A02 - Vol 1 of 3 - Specification 2079 - Natomas RIC2 and H - DRAFT.pdf

READY TO ADVERTISE SPECIFICATIONS (RTA)

AMERICAN RIVER COMMON FEATURES

NATOMAS BASIN - REACH I - CONTRACT 2:

STA 0+00 TO 115+00 AND REACH H - SUBREACH 1

SACRAMENTO COUNTY, CALIFORNIA

TECHNICAL SPECIFICATIONS

VOLUME 1: READY TO ADVERTISE SPECIFICATIONS

SPECIFICATION NO. 2079

DESIGN FILE NO. 1-04-0641 AND 1-04-0659

P2 #458598

DECEMBER 2025

DRAFT

This page intentionally left blank.

American River Common Features (ARCF) Spec No. 2079 Natomas Basin - Reach I Contract 2 & Reach H

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 15 LIST OF DRAWINGS

00 73 05 SUPPLEMENTARY CONDITION REQUIREMENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 20 00 PRICE AND PAYMENT PROCEDURES

01 32 01 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00 QUALITY CONTROL

01 45 01 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 71 10 MOBILIZATION AND DEMOBILIZATION

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 02 - EXISTING CONDITIONS

02 02 00 SUBSURFACE DATA

02 41 00 DEMOLITION

DIVISION 05 - METALS

05 50 13 MISCELLANEOUS METAL FABRICATIONS

DIVISION 10 - SPECIALTIES

10 14 01 SIGNAGE

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

31 11 00 CLEARING, GRUBBING, AND STRIPPING

31 23 00 BORROW SITE EXCAVATION

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 12 16 HOT-MIX ASPHALT (HMA) FOR ROADS

32 15 00 AGGREGATE SURFACE COURSE AND AGGREGATE BASE

32 17 24 PAVEMENT MARKINGS

32 31 13 CHAIN LINK FENCES AND GATES

32 92 33 GRASS SEEDING AND EROSION CONTROL

DIVISION 33 - UTILITIES

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 40 00 STORM DRAINAGE UTILITIES

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

THIS PAGE INTENTIONALLY LEFT BLANK

PROJECT TABLE OF CONTENTS Page 2

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 01 15

LIST OF DRAWINGS

PART 1 GENERAL

1.1 SUMMARY

1.2 CONTRACT DRAWINGS

-- End of Section Table of Contents --

DOCUMENT 00 01 15 Page 1

THIS PAGE INTENTIONALLY LEFT BLANK

DOCUMENT 00 01 15 Page 2

SECTION 00 01 15

LIST OF DRAWINGS

PART 1 GENERAL

1.1 SUMMARY

This section lists the drawings for the project pursuant to contract clause "DFARS 252.236-7001, Contract Drawings, Maps and Specifications."

1.2 CONTRACT DRAWINGS

Contract drawings are as follows:

REACH I CONTRACT 2 STA 0+00 TO 115+00 (VOLUME 2 OF 3)

DRAWING REVISION TITLE

NO. NO.

G-001 N/A COVER SHEET

G-002 N/A SHEET INDEX

G-003 N/A GENERAL NOTES (1 OF 2)

G-004 N/A GENERAL NOTES (2 OF 2)

G-005 N/A GENERAL SYMBOLS

G-006 N/A GENERAL ABBREVIATIONS

G-101 N/A LOCATION MAP

G-102 N/A CONTROL LINE PLAN

G-103 N/A CONTROL LINE TABLE

G-104 N/A CONSTRUCTION LIMIT PLAN

G-105 N/A CONSTRUCTION LIMIT SURVEY DATA

G-106 N/A SURVEY CONTROL MAP

G-107 N/A HAUL ROUTES AND STAGING AREAS

G-108 N/A BORROW PLAN - BROOKFIELD

V-101 N/A AERIAL PHOTO AND STUMP REMOVAL STA 0+00

TO STA 17+00 (CONTROL LINE A)

V-102 N/A AERIAL PHOTO AND STUMP REMOVAL STA 28+50

TO STA 37+00 (CONTROL LINE A)

V-103 N/A AERIAL PHOTO AND STUMP REMOVAL STA 37+00

TO STA 51+50 (CONTROL LINE A)

V-104 N/A AERIAL PHOTO AND STUMP REMOVAL STA 51+50

TO STA 68+50 (CONTROL LINE A)

V-105 N/A AERIAL PHOTO AND STUMP REMOVAL STA 68+50

TO STA 85+50 (CONTROL LINE A)

V-106 N/A AERIAL PHOTO AND STUMP REMOVAL STA 85+50

TO STA 102+00 (CONTROL LINE A)

V-107 N/A AERIAL PHOTO AND STUMP REMOVAL STA 102+00

TO STA 115+00 (CONTROL LINE A)

V-108 N/A TREE INVENTORY - STUMPS TO BE REMOVED (1 OF 3)

V-109 N/A TREE INVENTORY - STUMPS TO BE REMOVED (2 OF 3)

V-110 N/A TREE INVENTORY - STUMPS TO BE REMOVED (3 OF 3)

V-111 N/A TREE INVENTORY - TREES TO BE PROTECTED IN PLACE

(1 OF 1)

V-112 N/A TREE INVENTORY - DO NOT DISTURB (1 OF 1)

C-101 N/A PLAN AND PROFILE - STA 100+00 TO STA 106+50

(CONTROL LINE B)

DOCUMENT 00 01 15 Page 3

DRAWING REVISION TITLE

NO. NO.

