Solicitation_Purchase_Order_Clauses.docx

SECTION B - CONTINUATION BLOCK

B.1 - PRICE/COST SCHEDULE

SEE Section B Continuation Block B.1 Price/Cost Schedule

B.2 - IDENTIFICATION OF GOVERNMENT OFFICIALS (AUG 2014)

The Government Officials assigned to this contract are as follows:

Administrative Contracting Officer:

Name: David Orris Phone: 301-830-3235 Email: David.Orris@fema.dhs.gov Fax:

Contracting Officer’s Representative:

Name: TBD B.3 – Invoice Approval

(i) Invoice Approval The following FEMA individual (in addition to the Contracting Officer) is hereby delegated authority to accept goods and services and to review and approve invoices for this contract:

Authorized Invoice Approver:

Name: TBD Title: COR Phone:

Email:

B.4 Billing Instructions

(iii) Billing Instructions Contractors will use Standard Form 1034 (Public Voucher for Purchases and Services Other Than Personal) located at http://www.gsa.gov/portal/forms/type/SF when submitting a payment request. A payment request means any invoice or request for contract financing payment requesting reimbursement for supplies or services rendered. The Contractor shall not be paid more frequently than on a monthly basis.

Contractors must submit vouchers electronically in pdf format to the FEMA Finance Center at FEMA-Finance-Vendor-Payments@fema.dhs.gov. A copy of the voucher must be submitted electronically to the contracting officer identified within this contract. The submission of vouchers electronically will reduce correspondence and other causes for delay to a minimum and will facilitate prompt payment to the Contractor. Paper vouchers mailed to the finance center will not be processed for payment. If the Contractor is unable to submit a payment request in electronic form, the contractor shall submit the payment request using a method mutually agreed to by the Contractor, the Contracting Officer, and the payment office.

B.5 Defective or Improper Invoices Name, title, phone number, and email of officials of the business concern who are to be notified when the Government receives an improper invoice.

Name:

Title:

Phone:

Email:

B.6 Invoice Instructions Invoices shall be submitted as follows:

Contractors will use Standard Form 1034 (Public Voucher for Purchases and Services Other Than Personal) and SF 1035 Continuation sheet when requesting payment for supplies or services rendered. The voucher must provide a description of the supplies or services, by line item (if applicable), quantity, unit price, and total amount. The item description, unit of measure, and unit price must match those specified in the contract. Invoices that do not match the line item pricing in the contract will be considered improper and will be returned to the Contractor.

SF 1034 and 1035 instructions:

SF 1034 -Fixed Price The information which a contractor is required to submit in its Standard Form 1034 is set forth as follows:

(I 0) Shipped From; To; Weight Government BIL Number - insert for supply contracts.

"I certify that all payments requested are for appropriate purposes and in accordance with the agreements set forth in the contract."

INVOICE PREPARATION INSTRUCTIONS SF 1035

The SF l 035 will be used to identify the specific item description, quantities, unit of measure, and prices for each category of deliverable item or service. Suitable self-designed forms may be submitted instead of the SF 1035 as long as they contain the information required.

The information which a contractor is required to submit in its Standard Form 1035 is set forth as follows:

U.S. Department, Bureau, or Establishment - insert the name and address of the servicing finance office. Voucher Number - insert the voucher number as shown on the Standard Form 1034.

Schedule Number - leave blank.

Sheet Number - insert the sheet number if more than one sheet is used in numerical sequence. Use as many sheets as necessary to show the information required.

Number and Date of Order - insert payee's name and address as in the Standard Form 1034. Articles or Services - insert the contract number as in the Standard Form I 034.

Amount - insert the total quantities contract value, and amount and type of fee payable (as applicable).

A summary of claimed current and cumulative goods and services delivered and accepted to date. - Invoices shall include an itemization of all goods and services delivered and accepted for the period by item and by CLIN. Each invoice shall include sufficient detail to identify goods and services as compared to and in accordance with contract terms and conditions. Invoices that do not match the line item pricing in the contract will be considered improper and returned to the contractor. In addition, each invoice shall detail the total charges: by showing current and cumulative goods and services both currently invoiced and cumulative to date.

