Sol_6991PE17Q00015.docx

2 - Section 2 Clauses 52.209-2 Prohibition on Contracting With Inverted Domestic Corporations-Representation. (NOV 2015) 52.212-4 Contract Terms and Conditions - Commercial Items. (JAN 2017) 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders - Commercial Items. (JAN 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

(1) 52.203-6, Restrictions on Subcontractor Sales to the Government (SEP 2006), with Alternate I (OCT 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

[] (2) 52.203-13, Contractor Code of Business Ethics and Conduct (OCT 2015) (41 U.S.C. 3509).

[] (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

X] (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (OCT 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note).

(5) (Reserved)

(6) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

[] (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111-117, section 743 of Div. C).

X(8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (OCT 2015) (31 U.S.C. 6101 note).

[] (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (JUL 2013) (41 U.S.C. 2313).

[] (10) (Reserved) [] (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a).

[] (ii) Alternate I (NOV 2011) of 52.219-3.

[] (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

[] (ii) Alternate I (JAN 2011) of 52.219-4.

[] (13) (Reserved) X (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644).

[] (ii) Alternate I (NOV 2011).

[] (iii) Alternate II (NOV 2011).

[] (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (JUN 2003) (15 U.S.C. 644).

[] (ii) Alternate I (OCT 1995) of 52.219-7.

[] (iii) Alternate II (MAR 2004) of 52.219-7.

[] (16) 52.219-8, Utilization of Small Business Concerns (NOV 2016) (15 U.S.C. 637(d)(2) and (3)).

[] (17)(i) 52.219-9, Small Business Subcontracting Plan (JAN 2017) (15 U.S.C. 637(d)(4)).

[] (ii) Alternate I (NOV 2016) of 52.219-9.

[] (iii) Alternate II (NOV 2016) of 52.219-9.

[] (iv) Alternate III (NOV 2016) of 52.219-9.

[] (v) Alternate IV (NOV 2016) of 52.219-9.

[] (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)).

[] (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)).

[] (20) 52.219-16, Liquidated Damages-Subcontracting Plan (JAN 1999) (15 U.S.C. 637(d)(4)(F)(i)).

[] (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C. 657f).

X (22) 52.219-28, Post Award Small Business Program Rerepresentation (JUL 2013) (15 U.S.C. 632(a)(2)).

[] (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (DEC 2015) (15 U.S.C. 637(m)).

[] (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (DEC 2015) (15 U.S.C. 637(m)).

X (25) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

X] (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (OCT 2016) (E.O. 13126).

X] (27) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

X (28) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

x(29) 52.222-35, Equal Opportunity for Veterans (OCT 2015) (38 U.S.C. 4212).

X (30) 52.222-36, Equal Opportunity for Workers with Disabilities (JUL 2014) (29 U.S.C. 793).

X (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

X (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

X (33)(i) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O. 13627).

[] (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

[] (34) 52.222-54, Employment Eligibility Verification (OCT 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

[] (35) (Removed) Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

[] (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016).

[] (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (MAY 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[] (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[](38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693).

[](39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

[] (40)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

[] (ii) Alternate I (OCT 2015) of 52.223-13.

[] (41)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

(ii) Alternate I (JUN 2014) of 52.223-14.

[] (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b).

[] (43)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

[](ii) Alternate I (JUN 2014) of 52.223-16.

X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011) [] (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

[] (46) 52.223-21, Foams (JUN 2016) (E.O. 13693).

[] (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

[] (ii) Alternate I (JAN 2017) of 52.224-3.

[] (48) 52.225-1, Buy American-Supplies (MAY 2014) (41 U.S.C. chapter 83).

[] (49)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (MAY 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

[] (ii) Alternate I (MAY 2014) of 52.225-3.

[] (iii) Alternate II (MAY 2014) of 52.225-3.

[] (iv) Alternate III (MAY 2014) of 52.225-3.

[] (50) 52.225-5, Trade Agreements (OCT 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

X(51) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

[] (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

[] (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (NOV 2007) (42 U.S.C. 5150).

[] (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (NOV 2007) (42 U.S.C. 5150).

[] (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (FEB 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

[] (56) 52.232-30, Installment Payments for Commercial Items (JAN 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X (57) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (JUL 2013) (31 U.S.C. 3332).