C-102 N/A PLAN AND PROFILE - STA 106+50 TO STA 112+00

(CONTROL LINE B)

C-103 N/A PLAN AND PROFILE - STA 200+00 TO STA 208+00

(CONTROL LINE C)

C-104 N/A PLAN AND PROFILE - STA 300+00 TO STA 305+00

(CONTROL LINE D)

C-105 N/A PLAN AND PROFILE - STA 305+00 TO STA 311+50

(CONTROL LINE D)

C-106 N/A PLAN AND PROFILE - STA 400+00 TO STA 407+00

(CONTROL LINE E)

C-107 N/A PLAN AND PROFILE - STA 407+00 TO STA 415+00

(CONTROL LINE E)

C-108 N/A PLAN AND PROFILE - STA 415+00 TO STA 424+00

(CONTROL LINE E)

C-109 N/A PLAN AND PROFILE - STA 424+00 TO STA 433+50

(CONTROL LINE E)

C-110 N/A PLAN AND PROFILE - STA 433+50 TO STA 441+00

(CONTROL LINE E)

C-111 N/A PLAN AND PROFILE STA 441+00 TO STA 449+00

(CONTROL LINE E)

C-112 N/A PLAN AND PROFILE STA 500+00 TO 508+00 (CONTROL LINE F)

C-113 N/A PLAN AND PROFILE STA 508+00 TO 514+50 (CONTROL LINE F)

C-201 N/A SITE PLANS - (1 OF 6)

C-202 N/A SITE PLANS - (2 OF 6)

C-203 N/A SITE PLANS - (3 OF 6)

C-204 N/A SITE PLANS - (4 OF 6)

C-205 N/A SITE PLANS - (5 OF 6)

C-206 N/A SITE PLANS - (6 OF 6)

C-207 N/A SPEED LUMP PLAN

C-301 N/A TYPICAL SECTIONS - (1 OF 2)

C-302 N/A TYPICAL SECTIONS - (2 OF 2)

C-303 N/A TYPICAL DETAILS - (1 OF 5)

C-304 N/A TYPICAL DETAILS - (2 OF 5)

C-305 N/A TYPICAL DETAILS - (3 OF 5)

C-306 N/A TYPICAL DETAILS - (4 OF 5)

C-307 N/A TYPICAL DETAILS - (5 OF 5)

C-501 N/A LEVEE CROSS SECTIONS STA 101+00 TO STA 106+00

(CONTROL LINE B)

C-502 N/A LEVEE CROSS SECTIONS STA 107+00 TO STA 110+89

(CONTROL LINE B)

C-503 N/A LEVEE CROSS SECTIONS STA 201+00 TO STA 206+00

(CONTROL LINE C)

C-504 N/A LEVEE CROSS SECTIONS STA 207+00 (CONTROL LINE C)

C-505 N/A LEVEE CROSS SECTIONS STA 300+15 TO STA 305+00

(CONTROL LINE D)

C-506 N/A LEVEE CROSS SECTIONS STA 306+00 TO STA 310+00

(CONTROL LINE D)

C-507 N/A LEVEE CROSS SECTIONS STA 400+20 TO STA 405+00

(CONTROL LINE E)

C-508 N/A LEVEE CROSS SECTIONS STA 406+00 TO STA 411+00

(CONTROL LINE E)

C-509 N/A LEVEE CROSS SECTIONS STA 412+00 TO STA 417+00

(CONTROL LINE E)

DOCUMENT 00 01 15 Page 4

DRAWING REVISION TITLE

NO. NO.

C-510 N/A LEVEE CROSS SECTIONS STA 418+00 TO STA 423+00

(CONTROL LINE E)

C-511 N/A LEVEE CROSS SECTIONS STA 424+00 TO STA 429+00

(CONTROL LINE E)

C-512 N/A LEVEE CROSS SECTIONS STA 430+00 TO STA 435+00

(CONTROL LINE E)

C-513 N/A LEVEE CROSS SECTIONS STA 436+00 TO STA 441+00

(CONTROL LINE E)

C-514 N/A LEVEE CROSS SECTIONS STA 442+00 TO STA 447+00

(CONTROL LINE E)

C-515 N/A LEVEE CROSS SECTIONS STA 448+00 (CONTROL LINE E)

C-516 N/A LEVEE CROSS SECTIONS STA 500+00 TO STA 505+00

(CONTROL LINE F)

C-517 N/A LEVEE CROSS SECTIONS STA 506+00 TO STA 511+00

(CONTROL LINE F)

C-518 N/A LEVEE CROSS SECTIONS STA 512+00 TO STA 513+00

(CONTROL LINE F)

CU101 N/A UTILITY PLAN STA 0+00 TO STA 17+00 (CONTROL LINE A)

CU102 N/A UTILITY PLAN STA 23+00 TO STA 37+00 (CONTROL LINE A)

CU103 N/A UTILITY PLAN STA 37+00 TO STA 51+50 (CONTROL LINE A)

CU104 N/A UTILITY PLAN STA 51+50 TO STA 68+50 (CONTROL LINE A)

CU105 N/A UTILITY PLAN STA 68+50 TO STA 85+50 (CONTROL LINE A)

CU106 N/A UTILITY PLAN STA 85+50 TO STA 102+00 (CONTROL LINE A)

CU107 N/A UTILITY PLAN STA 102+00 TO STA 115+00 (CONTROL LINE A)

CP001 N/A TRAFFIC HANDLING - GARDEN HIGHWAY BETWEEN GATEWAY OAKS

AND INTERSTATE 5

CP002 N/A TRAFFIC HANDLING - GARDEN HIGHWAY AT NATOMAS PARK DRIVE

CP003 N/A TRAFFIC HANDLING - GARDEN HIGHWAY BETWEEN NATOMAS PARK

DRIVE AND TRUXEL ROAD

CP004 N/A TRAFFIC HANDLING - GARDEN HIGHWAY BETWEEN TRUXEL AND

ARDEN GARDEN CONNECTOR (1 OF 2)

CP005 N/A TRAFFIC HANDLING - GARDEN HIGHWAY BETWEEN TRUXEL AND

ARDEN GARDEN CONNECTOR (2 OF 2)

CP006 N/A TRAFFIC HANDLING - GARDEN HIGHWAY AT ARDEN GARDEN

CONNECTOR

CP101 N/A TRAFFIC DETOUR PLAN - GARDEN HIGHWAY BETWEEN NATOMAS

PARK DRIVE AND TRUXEL ROAD

CP102 N/A TRAFFIC DETOUR PLAN - GARDEN HIGHWAY BETWEEN TRUXEL

ROAD AND ARDEN GARDEN CONNECTOR

CP201 N/A SIGNAGE ADN STRIPING - GARDEN HIGHWAY AT NATOMAS PARK

E-001 N/A STREETLIGHT SPECIAL PROVISIONS

E-101 N/A ELECTRICAL UTILITY PLAN - STA 0+00 TO STA 16+00

(CONTROL LINE A)

E-102 N/A ELECTRICAL UTILITY PLAN - STA 16+00 TO STA 30+00

(CONTROL LINE A)

