RFO 697DCK-18-R-00353 ARSR Upgrades at GTFF.pdf

TERMINAL ACQUISITIONS 2200 S. 216TH St National Construction Team Des Moines, WA 98198

AAQ - 550

U.S. Department Terminal / Surveillance / Weather of Transportation

Federal Aviation Administration

Request for OFFER

Date: May 2, 2018

Prepared By: Dale Brown, Contracting Officer

Subject: Refurbishment of the Electrical, Mechanical, and Fire Alarm Systems at the GFAA Air Route Surveillance Radar (ARSR) Facility near Great Falls, Montana.

Requirement: The work covered under this specification includes the necessary labor, material equipment, transportation, and service for Refurbishment of the Electrical, Mechanical, and Fire Alarm Systems at the GFAA Air Route Surveillance Radar (ARSR) Facility near Great Falls, Montana according to the attached Specifications, Drawings, and Wage Determinations.

Invitees: Set-Aside for Tiered 8(a) and SDVOSB Firms

Solicitation ID: 697DCK-18-R-00353

Date: Project date is July 23 – September 23 2018

Location: GFAA ARSR Facility Lat 47.36.49N Long 111.17.25W Bootlegger Trail Great Falls, MT

Respond by: 2:00 P.M. 5.31.2018 (response by email preferred)

Respond to: Dale Brown 2200 S. 216th St.

Des Moines, WA 98198

PH: 206.231.3023

Email: dale.brown@faa.gov

Respectfully, Dale S. Brown

Dale S. Brown Contracting Officer

This request will be evaluated to determine Lowest Priced Technically Acceptable Offer It is the intention to make a single offer to the Firm which provides the lowest priced offer that meets the technical standards outlined herein.

Please submit Quotation Packages to:

Dale Brown, Contracting Officer email:dale.brown@faa.gov

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

FEDERAL AVIATION ADMINISTRATION

AAQ-500 - REGIONAL ACQUISITIONS

2200 S. 216TH STREET

DES MOINES WA 98198-6547

AAQ530ANM-AFN

Same as Box 7

Dale Brown 206-231-3023 x

05/02/2018 55

PURCHASE REQUEST NO.

697DCK-18-R-00353

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

The work covered under this specification includes the Refurbishment of the

Electrical and Mechanical Fire Alarm Systems at GFAA ARSR at Great Falls, Montana.

All contractors must have an active registration in S.A.M. in order to receive the award.

This Solicitation is a 2-Step Tiered Set-Aside for Certified 8 (a) and/or SDVOSB

Small Business Concerns.

NAICS Code: 238210 Small Business Size Standard: $15 Million.

Davis Bacon Wage Determination: MT180063 031618 M1 MT63

Estimated Project Magnitude is between $150,000.00 and $300,000.00.

Performance and Payment Bonds are required for this requirement IF the proposed price exceeds $150,000.00.

All submittals must be approved before issuance of Notice to Proceed (NTP).

Project Location: Bootlegger Trail 47.36.49N 111.17.25W Great Falls, MT

Site Visit: TBD

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

10 60 calendar days and complete it within ________________ ________________ calendar days after receiving

05/31/2018 x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

FEDERAL AVIATION ADMINISTRATION

AAQ-500 - REGIONAL ACQUISITIONS

2200 S. 216TH STREET

DES MOINES WA 98198-6547

AAQ530ANM-AFN

Dale Brown

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 55

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

697DCK-18-R-00353

(A) (B) (C) (D) (E) (F)

Period of Performance: 07/23/2018 to 09/24/2018

Section B - Supplies or Services/Prices

Section B - Schedule

B001. PRICES/COSTS: Furnish all labor, materials, equipment, transportation, insurance, notifications, licenses, permits, fees and supervision necessary for the Refurbishment of the Electrical, Mechanical, and Fire Alarm Systems at the GFAA Air Route Surveillance Radar (ARSR) near Great Falls, Montana, in accordance with the specifications, drawings, contract clauses, and wage rates.

Contract Line Item Description Quantity Total

CLIN0001 Refurbish Electrical, Mechanical, and Fire Alarm Bid Item $__________ Systems at GFAA ARSR near Great Falls, Montana

PROJECT TOTAL $___________________

OFFERS SHALL INCLUDE ALL APPLICABLE TAXES.

