697DCK-26-R-00208 - FE.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

WS-26-00608

FEDERAL AVIATION ADMINISTRATION

AAQ-500 - REGIONAL ACQUISITIONS

1701 COLUMBIA AVENUE

COLLEGE PARK GA 30337

AAQ510ATL-AFN

Rodgers Cox 617-719-2079 x

04/02/2026 41

PURCHASE REQUEST NO.

697DCK-26-R-00208

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

The Federal Aviation Administration utilizes the Acquisition Management System

(AMS)in place of the Federal Acquisition Regulations (FAR). Enclosed is a Request for Proposal for 697DCK-26-R-00208, for the San Luis Obispo (SBP) ATCT roof refurbishment project located in San Luis Obispo, CA.

IN ORDER TO DO BUSINESS WITH THE FEDERAL GOVERNMENT YOU MUST BE

REGISTERED IN THE SYSTEM FOR AWARD MANAGEMENT (SAM). SEE AMS CLAUSE 3.3.1-33 "SYSTEM

FOR AWARD MANAGEMENT" (JAN 2024).

NORTH AMERICAN INDUSTRY CLASSIFICATION SYSTEM SIZE STANDARDS (NAICS) 238160 ROOFING

CONTRACTING.

The small business size standard is: $19M The FAA is exempted from state and local taxes, this exemption however, does not pass through to the Contractor. The contractor, therefore, will be responsible for all state, local, and other applicable taxes.

Site visit will be held on April 21, 2026 at 10:00 am local time

Site visit request forms are due April 16, 2026. Email to Rodgers.l.cox@faa.gov

Questions are due NLT April 23, 2026

Proposals are due on May 4, 2026 1200 EST

Continued ...

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

30 90 calendar days and complete it within ________________ ________________ calendar days after receiving

1 1200

05/04/2026 x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

Rodgers L. Cox

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 41

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

697DCK-26-R-00208

(A) (B) (C) (D) (E) (F)

Delivery: 30 Days After Notice to Proceed

Delivery Location Code: 4699A79F

4699A79F

699A79 DOT FAA

SAN LUIS OBISPO ATCT

903 1 AIRPORT DR

SAN LUIS OBISPO CA 934010000 US

00001 Procurement to solicit a contractor to remove and replace tower cab roof.

Please contact Jose Salmeron at jose.salmeron@faa.gov and/or 424-335-5564.

Electronic & IT: 03

Period of Performance: 03/31/2026 to 06/01/2026

Section A - Solicitation/Contract Form

Section B - Supplies or Services/Prices Section B - Schedule

B.1GENERAL

Contractor shall furnish all labor, materials, services, equipment, insurance, security notifications, licenses, permits, and fees in accordance with applicable Federal, State, and local regulatory requirements to refurbish the ATCT roofing at the San Luis Obispo (SBP) Airport's Air Traffic Control Tower.

B.2 MARKUPS

Successful offeror's markup percentages (i.e. Overhead %, Profit %, Insurance %) once negotiated and awarded, will remain the consistent markup percentages used on any applicable negotiations and/or Contract Modifications during the life of the Award.

B.3 SCHEDULE OF VALUES (SOV)

After award but prior to issuance of NTP, an SOV (Schedule of Values – cost loaded schedule with milestones, used to evaluate all submitted Pay Applications) must be approved by an FAA COR/RE, and will be required to be updated with all subsequent Pay Applications/Invoices submitted during the duration of the performance of any resultant Award.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

All work must be performed in accordance with the Attachments set forth in Section J of this Solicitation.

The Subcontractor shall furnish all labor, materials, equipment, supervision and all other services required to replace the roof at ATCT at SBP. Attached drawings are for reference only. Approximate quantities ATCT Cab roof 361 sq. ft.

The scope of work includes but not limited to:

• Remove and dispose of existing roofing system from the SBP ATCT cab roof.

• Provide and install roof hatch guardrail kit with self closing gate, galvanized finish. to meet code compliance.

• Remove and replace all roof drains.

• Remove and replace roof hatch

• Remove and relocate grounding counterpoise from roof to parapet wall.

• Remove debris and trash generated from work and dispose of the debris per local and state requirements, daily.