E-103 N/A ELECTRICAL UTILITY PLAN - STA 30+00 TO STA 44+00

(CONTROL LINE A)

E-104 N/A ELECTRICAL UTILITY PLAN - STA 44+00 TO STA 58+50

(CONTROL LINE A)

E-201 N/A ELECTRICAL UTILITY PLAN - ONE LINE DIAGRAM

E-501 N/A STANDARD DETAILS FOR TRAFFIC SIGNALS NO. 1

E-502 N/A STANDARD DETAILS FOR TRAFFIC SIGNALS NO. 2

E-503 N/A ELECTRICAL STANDARD DETAILS

E-504 N/A ELECTRICAL AND TRAFFIC SIGNAL STANDARD DETAILS

DOCUMENT 00 01 15 Page 5

REFERENCE DRAWINGS (DFN 1-04-0570)

CU112 N/A SUMP 58 DISCHARGE LINES RELOCATION PLAN AND PROFILE

STA 1+00 TO STA 3+00

Contract drawings are as follows:

REACH H - SUBREACH 1 (VOLUME 3 OF 3)

DRAWING REVISION TITLE

NO. NO.

G-001 N/A TITLE SHEET

G-002 N/A BASIN MAP

G-003 N/A VICINITY MAP, DRAWING LIST, LEGEND, AND ABBREVIATIONS

G-004 N/A GENERAL NOTES

G-005 N/A SURVEY CONTROL POINTS (1 OF 2)

G-006 N/A SURVEY CONTROL POINTS (2 OF 2)

V-101 N/A NEMDC AERIAL PHOTO, REACH H STATIONS 0+00 TO 7+00

V-102 N/A NEMDC AERIAL PHOTO, REACH H STATIONS 7+00 TO 13+00

V-103 N/A NEMDC AERIAL PHOTO, REACH H STATIONS 189+00 TO 200+00

C-001 N/A CONTROL LINE PLAN AND PLAN & PROFILE SHEET LAYOUT

(1 OF 2)

C-002 N/A PLAN SHEET LAYOUT (2 OF 2)

C-003 N/A CONSTRUCTION LIMIT & FLPE PLAN

C-004 N/A TREE REMOVAL PLAN AND TABLE (1 OF 2)

C-005 N/A TREE REMOVAL PLAN AND TABLE (2 OF 2)

C-101 N/A NEMDC PLAN & PROFILE, STATIONS 0+00 TO 9+00

C-102 N/A NEMDC PLAN & PROFILE, STATIONS 9+00 TO 13+00 &

COLUMBUS AVENUE ACCESS ROAD RAMP PLAN & PROFILE

C-201 N/A TYPICAL SECTIONS AND DETAILS (1 OF 5)

C-202 N/A TYPICAL SECTIONS AND DETAILS (2 OF 5)

C-203 N/A TYPICAL SECTIONS AND DETAILS (3 OF 5)

C-204 N/A TYPICAL SECTIONS AND DETAILS (4 OF 5)

C-205 N/A TYPICAL SECTIONS AND DETAILS (5 OF 5)

C-301 N/A NEMDC CROSS SECTIONS STATIONS 0+00 TO 8+00

C-302 N/A NEMDC CROSS SECTIONS STATIONS 9+00 TO 13+00

-- End of Document --

DOCUMENT 00 01 15 Page 6

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 73 05

SUPPLEMENTARY CONDITION REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 SUPPLEMENTARY CONDITIONS REQUIREMENTS

1.3.1 SCR-1 Allowable Time, Schedule Constraints and Time of

Completion

1.3.2 SCR-2 Site Conditions

1.3.3 SCR-3 Lands and Right-of-Way

1.3.4 SCR-4 Access by Government, and Other Jurisdictional Public

Agencies

1.3.5 SCR-5 Borrow Source

1.3.6 SCR-6 Contractor's Tools and Equipment

1.3.7 SCR-7 Locking Gates

1.3.8 SCR-8 Water Source for Construction Operations

1.3.9 SCR-9 Cleaning Up

1.3.10 SCR-10 Protection of Existing Improvements

1.3.11 SCR-11 Record Drawings

1.3.12 SCR-12 Flood Emergency

1.3.13 SCR-13 Permits and Approvals

1.3.14 SCR-14 Dust Control

1.3.15 SCR-15 Fire Control

1.3.16 SCR-16 Air Pollution Control

1.3.17 SCR-17 Noise Control

1.3.18 SCR-18 Allowable Work Hours

1.3.19 SCR-19 Cultural Resources

1.3.20 SCR-20 Protection of Existing Trees

1.3.21 SCR-21 Biological Resources

1.3.22 SCR-22 Raptor and Migratory Birds

1.3.23 SCR-23 Wetlands and Sensitive Habitats

1.3.24 SCR-24 U.S. Fish and Wildlife Service

1.3.25 SCR-25 Speed Limit

1.3.26 SCR-26 Reclamation District 1000 (RD1000) Coordination

1.3.27 SCR-27 Safety and Management of Public and Unhoused

Individuals

1.3.28 SCR-28 Provision Regarding Maintaining Minimum Flood

Protection During Construction

1.3.29 SCR-29 Coordination with the Contracting Officer and

Utilities Relocation

1.3.30 SCR-30 Haul Routes

1.3.31 SCR-31 Resource Coordination

1.3.32 SCR-32 Flood Contingency Plan

1.3.33 SCR-33 Utility Provider Response Plan

1.3.34 SCR-34 Stop Work Authority

1.3.35 SCR-35 Floodway Construction Schedule

1.3.36 SCR-36 High Visibility Fencing, Habitat Preservation and

DOCUMENT 00 73 05 Page 1

Buffers

1.3.37 SCR-37 General Safety Requirements

1.3.38 SCR-38 Storm Water Pollution Prevention Plan

1.3.39 SCR-39 Grading (Encroachment) Permit

1.3.40 SCR-40 Staging Areas

1.3.41 SCR-41 Asbestos Cement Waterline Removal

1.3.42 SCR-42 Recreation/Community Mitigation

1.3.43 SCR-43 City Streets

1.3.44 SCR-44 City of Sacramento Mastarm Street Lights

1.3.45 SCR-45 Storage Area

1.3.46 SCR-46 Project Signage

1.3.47 SCR-47 Traffic Control Plan

1.3.48 SCR-48 Streetlights, Electrical, and Fiber Installations

PART 2 PRODUCTS

PART 3 EXECUTION

-- End of Section Table of Contents --

DOCUMENT 00 73 05 Page 2

SECTION 00 73 05

SUPPLEMENTARY CONDITION REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2024) Safety -- Safety and Occupational Health (SOH) Requirements

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation.

