36C26122Q0077_1.docx

36C26122Q0077

PAGE 1 OF

1. REQUISITION NO.

2. CONTRACT NO.

3. AWARD/EFFECTIVE DATE

4. ORDER NO.

5. SOLICITATION NUMBER

6. SOLICITATION ISSUE DATE

a. NAME

b. TELEPHONE NO. (No Collect Calls)

8. OFFER DUE DATE/LOCAL

TIME

9. ISSUED BY

CODE

10. THIS ACQUISITION IS

UNRESTRICTED OR

SET ASIDE:

% FOR:

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

8(A)

NAICS:

SIZE STANDARD:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13b. RATING

14. METHOD OF SOLICITATION

RFQ

IFB

RFP

15. DELIVER TO

CODE

16. ADMINISTERED BY

CODE

17a. CONTRACTOR/OFFEROR

CODE

FACILITY CODE

18a. PAYMENT WILL BE MADE BY

CODE

TELEPHONE NO.

DUNS:

DUNS+4:

PHONE:

FAX:

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER 18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW IS CHECKED

SEE ADDENDUM

19.

20.

21.

22.

23.

24.

ITEM NO.

SCHEDULE OF SUPPLIES/SERVICES

QUANTITY

UNIT

UNIT PRICE

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (For Govt. Use Only) 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

ARE

ARE NOT ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

ARE

ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN _______________

29. AWARD OF CONTRACT: REF. ___________________________________ OFFER

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DATED ________________________________. YOUR OFFER ON SOLICITATION

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

SET FORTH HEREIN IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER) 30b. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (TYPE OR PRINT) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

(REV. 2/2012)

PREVIOUS EDITION IS NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.212

7. FOR SOLICITATION

INFORMATION CALL:

STANDARD FORM 1449

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

36C26122Q0077 11-16-2021 Luis Gonzalez 775-785-7261 11-22-2021

4:00 PM

PST

Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno

NV

89502-2597 X 238290 $16.5 Million N/A X Department of Veterans Affairs VA Sierra Nevada Health Care System 975 Kirman Avenue

NV

89502 Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno

NV

89502-2597

Department of Veteran Affairs FMS-VA-2(101) Financial Services Center PO Box 149971 Austin

TX

78714-9971 See CONTINUATION Page This RFQ is a sole source procurement to PSI3G, Inc.

for the purchase of Skyfold retractable wall systems in support of the VA Palo Alt Health Care System IAW

FAR 6.302-1.

Please fill in the unit prices in Section B.2 "Price/Cost Schedule".

Please send information to Luis Gonzalez at luis.gonzalez5@va.gov.

Please complete block 17 and identify the DUNS number.

See CONTINUATION Page X X Luis Gonzalez Contracting Officer Table of Contents

SECTION B - CONTINUATION OF SF 1449 BLOCKS

B.1 CONTRACT ADMINISTRATION DATA

1. Contract Administration: All contract administration matters will be handled by the following individuals:

a. CONTRACTOR:

b. GOVERNMENT: Contracting Officer 36C261 Luis Gonzalez Department of Veterans Affairs VA Sierra Pacific Network (VISN 21) VA Sierra Nevada Health Care System 975 Kirman Avenue Reno NV 89502-2597

2. CONTRACTOR REMITTANCE ADDRESS: All payments by the Government to the contractor will be made in accordance with:

3. INVOICES: Invoices shall be submitted in arrears:

4. GOVERNMENT INVOICE ADDRESS: All Invoices from the contractor shall be submitted electronically in accordance with VAAR Clause 852.232-72 Electronic Submission of Payment Requests.

Department of Veteran Affairs FMS-VA-2(101) Financial Services Center

PO Box 149971 Austin TX 78714-9971 ACKNOWLEDGMENT OF AMENDMENTS: The offeror acknowledges receipt of amendments to the Solicitation numbered and dated as follows:

Page 1 of Page 1 of VA Palo Alto Health Care System 3801 Miranda Ave Palo Alto, CA 94304 Construction Project: STK-CBOC, Levels 1-4, Skyfold Zenith® 48 Automatic Vertically Retractable Acoustic Walls

STATEMENT OF WORK

1.0 GENERAL SCOPE

The Veterans Health Administration (VHA) has a requirement for healthcare furniture for VA Palo Alto healthcare System, in a new Outpatient Clinic at French Camp, CA in San Joaquin County.