SECTION C - Contract Clauses C.1 – 52.212-4 -- Contract Terms and Conditions -- Commercial Items (Jan 2017) by reference (see SF 1449 block 27a) C.2 – Addendum to FAR 52.212-4 In addition to the FAR 52.212-4 “Contract Terms and Conditions—Commercial Items” the following FAR, HSAR and FEMA Clauses are incorporated as an addendum to this solicitation:

FAR 52.252-2 Clauses Incorporated By Reference This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.acquisition.gov/far/index.html

C.2.1 NARA RECORDS MANAGEMENT LANGUAGE FOR CONTRACTS

The following standard items relate to records generated in executing the contract and should be included in a typical Electronic Information Systems (EIS) procurement contract:

1. Citations to pertinent laws, codes and regulations such as 44 U.S.C chapters 21, 29, 31 and 33; Freedom of Information Act (5 U.S.C. 552); Privacy Act (5 U.S.C. 552a); 36 CFR Part 1222 and Part 1228.

2. Contractor shall treat all deliverables under the contract as the property of the U.S. Government for which the Government Agency shall have unlimited rights to use, dispose of, or disclose such data contained therein as it determines to be in the public interest.

3. Contractor shall not create or maintain any records that are not specifically tied to or authorized by the contract using Government IT equipment and/or Government records.

4. Contractor shall not retain, use, sell, or disseminate copies of any deliverable that contains information covered by the Privacy Act of 1974 or that which is generally protected by the Freedom of Information Act.

5. Contractor shall not create or maintain any records containing any Government Agency records that are not specifically tied to or authorized by the contract.

6. The Government Agency owns the rights to all data/records produced as part of this contract.

7. The Government Agency owns the rights to all electronic information (electronic data, electronic information systems, electronic databases, etc.) and all supporting documentation created as part of this contract. Contractor must deliver sufficient technical documentation with all data deliverables to permit the agency to use the data.

8. Contractor agrees to comply with Federal and Agency records management policies, including those policies associated with the safeguarding of records covered by the Privacy Act of 1974. These policies include the preservation of all records created or received regardless of format (paper, electronic, etc.) or mode of transmission (e-mail, fax, etc.) or state of completion (draft, final, etc.).

9. No disposition of documents will be allowed without the prior written consent of the Contracting Officer. The Agency and its contractors are responsible for preventing the alienation or unauthorized destruction of records, including all forms of mutilation. Willful and unlawful destruction, damage or alienation of Federal records is subject to the fines and penalties imposed by 18 U.S.C. 2701. Records may not be removed from the legal custody of the Agency or destroyed without regard to the provisions of the agency records schedules.

10. Contractor is required to obtain the Contracting Officer's approval prior to engaging in any contractual relationship (sub-contractor) in support of this contract requiring the disclosure of information, documentary material and/or records generated under, or relating to, this contract. The Contractor (and any sub-contractor) is required to abide by Government and Agency guidance for protecting sensitive and proprietary information.

C.2.2 – 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS.

As prescribed in 9.108-5(b), insert the following clause:

PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (NOV 2015)

(a) Definitions. As used in this clause— “Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

(b) If the contractor reorganizes as an inverted domestic corporation or becomes a subsidiary of an inverted domestic corporation at any time during the period of performance of this contract, the Government may be prohibited from paying for Contractor activities performed after the date when it becomes an inverted domestic corporation or subsidiary. The Government may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of Government action under this clause.

(c) Exceptions to this prohibition are located at 9.108-2.

(d) In the event the Contractor becomes either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation during contract performance, the Contractor shall give written notice to the Contracting Officer within five business days from the date of the inversion event.

C.3 - 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders - Commercial Items. (JAN 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

[X] (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (SEP 2006), with Alternate I (OCT 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

[X] (2) 52.203-13, Contractor Code of Business Ethics and Conduct (OCT 2015) (41 U.S.C. 3509).

[X ] (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

[ ] (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (OCT 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note).

(5) (Reserved) [ ] (6) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

[ ] (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

[ ] (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (OCT 2015) (31 U.S.C. 6101 note).

[X] (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (JUL 2013) (41 U.S.C. 2313).

[ ] (10) (Reserved) [ ] (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a).

[ ] (ii) Alternate I (NOV 2011) of 52.219-3.

[ ] (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

[ ] (ii) Alternate I (JAN 2011) of 52.219-4.

[ ] (13) (Reserved) [ ] (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

[ ] (ii) Alternate I (NOV 2011).