The following must be in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals ; G

Permits and Approvals ; G

Construction emission/dust control plan ; G

Permit, waiver or other documentation with the mapped haul routes from local jurisdictions to repair or compensate for damage ; G

Flood Contingency Plan ; G

Utility Provider Response Plan ; G

Storm Water Pollution Prevention Plan ; G

Grading (Encroachment) Permit ; G

Traffic Control Plan ; G

Public and Unhoused Population Safety Plan ; G

Work Plan ; G

1.3 SUPPLEMENTARY CONDITIONS REQUIREMENTS

1.3.1 SCR-1 Allowable Time, Schedule Constraints and Time of Completion

The time of completion for this contract, which includes all segments of work to be completed in their entirety and in accordance with the project plans and these specifications, must be as outlined below and incorporated into the Contractor's schedule.

DOCUMENT 00 73 05 Page 3

TIME OF COMPLETION FOR REACH I - CONTRACT 2 AND REACH H SUBREACH 1

Description of Work Date of Completion

A. Contracting Officer and Resident Engineer's Office Facility

Installed and ready for occupancy not later than five (5) calendar days prior to start of construction

B. Traffic Control Plan Traffic Control Plan must be approved and traffic control measures installed prior to the start of construction activities

C. Copies of Permits Contractor to provide to Contracting Officer within 10 calendar days of receipt and 15 days prior to start of construction

D. Flood contingency plan Submit to Contracting officer 30 calendar days prior to commencement of construction activities

E. Record Drawings Submit to Contracting Officer within 10 calendar days after Government approval of working drawings

Ground disturbance work along Garden Highway must take place between April 15 and November 1.

Construction will initiate at the eastern end of project (Reach H) and progress westerly.

1.3.2 SCR-2 Site Conditions

The Contractor must satisfy himself or herself concerning the nature and location of the work; the general and local conditions, particularly those affecting transportation, disposal, handling and storage facilities;

availability of labor, water, power, communications, roads, climatic conditions and seasons; physical conditions at the job sites and Project areas as a whole; job-site topography and ground conditions; permits, equipment, and facilities needed preliminary to, and during, work prosecution; and all other matters which can in any way affect the work, including cost thereof. Failure of the Contractor to become acquainted with all available information regarding any applicable conditions will not relieve the Contractor from the responsibility for properly estimating either the difficulties or the costs of successfully performing the work.

1.3.3 SCR-3 Lands and Right-of-Way

The right-of-way for the construction work, as shown on the Plans, will be provided by the Government. The Contractor is responsible for obtaining land rights and easements for areas to be used for the Contractor's own convenience outside the right of way shown and footprint limits on the Plans and must absorb complete liability for the use, and/or associated activities related to the use of such land. The Contractor is responsible

DOCUMENT 00 73 05 Page 4 for all work and costs associated with obtaining land rights and easements.

If the contractor receives land rights and easements outside of the construction limits, these rights must be received in writing and forwarded to the Government for their records. Contractor must also receive release of liability of the Government for any damage to these addition areas in writing.

Compliance with environmental and cultural laws must be followed by the contractor if using lands other than those identified by the Government.

1.3.4 SCR-4 Access by Government, and Other Jurisdictional Public Agencies

The Contractor must allow the following Agencies and Jurisdictional public agencies unrestricted access to the project site at all times:

United States Army Corps of Engineers

California Department of Water Resources

Reclamation District 1000

Sacramento Area Flood Control Agency

County of Sacramento

City of Sacramento

Sacramento Area Sewer District

Central Valley Flood Protection Board

California State Department of Fish and Wildlife

United States Fish and Wild Life Service

National Marine Fishery Service

All Visitors must comply with the safety requirement in the EM 385-1-1 and contractor safety plans. All Visitors must coordinate with the onsite Government representative prior to visiting the job site.

1.3.5 SCR-5 Borrow Source

A borrow source for the project has been identified and included in the Plans. Borrow material, borrow site, and borrow activities must comply with all applicable local, state, and federal regulations.

1.3.6 SCR-6 Contractor's Tools and Equipment

The Contractor must furnish all equipment, materials, tools, supplies, and manufactured articles required for the completion of the work in accordance with the Contract. The Contractor must take the necessary precautions to secure tools and equipment from theft while on-site. The Government assumes no responsibility for lost, vandalized, or stolen equipment belonging to the Contractor, its subcontractors, or its employees.

DOCUMENT 00 73 05 Page 5

1.3.7 SCR-7 Locking Gates

The Contractor must take care to protect and operate any existing gates that control access to the Project right-of-way, in conformance with the Government, RD1000, and the City and County of Sacramento requirements.

These requirements include preventing passage through the gates of unauthorized persons and equipment during periods of Contractor use of the gates and locking the gates during non-construction periods, if so directed by the Contracting Officer.

1.3.8 SCR-8 Water Source for Construction Operations

Contractor is responsible for identifying, securing, and obtaining all water needed for the project for both potable uses and for construction purposes. Water must not be pumped from the American River or Steelhead Creek. Construction water should be reused onsite to the extent practical and disposed of in a manner consistent with the environmental permits.

Excess water must not be disposed of into any wetland, stream, river, or storm drainage without all applicable local and regulatory permitting.

Contractor is responsible for disposal of all construction water.

1.3.9 SCR-9 Cleaning Up

The Contractor must dispose of all trash items in closed containers, which must be removed at least once per day. Vegetative wastes must be chipped and delivered to waste energy facilities, mulched, composted, or used for firewood and removed at least once per week.

1.3.10 SCR-10 Protection of Existing Improvements

Except as specified herein or as shown on the Plans, existing structures and utility lines are not to be disturbed, damaged, or undermined by the Contractor, except where in the opinion of the Contracting Officer it is essential to relocate such improvements. If relocation of any facility is required, the Contractor must relocate the improvements to be at least equal in condition to the original. The Contractor must take all necessary precautions to prevent any damage to existing facilities.