DAVIS BACON WAGE RATES DETERMINATION: MT180063 031618 M1 MT63.

All Contract Line Items shall encompass all costs related to (a) direct and indirect labor, fringe benefits, overhead, G&A expenses, profit, material, equipment, other direct costs, insurance, freight, handling, transportation, inspection, testing, operation and maintenance manuals, bonds, etc., (b) federal, state, and local taxes, (c) all applicable fees permits, licenses, and (d) any miscellaneous charges.

An offeror is required to provide a price for each contract line item (CLIN). Failure to comply may result in the rejection of the subject offer. A single award shall be made. There shall be no split award. In the event that the CLIN price for any line item is materially unbalanced, the entire offer may be rejected without discussion with the offeror.

In the event of any disparity between the CLIN price and the total offered price, the CLIN price shall be deemed correct, and the total offered amount shall be revised accordingly, unless available information indicates otherwise.Effective April 1, 1996, the Federal Aviation Administration (FAA) began operating under the new FAA Acquisition Management System. The l996 DOT Appropriation Act, Public Law 104-50, mandated that the FAA rewrite its acquisition regulations and granted legislative relief from certain laws. The Federal Acquisition Regulations (FAR), Federal Acquisition Streamlining Act of 1994, Small Business Act, and Competition in Contracting Act, are four of these laws.

B002. INSURANCE REQUIREMENTS: Worker’s compensation and employer’s liability.

• Employer’s liability coverage of at least $500,000.00 shall be required.

• General Liability. Bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000.00 per occurrence.

• Automobile liability coverage of at least $1,000,000.00 per person and $1,000,000.00 per occurrence for bodily injury and $1,000,000.00 per occurrence for property damage

B003. BID GUARANTEE

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the BID TOTAL price.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 14 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

B004. This Contract is being Solicited as a SPECIAL SMALL BUSINESS SET-ASIDE (Tiered Evaluation among 8a and SDVOSB firms): NAICS Code for general description of work: 238210, Electrical Contractors and Other Wiring Installation Contractors.

The ESTIMATED PRICE RANGE for this Project is BETWEEN $150,000.00 and $300,000.00 for the Work.

Clause List

SA28 COST OF PERFORMANCE AND PAYMENT BONDS

Offerors are instructed that if (1) any of the following bond clauses are present in Part II - Section I of this Request for Offers, and if (2) the sum of Contract Line Items (CLIN) in B001 above is either at or above $150,000, then they shall include their fee-quote for these bonds in the TOTAL price at B001. If either condition 1 or 2 above is not met, then offerors will not include a fee-quote for bonds.

3.4.1-4 Performance Bond Requirements 3.4.1-5 Payment Bond Requirements

(End of Clause)

SA30 SITE VISIT

There is an optional site visit on pending request at a time to be determined..

a. Meeting point.

Loction to be determined if Site Visit is requested..

b. The FAA facility escort has been instructed not to answer any questions about the project during the site visit, please do not ask them any. All questions from the site visit must be submitted in writing according to the RFO's instructions in Section B, Clause B005 Solicitation Questions (above). The FAA assumes no responsibility for any conclusions or interpretations made by the contractor based on the information received by any means other than in writing from the Contracting Officer. The FAA does not assume responsibility for any understanding reached or representation made concerning conditions, which can affect the work, by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in the contract.

c. To attend the site visit, advance notice by Email is required by May 10th 2018, at 1100 PDST to the FAA points of contact listed just below. You are required to provide your company representative's name.

POC: Jay Kamani Jay.Kamani@faa.gov (206)231-2681

(End of Clause)

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications

Scope of Work

SCOPE OF WORK

The Contractor shall furnish all labor, equipment, and materials for installation of a Transformer and associated equipment for the Air Route Surveillance Radar (ARSR) facility located in Great falls, MT. The following items are a brief summary of the project and are provided solely for the purpose of revealing the general nature of the work involved. The Contractor is responsible for accomplishing all items of work in accordance with the applicable drawings, specifications and provisions of the contract. Any additional labor, materials, equipment, and/or appurtenances not specifically detailed or specified, but required to complete the project, shall be provided by the contractor as an integral part of the scope of work specified.