[ ] (iii) Alternate II (NOV 2011).

[ ] (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (JUN 2003) (15 U.S.C. 644).

[ ] (ii) Alternate I (OCT 1995) of 52.219-7.

[ ] (iii) Alternate II (MAR 2004) of 52.219-7.

[ ] (16) 52.219-8, Utilization of Small Business Concerns (NOV 2016) (15 U.S.C. 637(d)(2) and (3)).

[ ] (17)(i) 52.219-9, Small Business Subcontracting Plan (JAN 2017) (15 U.S.C. 637(d)(4)).

[ ] (ii) Alternate I (NOV 2016) of 52.219-9.

[ ] (iii) Alternate II (NOV 2016) of 52.219-9.

[ ] (iv) Alternate III (NOV 2016) of 52.219-9.

[ ] (v) Alternate IV (NOV 2016) of 52.219-9.

[ ] (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)).

[ ] (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)).

[ ] (20) 52.219-16, Liquidated Damages-Subcontracting Plan (JAN 1999) (15 U.S.C. 637(d)(4)(F)(i)).

[ ] (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C. 657f).

[ ] (22) 52.219-28, Post Award Small Business Program Re-representation (JUL 2013) (15 U.S.C. 632(a)(2)).

[ ] (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (DEC 2015) (15 U.S.C. 637(m)).

[ ] (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (DEC 2015) (15 U.S.C. 637(m)).

[X] (25) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

[X] (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (OCT 2016) (E.O. 13126).

[X] (27) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

[X] (28) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

[X] (29) 52.222-35, Equal Opportunity for Veterans (OCT 2015) (38 U.S.C. 4212).

[X] (30) 52.222-36, Equal Opportunity for Workers with Disabilities (JUL 2014) (29 U.S.C. 793).

[X] (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

[ ] (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

[X] (33)(i) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O. 13627).

[X] (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

[ ] (34) 52.222-54, Employment Eligibility Verification (OCT 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

[ ] (35) (Removed) Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

[ ] (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016).

[ ] (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (MAY 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[ ] (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[ ](38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693).

[ ](39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

[ ] (40)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

[ ] (ii) Alternate I (OCT 2015) of 52.223-13.

[ ] (41)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

(ii) Alternate I (JUN 2014) of 52.223-14.

[ ] (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b).

[ ] (43)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

[ ](ii) Alternate I (JUN 2014) of 52.223-16.

[X] (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011) [ ] (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

[ ] (46) 52.223-21, Foams (JUN 2016) (E.O. 13693).

[ ] (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

[ ] (ii) Alternate I (JAN 2017) of 52.224-3.

[ ] (48) 52.225-1, Buy American-Supplies (MAY 2014) (41 U.S.C. chapter 83).

[ ] (49)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (MAY 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

[ ] (ii) Alternate I (MAY 2014) of 52.225-3.

[ ] (iii) Alternate II (MAY 2014) of 52.225-3.

[ ] (iv) Alternate III (MAY 2014) of 52.225-3.

[X ] (50) 52.225-5, Trade Agreements (OCT 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

[X] (51) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

[ ] (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

[ ] (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (NOV 2007) (42 U.S.C. 5150).

[ ] (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007) (42 U.S.C. 5150).

[ ] (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (FEB 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

[ ] (56) 52.232-30, Installment Payments for Commercial Items (JAN 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

[X] (57) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (JUL 2013) (31 U.S.C. 3332).

[ ] (58) 52.232-34, Payment by Electronic Funds Transfer - Other than System for Award Management (JUL 2013) (31 U.S.C. 3332).

[ ] (59) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

[ ] (60) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)).

[ ] (61) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

[ ] (62)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

[ ] (ii) Alternate I (APR 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

[ ] (1) 52.222-17, Non-displacement of Qualified Workers (MAY 2014) (E.O. 13495).

[ ] (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

[ ] (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

[ ] (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

[ ] (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

[ ] (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (MAY 2014) (41 U.S.C. chapter 67).

[ ] (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) (41 U.S.C. chapter 67).

[ ] (8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015).

[ ] (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

[ ] (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792).

[ ] (11) 52.237-11, Accepting and Dispensing of $1 Coin (SEP 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records - Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) of this paragraph in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (OCT 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (NOV 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Non-displacement of Qualified Workers (MAY 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (OCT 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (JUL 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

(xii) [X] (A) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O. 13627).

