47PH0622R0014 SF1442 package.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

47PH0622R0014, Standard Form Page 1

47PH0622R0014

ACQUISITION NON-PROSPECTUS

200 NW 4th St., Room 4050 Oklahoma City, OK 73102 USA

(1) Statement of Work for Dated March 29, 2022

(2) Construction Drawings for March 29, 2022

(3) Wage Determination NM20220044, April 1, 2022

7PQC

ACQUISITION MANAGEMENT DIVISION

ACQUISITION NON-PROSPECTUS

819 TAYLOR ST 12B01

FORT WORTH, TX 76102

EQ7PACS-22-0081

7PQCOK

Kevin Pollard 405-664-1765

70160

1 35/3/2022

6/9/2022

4:00 PM (CST)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

47PH0622R0014, Standard Form Page 2

Tiffany Weber

PAGE

GENERAL SERVICES ADMINISTRATION

OF

ITEM NO.

(a)

SUPPLIES OR SERVICES

(b)

QUANTITY

ORDERED

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

0001 __________

Deliverable

87102-2272 the 7th floor roof, including penthouse and atrium roofs, to necessary safety measures.

Re-coat the existing liquid-applied roof coating system at

Place of Performance: 333 LOMAS BLVD NW ALBUQUERQUE, NM contract documents. Contractor is also responsible for all

PoP: 07/11/2022 - 11/11/2022

Roof Replacement daily supervision to accomplish tasks as outlined in shall provide all materials, labor, tools, equipment and

LS

Contract Type: Firm Fixed Price

PSC: Z2AA -- REPAIR OR ALTERATION OF OFFICE BUILDINGS

extend/renew the warranty period as specified. Contractor

47PH0622R0014, Standard Form Page 3

47PH0621R0014.

Document: C201-SB LPTA/AUGUST 2021 (The Solicitation)

Construction Contract for: Pete V. Domenici Federal Courthouse Roof Recoating

The Solicitation

Table of Contents

I. General Information A. The Solicitation and Contract B. List of Solicitation Documents C. Authorized Representatives D. Pre-Proposal Conference E. Estimated Price Range F. FAR 52.228-1 Bid Guarantee G. FAR 52.236-27 Site Visit – Construction H. Receipt of Offers

II. Proposals

A. Proposal Contents B. Proposal Format C. Price Proposal D. Technical Proposal E. Other Information to be Submitted with Proposal F. Requirements of Joint Venture Offerors

III. General Provisions

A. Availability of Funds B. Requests for Clarification or Interpretation C. Notice to Small Business Firms D. Information Concerning the Disclosure of Solicitation Results E. Affirmative Procurement Program F. Notice Concerning Preparation of Proposals G. Bond Requirements H. Contractor Performance Information I. Safeguarding and Dissemination of Controlled Unclassified Information (CUI)

Building Information

IV. FAR/GSAR Solicitation Provisions A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal

Specifications, Standards and Commercial Item Descriptions, FPMR 101-29 B. FAR 52.211-3, Availability of Specifications Not Listed in the GSA Index of

Federal Specifications, Standards and Commercial Items Description C. FAR 52.216-1 Type Of Contract D. FAR 52.222-5 Construction Wage Rate Requirements-Secondary Site of Work E. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal

Employment Opportunity for Construction F. Buy American Requirements G. Buy American Exceptions H. FAR 52.233-2 Service of Protest I. FAR 52.252-1 Solicitation Provisions Incorporated by Reference J. GSAR 552.102 Incorporating Provisions and Clauses by Reference K. Additional Provisions

(i) GSAR 552.236-74, Evaluation of Options (Mar 2019)

(ii) GSAR Clause 552.236-77, Government’s Right to Exercise Options (Mar 2019)