[] (58) 52.232-34, Payment by Electronic Funds Transfer - Other than System for Award Management (JUL 2013) (31 U.S.C. 3332).

[] (59) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

[] (60) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(12)).

[] (61) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

[] (62)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

[] (ii) Alternate I (APR 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.)

[] (1) 52.222-17, Nondisplacement of Qualified Workers (MAY 2014) (E.O. 13495).

X (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

X (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

This Statement is for Information Only:

[] (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

X (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

[] (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (MAY 2014) (41 U.S.C. chapter 67).

[] (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) (41 U.S.C. chapter 67).

X (8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015).

X (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

[] (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792).

[] (11) 52.237-11, Accepting and Dispensing of $1 Coin (SEP 2008) (31 U.S.C. 5112(p)(1)).

(d) 1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (d)(1) of this paragraph in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (OCT 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (NOV 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (MAY 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(vi) 52.222-26, Equal Opportunity (SEP 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (OCT 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (JUL 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67).

(xii) [] (A) 52.222-50, Combating Trafficking in Persons (MAR 2015) (22 U.S.C. chapter 78 and E.O. 13627).

[] (B) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (MAY 2014) (41 U.S.C. chapter 67).

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (MAY 2014) (41 U.S.C. chapter 67).

(xv) 52.222-54, Employment Eligibility Verification (OCT 2015) (E. O. 12989).

(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015).

(xvii) (Removed) Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016)).

(xix)(A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xx) 52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xxi) 52.225-26, Contractors PerformingPrivate Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor May include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause) 52.252-2 Clauses Incorporated by Reference. (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

33TUhttps://www.acquisition.gov/?q=/browse/far/52U33T

(End of clause)

The Contractor may submit invoices in either electronic or paper format. Electronic submission is preferred.

(1) Electronic invoices shall be addressed to MARADInvoices@faa.gov. Electronic invoices shall conform to the following criteria, or be subject to rejection:

a. Invoice and supporting documentation shall be in Adobe Acrobat (pdf) format.

b. The e-mail subject shall include the contract/purchase order number and invoice number.

c. The transmitting e-mail shall include the following information: Name of the Contractor; Invoice date and number; Invoice amount; Contract number and, if applicable, the order or modification number; Terms of any discount for prompt payment offered; Payment instructions (i.e., financial institution, ABA routing #, account #)

(2) Paper invoices shall be submitted to one of the following addresses. Multiple copies are not required.

MARAD A/P Invoices Branch

AMZ-160

PO Box 25710 Oklahoma City, OK 73125

If a street address is required for delivery (i.e., Federal Express), the following address may be used in lieu of the post office box:

MARAD A/P Invoices Branch

AMZ-160

6500 S MacArthur Blvd.

Oklahoma City, OK 73125 MCL.H-2 Supplemental Work Requests

(a) In the complex world of ship repairs, supplemental work often emerges as a result of test, inspection, or discovery of unknown or otherwise differing conditions. The extent and nature of such supplemental work can neither be identified in bid or proposal specifications, and both parties recognize the possibility that such work may arise. Notwithstanding the possibility of the identification of such work, MARAD does not guarantee the award of any supplemental work during contract performance.

(b) Although MARAD shall be under no obligation to award supplemental work during contract performance, MARAD has provided an estimate for labor (in labor hours) and material (in dollars) for such work in the Schedule (Section B of the solicitation under applicable supplemental work contract line item numbers (CLIN or CLINs)). The offeror shall specify an hourly composite billing rate in its bid or proposal for supplemental work labor. The composite labor-billing rate shall be the rate applicable to labor for all supplemental work that MARAD orders under the applicable supplemental CLIN of the resulting contract. Any supplies or subcontracts required to complete supplemental work will be charged as a direct cost reimbursable under the applicable supplemental work CLIN; additional indirect charges for materials and subcontracts will not be allowed.

(c) During the performance of the contract, when conditions indicate a need for supplemental work, the Contracting Officer's Representative (COR) is empowered to provide technical direction, negotiate the amount of labor and material, and authorize the contractor to perform supplemental work through the issuance of a written authorization. The COR will issue authorizations for supplemental work in accordance with the following:

(1) When conditions make supplemental work appropriate, the COR shall submit to the contractor a supplemental work request that identifies the work to be accomplished.