Should damage or injury occur because the Contractor's operations, the Contractor must repair or replace such damaged facilities to the Contracting Officer's satisfaction at the Contractor's expense.

The Contractor must repair any damage to public and private streets resulting from the Contractor's operations, as directed by the Contracting Officer. Repair must be made per industry standards and conform to local jurisdictional requirements. Repairs must be made at no additional cost to the Government.

1.3.11 SCR-11 Record Drawings

The Contractor must maintain a neat and accurate marked set of working record drawings in accordance with Specifications. The record drawings are subject to the inspection of the Contracting Officer at all times and must be kept current weekly with all work instructions, change orders, and construction adjustments shown thereon and initiated by inspection. The Contracting Officer reserves the right to withhold progress payments, or portions thereof, if record drawings are not maintained as stated above.

DOCUMENT 00 73 05 Page 6

1.3.12 SCR-12 Flood Emergency

In the event of a flood emergency requiring action by the jurisdictional flood control agencies prior to completion of the work, the Contracting Officer has the right to suspend the work in accordance with the General Specifications. Such suspension includes the right of the Contracting Officer to take over the Project to conduct flood protection activities.

The flood emergency plan will be commenced when the H Street Gauge reads 26 feet NGVD29 and is forecasted to rise.

1.3.13 SCR-13 Permits and Approvals

The Contracting Officer has obtained various permits, agreements, and rights for performance of the work. These permits may be described more fully in other SCRs and these specifications. The Contractor will be required to obtain additional permits or be a signatory on the Contracting Officer obtained permits as noted throughout the specifications. The Contractor is responsible for complying with all conditions of the permits and agreements. Any delays to the Project resulting from the Contractor's failure to follow permit requirements will not be the responsibility of the Contracting Officer and the Contractor will not be granted any extension of time for such delays.

The Contractor is responsible for obtaining all environmental permits or use permits (including CALTRANS Encroachment Permit) required for easements to land being used for the Contractor's own convenience and for work within the State Right of Way. Any delays to the Project resulting from the lack of these additional permits or the Contractor's failure to follow permit requirements will not be the responsibility of the Contracting Officer and the Contractor will not be granted any extension of time or additional compensation for such delays. Copies of all permits obtained by the Contractor must be given to the Contracting Officer within 10 days of receipt of permit. The contractor is responsible for paying all permit fees.

1.3.14 SCR-14 Dust Control

The Contractor must comply with the provisions of Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS of the Specifications. The Contractor must prepare and submit a construction emission/dust control plan to the Contracting Officer and Sacramento Metropolitan Air Quality Management District (SMAQMD) and must receive approval of the plan before groundbreaking. During the performance of the work, the Contractor must assume all responsibility for dust control and furnish all labor, equipment, and means required, and must carry out proper and efficient measures wherever and as often as necessary to prevent the construction operations from producing dust in amounts harmful to persons, damaging to property, or causing a nuisance to persons living nearby or occupying buildings in the vicinity of the work, or as directed by the Contracting Officer. Dust control will be strictly enforced with particular emphasis on work areas adjacent to residential and agricultural properties. The curtailment of the construction activities as a result of inadequate dust control measures will not be considered an unavoidable delay. The Contractor must suspend all grading operations when fugitive dust levels exceed levels specified by SMAQMD regulations or deemed unacceptable by the Contracting Officer. The Contractor is responsible for paying any fees assessed by SMAQMD.

DOCUMENT 00 73 05 Page 7

1.3.15 SCR-15 Fire Control

Burning is not allowed for any activities associated with this project.

Delivering removed vegetative material to compost or waste-to-energy facilities, or repurposing is encouraged. Land filling of material must be minimized.

Smoking is not permitted in areas near flammable materials such as dry grass or in restricted areas as identified by the Contracting Officer.

Cigarette butts must be placed in appropriate receptacles.

1.3.16 SCR-16 Air Pollution Control

The Contractor must comply with the air pollution control protocols specified in Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS of the Specifications. To the extent available, the Contractor must use existing power sources for the Contractor provided trailers rather than temporary power generators. If existing power sources are unavailable, clean fuel, low-emission on-site stationary generator equipment must be used. Use low -sulfur fuel for stationary construction equipment. The Contractor is responsible for arranging appropriate consultation with the Air Resources Board and the SMAQMD, to determine registration and permitting requirements before operating portable engines or portable engine-driven equipment at the project site.

1.3.17 SCR-17 Noise Control

The Contractor must comply with Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS of the Specifications to avoid and minimize noise impacts from the construction activities.

Before construction activity begins within 500 feet of one or more residences, the Contractor must provide written notification to the potentially affected residents, identifying the type, duration, and frequency of activities. Notification materials must also identify a mechanism for residents to register complaints with the appropriate jurisdiction if demolition noise levels are overly intrusive.

Before haul truck trips are initiated on roads within 600 feet of one or more residences, the Contractor must provide written notification at least one day before to the potentially affected residents, identifying the hours and frequency of haul truck trips. Notification materials must also identify a mechanism for residents to register complaints with the appropriate jurisdiction if haul truck noise levels are overly intrusive or outside exempt daytime hours.

1.3.18 SCR-18 Allowable Work Hours

The Contractor must limit construction activities to between the following hours on the following days:

Construction work hours are Monday through Saturday 7 AM to 6 PM. Sunday construction work hours are 9 AM to 6 PM with approval from Contracting Officer. Requests for Sunday work must be submitted 72 hours in advance of working on Sunday.

Heavy machinery activity off the levee is restricted to the staging area for one hour prior to 7:00 AM and for one hour after sunset (as posted in

DOCUMENT 00 73 05 Page 8 the newspaper or online) or 10:00 PM whichever occurs sooner. No other construction work will be allowed outside the above-mentioned hours. Any extended work hours must be reflected in the Contractor's initially approved schedule for the Project.

The Contractor must be aware of major events taking place at Discovery Park during the construction period of the Project. Contractor to refer to the Sacramento County Regional Parks calendar at http://regionalparks.saccounty.net/pages/parkcalendar.aspx. The Contractor must plan accordingly.

1.3.19 SCR-19 Cultural Resources

The Contractor must comply with protocols in Section 01 57 19 , TEMPORARY ENVIRONMENTAL CONTROLS, of the Specifications.