All safety, security, and protections rules and regulation required by the federal, state and local entities shall be followed and adhered to. Any deviation from these rules may result in work stoppage by the FAA COR

Section D - Packaging and Marking

Section E - Inspection and Acceptance Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

Section F - Deliveries or Performance Clause List

3.10.1-24 NOTICE OF DELAY (MAR 2009)

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

(a) If the performance of all or any part of the work of this contract is delayed or interrupted (1) by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2) by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed:

(1) for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved, and

(2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

(End of clause)

SA13 HOLIDAYS

The following Federal holidays are observed by the Federal Aviation Administration.

New Year's Day January 1st

Martin Luther King's Birthday Third Monday in January

Presidents Day Third Monday in February

Memorial Day Last Monday in May

Juneteenth third Friday

Independence Day July 4th

Labor Day First Monday in September

Columbus Day Second Monday in October

Veterans Day November 11th

Thanksgiving Day Fourth Thursday in November

Christmas Day December 25th

SA35 FAA HOLIDAY MORATORIUM

No work shall be scheduled or take place during the week of and the weekend preceding the following holidays:

Thanksgiving, Christmas and New Year's Day. Only emergency work to restore critical services to the facility will be considered and a moratorium waiver must be submitted and approved. The moratorium period will not be counted against the contract construction duration for the project.

Maintenance Moratorium Program NAS Security and Enterprise Operations manages the Maintenance Moratorium program to ensure a stable NAS during peak travel times and special events. A maintenance moratorium may be local or national in scope. Local maintenance moratoria are used to manage NAS activities for localized events such as the Olympics, Super Bowl, air shows and political conventions. These moratoria are managed by the Service Area with Tactical Operations Programs assistance. Scheduled maintenance tasks are restricted during a moratorium period to ensure Technical Operations maintenance activities do not impact the National Airspace System (NAS). Facility restoration and certification activities continue, and other work is allowed with an approved waiver. National moratoria are imposed annually during peak holiday travel times, and when deemed necessary by senior Technical Operations management.

Maintenance moratoria are communicated to specialists via a National Maintenance Alert, which contains all of the pertinent information about an individual moratorium.

National Moratorium Events A holiday maintenance moratorium is imposed annually by Technical Operations during the peak holiday travel periods, and as such no work shall be scheduled or take place during any FAA Moratoriums. Known Moratoriums are listed as follows:

Calendar Year 2026 Memorial Day - May 21, 2026 @ 0000Z to May 26, 2026 @ 0800Z Independence Day - July 1, 2026 @ 0000Z to July 6, 2026 @ 0800Z Labor Day - September 3, 2026 @ 0000Z to September 8, 2026 @ 0800Z Thanksgiving - November 21, 2026 @ 0000Z to November 30, 2026 @ 0800Z Christmas/New Year - December 19, 2026 @ 0000Z to January 4, 2027 @ 0800Z

*Any future recurring of these listed Holiday Moratoriums can be expected to be scheduled similarly. Local Moratorium Events The dates, times, and affected facilities for local moratorium events are determined at the district level in consultation with local Air Traffic and aren't know at this time. these will have to be addressed on a case-by-case basis, if realized.

Contract Period of Performance (PoP) will be 120 calendar days after effective date of the Notice to proceed (NTP). This calendar day period of performance was calculated having already taken into account any known Moratoriums (as detailed in SA35) and/or Federal Holidays (as detailed in SA13).

As such, the awarded Prime Contractor will be responsible to take these into account on any subsequent schedule submission(s). The FAA also has taken into account 40 hour weeks, as that's the only guarantee of coverage we can validate. Any additional time may be considered, and/or granted by the FAA, but cannot be assumed in developing any schedules.

(End of Clause)

Section G - Contract Administration Data Clause List

SA14 AUTHORITY OF THE GOVERNMENT

No one other than the Contracting Officer has the authority to authorize or make changes in the terms, conditions, change the scope of work or specifications in the contract, make any commitments or otherwise obligate the Government, or authorize any changes which affect the contract price, delivery schedule, period of performance, or other terms and conditions of the contract.