(2) The Contractor shall promptly review each supplemental work request upon receipt and shall, within seventy-two (72) hours of issuance, or sooner, as specified by the COR, provide the COR with a proposed price for the supplemental work. Price proposals for all supplemental work must be broken down by labor hours, materials, and subcontracts and allocated to the applicable supplemental work CLIN as appropriate. The contractor shall price the supplemental work to be performed in accordance with the composite labor rate bid or proposed under the supplemental work CLIN in the contract. If necessary, the Contractor shall submit prices for subcontractors, which will be negotiated and treated as direct materials. Once the COR and contractor agree on the technical direction and price to accomplish the supplemental work, the contractor and COR shall sign the authorization for supplemental work, which shall be final and binding on the contractor and MARAD. Subject to paragraphs (c.)(3.) through (c.)(6.), if urgent circumstances do not permit waiting for a written authorization, the parties may orally agree and follow up with written confirmation.

(3) Notwithstanding the preceding, the COR shall not authorize and the contractor shall not accept individual supplemental work authorizations from the COR in excess of the price ceiling established by the Contracting Officer pursuant to paragraph (d.)(10.). In addition, the COR shall not authorize and the contractor shall not accept a supplemental work authorization from the COR that, when combined with all previously authorized supplemental work under the contract, exceeds the amount of labor hours and materials specified in the applicable supplemental work CLINs.

(4) If the contractor requests an adjustment to the contract completion date in its proposal for the supplemental work, the COR must refer the issue to the Contracting Officer for resolution, which could include modifying the performance period of the contract. All supplemental work must be accomplished within the contract performance period. The COR shall not authorize and the contractor shall not accept supplemental work authorizations from the COR that cannot be completed within the contract performance period.

(5) If the COR and contractor cannot agree upon the price, the time required, or any other term of a supplemental work request, the matter shall be referred to the Contracting Officer who may resolve the issue in accordance with the procedures contained in the Changes clause incorporated in the contract. Specifically, the Contracting Officer shall have the option of (i) directing that the Contractor perform the work at a price and within a time period determined by the Contracting Officer to be reasonable, or (ii) withdrawing said supplemental work request. The Contractor's refusal to perform the work as directed by the Contracting Officer shall constitute an event of default under the default clauses of the contract. Disputed issues resulting from supplemental work unilaterally directed by the Contracting Officer may be handled under the disputes clause of the contract.

(6) If the Contracting Officer directs the Contractor to perform the work at a price and within a time period determined by the Contracting Officer to be reasonable, the Contractor shall maintain and submit to MARAD on a daily basis, report sheets itemizing materials used, the costs and man hours of all labor (direct, indirect, and impact), production schedule activities affected by and/or related thereto, and charges for equipment, whether furnished by the Contractor, subcontractors or others. Material charges shall be substantiated by valid copies of materials and/or suppliers invoices. Such invoices shall be submitted with the daily report sheets or, if not available, as soon as reasonably practicable thereafter. Said daily reports shall also include an indication as to which specific schedule activity(ies) are affected by the order which are the subject of the daily report sheets. To the extent the contractor fails or refuses to submit the aforementioned daily report sheets on a daily basis, such failure or refusal shall constitute a basis for the Contracting Officer to suspend payment for work completed under the supplemental work until appropriate documentation required by the contract is provided.

(d) The following rules apply to supplemental work authorizations:

(1) The COR shall authorize supplemental-work only during the period of performance of the contract.

(2) All authorizations for supplemental work are subject to the terms and conditions of the contract and must be within the scope of the contract.

(3) If mailed, an authorization is considered "issued" when MARAD deposits the order in the mail. Authorizations may also be issued orally, or by written communications, that is hand-delivered or sent by facsimile or electronic transmission. Oral orders must be followed up by written confirmation as soon as practicable thereafter.

(4) Unless otherwise explicitly noted in the authorization for supplemental work, all authorizations for supplemental work are firm fixed price. The agreed upon price shall cover all costs including, but not limited to, direct and indirect labor and material, overhead, delay, acceleration, and disruption caused by the supplemental work. Where the parties are unable to agree that an order establishes mutually agreeable terms, the parties shall note the specific differences that are not agreed upon in the text of the proposed work authorization and refer the matter to the Contracting Officer for resolution pursuant to paragraph (c.)(5.).