L. Certified Cost or Pricing Data V. Instructions to Offerors and Clauses

A. FAR 52.215-1 Instructions to Offerors – Competitive Acquisition B. Security Requirements C. Additional Clauses

VI. Method Of Award A. Evaluation of Offers – Lowest Price Technically Acceptable B. Lowest Price Technically Acceptable Process C. Determination of Responsibility D. Price Reasonableness/Price Realism E. Unbalanced Price F. Total Evaluated Prices G. Non Price Factors H. Evaluation of Joint Ventures

I. General Information

I.A. The Solicitation and Contract

(1) This Solicitation is set-aside for Service-Disabled Veteran-Owned Small Businesses in accordance with FAR 19. This Solicitation sets forth requirements for proposals for a Contract to construct the Project described in the attached Agreement. Proposals conforming to the Solicitation requirements will be evaluated in accordance with the Method of Award set forth herein. The Government will award the Contract to the selected Offeror, subject to the conditions set forth herein.

(2) Neither the Solicitation nor any part of an Offeror's proposal shall be part of the Contract except to the extent expressly incorporated therein by the Contracting Officer.

(3) The Offeror's proposal submitted in response to this Solicitation shall constitute a firm offer.

No contract shall be formed unless and until the Contracting Officer has countersigned the SF 1442 submitted by an Offeror, and delivered to the Contractor a copy of the SF 1442 with original signatures together with the Agreement reflecting the Offeror's proposed prices.

I.B. List of Solicitation Documents The Solicitation Documents are comprised of:

(1) The Solicitation

(2) Offeror Representations and Certifications Form

(3) Standard Form (SF) 1442 – Solicitation Offer and Award

(4) The Agreement and Attachments to the Agreement

(5) Other Forms Required for Submission with Proposals:

Appendix 1-Bid Schedule, Appendix 2-Past Performance Questionnaire

I.C. Authorized Representatives

The following individuals are designated as the authorized GSA representatives under this Solicitation:

Authorized Representative Information:

Contracting Specialist Information

Name: Kevin Pollard

Address: 200 NW 4th Street, Oklahoma City, OK

Telephone: 405-664-1765

Email: kevin.pollard@gsa.gov

Authorized Representative Information:

Contract Officer’s Information

Name: Tiffany Weber

Address: 819 Taylor St. FT. Worth, TX

Telephone: 817-201-2798

Email: tiffany.weber@gsa.gov

I.D. Pre-Proposal Conference

A virtual pre-proposal conference will be conducted MAY 12, 2022 from 1:00-2:00 CST.

Please email Contract Spec. Kevin Pollard at kevin.pollard@gsa.gov by June 02, 2022, 4:00PM CST for the weblink to the virtual conference.

I.E. Estimated Price Range The estimated price range for the Project is between $250.000.00 and $500,000.00 .

I.F. FAR 52.228-1 Bid Guarantee (Sep 96)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds

(including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

I.G. FAR 52.236-27 Site Visit – Construction (FEB 95)

(1) The clauses at FAR 52.236-2, Differing Site Conditions, and FAR 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, Offerors are urged and expected to inspect the site where the work will be performed.

(2) Site visits will be held at the following dates and times:

Date: May 12, 2022

Time: Outside the front entrance of Pete Domenici Courthouse at.9:00 MST

(3) Pre-registration is required for all attendees to the pre-proposal Site Visit. The Site Visit shall be limited to not more than two (2) representatives from each Offeror. Offerors shall submit a Visit Authorization Request (VAR) identifying all attendees from their respective team. Participants must have a valid, Government issued picture identification, driver’s license preferred, to gain access for the pre-proposal Site Visit. Notification of the location of entry, where attendees are required to meet, and all other requirements for the Site Visit will be issued to the Offerors. Submit the VAR to the point of contact listed below.

