notation of coordination requirements.

j. Notation of dimensions established by field measurement.

k. Relationship to adjoining construction clearly indicated.

l. Seal and signature of professional engineer if specified.

m. Wiring Diagrams: Differentiate between manufacturer-installed and field-installed wiring.

n. Compliance with specified standards

2. Sheet Size: Except for templates, patterns, and similar full-size drawings, submit Shop Drawings on sheets at least 8-1/2 by 11 inches but no larger than 22 by 34 inches.

3. Number of Copies: Submit two opaque (bond) copies of each submittal. Contracting Officer will return one copy.

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-6

D. Samples: Submit Samples for review of kind, color, pattern, and texture for a check of these characteristics with other elements and for a comparison of these characteristics between submittal and actual component as delivered and installed.

1. Transmit Samples that contain multiple, related components such as accessories together in one submittal package.

2. Identification: Attach label on unexposed side of Samples that includes the following:

a. Project name and submittal number

b. Generic description of Sample.

c. Product name and name of manufacturer.

d. Sample source.

e. Number and title of applicable Specification Section.

f. Specification paragraph number and generic name of each item

g. Locations of use.

h. Number and title of appropriate Specification Section.

3. Email Transmittal: Provide PDF transmittal. Include digital image file illustrating Sample characteristics, and identification information for record.

4. Web-Based Project Software: Prepare submittals in PDF form, and upload to web-based Project software website. Enter required data in web-based software site to fully identify submittal.

5. Paper Transmittal: Include paper transmittal including complete submittal information indicated.

6. Disposition: Maintain sets of approved Samples at Project site, available for quality-control comparisons throughout the course of construction activity. Sample sets may be used to determine final acceptance of construction associated with each set.

7. Samples for Initial Selection: Submit manufacturer's color charts consisting of units or sections of units showing the full range of colors, textures, and patterns available. Color selections will be made only after all related color samples have been received.

a. Number of Samples: Submit one full set(s) of available choices where color, pattern, texture, or similar characteristics are required to be selected from manufacturer's product line. Contracting Officer will return submittal with options selected.

8. Samples for Verification: Submit full-size units or Samples of size indicated, prepared from same material to be used for the Work, cured and finished in manner specified, and physically identical with material or product proposed for use, and that show full range of color and texture variations expected. Samples include, but are not limited to, the following: partial sections of manufactured or fabricated components; small cuts or containers of materials; complete units of repetitively used materials; swatches showing color, texture, and pattern; color range sets; and components used for independent testing and inspection.

a. Number of Samples: Submit three sets of Samples. Contracting Officer will retain two Sample sets; remainder will be returned. Mark up and retain one returned Sample set as a Project Record Sample.

E. Product Schedule or List: As required in individual Specification Sections, prepare a written summary indicating types of products required for the Work and their intended location.

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-7

1. Number of Copies: Submit three copies of product schedule or list, unless otherwise indicated. Contracting Officer will return two copies.

F. Submittals Schedule: Comply with requirements specified in Division 01 Section "Construction Progress Documentation."

G. Schedule of Values: Comply with requirements specified in Division 01 Section "Schedule of Values."

H. Subcontract List: Prepare a written summary identifying individuals or firms proposed for each portion of the Work, including those who are to furnish products or equipment fabricated to a special design.

1. Number of Copies: Submit three copies of subcontractor list, unless otherwise indicated.

Contracting Officer will return two copies.

I. LEED Submittals: Comply with requirements specified in Division 01 Section "LEED Requirements."

1. Number of Copies: Submit three copies of LEED submittals, unless otherwise indicated.

J. Material Safety Data Sheets (MSDSs) for LEED Certification: Submit information necessary to show compliance with LEED certification requirements, which will be the limit of the Contracting Officer's review.

1. Contracting Officer will not review non-LEED submittals that include MSDSs and will return the entire submittal for resubmittal.

1.5 INFORMATIONAL SUBMITTALS

A. Prepare and submit Informational Submittals required by other Specification Sections.

1. Number of Copies: Submit two copies of each submittal, unless otherwise indicated.

Contracting Officer will not return copies.

2. Certificates and Certifications: Provide notarized statement that includes signature of entity responsible for preparing certification, signed by officer or other individual authorized to sign documents on behalf of that entity. State that the named product conforms to the Contract requirements. Submit certificate with a certified copy of test results or certify that such test results are on file with the manufacturer and will be furnished to Contracting Officer upon request. Provide name and address of manufacturer, testing agency, and date of tests. The certificate shall set forth the means of identification which will permit field determination of the product delivered as being the product covered by the certification.