(5) Unless the contractor otherwise explicitly notes in the supplemental work authorization, in consideration of the price of the order, the Contractor remises, releases, and forever discharges MARAD, its officers, agents, employees, and sureties from any and all civil claims and requests for equitable adjustment whatsoever, relating to, arising out of, or connected with said supplemental work authorization. Such release is full and final settlement of all claims and requests for equitable adjustment relating to, arising out of, or connected with the work authorization, as modified, including, but not limited to, all impact claims such as delay, acceleration, disruption, and cumulative effects of the instant and all previously issued supplemental work authorizations. The executed work authorization constitutes a complete and final adjustment of the price and the delivery schedule.

(6) When MARAD requires supplies or services covered by the contract in an amount less than the total value of the contract, MARAD is not obligated to award supplemental work for the balance of the price bid or proposed for supplemental work. The Contractor is not obligated to honor additional supplemental work in excess of the estimated labor hours identified in the Schedule. This subparagraph does not affect or change the Contracting Officer's authority under the changes clause of the contract.

(7) Except for limitations of labor hours estimated in the Schedule, there is no limit to the number of supplemental work authorizations that may be issued. MARAD may issue supplemental work authorizations requiring delivery or performance in multiple locations, if the contract contemplates multiple locations.

(8) In the event a supplemental work authorization covers a series of related procedures, the Contracting Officer may request the Contractor to furnish separate prices for each item of the work.

(9) If not otherwise provided, the Contracting Officer may request at any time during performance of supplemental work a list of subcontractors performing work covered by the supplemental work, the dollar value of the respective subcontracts, and a description of the subcontracted work and the contractor shall promptly provide the requested information.

(10)The COR shall not issue and the contractor shall not accept supplemental work authorizations from the COR that exceeds (Contracting Officer fills in amount up to $5000.)

MCL.H-3 Indemnity and Insurance The Contractor shall indemnify and save and keep harmless the Government against any or all loss, cost, damage, claim, expense or liability whatsoever because of accident or injury to persons or property of others occurring in connection with the operations under this contract. The Contractor shall secure, pay the premiums for and keep in force until the expiration of this contract, and any renewal thereof, adequate insurance. Such insurance to specifically include liability assumed by the Contractor under this contract.

Each policy of insurance shall contain an endorsement that any cancellation or material change in the coverage adversely affecting the Government's interest shall not be effective unless the insurer or the Contractor gives written notice of cancellation or change as required to the Contracting Officer. When the coverage is provided by self-insurance, the Contractor shall not change or decrease the coverage without the Administrative Contracting Officer's prior approval.

A certificate of each policy of insurance shall be furnished to the Contracting Officer within ten (10) days after notice of award certifying, among other things, that the policy contains the aforesaid endorsement. The insurance companies providing the above insurance shall be satisfactory to the Government. Notices of policy changes shall be furnished to the Contracting Officer.

The contractor shall provide at the Contractor's expense, within five days of request from the MARAD contracting officer, a copy of all original insurance policies. These may be sent by mail or facsimile machine.

MCL.H-4 Indemnity and Insurance (Additional)

(a) INDEMNITY

(1) The Contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property in and about the work, and to the vessel or portion thereof upon which work is done.

(2) Except as provided elsewhere in this contract, including any guarantee clause, the MARAD assumes the risk of physical loss or damage to any part of the vessel, its machinery, equipment, stores, and other property including cargo if owned by the Government except to the extent that such loss or damage is caused by the negligence, fault, error, act or omission of the Contractor, its subcontractors, agents, or employees. The burden of proving freedom from fault shall be borne by the Contractor. Unless the loss or damage was caused by the willful misconduct of the Contractor, its executive officers, or superintendents the Contractor's liability under this Contract shall not exceed total damage to the ship or ships including total loss up to $5,000,000 per accident or occurrence per vessel, and shall not exceed in the aggregate per accident or occurrence the sum of total damage to the ship or ships including total loss up to $5,000,000 multiplied by the number of MARAD's vessels in the care, custody or control of the Contractor at the location and at the time of the accident or occurrence giving to the loss or damage.