For further information about the site visit or access requirements, please contact:

Name: Kevin Pollard Seth Sutherland, Project Manager

Address: 200 NW 4th Street, Oklahoma City, OK 421 Gold Ave, SW, Albuquerque, NM

Telephone: 405-664-1765 505-203-4628

Email: kevin.pollard@gsa.gov Seth.sutherland@gsa.gov

I.H. Receipt of Offers

(1) In order to be considered for award, offers conforming to the requirements of the Solicitation must be received at the following office no later than 4:00 pm local time on the following date and at the following address.

Date: June 09, 2022 Address: kevin.pollard@gsa.gov

Electronic Submission of Proposals Offers sent shall be deemed timely if received by the email address of the GSA Point of Contact (POC) listed herein on or before the date and time established for receipt of offers, as recorded by the Government computer system’s documentation of the exact official time of receipt, not by the time it was sent by the Offeror or received on the GSA server. It is the Offeror’s responsibility to ensure proposals are complete and submitted early enough to be received by the GSA POC before the deadline, and to confirm receipt before the deadline. Proposals or portions of proposals which

Date: June 09, 2022 are received by the GSA POC later than the time noted within will not be accepted, reviewed, or considered. NOTE: The maximum file size is 25 MB, therefore contractors/offerors need to plan accordingly. WARNING: Consistent with GAO case law on the issue of “late proposal,” GSA will strictly comply with and enforce FAR 52.215-1. Under FAR 52.215-1, an electronically submitted proposal that is received late will not be considered unless “(1) it is received before award is made, (2) the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition and (3) it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals.” FAR 52.215-1 (c)(3)(ii)(A).

II. Proposals

II.A. Proposal Contents

Proposals shall consist of the following documents, completed and executed in accordance with this Solicitation:

1. Price Proposal

2. Technical Proposal

3. Representations and Certifications

4. Standard Form 24, Bid Bond

5. GSA Form 527 – Contractor’s Qualification and Financial Information

6. Other Documents as Required: Appendix 1-Bid Schedule, Appendix 2-Past

Performance Questionnaire II.B. Proposal Format

II.C. Price Proposal

(1) Contents

The Price Proposal shall consist of the SF 1442, Bid Schedule with Summary/Division Breakdown and the Agreement, with prices and/or rates indicated for each price element shown on the pricing form included in Section II of the Agreement. Indicate the Base Contract Price, or if no such distinction is made, the Contract Price, in Block 17 of the SF 1442, which must be fully executed by the Offeror.

(2) Qualifications, Exclusions and Conditions

If the Offeror communicates in its proposal any qualifications, exclusions, or conditions to the proposed prices not provided for in the Contract Documents, the Contracting Officer may reject the proposal and exclude the Offeror from further discussions.

(3) Additional Proposal Requirements

N/A.

II.D. Technical Proposal

The Technical Proposal shall include the information requested below for the non-price factors described in Section VI.

Technical proposal shall consist of:

Offerors are required to submit proposals as described herein the Electronic Submission of Proposals. Each part must be emailed in PDF format.

Electronic Submission of Proposals Offers sent shall be deemed timely if received by the email address of the GSA Point of Contact (POC) listed herein on or before the date and time established for receipt of offers, as recorded by the Government computer systems documentation of the exact official time of receipt, not by the time it was sent by the Offeror or received on the GSA server. It is the Offerors responsibility to ensure proposals are complete and submitted early enough to be received by the GSA POC before the deadline, and to confirm receipt before the deadline.

Proposals or portions of proposals which are received by the GSA POC later than the time noted within will not be accepted, reviewed, or considered.

NOTE: The maximum file size is 25 MB, therefore contractors/offerors need to plan accordingly.

WARNING: Consistent with GAO case law on the issue of late proposal, GSA will strictly comply with and enforce FAR 52.215-1. Under FAR 52.215-1, an electronically submitted proposal that is received late will not be considered unless (1)it is received before award is made, (2) the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition and (3) it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m.one working day prior to the date specified for receipt of proposals. FAR 52.215-1 (c)(3)(ii)(A).