Section H - Special Contract Requirements Clause List

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.2.2.3-42 DIFFERING SITE CONDITIONS (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2024)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2024)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2024)

3.2.2.3-48 OTHER CONTRACTS (JUL 2024)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (JUL 2024)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (JUL 2024)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2024)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2024)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2024)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2024)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (OCT 2024)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2024)

3.2.5-4 CONTINGENT FEES (OCT 2024)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 2025)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2024)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (OCT 2024)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2024)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.8.9-2 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JUL 2023)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.1-28 CHANGES REQUIRED BY AMS (JAN 2024)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.11-62 PREFERENCE FOR PRIVATELY OWNED U.S. FLAG COMMERCIAL VESSELS (APR

2025)

3.2.2.3-41 PERFORMING WORK (APR 2024)

The Contractor must perform, using its own organization, work equivalent to at least [Contracting Officer (CO) insert percent] percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if the Contractor requests a reduction and the CO determines that it would be to the FAA's advantage to do so.

(End of clause)

3.2.2.3-50 PROPERTY PROTECTION (JUL 2024)

(a) The Contractor must construct and maintain any temporary fences, gates and other facilities needed to preserve crops, control livestock, and protect property. Before cutting a fence, the Contractor must take necessary precautions to prevent livestock from straying. The Contractor must prevent loss of tension in or damage to adjacent portions of the fence. The Contractor must immediately replace all fencing and gates cut, removed, damaged, or destroyed with new materials to the original standard. Undamaged gates may be reused.

(b) The Contractor must comply with the property owner's requests to leave gates open or closed.

(c) The Contractor must use all necessary precautions to avoid destroying surveying markers such as section corners, witness trees, property corners, mining claim markers, bench markers, triangulation stations, and the like. If the Contractor must destroy any marker, the Contractor must first notify the agency responsible for the marker, as well as the Contracting Officer's (CO) representative, and replace the markers.

(d) The Contractor must use care to prevent unnecessary damage to property in or near the work area caused by the Contractor's work. Unnecessary damage is that which the Contractor can avoid through efficient and careful performance of the work, considering the Contractor's land rights. If the Contractor damages any property, the Contractor must at once notify the owner or custodian and make or arrange to make prompt and full restitution.

(e) Maps and specifications the FAA provides may not give the location of all water supply, drainage, irrigation, and other underground facilities. Before entering a tract of land for contract purposes, the Contractor must determine from the property owner (or other reasonably available source) the location of any irrigation system, domestic water system, source of water, and drainage system existing on the property, whether serving that property or other property. The Contractor must avoid damaging or obstructing these facilities or polluting water supplies.

(f) The Contractor must hold the FAA harmless from any and all suits, actions, and claims for damages, including environmental impairment, to property arising from any of the Contractor's acts or omissions, the Contractor's subcontractors, or any of the Contractor's employees or subcontractor employees, in any way related to the work or operations under this contract.

(g) The Contractor must indemnify and hold harmless the property owners or parties lawfully in possession against all claims or liabilities asserted by third parties, including all governmental agencies, resulting directly or indirectly from the Contractor's wrongful or negligent acts or omissions.

(End of clause)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (JUL 2024)

(a) If either the specifications or the drawings (but not both) mention tasks, the Contractor must assume that the tasks are in both. If the drawings and specifications differ, the specifications govern. If there is a discrepancy in the figures, in the drawings, or in the specifications, the Contractor must submit the matter promptly to the Contracting Officer (CO), who will promptly determine which governs, and notify the Contractor in writing. Any adjustment made by the Contractor without the CO's determination is at the Contractor's own risk and expense. As needed, the CO will provide necessary detailed drawings and other information, unless otherwise provided.

(b) Wherever in the specifications or the drawings, the FAA uses "directed," "required," "ordered," "designated," "prescribed," or similar words, they refer to the CO's requirements. Similarly, "approved," "acceptable," "satisfactory," or similar words refer to the CO's approval, unless otherwise expressly stated. The Contractor must have a complete set of plans and specifications on-site and available for the FAA's use.

(c) Where the FAA uses "as shown," "as indicated," "as detailed," or similar words, they refer to the drawings accompanying this contract, unless stated otherwise. The word "provided" means "provided and installed."

(d) Omissions from the drawings and specifications or the erroneous description of details of work which are necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve the Contractor from performing those omitted or erroneously described details of the work. The Contractor must perform them as if fully and correctly set forth and described in the drawings and specifications.