[X] (B) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (MAY 2014) (41 U.S.C. chapter 67).

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) (41 U.S.C. chapter 67).

(xv) 52.222-54, Employment Eligibility Verification (OCT 2015) (E. O. 12989).

(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015).

(xvii) (Removed) Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016)).

(xix)(A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xx) 52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor May include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

3052.212-70 CONTRACT TERMS AND CONDITIONS APPLICABLE TO DHS ACQUISITION OF COMMERCIAL ITEMS (SEP 2012) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The provision or clause in effect based on the applicable regulation cited on the date the solicitation is issued applies unless otherwise stated herein. The following provisions and clauses are incorporated by reference: http://farsite.hill.af.mil/VFHSARA.HTM

(a) Provisions.

_____3052.209-72 Organizational Conflicts of Interest.

_____3052.216-70 Evaluation of Offers Subject to An Economic Price Adjustment Clause.

_____3052.219-72 Evaluation of Prime Contractor Participation in the DHS Mentor Protege Program.

(b) Clauses.

_____3052.203-70 Instructions for Contractor Disclosure of Violations.

_____3052.204-70 Security Requirements for Unclassified Information Technology Resources.

_____3052.204-71 Contractor Employee Access.

_____Alternate I __X__3052.205-70 Advertisement, Publicizing Awards, and Releases.

_____3052.209-73 Limitation on Future Contracting.

_____3052.215-70 Key Personnel or Facilities.

_____3052.216-71 Determination of Award Fee.

_____3052.216-72 Performance Evaluation Plan.

_____3052.216-73 Distribution of Award Fee.

_____3052.217-91 Performance. (USCG) _____3052.217-92 Inspection and Manner of Doing Work. (USCG) _____3052.217-93 Subcontracts. (USCG) _____3052.217-94 Lay Days. (USCG) _____3052.217-95 Liability and Insurance. (USCG) _____3052.217-96 Title. (USCG) _____3052.217-97 Discharge of Liens. (USCG) _____3052.217-98 Delays. (USCG) _____3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair. (USCG) _____3052.217-100 Guarantee. (USCG) _____3052.219-70 Small Business Subcontracting Plan Reporting.

_____3052.219-71 DHS Mentor Protege Program.

_____3052.228-70 Insurance.

_____3052.228-90 Notification of Miller Act Payment Bond Protection. (USCG) _____3052.228-91 Loss of or Damage to Leased Aircraft. (USCG) _____3052.228-92 Fair Market Value of Aircraft. (USCG) _____3052.228-93 Risk and Indemnities. (USCG) _____3052.236-70 Special Provisions for Work at Operating Airports.

___X_3052.242-72 Contracting Officer's Technical Representative.

_____3052.247-70 F.o.B. Origin Information.

_____Alternate I _____Alternate II _____3052.247-71 F.o.B. Origin Only.

__X__3052.247-72 F.o.B. Destination Only.

FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): http://www.acquisition.gov/far/index.html

E.4 - 52.212-3 Offeror Representations and Certifications-Commercial Items. (JAN 2017) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision- Administrative merits determination means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Arbitral award or decision means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Civil judgment means-

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

DOL Guidance means the Department of Labor (DOL) Guidance entitled: "Guidance for Executive Order 13673, 'Fair Pay and Safe Workplaces'". The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

Enforcement agency means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-

(1) Department of Labor Wage and Hour Division (WHD) for-

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for-

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for-

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for-

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

Forced or indentured child labor means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

Inverted domestic corporation means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

Labor compliance agreement means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

Labor laws means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

Labor law decision means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of "labor laws".

Manufactured end product means any end product in product and service codes (PSCs) 1000-9999, except-

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

Place of manufacture means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Restricted business operations means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate-

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology-

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically-

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

Service-disabled veteran-owned small business concern-

(1) Means a small business concern-

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that-

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Subsidiary means an entity in which more than 50 percent of the entity is owned-

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term "successor" does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

Veteran-owned small business concern means a small business concern-

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned business concern means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

Women-owned small business concern means a small business concern-

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: "Administrative merits determination", "Arbitral award or decision", paragraph (2) of "Civil judgment", "DOL Guidance", "Enforcement agency", "Labor compliance agreement", "Labor laws", and "Labor law decision". The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code…