Major items of contractor work: (see drawings for details).

1. Demolish the existing 45 KVA transformer which is located behind equipment room and all conductors connected to it.

2. Install new Square D (Or approved equal) 45 KVA, 480-208y/120v, 3p, 4w, 1%Z transformer on existing slab

3. Provide and install new Square D (Or approved equal) Transformer 200Amp, non-fused Disconnect switch, new TVSS at Panel ‘PF’ which is located in the UPS room.

4. Provide and install new T-8 LED Fluorescent Fixtures in the Pedestal Maintain Room and wherever T-4 (or not T-8) present. T-8 LED Fluorescent must be approved by FCC.

5. Patch and paint areas damaged/exposed during construction or equipment removal.

6. New installation materials pertaining to this project shall be certified asbestos free.

7. Create a set of Redline drawings to turn over to the RE at the end of the project.

8. All electrical work shall comply with the latest revision of FAA FAA-C-1217G, “Electrical Work, Interior.”

9. All equipment grounding shall comply with the latest revision of FAA specification FAA-STD-019F, “Lightning Protection, Grounding, Bonding and Shielding Requirements for Facilities and Electronic Equipments.”

10. Once excess of the equipment has been completed by the SSC, dispose of the old transformer.

11. Provide and Install an emergency eye wash station in the UPS room.

12. Troubleshoot and fix the EG exhaust louver damper controls.

13. Demolish existing fire alarm system in its entirety unless otherwise noted. Provide new addressable fire alarm system.

14. Connect new fire alarm control panel to the existing ERMS.

The contractor is required to furnish all labor, materials (except Government furnished), services, equipment, insurance, bonds, security notifications, licenses, permits, and fees in accordance with applicable federal, state and local regulatory requirements to complete the specified work. Any miscellaneous labor, equipment and/or materials not specifically detailed or specified, but required to complete the project, shall be provided as an integral part of the work.

SPECIFICATIONS and DRAWINGS The Authorized Contract Document Specifications and Drawings for this Project are attached to this Solicitation/Contract as "Volume IIA: Project Specifications; and Volume IIB: Project Drawings Attachment to Specifications"

Clause List

Section D - Packaging and Marking

Clause List

Section E - Inspection and Acceptance

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

Section F - Deliveries or Performance

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.11-34 F.O.B. DESTINATION (APR 1999)

Section G - Contract Administration Data

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within ____ calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

Section H - Special Contract Requirements

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2013)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

Contractors may use the following means of electronic signature technology Docusign and ESignatures by Adobe.

Section I - Contract Clauses

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.1.7-1 EXCLUSION FROM FUTURE AGENCY CONTRACTS (AUG 1997)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (AUG 1997)

3.2.2.3-33 ORDER OF PRECEDENCE (MAR 2009)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2004)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2004)

3.2.2.3-67 SPECIAL PRECAUTIONS FOR WORK AT OPERATING AIRPORTS (JUL 2004)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 1996)

3.2.5-3 GRATUITIES OR GIFTS (JAN 1999)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2010)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (APR 1996)

3.3.1-9 INTEREST (SEP 2009)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

3.3.1-15 ASSIGNMENT OF CLAIMS (APR 1996)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-31 PROGRESS PAYMENTS (NOV 2000)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(AUG 2012)

3.3.2-1 FAA COST PRINCIPLES (JAN 2016)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (APR 1996)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JUL 1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2013)

3.5-1 AUTHORIZATION AND CONSENT (JAN 2009)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JAN

2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.6.1-1 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (JAN 2010)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED, AND

SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS CONCERNS (MAR 2009)

3.6.1-4 SMALL, SMALL DISADVANTAGED, WOMEN-OWNED AND SERVICE-DISABLED VETERAN

OWNED SMALL BUSINESS SUBCONTRACTING PLAN (JUL 2017)

3.6.1-7 LIMITATIONS ON SUBCONTRACTING (APR 2016)

3.6.1-12 NOTICE OF SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS SET-ASIDE (OCT

2011)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2016)

3.6.2-1 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT-OVERTIME COMPENSATION

(JAN 2012)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-9 EQUAL OPPORTUNITY (AUG 1998)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (JAN 2011)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2010)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 1996)