Contractor must conduct Construction Personnel Training for all on-site employees. If cultural resources are discovered during construction activities, Contractor must cease work within 100 feet of the vicinity of the find and immediately contact the archaeologist, through the Contracting Officer, and cooperate with all pertinent mitigation procedures. Construction personnel must participate in a cultural awareness program, which will be provided by the USACE Archeologist at the start of construction. As needed, the Contractor must provide a translator to allow the training to be conducted in Spanish for Spanish language speakers and other languages as needed or necessary.

1.3.20 SCR-20 Protection of Existing Trees

All trees of any kind inside the work limits and designated in the drawings as protect in place are to be protected. Contractor must place protective barrier fencing where possible at the drip line around trees designated as protect in place in the drawings. All trees outside the work limits, of any kind, must not to be disturbed. Contractor must place protective barrier fencing around trees adjacent to construction areas as directed by the Contracting Officer. If damaged by the Contractor, damaged trees and landscaping must be replaced by Contractor or otherwise mitigated as directed by Contracting Officer at the Contractor's expense.

1.3.21 SCR-21 Biological Resources

The Contractor must comply with the Section 01 57 19 , TEMPORARY ENVIRONMENTAL CONTROLS, of the Specifications to avoid and minimize effect upon endangered or sensitive species in the Project area. The Contractor must schedule activities to comply with the provisions and provide required notice for surveys to be conducted by the Government's Environmental Representative. Construction personnel must participate in an environmental awareness program, which will be provided by the USACE Biologist at the start of construction. As needed, the Contractor must provide a translator to allow the training to be conducted in Spanish for Spanish language speakers and other languages as needed or necessary.

1.3.22 SCR-22 Raptor and Migratory Birds

The Contractor must comply with the provisions of the Construction Contractor Protocols for Avoiding and Minimizing Impacts to Raptors, Special Status, and Other Nesting Birds, which are included in Section 01 57 19 , TEMPORARY ENVIRONMENTAL CONTROLS, of the Specifications. If a nesting bird is found injured on the Project site, the Contracting Officer

DOCUMENT 00 73 05 Page 9 must be notified immediately so the animal can be relocated to a either a wildlife care facility or a raptor recovery facility.

1.3.23 SCR-23 Wetlands and Sensitive Habitats

The Contractor must not impact Wetlands and Sensitive Habitats.

1.3.24 SCR-24 U.S. Fish and Wildlife Service

A Biological Opinion has been issued by the U.S. Fish and Wildlife Service. The Contract Documents contain all of the terms and conditions from the Biological Opinion, and the Contractor is responsible for implementing all requirements and obligations sited in the Contract Documents.

1.3.25 SCR-25 Speed Limit

The speed limit in all Project work areas and along levees is 15 m.p.h., except on county roads, city streets and highways. The Contracting Officer may also require that speed limits on project site be reduced further to ensure vibration limits, dust protocols or other criteria are not violated. The Contractor must post, at a minimum, two speed limit signs at each end of the work zone.

1.3.26 SCR-26 Reclamation District 1000 (RD1000) Coordination

RD1000 manages the existing levees throughout the project area. The Contractor must coordinate their work with RD1000 through the Contracting Officer, allowing RD1000 personnel and equipment access to and passage along the existing levees at all times.

1.3.27 SCR-27 Safety and Management of Public and Unhoused Individuals

The project site is accessible to the public including unhoused individuals. Site security is required for the duration of the contract and must be provided by the Contractor. Management of the public including unhoused individuals is required for the duration of the contract and must be provided by the Contractor. The City of Sacramento Police Department is the governing agency for the project site location and must be contacted to provide notification of the project. They can be contacted at the link provided:

https://www.cityofsacramento.gov/police/police-services/hire-supplemental-police-officers

Prior to commencement of construction activities, the Contractor must submit a Public and Unhoused Population Safety Plan that includes the following:

o Proposed construction phasing, signage, fencing, and other protective measures to provide for the safety of the public and unhoused individuals.

o Work zones in which the public and unhoused individuals must be excluded during the various phases of construction.

o Locations within the project limits that must remain open to the public during periods of non-construction activity based on various phases of construction.

DOCUMENT 00 73 05 Page 10 o Identification of public access and path of travel during various phases of construction (coordinate with traffic control plan).

1.3.28 SCR-28 Provision Regarding Maintaining Minimum Flood Protection During Construction

Contractor must have all levee improvements completed by the deadlines outlined and described in paragraph 1.3.1, SCR-1, herein. Contractor must not disturb the existing levee system beyond the limits of construction.

Disturbance includes but is not limited to trees, roadways, ramps, pipes and/or utilities crossings, or excavations within the limits of construction. Stockpiling suitable construction materials is acceptable provided written approval is first obtained from the Contracting Officer.

1.3.29 SCR-29 Coordination with the Contracting Officer and Utilities Relocation

Contractor must coordinate and cooperate with the Contracting Officer and all utility providers on relocation of any overhead and underground electrical, sewer, water and storm utilities within the limits of construction. Contractor must lead in coordination and work with the Contracting Officer such that the utilities are relocated in time not to delay and to allow for completion of improvements in accordance with the Time of Completion schedule. The cost of any relocations is the responsibility of the Contractor except where the drawings indicate otherwise.

1.3.30 SCR-30 Haul Routes

All haul and access routes must be existing public roads and maintenance roads, except for restrictions noted on the drawings. Stockpiling of construction materials, including portable equipment, vehicles, and supplies, is restricted to designated construction staging areas and work sites. Movement of heavy equipment to and from the Project site is restricted to load limit approved roadways. The Contractor's construction access points are limited to those shown on the Plans, defined in the Specifications, or as directed in the field by the Contracting Officer.

Paved areas at these controlled access points must be swept each day, or more frequently, as required by the Contracting Officer to control dust and clean up material tracked or spilled on said paved areas or roadways.

The Contractor must conform to all governing codes, laws, and ordinances.