(3) As to third parties, including, but not limited to, agents, employees or servants of the Contractor, or any subcontractor, the Contractor will defend, indemnify and hold harmless the Government, the vessel, its owners and charterers, from all claims, actions, suits, costs, demands and expense of all descriptions arising out of disease, illness, personal injury, death or property damage to any third party in any way related to or arising out of the performance of work under this contract except to the extent caused by the fault, error, act or omission, or negligence of the Government, its agencies or employees. The burden of proving fault of the Government, its agencies or employees shall be borne by the Contractor.

(4) As to loss and damage which are the responsibility of the Government, the Government shall be subrogated to any claim, demand, or course of action against third parties which exists in favor of the Contractor, and the Contractor shall, if required, execute a formal assignment or transfer of such claim, demand, or course of action, and shall aid in securing information, evidence, obtaining of witnesses, and cooperate with MARAD in all matters MARAD may deem necessary in defense of any claim, or suit or appeal from any judgment or in effecting indemnity, provided, further, that nothing contained in this paragraph shall create or give rise to any right, privilege or power in any person except the Contractor, nor shall any person (except the Contractor) be or become entitled thereby to proceed directly against the Government, its agencies or instrumentalities, or to join the Government, its agencies or instrumentalities, as a codefendant in any action against the Contractor brought to determine the Contractor's liability or for any other purpose.

(b) TYPES OF INSURANCE AND MINIMUM COVERAGE. The Contractor shall at its own expense, provide and maintain the following insurances during the entire performance of this contract.

(1) Workmen's Compensation, including Longshoremen & Harbor Worker's Act coverage - Covering all agents, servants, borrowed servants, statutory employees of Contractor for all compensation and other benefits required by applicable state and federal law or by governmental authority on account of injury, death, sickness or disease - Statutory - no minimum.

(2) Employers Liability - to cover both injury and death resulting from accident, sickness or disease - $5 million bodily injury by accident, each accident - $5 million bodily injury by disease each accident - $5 million bodily injury by disease in the aggregate.

(3) Maritime Employers Liability (Jones Act) to cover both injury and death resulting from accident, sickness or disease - $5 million for each person per occurrence and $5 million in the aggregate.

(4) Comprehensive General Liability to include coverage for (but not limited to) products and completed operations liability, property damage liability and contractual liability - $5 million combined single per occurrence limit for bodily injury and property damage and $5 million in the aggregate.

(5) Ship Repairers Legal Liability - coverage to be provided under the standard London or American Institute forms or their equivalent $5 million per vessel, per occurrence or such other amount as may be requested.

(6) Pollution - sudden and accidental liability - $5 Million per occurrence.

(c) All such insurance shall be subject to the approval of the Division of Marine Insurance and will contain thirty (30) calendar days advance notice of cancellation or of any non-renewal which is the option of the insurer, said notice to be provided to the U.S. Maritime Administration, Division of Marine Insurance MAR-710, 1200 New Jersey Avenue SE, Washington, DC 20590.

(d) FORM OF CONFIRMATION

(1) The pollution insurance may be a separate policy or part of the Comprehensive General Liability policy, but the coverage must be specifically shown on the required confirmation of insurance. Excess liability and umbrella liability policies may be used in the excess of primary policies to meet the minimum limit requirements. The United States of America shall be an additional assured in the Ship Repairs Legal Liability policy, Comprehensive General Liability Policy and Pollution Policy. Such policies shall contain a clause statement that there is no recourse against the United States of America for payment of premium. All such insurance shall be subject to the approval of the Division of Marine Insurance and must contain thirty (30) calendar days advance notice of cancellation (without disclaimer) or of any non-renewal which is the option of the insurer, said notice to be provided to the U.S. Maritime Administration, Division of Marine Insurance MAR-710, 1200 New Jersey Avenue SE, Washington, DC 20590.

(2) The Contractor shall have its insurance broker provide a detailed certificate of insurance, cover note or policy confirming the above required coverage. The confirmation shall name the Contractor and United States of America as assureds and confirm the types of coverage, policy forms, policy periods, deductibles (if any) and underwriters with their percentage of participation. The N.Y. Suable Clause or Service of Suit USA Clause must be confirmed for any Foreign underwriter placements. The policy amounts, terms and conditions, deductibles and underwriters shall at all times be satisfactory to the Maritime Administration.