3.6.2-18 DAVIS BACON ACT (APR 2017)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2017)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (APR 2017)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (APR 2017)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (APR 2017)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (AUG 1998)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2015)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2012)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (OCT 2016)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-17 EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (OCT 2016)

3.6.3-19 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (OCT 2016)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.3-25 AEROSOLS (OCT 2016)

3.6.3-26 FOAMS (OCT 2016)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JUL 2010)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.5-1 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN OWNED ECONOMIC

ENTERPRISES (MAR 2009)

3.8.2-11 CONTINUITY OF SERVICES (OCT 2008)

3.9.1-1 CONTRACT DISPUTES (OCT 2011)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.2-1 SUBCONTRACTS (FIXED-PRICE CONTRACTS) (APR 1996)

3.10.3-1 DEFINITIONS (APR 2012)

3.10.3-2 GOVERNMENT PROPERTY - BASIC CLAUSE (APR 2012)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV 1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-11 PLAIN LANGUAGE (JUL 2006)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(JAN 2018)

3.14-3 FOREIGN NATIONALS AS CONTRACTOR EMPLOYEES (OCT 2017)

3.2.2.3-41 PERFORMING WORK (JUL 2004)

The Contractor (you) must perform, using your own organization, work equivalent to at least 30 percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if you request a reduction and the CO determines that it would be to the Government's advantage to do so.

(End of clause)

3.2.2.3-44 PHYSICAL DATA (JUL 2004)

Data and information the FAA (we, us) provides or refers to below is for the Contractor's (your) information. We are not responsible for your interpretation of or conclusions based on the data or information. Further, we do not warrant construction methodology which may be included in these documents.

(a) The descriptions of physical conditions on the drawings and in the specifications are the result of site investigations by FAA engineers' site surveys.

(b) Other relevant information This is a remote, mountainous site; special care must be anticipated.

(End of clause)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014) - ALTERNATE I (JUL 2009)

(a) The Contractor (you) must construct and maintain any temporary fences, gates and other facilities needed to preserve crops, control livestock, and protect property. Before cutting a fence, you must take necessary precautions to prevent livestock from straying. You must also prevent loss of tension in or damage to adjacent portions of the fence. You must immediately replace all fencing and gates you cut, remove, damage, or destroy with new materials to the original standard. You may reuse undamaged gates.

(b) You must comply with the property owner's requests to leave gates open or closed.

(c) You must use all necessary precautions to avoid destroying surveying markers such as section corners, witness trees, property corners, mining claim markers, bench markers, triangulation stations, and the like. If you must destroy any marker, you must first notify the agency responsible for the marker, as well as the Contracting Officer's (CO) representative, and replace the markers.

(d) You must use care to prevent unnecessary damage to property in or near the work area caused by your work.

Unnecessary damage is that which you can avoid through efficient and careful performance of the work, taking into account the land rights you have. If you damage any property, you must at once notify the owner or custodian and make or arrange to make prompt and full restitution.

(e) Maps and specifications FAA (we, us) provides may not give the location of all water supply, drainage, irrigation, and other underground facilities. Before entering a tract of land for contract purposes, you must find out from the property owner (or other reasonably available source) the location of any irrigation system, domestic water system, source of water, and drainage system existing on the property, whether serving that property or other property. You must avoid damaging or obstructing these facilities or polluting water supplies.

(f) You must hold us harmless from any and all suits, actions, and claims for damages, including environmental impairment, to property arising from any of your acts or omissions, your subcontractors, or any of your employees or subcontractor employees, in any way related to the work or operations under this contract.

(g) You must indemnify and hold harmless the property owners or parties lawfully in possession against all claims or liabilities asserted by third parties, including all governmental agencies, resulting directly or indirectly from your wrongful or negligent acts or omissions.

(h) Managing and disposing of hazardous wastes and materials may expose the Contractor (you) and FAA (we) to short- and long-term liabilities. To reduce these possible liabilities you must be fully aware of the hazards and regulatory requirements associated with the hazardous materials involved in this project. You must use qualified personnel to handle and transport hazardous materials.