(e) The Contractor must check all drawings the FAA provides before starting work and must promptly notify the CO of any discrepancies. In general, the Contractor should follow figures marked on drawings, rather than scale measurements. In general, large-scale drawings have precedence over small-scale drawings. The Contractor must compare all drawings and verify the figures before laying out the work. If the Contractor does not verify the figures, the Contractor will be responsible for any errors that might have been avoided had it verified them.

(f) "Shop drawings" means drawings, the Contractor or any subcontractor submit to the FAA under a construction contract, showing in detail the proposed fabrication and assembly of structural elements and the installation (that is, form, fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials the Contractor provided to explain in detail specific portions of the work the contract requires.

The FAA may duplicate, use, and disclose in any manner and for any purpose shop drawings you deliver under this contract.

(g) If this contract requires material offers (for example, shop drawings, catalog cuts, certificates of conformance), the Contractor must coordinate all of its offers, and review them for accuracy, completeness, and compliance with contract requirements. The Contractor must provide evidence that it approves the submittals. If the Contractor submits materials to the FAA without this evidence, the FAA may return them and ask the Contractor to resubmit the materials. The CO will indicate whether he or she approves or disapproves the offer, and if the CO does not approve it as submitted, will indicate the reasons for rejecting it. Any work done before the CO's approval is at the Contractor's risk. The CO's approval does not relieve the Contractor from responsibility for any errors or omissions in the submittals, nor from responsibility for complying with the contract requirements, except as described under (h).

(h) If the submittals vary from the contract requirements, the Contractor must describe the variations in writing, separate from the submittal, when it submits them. Send this description, a copy of the offer, and a proposal to incorporate it into the contract directly to the CO. If the CO approves a variation, the CO must issue an appropriate contract modification, unless the variation is minor or does not involve a change in price or in time of performance.

(i) The Contractor must submit to the CO for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. The CO will keep three sets (unless otherwise indicated) of all offers and will return one set to the Contractor.

(j) The Contractor must insert this clause, with appropriate changes in the designation of the parties, in all subcontracts.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2024)

The Contractor must (a) begin work under this contract within [CO insert number] calendar days after the date the Contractor receives the notice to proceed, (b) perform the work diligently, and (c) complete the entire work ready for use not later than [CO insert date]. The time stated for completion must include final cleanup of the premises.

(End of clause)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (OCT 2024)

(a) The FAA will pay the Contractor the contract price as provided in this contract.

(b) The FAA will make financing payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer (CO), on estimates of work accomplished that meets the standards of quality established under the contract, as approved by the CO. The Contractor must furnish a breakdown of the total contract price showing the amount included therein for each principal category of the work, which must substantiate the payment amount requested in order to provide a basis for determining financing payments, in such detail as requested by the CO. In the preparation of estimates, the CO may authorize material delivered on the site and preparatory work done to be taken into consideration. Material delivered to the Contractor at locations other than the site may also be taken into consideration if --

(1) Consideration is specifically authorized by this contract; and

(2) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract.

(c) Along with each request for financing payments, the contractor must furnish the following certification, or payment will not be made:

I hereby certify, to the best of my knowledge and belief, that-

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) Payments to subcontractors and suppliers have been made from previous payments received under the contract, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of chapter 39 of Title 31, United States Code; and

(3) This request for financing payments does not include any amounts that the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and conditions of the subcontract.

(Name) (Title) (Date)

(d) If the Contractor, after making a certified request for financing payments, discovers that a portion or all of such request constitutes a payment for performance by the Contractor that fails to conform to the specifications, terms, and conditions of this contract (hereinafter referred to as the unearned amount), the Contractor must-

(1) Notify the CO of such performance deficiency;

(2) Be obligated to pay the FAA an amount (computed by the CO in the manner provided in "Interest" clause) equal to interest on the unearned amount from the date of receipt of the unearned amount until-

(i) The date the Contractor notifies the CO that the performance deficiency has been corrected; or

(ii) The date the Contractor reduces the amount of any subsequent certified request for financing payments by an amount equal to the unearned amount.

