36C26318Q0596-00003000.docx

5. PROJECT NUMBER (if applicable)

CODE

7. ADMINISTERED BY

2. AMENDMENT/MODIFICATION NUMBER

CODE

6. ISSUED BY

8. NAME AND ADDRESS OF CONTRACTOR

4. REQUISITION/PURCHASE REQ. NUMBER

3. EFFECTIVE DATE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED

PAGE

OF PAGES

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED

BPA NO.

1. CONTRACT ID CODE

FACILITY CODE

CODE

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

E. IMPORTANT:

is extended,

(a) By completing Items 8 and 15, and returning __________ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY is not extended.

12. ACCOUNTING AND APPROPRIATION DATA

(REV. 11/2016)

is required to sign this document and return ___________ copies to the issuing office.

is not, A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

15C. DATE SIGNED

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER

BY

Contractor

16C. DATE SIGNED

14. DESCRIPTION OF AMENDMENT/MODIFICATION

16B. UNITED STATES OF AMERICA

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER

16A. NAME AND TITLE OF CONTRACTING OFFICER

15B. CONTRACTOR/OFFEROR

STANDARD FORM 30

PREVIOUS EDITION NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.243 (Type or print) (Type or print) (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

(Number, street, county, State and ZIP Code) (If other than Item 6) (Specify type of modification and authority) (such as changes in paying office, appropriation date, etc.)

(If required)

(SEE ITEM 11)

(SEE ITEM 13)

(X)

CHECK

ONE

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

(Signature of person authorized to sign) (Signature of Contracting Officer) 00003 05-30-2018

NONE

Department of Veterans Affairs

NETWORK 23 CONTRACTING OFFICE

Melanie Stockman, Contracting Officer 4801 Veterans Drive St. Cloud

MN

56303

SAME AS ISSUED BY/BLOCK 6

To all Offerors/Bidders

36C26318Q0596 05-30-2018

X X X x

ONE

Amendment #3 is being issued to include the following information:

-See attached document

NOTE: The due date for quotes has NOT been extended and remains June 11, 2018, no later than noon (local time)

Melanie Stockman Contracting Officer

NCO2315L2-1814

CONTINUATION PAGE

SUBJ: SOLICITATION NO. 36C26318Q0596 -BOILER SAFETY DEVICE REPAIR AMENDMENT #3 FOR OMAHA VA

DATE: 30 MAY 2018

Offerors to Note:

-Both boilers have a steam output of 30,000 pounds per hour at full load.

1. Submittal Log: Due to the critical nature of the repairs, the contractor is to submit all parts receipts, manufacturers manuals, cut / data sheets prior to installation for review and approval by the Omaha VA Engineering Department.

2. Boiler Shutdown / Tagout: Tag outs must be coordinated between the Boiler Plant Supervisor / Boiler Plant personnel based on projected plant loads and equipment available order to maintain plant reliability during the upgrades, only one boiler can be removed from service at a time.

3. Plan of Action and Milestones: The contractor will be required to submit a Plan of Action and Milestones (POaM) that lists at a minimum:

A. Project start and projected completion date.

B. Projected start and end dates of each line item specified in the Scope of Work.

C. Projected safety device test date to allow “Eyes On” verification by Omaha VA Engineering personnel.