(i) Before commencing work, you must:

(1) Do an environmental assessment of the work the contract requires, identifying tasks which involve using, handling or transporting hazardous materials or wastes. The following work items are known to involve such substances: [Contracting Officer (CO) list items here]

(2) Submit an environmental plan identifying and dealing with each specific task involving the wastes. The plan must be specific enough to demonstrate a thorough understanding of the environmental risks and the appropriate method for dealing with them. The plan must also list the required permits and reference the regulations that govern the activities needed to deal with the materials or wastes.

(3) Meet with the CO's representatives during the preconstruction conference to discuss and to develop a mutual understanding on implementing the plan.

(4) The CO may require other tasks to be added to the plan. If the CO considers your planned methods for dealing with the risks insufficient, the CO may require you to revise the plan. Work involving hazardous materials or wastes must not start until we have approved your plan. Our review of your plan does not relieve you of liability for environmental law and regulatory compliance.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within ten (10) calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than September 23, 2018. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004) -

ALTERNATE I (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within ten (10) calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than September 23, 2018. The time allowed for completion must include final cleanup of the premises.

(d) The completion date assumes that the successful offeror will receive the notice to proceed by July 13, 2018. The CO will extend the completion date by the number of calendar days after the above date that you receive the notice to proceed, except to the extent that the delay in issuing the notice to proceed results from your failure to execute the contract and give the required performance and payment bonds to FAA within the time specified.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://www.vip.vetbiz.gov.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) change the name in the SAM database;

(B) comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.4.1-4 PERFORMANCE BOND REQUIREMENTS (JAN 2017)

(a) The contractor is required to submit a performance bond in a penal amount equal to 100 percent of the contract price, but for this contract the amount required by the Contracting Officer is [ ].

(b) The bond must be executed on specified forms, and sureties must be acceptable to the Federal Aviation Administration. Corporate sureties must appear on the list in Treasury Circular 570, and the amount of the bond may not exceed the underwriting limit stated for the surety on that list.

(c) Failure to submit an acceptable bond may be cause for termination of the contract for default.

(End of clause)

3.4.1-5 PAYMENT BOND REQUIREMENTS (JAN 2018)

(a) The contractor is required to submit a payment bond in the penal amount of [ ] within the time required by the Contracting Officer.

(b) The bond must be executed on the forms attached to this SIR, and sureties must be acceptable to the Federal Aviation Administration. Corporate sureties must appear on the list in Treasury Circular 570, and the amount of the bond may not exceed the underwriting limit stated for the surety on that list.

(c) Failure to submit an acceptable bond may be cause for termination of the contract for default.

3.6.1-16 NOTICE OF COMBINED SET-ASIDE (JAN 2017)

(a) Definitions

(1) "Combined set-aside" means a set-aside consisting of both of the following business categories: Eligible small disadvantaged business (SDB) concerns and Service-disabled veteran-owned small business concerns (SDVOSB).

(2) "Eligible small disadvantaged business (SDB) concerns. As used herein, an "Eligible SDB" concern is a small business concern expressly certified by the Small Business Administration (SBA) for participation in the SBA's 8(a) program and which meets the following criteria at the time of submission of offer.

(i) The offeror is in conformance with the 8(a) support limitation set forth in its approved business plan; and

(ii) The offeror is in conformance with the Business Activity Targets set forth in its approved business plan or any remedial action direct by the SBA.

(3) "Service-disabled veteran-owned small business concern"

(i) Means a small business concern not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and the management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(ii) "Service-disabled veteran" means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

(b) Offers are only solicited from concerns that qualify as both an eligible Small Disadvantaged Business (SDB) concern and Service Disabled Veteran-Owned Small Business (SDVOSB).

Offers that are received from concerns that do not qualify in each of the specified categories will not be considered.

(c) SDVOSB requirements For all combined set asides having SDVOSBs as one of the specified categories, a service-disabled veteran-owned small business concern agrees that in the performance of the contract, in the case of a contract for:

(1) Services (except construction), at least 50 percent of the cost of personnel for contract performance will be spent for employees of the concern or employees of other service-disabled veteran-owned small business concerns;

(2) Supplies (other than acquisition from a nonmanufacturer of the supplies), at least 50 percent of the cost of manufacturing, excluding the cost of materials, will be performed by the concern or other service-disabled veteran-owned small business concerns;

(3) General construction, at least 15 percent of the cost of the contract performance incurred for personnel will be spent on the concern's employees or the employees of other service-disabled veteran-owned small business concerns; or

(4) Construction by special trade contractors, at least 25 percent of the cost of the contract performance incurred for personnel will be spent on the concern's employees or the employees of other service-disabled veteran-owned small business concerns.