(e) If the CO finds that satisfactory progress was achieved during any period for which a progress payment is to be made, the CO will authorize payment to be made in full. However, if satisfactory progress has not been made, the CO may retain a maximum of 10 percent of the amount of the payment until satisfactory progress is achieved. When the work is substantially complete, the CO may retain from previously withheld funds and future financing payments that amount the CO considers adequate for protection of the FAA and will release to the Contractor all the remaining withheld funds. Also, on completion and acceptance of each separate building, public work, or other division of the contract, for which the price is stated separately in the contract, payment will be made for the completed work without retention of a percentage.

(f) All material and work covered by financing payments made will, at the time of payment, become the sole property of the FAA, but this will not be construed as--

(1) Relieving the Contractor from the sole responsibility for all material and work upon which payments have been made or the restoration of any damaged work; or

(2) Waiving the right of the FAA to require the fulfillment of all the terms of the contract.

(g) In making these financing payments, the FAA will, upon request, reimburse the Contractor for the amount of premiums paid for performance and payment bonds (including coinsurance and reinsurance agreements, when applicable) after the Contractor has furnished evidence of full payment to the surety. The retainage provisions in paragraph (e) above will not apply to that portion of financing payments attributable to bond premiums.

(h) The FAA will pay the amount due the Contractor under this contract after-

(1) Completion and acceptance of all work;

(2) Presentation of a properly executed voucher; and

(3) Presentation of release of all claims against the FAA arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically excepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned.

(i) Notwithstanding any provision of this contract, financing payments will not exceed 80 percent on work accomplished on undefinitized contract actions. A contract action is any action resulting in a contract, including contract modifications for additional supplies or services, but not including contract modifications that are within the scope and under the terms of the contract, such as contract modifications issued pursuant to the "Changes" clause, or funding and other administrative changes.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JAN 2024)

(a) Definitions. As used in this clause

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the Unique Identity Identifier (UEI) or the Electronic Funds Transfer indicator, into the SAM database.

"System for Award Management (SAM) database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

"Unique Entity Identifier (UEI)" (also known as the Unique Entity ID) means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

"Electronic Funds Transfer indicator" means a 4-character suffix to the Unique Entity Identifier. This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the UEI or EFT indicator that identifies the offeror's name and address exactly as stated in the offer. The UEI will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a UEI, it should contact www.sam.gov directly to obtain one.

The offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company Physical Street Address, City, State, and ZIP Code.

(4) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(5) Company Telephone Number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran- Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are certified as an SDVOSB under the Small Business Administration's Veteran Small Business Certification Program (VetCert).

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor must not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees must be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

3.3.2-1 FAA COST PRINCIPLES (OCT 2019)

(a) Federal Aviation Administration (FAA) "Contract Cost Principles" must be used for:

(1) The pricing of contracts, subcontracts, and modifications to contracts and subcontracts whenever cost analysis is performed; and

(2) The determination, negotiation, or allowance of costs when required by a contract clause.

(b) The Contracting Officer will incorporate the FAA cost principles and procedures in contracts with commercial organizations as the basis for:

(1) Determining reimbursable costs under

(i) Cost-reimbursement contracts and cost-reimbursement subcontracts under these contracts performed by commercial organizations and

(ii) The cost-reimbursement portion of time-and-materials contracts except when material is priced on a basis other than at cost;

(2) Negotiating indirect cost rates, when:

(i) FAA has division or corporate contract administration responsibilities;

(ii) Quick Close-out procedures are used; or

(iii) Indirect rate caps are negotiated in the contract.

(3) Proposing, negotiating, or determining costs under terminated contracts;

(4) Price revision of fixed-price incentive contracts;

(5) Price redetermination of price redetermination contracts; and

(6) Pricing changes and other contract modifications.

(c) When division or corporate contract administration responsibilities rest with another Government agency, the FAA will apply the cost principles of the administering agency for the determination or negotiation of indirect rates not covered by (2)(ii) or (2)(iii) above.

(d) Upon request, the Contracting Officer will provide a copy of the FAA "Contract Cost Principles."

(End of clause)

3.6.3-12 ASBESTOS - FREE CONSTRUCTION (OCT 2024)

(a) In performing this contract, the Contractor must not use asbestos or asbestos-containing building materials during construction, renovation, and/or modernization of this facility.