A.) Management Plan (not to exceed 5 pages) Organizational structure - A brief presentation of the Offerors organization and key project partners including the Major Subcontractor for the project. Narrative is project specific and demonstrates the contractor possesses a clear and logical understanding of the GSA Scope of Work. Management plan shall include a Safety Plan and Quality Control Plan.

B.) Project Schedule indicates a clear understanding of work staging. Schedule provides a clear understanding of the work component as presented in the Project Narrative and in the sequence the work must be performed in.

1. Schedule uses Critical Path Method Scheduling

2. Project indicates Start and Finish Milestones.

3. Work Packages are represented in a Gantt Chart format

C.) Qualifications

1. Past Experience- Provide verification that contractor has the experience to perform a project of this magnitude. Provide information on two (2) projects of similar size and scope performed within the last five (5) years. Similar size and scope means roofing projects involving multi-story buildings and historical buildings within project cost range of 250K-1M.

Experience can include experience from major a subcontractor.

Contractor must provide reference contact information for each project submitted.

2. Key Personnel-Provide Resumes for: Project Manager, Superintendent, On Site Lead for Roof Contractor. Roofing contractor shall demonstrate a minimum 5 years of experience applicable to this project.

D.) Past Performance-The Offeror must submit a PBS Past Performance Questionnaire (PPQ) (included in the solicitation as Appendix 2, completed by the applicable client, for each project included in its proposal for Factor 3, Qualifications. Completed PPQs should be submitted with the proposal. Ensure correct phone numbers and email addresses are provided for the client point of contact. Offerors should follow-up with clients/references to ensure timely submittal of questionnaires. If the Offeror is unable to obtain a completed PPQ from a client for a project before proposal closing date, the Offeror should complete and submit with the proposal the first page of the PPQ, which will provide contract and client information for the project. If the client requests, the client may submit a questionnaire directly to the Government's point of contact, via email at kevin.pollard@gsa.gov prior to proposal closing date. Offerors may resubmit questionnaires previously submitted with other proposals or may obtain an updated/new PPQ from a client for any submission. Offerors shall not incorporate by reference into their proposal PPQs previously submitted for other RFPs.

II.E. Other Information to Submit with Proposal

(1) Representations and Certifications

Offerors are reminded their SAM registration status must be “Active”, at the time their offer is submitted, to be considered for award (see 52.204-7). Offerors submitting a proposal in response to this Solicitation shall complete electronic Annual Representations and Certifications in conjunction with required Entity registration in System for Award Management (SAM), accessed via System for Award Management. Offerors shall also submit with their proposal, the Annual Representations and Certifications (FAR 52.204-8), using the attached Offeror’s Representations and Certifications (C301-SAT).

(2) Qualifications of Offerors

Offerors submitting a proposal in response to this Solicitation shall submit with their proposal evidence of their financial responsibility and capacity to perform the Contract. Offerors shall submit this information on GSA Form 527 – Contractor’s Qualifications and Financial Information. Where applicable, point of contact, including names and telephone numbers, are required for all contracts listed.

II.F. Requirements of Joint Venture Offerors[

(1) All offers submitted by joint ventures must include a copy of an executed joint venture agreement (with original signatures) which fully discloses the legal identity of each member of the joint venture, the relationship between the members, the form of ownership of each member, and any limitations on liability or authority for each member.

(2) An authorized representative of each member of the joint venture must sign the SF 1442 accompanying an offer regardless of any agency relationship established between the members.

(3) In the case of corporations that are joint venture members, the corporation secretary must certify that the corporation is authorized to participate in the joint venture, either by so certifying in the joint venture agreement, or by submitting a separate certification to the Government. The joint venture must also provide a certificate that identifies a principal representative of the joint venture with full authority to bind the joint venture.

(4) Representations and certifications, financial information, and past performance information must be submitted for each member of the joint venture.