(5) A joint venture may be considered to be both an eligible SDB and a SDVOSB concern if:

(i) At least one member of the joint venture is a service-disabled veteran-owned small business concern, and makes the following representations: That it is a service-disabled veteran-owned small business concern, and that it is a small business concern under the North American Industry Classification Systems (NAICS) code assigned to the procurement;

(ii) Each other concern is small under the size standard corresponding to the NAICS code assigned to the procurement;

(iii) The joint venture is designated as a SDVOSB by the Department of Veterans Affairs;

(iv) The joint venture is certified by the SBA for participation in the SBA's 8(a) program;

(v) The joint venture meets the affiliation requirements of AMS; and

(vi) The joint venture meets the requirements of 13 CFR 125.15(b).

(6) Any service-disabled veteran-owned small business concern (nonmanufacturer) must meet the NAICS size standard requirements.to receive a benefit under this program.

(d)(1) Agreement. A manufacturer or regular dealer submitting an offer in its own name agrees to furnish, in performing the contract, only end items manufactured or produced by small business concerns in the United States or its outlying areas. However, this requirement does not apply in connection with construction or service contracts.

(2) The offeror will notify the Contracting Officer in writing immediately upon entering an agreement (either oral or written) to transfer all or part of its stock or other ownership interest to any other party.

(End of clause)

3.6.2-14 EMPLOYMENT REPORTS ON VETERANS (JAN 2011)

(a) Unless the contractor is a State or local government agency, the contractor must report at least annually, as required by the Secretary of Labor, on:

(1) The total number of employees in the contractor's workforce, by job category and hiring location, who are disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans,

(2) The total number of new employees hired during the period covered by the report, and of the total, the number of disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans;

and

(3) The maximum number and minimum number of employees of the Contractor or subcontractor at each hiring location during the period covered by the report.

(b) The above items must be reported by completing the form titled 'Federal Contractor Veterans' Employment Report VETS-100A.'

(c) Reports shall be submitted no later than September 30 of each year.

(d) The employment activity report required by paragraph (a)(2) of this clause must reflect total hires during the most recent 12-month period as of the ending date selected for the employment profile report required by paragraph (a)(1) of this clause. Contractors may select an ending date: (1) As of the end of any pay period during the period January through March 1st of the year the report is due, or (2) as of December 31, if the contractor has previous written approval from the Equal Employment Opportunity Commission to do so for purposes of submitting the Employer Information Report EEO-1 (Standard Form 100).

(e) The count of veterans reported according to paragraph (a) of this clause must be based on data known to the contractor when completing the VETS-100A. .The Contractor's knowledge of veterans status may be obtained in a variety of ways, including an invitation to applicants to self-identify (in accordance with 41 CFR 60-300.42), voluntary self-disclosure by employees, or actual knowledge of veteran status by the contractor. This paragraph does not relieve the employer of liability for a determination under 38 U.S.C. 4212.

(f) Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order of $100,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor.

(End of clause)

3.6.2-24 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (OCT 2010)

(a) Definitions.

(1) "Employer identification number," as used in this clause, means the last four digits of the Federal Social Security number used on the employer's quarterly federal tax return, U.S. Treasury Department Form 941.

(2) "Minority," as used in this clause, means

(i) Black (all persons having origins in any of the black African racial groups not of Hispanic origin);

(ii) Hispanic (all persons of Mexican, Puerto Rican, Cuban, Central or South American, or other Spanish culture or origin, regardless of race);

(iii) Asian and Pacific Islander (all persons having origins in any of the original peoples of the Far East, Southeast Asia, the Indian Subcontinent, or the Pacific Islands); and

(iv) American Indian or Alaskan Native (all persons having origins in any of the original peoples of North America and maintaining identifiable tribal affiliations through membership and participation or community identification).

(b) If the Contractor, or a subcontractor at any tier, subcontracts a portion of the work involving any construction trade, each such subcontract in excess of $10,000 shall include this clause, including the goals for minority and female participation stated herein.

(c) The goals for minority and female participation, expressed in…