(b) The Contractor must provide to the Contracting Officer (CO) a signed statement by [CO insert due date of statement here related to completion of the project] indicating that no asbestos or asbestos-containing building materials were used during construction, renovation, and/or modernization of this facility. The Contractor's certification under this clause is a material requirement of the contract and the FAA may withhold payment pending submittal and receipt of an acceptable certification.

(c) The FAA retains the right to conduct sampling of contractor building materials used during construction, renovation, and/or modernization of this facility to verify that they are asbestos-free. If asbestos-containing material is found, the Contractor must bear the expense of the sampling conducted by the FAA, remove, and replace the asbestos-containing material and decontaminate the site of asbestos contamination caused by the Contractor at no additional cost to the Government. In addition, the Contractor must bear the expense of all testing (bulk sampling and air sampling conducted by the contactor and the FAA) to determine that the asbestos removal and site decontamination are satisfactorily completed. The Contractor must follow all applicable federal, state, and local asbestos regulatory requirements as well as applicable FAA Orders with respect to asbestos abatement when the Contractor is required to remove asbestos materials they have installed.

(End of clause)

3.8.9-4 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB ENTITIES (JAN 2024)

(a) Definitions. As used in this clause-

Kaspersky Lab covered article means any hardware, software, or service that-

(1) Is developed or provided by a Kaspersky Lab covered entity;

(2) Includes any hardware, software, or service developed or provided in whole or in part by a Kaspersky Lab covered entity; or

(3) Contains components using any hardware or software developed in whole or in part by a Kaspersky Lab covered entity.

Kaspersky Lab covered entity means-

(1) Kaspersky Lab;

(2) Any successor entity to Kaspersky Lab, including any change in name, e.g. "Kaspersky";

(3) Any entity that controls, is controlled by, or is under common control with Kaspersky Lab; or

(4) Any entity of which Kaspersky Lab has a majority ownership.

(b) Prohibition. Section 1634 of Division A of the National Defense Authorization Act for Fiscal Year 2018 (Pub. L. 115-91) prohibits Government use of any Kaspersky Lab covered article. The Contractor is prohibited from-

(1) Providing any Kaspersky Lab covered article that the Government will use; and

(2) Using any Kaspersky Lab covered article in the development of data or deliverables first produced in the performance of the contract.

(c) Reporting requirement.

(1) In the event the Contractor identifies a Kaspersky Lab covered article provided to the Government during contract performance, or the Contractor is notified of such by a subcontractor at any tier or any other source, the Contractor must report this in writing to the Contracting Officer. For indefinite delivery contracts, the Contractor must report this in writing to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order.

(2) The Contractor must report the following information pursuant to paragraph (c) (1) of this clause:

(i) Within 3 business days from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; brand; model number (Original Equipment Manufacturer (OEM) number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the report pursuant to paragraph (c)(1) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor must describe the efforts it undertook to prevent use or submission of a Kaspersky Lab covered article, any reasons that led to the use or submission of the Kaspersky Lab covered article, and any additional efforts that will be incorporated to prevent future use or submission of Kaspersky Lab covered articles.

(d) Subcontracts. The Contractor must insert the substance of this clause, including this paragraph (d), in all subcontracts including subcontracts for the acquisition of commercial products or commercial services.

(End of clause)

3.8.9-5 PROHIBITION ON USING BYTEDANCE COVERED APPLICATIONS INCLUDING

TIKTOK (JUL 2023)

(a) Definitions. As used in this clause-

"Covered Application" means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

"Information technology," as defined in 40 U.S.C. 11101(6)-

(1) Means any equipment, or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a Contractor under a contract with the executive agency that requires the use-

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal Contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L. 117- 328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, "No TikTok on Government Devices" Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor's employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that a waiver has been granted in accordance with AMS Guidance T3.8.9C.3.c.(2).

(c) Subcontracts. The Contractor must insert the substance of this clause, including this paragraph (c), in all subcontracts including subcontracts for the acquisition of commercial products or commercial services.

(End of clause)

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within [Enter number of days] calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

3.13-16 RECORDS MANAGEMENT (OCT 2023)

(a) Definitions.

Federal record as defined in 44 U.S.C. § 3301, means all recorded information, regardless of form or characteristics, made or received by a Federal agency under Federal law or in connection with the transaction of public business…