3. Test and Inspection Reports: Comply with requirements specified in Division 01 Section "Quality Requirements."

B. Coordination Drawings: Comply with requirements specified in Division 01 Section "Project Management and Coordination."

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-8

C. Contractor's Construction Schedule: Comply with requirements specified in Division 01 Section "Construction Progress Documentation."

D. Conformance Certificates: Prepare written certification that material complies with Contract Documents. Include evidence prior to sampling and testing.

E. Welding Certificates: Prepare written certification that welding procedures and personnel comply with requirements in the Contract Documents. Submit record of Welding Procedure Specification (WPS) and Procedure Qualification Record (PQR) on AWS forms. Include names of firms and personnel certified.

F. Installer Certificates: Prepare written statements on manufacturer's letterhead certifying that Installer complies with requirements in the Contract Documents and, where required, is authorized by manufacturer for this specific Project.

G. Manufacturer Certificates: Prepare written statements on manufacturer's letterhead certifying that manufacturer complies with requirements in the Contract Documents. Include evidence of manufacturing experience where required.

H. Product Certificates: Prepare written statements on manufacturer's letterhead certifying that product complies with requirements in the Contract Documents.

I. Material Certificates: Prepare written statements on manufacturer's letterhead certifying that material complies with requirements in the Contract Documents.

J. Material Test Reports: Prepare reports written by a qualified testing agency, on testing agency's standard form, indicating and interpreting test results of material for compliance with requirements in the Contract Documents.

K. Product Test Reports: Prepare written reports indicating current product produced by manufacturer complies with requirements in the Contract Documents. Base reports on evaluation of tests performed by manufacturer and witnessed by a qualified testing agency, or on comprehensive tests performed by a qualified testing agency.

L. Research/Evaluation Reports: Prepare written evidence, from a model code organization acceptable to authorities having jurisdiction, that product complies with building code in effect for Project.

M. Preconstruction Test Reports: Prepare reports written by a qualified testing agency, on testing agency's standard form, indicating and interpreting results of tests performed before installation of product, for compliance with performance requirements in the Contract Documents.

N. Compatibility Test Reports: Prepare reports written by a qualified testing agency, on testing agency's standard form, indicating and interpreting results of compatibility tests performed before installation of product. Include written recommendations for primers and substrate preparation needed for adhesion.

O. Field Test Reports: Prepare reports written by a qualified testing agency, on testing agency's standard form, indicating and interpreting results of field tests performed either during installation of product or after product is installed in its final location, for compliance with requirements in the Contract Documents.

JANUARY 2020 SUBMITTAL PROCEDURES

FILLMORE AND LITTLE SAHARA FIRE REMODEL 013300-9

P. Maintenance Data: Prepare written and graphic instructions and procedures for operation and normal maintenance of products and equipment. Comply with requirements specified in Division 01 Section "Operation and Maintenance Data."

Q. Design Data: Prepare written and graphic information, including, but not limited to, performance and design criteria, list of applicable codes and regulations, and calculations. Include list of assumptions and other performance and design criteria and a summary of loads. Include load diagrams if applicable. Provide name and version of software, if any, used for calculations.

Include page numbers.

R. Manufacturer's Instructions: Prepare written or published information that documents manufacturer's recommendations, guidelines, and procedures for installing or operating a product or equipment. Include name of product and name, address, and telephone number of manufacturers.

S. Manufacturer's Field Reports: Prepare written information documenting factory-authorized service representative's tests and inspections. Include the following, as applicable:

1. Statement on condition of substrates and their acceptability for installation of product.

2. Summary of installation procedures being followed, whether they comply with requirements and, if not, what corrective action was taken.

3. Results of operational and other tests and a statement of whether observed performance complies with requirements.

T. Insurance Certificates and Bonds: Prepare written information indicating current status of insurance or bonding coverage. Include name of entity covered by insurance or bond, limits of coverage, amounts of deductibles, if any, and term of the coverage.

U. Construction Photographs: Comply with requirements specified in Division 01 Section "Photographic Documentation."

1.6 DELEGATED DESIGN

A. Performance and Design Criteria: Where professional design services or certifications by a…