Contractor must obtain a permit, waiver or other documentation with the mapped haul routes from local jurisdictions to repair or compensate for damage to local roads used in hauling to or from the project site. The permit, waiver or other documentation provided by the local jurisdiction may specify the conditions for repairs to be performed or appropriate compensation to account for the road damage. Contractor must provide a copy of the permit, waiver or other documentation from local jurisdictions with the mapped haul routes to the Contracting Officer and resident engineer prior to commencement of haul operations. All cost associated with permits, haul road repairs, and fees are the responsibility of the Contractor and must not be paid separately from unit prices or lump-sum prices contained in the Bidding Schedule.

1.3.31 SCR-31 Resource Coordination

All contact and coordination with the resource agencies must occur through

DOCUMENT 00 73 05 Page 11 the Contracting Officer in coordination with the Government's environmental representative.

1.3.32 SCR-32 Flood Contingency Plan

In the event the water surface elevation of the adjacent river is forecasted by the State-Federal Flood Forecast Center to increase significantly for any reason, the Contracting Officer reserves the right to require the Contractor to stop excavation and to begin continuous operations to complete all partially completed section(s) of the levee embankment. At least 30 days prior to any Levee Excavation, the Contractor must submit a contingency plan outlining the contingency operations in the event the H Street Gauge reads 26 feet NGVD and is forecasted to rise.

The contingency plan must include the proposed measure to protect the landside areas which have a reduced level of protection due to construction activities. The plan must include river stage monitoring, river stage at which the plan will be activated, material and equipment to be used in performance of the contingency plan, and location, type and quantity of the stockpiled emergency material. The plan must also include the length of levee, where stockpiled material will be stored, and the method for monitoring river elevations. The Contractor must keep any levee degrade material on the project site for the duration of the construction period, protected from inclement weather, for use as emergency backfill as necessary. The Flood Contingency Plan must be submitted to the Contracting Officer for review.

1.3.33 SCR-33 Utility Provider Response Plan

Contractor must prepare and submit a Utility Response Plan to the Contracting Officer, Sacramento Area Sewer District (SASD), Sacramento Municipal Utility District (SMUD), Comcast, and the City of Sacramento.

Plan must detail how utility locations are verified, provide protocol for coordination with Utility Providers, detail process on conducting required worker training for all on-site employees with respect to accidental utility damage, and provide utility provider emergency contact information. Contractor is responsible for coordinating any temporary utility services needs during construction, and will assume all temporary utility services cost.

1.3.34 SCR-34 Stop Work Authority

The Contracting Officer and Administrative Contracting Officer have the authority to immediately stop any activity that is not in compliance with the permits, and/or order any reasonable measure to avoid the unauthorized take of an individual of the Covered Species (e.g., giant garter snake, Swainson's hawk, valley elderberry longhorn beetle, Federally- and State-listed fish).

1.3.35 SCR-35 Floodway Construction Schedule

Contractor must not perform any work within the existing floodway per the date restrictions in Time of Completion requirement herein and must not begin any construction until evaluation of upstream conditions indicate that inundation of these areas is unlikely to occur.

1.3.36 SCR-36 High Visibility Fencing, Habitat Preservation and Buffers

Contractor must provide high visibility fencing that must be placed to prevent encroachment of construction personnel and equipment into areas

DOCUMENT 00 73 05 Page 12 outside of or adjacent to the project footprint that contain sensitive habitats, including at least 20 feet from the dripline of elderberry shrubs and up to 200 feet from the edge of aquatic features that are suitable giant garter snake habitat. K-Rails, if used, must be used in areas noted on the drawings. The fencing must be inspected by the Contractor before the start of each workday and must be maintained until completion of the Project. The Contractor must not remove the fencing until construction of the Project is completed. Insecticides, herbicides, or other chemicals that might harm the valley elderberry longhorn beetle or its host plant must not be used within 100 feet of the elderberry shrubs.

1.3.37 SCR-37 General Safety Requirements

The Contractor must conform to all applicable occupational safety and health standards, rules, regulations, and orders established by the State of California or Federal Government. The Contractor must, upon request, submit to the Contracting Officer a copy of their Injury Illness Prevention Program (IIPP) (including Site Safety Plan and Code of Safe Work Practices) for review. The Contractor is required to fulfill the requirements of these programs during the prosecution of the Work, and comply with conditions set forth in the Specifications. The Contractor must comply with all regulations set forth in Consolidated EM 385-1-1 .

1.3.38 SCR-38 Storm Water Pollution Prevention Plan

Coverage under the State Water Resources Control Board (SWRCB) General Construction Permit to Discharge Water Associated with Construction Activity must be obtained by the Contractor for this Project prior to initiation of any construction activities as described in Specification 01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL. The Contractor is responsible for preparation and for paying all SWPPP fees.

1.3.39 SCR-39 Grading (Encroachment) Permit

Contractor must obtain an Encroachment Permit from City of Sacramento prior to initializing work. Copy of work permit must be submitted to the Contracting Officer prior to disturbing ground.

1.3.40 SCR-40 Staging Areas

Staging areas available to the Contractor for the project have been identified in the Drawings and permits have been obtained for them by the Government. If additional areas are available for use, they will be the responsibility of the Contractor to obtain.

1.3.41 SCR-41 Asbestos Cement Waterline Removal

Contractor to coordinate the removal of the existing 12-in asbestos cement waterline shown on drawings with SAFCA. Contractor is responsible for exposing the 12-in asbestos cement waterline and providing access for removal. SAFCA is responsible for removal of 12-in asbestos cement waterline, which will require a 2-3 week duration for removal. The asbestos cement waterline must not be stored on site for any duration of time. Contractor to coordinate all asbestos cement waterline removal activities with Contracting Officer.

DOCUMENT 00 73 05 Page 13

1.3.42 SCR-42 Recreation/Community Mitigation

A minimum of two weeks prior to start of work Contractor must provide written notification to the City of Sacramento DPW Representatives, City of Sacramento Department of Transportation, City of Sacramento Bike/Pedestrian Coordinator, City Public Information Officers, and Sacramento Regional Transit, as well as outreach to the immediate project neighbors advising of the work, duration, the days of the week work is to take place, and the hours to be worked for each day. Contractor must provide, via posted signage, a USACE project manager name, contact number and e-mail address as well as a Contractor project manager name, contact number and e-mail address, for residents in the vicinity of the Premises should any concern from the immediate project neighbors arise with regard to noise, traffic, or other such disturbance which directly results from Contractor's work. The purpose of USACE and Contractor posting their respective contact information is to avoid Construction Inspection and Survey staff having to field telephone calls and other inquiries related to Contractor's work.

