Amd A001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

N/A

PAGE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE NO. 5. PROJECT NO. (If applicable)

A001 04/29/2021 N/A See Box 14

6. ISSUED BY CODE N/A 7. ADMINISTERED BY (If other than Item 6) CODE N/A

Department of Transportation Federal Highway Administration 610 East Fifth Street Vancouver WA 98661-3801

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and Zip Code) 9A. AMENDMENT OF SOLICITATION NO.

X

69056721B000006

9B. DATED (SEE ITEM 11)

04/28/2021

10A. MODIFICATION OF CONTRACT/ORDER NO.

N/A

10B. DATED (SEE ITEM 13)

CODE: N/A FACILITY CODE: N/A

N/A

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

| X | The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

(__ ) is extended, ( x ) is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

N/A

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A THIS CHANGE ORDER IS ISSUED PURSUANT TO (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN

ITEM 10A.

N/A

B THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (Such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D OTHER (Specify type of modification and authority)

N/A

E. IMPORTANT: Contractor n/a is not, n/a is required to sign this document and return n/a copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

MT DAR 2021(1), Defense Access Roads FY 2021

See page 2.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15a. NAME AND TITLE OF SIGNER (Type or print) 15a. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

N/A

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

BY_________________________________________ BY N/A___________________________ N/A (Signature of person authorized to sign) (Signature of Contracting Officer)

NSN 7540-01-152-8070

PREVIOUS EDITION NOT USABLE

30-105 STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

Amendment No. A001, dated 04-29-2021 MT DAR 2021(1) Solicitation No. 69056721B000006 Defense Access Roads FY 2021

REVISIONS ARE AS FOLLOWS:

SF 1442, SOLICITATION, OFFER, AND AWARD

Pages A-3 through A-6, Revises Standard Form-1442, and Adds Pages A-5 through A-6.

CONTRACT CLAUSES

Page C-83. Revises FAR Clause 52.236-4, Physical Data (Apr 1984).

ENCLOSURES

Pages:

A-3 through A-6 C-83

- -2021

This solicitation is designed

IN STRICT ACCORDANCE WITH:

Federal Acquisition Regulations (FAR) and Transportation Acquisition

Regulations(TAR).

General Wage Decision Special Contract Requirements Standard Specifications for Construction of Roads and Bridges on Federal

Highway Projects, FP-14

A-3

Federal Highway Administration Western Federal Lands Highway Div.

610 E. 5th St.

Vancouver WA 98661

A-4

A-5

Continuation SF 1442

Block 9 FOR GENERAL INFORMATION, call 360.619.7520 from the hours of 8:00 a.m. to 4:00 p.m. local time or e-mail us at wfl.contracts@dot.gov.

FOR TECHNICAL INFORMATION (plan and specification questions only), requests for technical information about this project will only be accepted in writing.

Submit questions via fax (360.619.7932) or e-mail at wfl.plans-spec@dot.gov.

QUESTIONS/ANSWERS POSTED ONLINE. You can view questions and answers on the Contract Opportunities Website https://beta.sam.gov/ .

Insert the solicitation number in the search box Scroll to the project.

Make sure you are on the most recent view and look in the right section of the page for the most recent Q&A document.

FOR DAVIS-BACON WAGE RATE INFORMATION call the Department of Labor at 415.625.7716 (DRBA - Western Region)

FOR PHYSICAL DATA, See FAR Contract Clause 52.236-4, Physical Data, (clauses begin on page C-1) for a listing of available data. Physical Data will be posted with the solicitation on the Federal Business Opportunities website.

FOR BID RESULTS, Bid opening summary will be posted on the Contract Opportunities Website https://beta.sam.gov/ shortly after bid opening. Bid tabulations will be available on our website approximately 3 work days after the bid opening. Our website is located at: http://flh.fhwa.dot.gov/business/construction/bids/ filter by WFL Division and applicable state.

Block 11 COMPLETION DATE: Work shall be completed on or before the date specified in

FAR Clause 52.211-10, Commencement, Prosecution, and Completion of Work, subject to such extensions as may be authorized by the terms of the contract and the specifications made a part thereof. Contract Clauses begin on pages C-1.

Block 12A PERFORMANCE & PAYMENT BONDS: See FAR Clause, 52.228-15, Performance and Payment Bonds - Construction (clauses begin on page C-1) and Subsection 102.06 of the Standard Specifications for Construction of Roads and Bridges on Federal Highway Projects, FP-14, U.S. Customary Units.

Block 13B BID BOND AMOUNT: See FAR Clause 52.228-1, Bid Guarantee (clauses begin on page C-1).

ADDITIONAL INFORMATION: See Subsections 102.03 and 102.04 of Standard Specifications for Construction of Roads and Bridges on Federal Highway Projects, FP- 14, U.S. Customary Units.

Block 24 SUBMITTING INVOICES: See Subsection 109.08 of the Standard Specifications for

Construction of Roads and Bridges on Federal Highway Projects FP-14, U.S. Customary Units.

Revised by Amendment A001

A-6

Continuation SF 1442

ESTIMATED PRICE RANGE. The price range of the project work is between $4,000,000 and $7,000,000.

C-83

(e) Geotechnical data, design data, and environmental information consisting of the following, will be posted with the solicitation.

(l) DAR Grizzly Bear Sightings Log.docx

(2) mt-d202101_DAR2021(1)_G-05_Hydraulics_Memo_SIGNOFF.pdf

52.236-5 Material and Workmanship (Apr 1984)

(a) All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

(b) The Contractor shall obtain the Contracting Officer's approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer's approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor's expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

(c) All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

52.236-6 Superintendence by the Contractor (Apr 1984)

At all times during performance of this contract and until the work is completed and accepted, the

Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.

52.236-7 Permits and Responsibilities (Nov 1991)

The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State, and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor's fault or negligence. The Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the entire work, except for any completed unit of work which may have been accepted under the contract.

52.236-8 Other Contracts (Apr 1984)

The Government may undertake or award other contracts for additional work at or near the site of the work under this contract. The Contractor shall fully cooperate with the other contractors and with Government employees and shall carefully adapt scheduling and performing the work under this contract to accommodate the additional work, heeding any direction that may be provided by the Contracting

Contract Clauses Project: MT DAR 202l(l), Defense Access Roads FY 202l