III. General Provisions

III.A. Availability of Funds

Issuance of this Solicitation does not warrant that funds are presently available for award of a Contract. Award of the contract shall be subject to the availability of appropriated funds, and the Government shall incur no obligation under this Solicitation in advance of such time as funds are made available to the Contracting Officer for the purpose of contract award.

III.B. Requests for Clarification or Interpretation

The Government will attempt to answer all requests for clarifications or interpretations of the Solicitation Documents prior to the date set for receipt of offers, but do not warrant that all such requests will be answered within 15 calendar days. Prospective Offerors should make such requests not less than 15 calendar days prior to the date set for receipt of offers.

III.C. Notice to Small Business Firms

A program for the purpose of assisting qualified small business concerns in obtaining certain bid, payment, or performance bonds that are otherwise not obtainable is available through the Small Business Administration (SBA) (Small Business Administration). For information concerning SBA's surety bond guarantee assistance, contact your SBA District Office.

III.D. Information Concerning the Disclosure of Solicitation Results

This acquisition is being conducted under the provisions of FAR Part 15 as a negotiated procurement. In accordance with FAR 3.104 and FAR 15.207, after receipt of proposals, no information regarding the identity of those submitting offers, the number of offers received, or the information contained in such offers will be made available until after award except as provided by FAR 15.503.

III.E. Affirmative Procurement Program

GSA has implemented an Affirmative Procurement Program (APP) intended to maximize the use of recovered materials, environmentally preferable, and bio-based products. Offerors should familiarize themselves with the requirements for using and reporting on the use of such materials in performance as set forth in the Agreement. Refer to Clause FAR 52.223-10 encouraging vendors to practice waste reduction.

III.F. Notice Concerning Preparation of Proposals

Offerors are cautioned to carefully read the entire Solicitation and the Agreement to be included in the Contract contemplated by the Solicitation in order to be fully aware of all requirements and clauses in the contemplated Contract. Verify that all blanks requiring information to be supplied in an Offer have been properly filled out, that all pricing and other numerical data is accurately calculated, and that all copies of the Offer contain the same information.

III.G. Bond Requirements

If a bid guarantee is required to be submitted with your offer, any contract awarded will require a performance bond and payment bond as specified in the Agreement. Offerors who utilize individual sureties should note the requirement for a certified, audited, financial statement for each person acting as an individual surety under clause FAR 52.228-1 Bid Guarantee and the requirements of clause FAR 52.228-11 Pledge of Assets.

III.H. Contractor Performance Information

(1) Evaluating Contractor Performance: The General Services Administration is using the Contractor Performance Assessment Reporting System (CPARS) module as the secure, confidential, information management tool to facilitate the performance evaluation process.

CPARS enables a comprehensive evaluation by capturing comments from both GSA and the contractor. The website for CPARS is Contractor Performance Assessment Completed CPARS evaluations may then be used by Federal acquisition community for use in making source selection decisions. CPARS assists acquisition officials by serving as the single source for contractor past performance data.

(2) CPARS Registration: Each award requiring an evaluation must be registered in CPARS.

The contractor will receive several automated emails. Within thirty days of award, the contractor will receive an e-mail that contains user account information, as well as the applicable contract and order number(s) assigned. Contractors will be granted one user account to access all evaluations.

(3) Contractor CPARS Training: Contractors may sign up for CPARS training. A schedule of classes will be posted to the CPARS training site (CPARS Training) and updated as needed.

(4) Contractor Representative (CR) Role: All evaluations will be sent the Contractor Representative (CR) named on your award. The CR will be able to access CPARS to review and comment on the evaluation. If your CR is not already in the CPARS system, the contracting officer will request the name and email address of the person that will be responsible for the CR role on your award.

Once an evaluation is ready to be released the CR will receive an email alerting them the evaluation is ready for their review and comment. The email will indicate the time frame the CR has to respond to the evaluation; however, the CR may return the evaluation earlier than this date.