1.3.43 SCR-43 City Streets

The Contractor must ensure that its construction equipment and hauling operations do not damage City streets. Prior to start of construction, Contractor must provide a Pre-Construction Video and Photograph Survey as described in Section 01 00 00 with video and photograph all city streets within the construction area and along all haul routes, including to and from borrow source. Photographs must be submitted to the Contracting Officer and the City Department of Public Works Representative, Jon Liffring, Supervising Construction Inspector, (the "DPW Representative"),

(916) 808-7124, and will be used to compare before and after project conditions at the project's end.

The Contractor must notify and submit truck routes for review to the Contracting Officer and the DPW Representative prior to starting work.

Furthermore, the Contractor must provide the City Representative with a location for a wash out area to wash and clean Contractor's trucks, equipment and tires before they exit the construction area.

At the completion of work and prior to the Contractor leaving the project, the Contractor must restore to pre-project conditions all such roads as directed by the Contracting Officer at no additional cost to the Government in accordance with the local permits obtained. Repairs will include replacement of base rock and/or surface treatment as required.

Repairs are documented with a thorough description of repair made, location, and photographs. Documentation of haul road repairs must be submitted to the Contracting Officer following repair.

1.3.44 SCR-44 City of Sacramento Mastarm Street Lights

Existing City of Sacramento Mastarm Street Lights must be removed and delivered to the City of Sacramento at the address below. Contractor must not damage street lights. Contractor to document conditions of existing street lights prior to removal. Notify the City's Operations Supervisor 48 hours prior to delivery.

Xavier Covarrubias Operations Supervisor - Signal and Lighting

(916) 808-3719 City of Sacramento North Area Corporation Yard

DOCUMENT 00 73 05 Page 14

918 Kenmar Road Sacramento, CA 95834

1.3.45 SCR-45 Storage Area

Contractor must erect chain link fencing a minimum of eight (8) feet tall around the perimeter of its storage area. The fencing must display post signs no smaller than 3' x 3' in size, with 1" tall lettering, providing the Contractor's company name as well as a name and telephone number for Contractor who may be contacted by the public in the event that any issues arise out of the use of the Premises. Contractor must report any calls received from the public to the Contracting Officer. All material remnants need to be removed from the storage site. Otherwise, a protective barrier must be placed between the ground surface and stockpiled materials. Upon completion of the work, or prior to the time that the use of the staging area must cease, whichever occurs first, Contractor must return the site to a condition equal to or better than the condition it was in at the time the of the Contractor's entry into the site.

1.3.46 SCR-46 Project Signage

The Contractor must provide all signage for the project as shown in the Contract Drawings and as specified by the Contractor's Traffic Control Plan.

Costs for such signs are to be paid under CLIN "TRAFFIC CONTROL AND

SIGNAGE".

1.3.47 SCR-47 Traffic Control Plan

In lieu of the traffic plan provided for Reach I as a part of these contract documents, the contractor may opt to submit an alternative Traffic Control Plan to USACE (SPK) and City of Sacramento for review and approval prior to commencing construction activities.

Reach H - Subreach 1 Traffic Plan was not provided as part of these contract documents. The Contractor must submit a Traffic Control Plan to USACE (SPK) and City of Sacramento for review and approval prior to commencing construction activities. At a minimum, the Traffic Control Plan must achieve the following objectives:

(1) The northern entrance to Discovery Park at Natomas Park Drive and Garden Highway must not be impacted by construction during scheduled events. During construction, the Discovery Park entrance will remain open.

(2) At least one westbound and one eastbound lane must remain open to traffic on Garden Highway between Gateway Oaks Drive and Natomas Park Drive during construction.

(3) The contractor must implement traffic control measures to ensure vehicles exiting I-5 onto Garden Highway will not impact I-5 mainline operations.

(4) The contractor must provide continuous access to adjacent properties.

(5) All signs must be placed in conformance with the current California

Manual on Uniform Traffic Control Devices or as Directed by the Contracting Officer.

1.3.48 SCR-48 Streetlights, Electrical, and Fiber Installations

The Contractor must coordinate with the City of Sacramento, follow City standards, and provide a Work Plan for the street light, electrical, and fiber installations prior to start of work.

DOCUMENT 00 73 05 Page 15

The fiber installation must be continuous between Gateway Oaks Drive and Truxel Road, and connected to all traffic signal cabinets throughout this corridor. The plans show limits of joint trench where fiber and copper (for streetlights and traffic loop detectors) must be installed.

Furthermore, the City of Sacramento requires the installation of fiber in areas beyond the joint trench. The Contractor must use existing conduits through which the fiber must be pulled, and those alignments are shown schematically on the plans.

The Contractor must submit the Electrical and Fiber Work Plan to the contracting officer for approval. At a minimum, the Work Plan must include:

a. Schedule of activities

1) Durations of outages for streetlights, traffic loop detectors, and traffic signals

2) Timing and duration of work within Caltrans R/W

b. Method of confirming limits of the fiber pull through existing conduits as shown on the plans

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

DOCUMENT 00 73 05 Page 16

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 00 00

GENERAL REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 SCRAP MATERIAL

1.4 UTILITIES

1.5 GENERAL SAFETY REQUIREMENTS

1.5.1 General

1.5.2 The Contractor's Superintendent

1.5.3 Violations

1.5.4 Fire Prevention

1.5.5 Recordkeeping/Reporting Requirements

1.5.6 Accident Reporting

1.6 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.7 PLANNED STREET CLOSURES

1.7.1 Transportation Mitigation

1.8 EQUIPMENT DATA FORM

1.9 SPECIAL CONSTRUCTION PROCEDURES

1.10 GOVERNMENT RETAINED ARCHITECT-ENGINEER (A/E)

1.11 COMMERCIAL DISPOSAL SITE

1.12 HAUL ROUTE PLAN

1.13 PROJECT SECURITY AND PUBLIC SAFETY

1.14 BID ITEM OVERRUN

1.15 NON CONTRACT WORK

1.16 WARRANTY OF CONSTRUCTION

1.17 PAYMENT

1.18 PROJECT SURVEYS

1.18.1 Survey Supervision and Scheduling

1.18.2…