(e) The contractor shall insert the substance of this clause in subcontracts under this contract that require work on a Government installation.

MCL.H-6 Standards of Employee Conduct The Contractor shall be responsible for maintaining satisfactory standards of employee competency, conduct, and integrity, and shall be responsible for taking such disciplinary action with respect to its employees as may be necessary.

MCL.H-10 Supplemental Growth Requirements The labor rate offered in Section B under the Supplemental Repair Work CL1N shall be a yardwide composite labor rate and shall include all management, supervision, overhead, G&A, handling charges, freight and profit. The yardwide composite rate offered by the Contractor shall be binding during the entire period of this Contract for all supplemental work which cannot be accurately described at this time and is not included in other CLIN specifications. The Government may order up to 50 percent more hours than are currently estimated in the CLIN at the same labor rate provided therein.

MCL.H-11 Disposition of Removed Equipment and Scrap Any ship's equipment, fuel, lube oil, supplies, stores, furniture, fixtures, salvage, scrap and other movable property, removed from the vessel shall be and become the property of the Government and any ship's equipment, fuel, supplies, lube oil, stores, furniture, fixtures, salvage, scrap and other movable property so removed shall be disposed of in such manner as the Contracting Officer may direct, provided such direction is given to the Contractor within sixty (60) days from the date of the completion of the work. During said sixty (60) calendar days period such ship's equipment, fuel, lube oil, supplies, stores, furniture, fixtures, salvage, scrap and other moveable property shall be stored and protected by the Contractor without charge to the Government. If within sixty (60) calendar days such direction is not given to the Contractor, it shall, after said sixty (60) calendar days, store and protect the same in the Contractor's facility or outside of the Contractor's facility, at the Contractor's election, for the additional period directed by the Government. Such direction shall be covered by a change order, and the increased contract price for such additional storage shall be determined as provided in the changes provisions of this contract.

MCL.H-12 Maritime Liens, No Authority to Incur

(a) The Contractor is an independent contractor and does not act as an agent for the Government, its agents, its vessels, servants, or employees.

(b) The Contractor, its agents, servants, and employees, and all persons acting by, at the direction of, or on behalf of the Contractor (including, without limitation any subcontractors) have no right, power, or authority whatsoever to create, incur, or permit to be placed or imposed (i) any lien or (ii) any right in remedy of any kind, upon or against any vessel upon which work is being performed under this Agreement or against the United States of America or its agents, vessels, servants, or employees. This contractual provision governs notwithstanding any other provision of this contract.

(c) The Contractor, on behalf of itself, its agents, servants, and employees, and all persons acting by, at the direction of, or on behalf of the Contractor (including, without limitation any subcontractors) hereby waives its right to any maritime lien as well as any right in remedy of any kind based upon a maritime lien theory, upon or against any vessel upon which work has been, is being, or will be performed under this contract or against the United States of America or its agents, servants, or employees, whether known or unknown. The foregoing clause shall not prevent the Contractor's rights to proceed on this contract under the Contract Disputes Act.

(d) The Contractor shall pay when due all costs and expenses incident to the work performed by it or for its account. Neither the Contractor, nor its agents, servants, and employees, nor persons acting by, at the direction of, or on behalf of the Contractor (including, without limitation, any subcontractors) shall have the power to incur any lien of any kind maritime or otherwise. Such entities shall not (i) create, incur, suffer, or permit to be placed or imposed upon any vessel (or portion thereof), any maritime lien or other lien or encumbrance or charge in any way arising from any act or omission or (ii) incur or allow their subcontractors to incur any debts, obligations, or charges upon the credit of the vessel or against the United States of America or its agents, servants, or employees.

(e) Although it is not intended that the Contractor shall have the power to incur such liens, the Contractor shall immediately discharge or cause to be discharged any lien or right in remedy of any kind, whether incurred by the Contractor or its subcontractors, other than in favor of the Maritime Administration, which at any time exists or arises in connection with the work done or materials furnished under this contract.

(f) If any lien or right in remedy is not immediately discharged, MARAD may discharge or cause to be discharged such lien or right in remedy at the expense of the Contractor. MARAD shall have the right to recoup or setoff such funds from any monies owing to the Contractor from any other MARAD contract or any other Government contract. Should a question exist whether there is a valid lien or right in remedy, among other rights, MARAD shall have the right to retain such funds as security without interest.