GSA shall provide for review at a level above the contracting officer (i.e., contracting director) to consider any disagreement between GSA and the contractor regarding GSA’s evaluation of the contractor. Based on the review, the individual at a level above the contracting officer will issue the ultimate conclusion on the performance evaluation.

Copies of the evaluations, contractor responses, and review comments, if any, will be retained as part of the contract file.

III.I. Safeguarding and Dissemination of Controlled Unclassified Information (CUI) Building Information

Certain information contained in the Solicitation Documents may have been designated as Controlled Unclassified Information (CUI) building information. With respect to such information, Offerors shall agree to the terms for receipt of such information, as set forth in the provision “Administrative Matters” in Section III of the Agreement, as a condition of receipt of such information.

IV. FAR/GSAR Solicitation Provisions

IV.A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29 (AUG 98)

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to—

GSA Federal Supply Service Specifications Section, Suite 8100 470 East L’Enfant Plaza, SW Washington, DC 20407

Telephone (202) 619-8925 Facsimile (202) 619-8978

(b) If the General Services Administration, Department of Agriculture, or Department of

Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision. Additional copies will be issued for a fee.

IV.B. FAR 52.216-1 Type of Contract (APR 84) The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

IV.C. FAR 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work

(MAY 14)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

IV.D. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative

Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade

Goals for Female Participation for Each Trade

38.3% 6.9%

These goals are applicable to all of the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the--

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is: City of Albuquerque, Bernalillo County, State of New Mexico

IV.F. Buy American Requirements

FAR 52.225-10 Notice of Buy American Requirement-Construction Materials (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested-

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

IV.G. Buy American Exceptions

For Buy American exceptions, if any, see the applicable Buy American clause in Section IV of the Agreement

IV.H. FAR 52.233-2 Service of Protest (SEP 06)

(a) Protests, as defined in section 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the Contracting Officer at the address provided in the provision “Receipt of Offers” in Section I (General Information).

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

IV.I. FAR 52.252-1 Solicitation Provisions Incorporated by Reference (FEB 98)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting

Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address:

Federal Acquisition Regulation

NUMBER TITLE DATE

52.214-34 Submission of Offers in the English

Language

APR 91

52.215-16 Facilities Capital Cost of Money JUN 03 52.236-28 Preparation of Proposals - Construction OCT 97

IV.J. GSAR Clause 552.102 Incorporating Provisions and Clauses

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

IV.K. Additional Provisions

(iii) FAR 52.211-6 Brand Name or Equal

52.211-6 Brand Name or Equal.

As prescribed in 11.107(a), insert the following provision:

BRAND NAME OR EQUAL (AUG 1999)

(a) If an item in this solicitation is identified as "brand name or equal," the purchase description reflects the characteristics and level of quality that will satisfy the

Government’s needs. The salient physical, functional, or performance characteristics that "equal" products must meet are specified in the solicitation.

(b) To be considered for award, offers of "equal" products, including "equal" products of the brand name manufacturer, must-

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by:

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the

Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate "equal" products on the basis of information furnished by the offeror or identified in the offer and reasonably available to the Contracting Officer. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

(d) Unless the offeror clearly indicates in its offer that the product being offered is an "equal" product, the offeror shall provide the brand name product referenced in the solicitation.

(End of provision)

V. Instructions and Clauses

V.A. FAR 52.215-1 Instructions to Offerors – Competitive Acquisition (Jan 2017)

(a) Definitions. As used in this provision.

“Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer’s discretion, result in the offeror being allowed to revise its proposal.

“In writing,” “writing,” or “written” means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

“Proposal modification” is a change made to a proposal before the solicitation’s closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

“Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

“Time,” if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show.

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror’s behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent’s authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and.

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award.

Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225- 17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall.

(1) Mark the title page with the following legend:

This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed.in whole or in part.for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of.or in connection with.the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend:

Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award.

(1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government’s interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror’s initial proposal should contain the offeror’s best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to…