(g) From the start of work under this contract the Contractor shall cause a notice, reading as follows (or containing such other information as may be approved by MARAD), in plain type and of such size that the reading matter shall cover a space of at least 2 feet wide by 2 feet high in weather resistant paint to be placed and maintained by the gangway and shall read as follows:

"NOTICE TO SUBCONTRACTORS, MATERIALMEN, AND LABORERS

This vessel is owned by the United States of America, acting by and through the Maritime Administration. The Contractor, and all persons acting by, (prime contractor), at the direction of, or on behalf of the Contractor (including, without limitation, any subcontractors) have no right, power, or authority whatsoever to create, incur, or permit to be placed or imposed any lien or right in remedy of any kind upon any vessel upon which work is being performed under this Agreement. The Contractor, its agents, servants, and employees, have no authority, either express or implied, to pledge the credit of said vessel."

(h) At the option of MARAD, the Contracting Officer may require that as a condition either for entry upon a vessel of the MARAD by any subcontractor or in order for any subcontractor to provide necessaries to a vessel of the MARAD, that such subcontractor shall on behalf of itself, its agents, subcontractors, servants, and employees, and all persons acting by, at the direction of, or on behalf of such subcontractor waive its right to any maritime lien as well as any right in remedy of any kind based upon a maritime lien theory, upon or against any vessel upon which work has been, is being, or will be performed under this contract or against the United States of America or its agents, servants, and employees, known or unknown. The foregoing clause shall not prevent such subcontractor's right, if any, to proceed under the Contract Disputes Act.

(i) The foregoing clause shall not deprive MARAD of any of the rights or remedies which it has under the common law.

Solicitation Provisions

4 - Section 4 Clauses 52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015) 52.212-1 Instructions to Offerors - Commercial Items. (JAN 2017)

ADDENDUM FOR THIS SOLICITATION

1. Offeror shall provide documentation to be evaluated in determining Technical Acceptability to include:

0. Provide a written description of the proposed dry dock facility sufficient to establish its suitability for dry docking the ships Address current certifications for facility and material handling equipment intended to be used for this requirement.

0. Provide a Gantt chart or similar illustrating your proposed project schedule for the dry docking with start and finish dates for elements comprising your work breakdown structure. Indicate workforce numbers and classifications throughout the period of performance.

1. To permit evaluation of Relevant Past Performance, Quoter shall provide:

1. Provide a listing of regulatory dry dockings completed within the past 3 years involving vessels of similar characteristics to those of the ships . Include with the listing contact information for the owner/operator of the vessel and/or the Contracting Officer for Public Vessels.

1. Provide the names of all ships (including Port Engineer’s names and contact numbers) whose within the past three years.

1. The Contracting Officer may also use past performance information available in Government past performance databases.

1. Offeror shall include a price for each ITEM as well as a total contract price on the Standard Form 1449 (applies to base and optional items).

52.211-6 Brand Name or Equal (Aug 1999)

(a) If an item in this solicitation is identified as “brand name or equal,” the purchase description reflects the characteristics and level of quality that will satisfy the Government’s needs. The salient physical, functional, or performance characteristics that “equal” products must meet are specified in the solicitation.

(b) To be considered for award, offers of “equal” products, including “equal” products of the brand name manufacturer, must—

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by—

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate “equal” products on the basis of information furnished by the offeror or identified in the offer and reasonably available to the Contracting Officer. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

(d) Unless the offeror clearly indicates in its offer that the product being offered is an “equal” product, the offeror shall provide the brand name product referenced in the solicitation.

52.212-2 Evaluation - Commercial Items. (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

X Base on the following factors: (i) technical capability of the item offered to meet the Government requirement; (ii) price; (iii) past performance (see FAR 15.304).

Technical and past performance, when combined, are equal , in accordance with FAR 15.304, the relative importance of all other evaluation factors, when combined, when compared to price.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision) 52.212-3 Offeror Representations and Certifications-Commercial Items. (JAN 2017) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision- Administrative merits determination means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Arbitral award or decision means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

Civil judgment means-

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law.