Healthcare furnishings include Automatic Vertically Retractable Acoustical Wall for multiple spaces throughout the building. Suitable for heavy-wear environments, clean architectural aesthetic and available in a variety of configurations and finishes. Automatic Vertically Retractable Acoustical Wall provide flexibility for future reconfigurations.

This requirement includes product, delivery, and design integration and pre-construction services. Note: Installation services to be provided by General Contractor.

The contractor shall provide all labor during regular business hours, materials, equipment, transportation, and supervision necessary to satisfy the needs of each ordering activity.

2.0 PERFORMANCE REQUIREMENTS

Associated design/drafting, structural engineering, project management as required to field verify and produce shop-drawings, storage, parts and delivery transportation of goods shall be provided by the awarded Contractor. Note: Additional project management, and installation services to be provided by General Contractor (G.C.) as this product is owner furnished/general contractor installed (V/C).

Product delivery will be required by April 11, 2022. Awarded contractor to coordinate delivery of product with VA Interior Designer and General Contractor’s installation sub-contractor to meet this date. Subject to change based on construction completion date.

Project Job Site: 6505 S. Manthey Rd, French Camp, CA 95231 Duty hours will be 7:30am-4:30pm Monday through Friday. The Government recognized US holidays are: New Year’s Day, Martin Luther King, Jr. Day, Presidents Day, Juneteenth National Independence Day, Memorial Day, Independence Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day and Christmas Day. If the holiday falls on Sunday, it is observed on Monday.

The contractor shall procure and deliver the following furniture/products for VA Palo Alto Healthcare System

· Automatic Vertically Retractable Acoustical Wall, shall refer specifically to acoustical partitions that, when in the down position (closed) are hard, rigid, flat, plumb walls, made of a grid of rectangular acoustical panels, and when are lifted (opened), fold upward (vertically) without the use of any manual labor, into a pocket in the ceiling, between roof joists, or up between built in bulkheads. In the down (closed) position, the operable wall shall be comprised of two vertical planes of acoustical panels, separated by an acoustical air space. Acoustical panels to be Skyfold graded-in Xorel fabric. Provide color chart to VA Designer upon award.

· 3 each 24’L X 9’H, located on the 2nd,3rd and 4th floor

· 2 each 23’L X 9’H, located on the 1st floor

· Standard Drive System.

· Provide maintenance manuals for all products specified.

· Provide sustainability certification documentation for all products specified.

3.0 PRODUCT

General

All finished surfaces shall be free of scratches, mars, dents, or blemishes, and withstand staining, and exhibit to flaking, cracking, or loss or adhesion.

Furnishings shall have smooth finishes with no hazardous projections, sharp corners, or detail, which can be hazardous and cause personal injury or damage to clothing.

See attachment for technical requirement of products.

4.0 SERVICES

Deliver product to jobsite according to VA approved shop drawings.

a. Coordinate and provide project management of all products and services to manage, design, order, ship, and delivery of all new furniture/product from the manufacturer until final acceptance by the VA Point of Contact.

b. Service to include project management to perform field measurements, structural drawings, and shop drawings.

c. Deliver the motors, pantographs, and the panels.

Design Contract Tasks/Requirements.

a. Awarded Contractor shall be familiar with VA Palo Alto’s forthcoming new Stockton campus, regulations, security requirements, loading dock locations, and hours of operations.

b. Personnel shall always wear contractor provided identification and VA visitor’s badge while on VA property.

c. Contractor shall provide Proof liability of Insurance upon request of VA or General contractor for any worker who will be on site to conduct field verification and unloading of products.

d. Personnel shall comply with OSHA regulations and safety guidelines while on job-site.

e. Contractor shall provide Project Manager/Lead Supervisor, Client Representative, and Service Technicians as needed when providing service to the VA.

f. Contractor shall provide all necessary materials, equipment, labor, supervision, and Management to: (A) coordinate delivery: (B) load and unload; (C) place/install in designated rooms/locations; (D) assemble items as required; (E) secure as designated; and (F) properly dispose of all associated packing/crating materials off-site of VA premises.

g. Contractor shall track manufacturing schedule and notify VA Point of Contact (POC) with updates of estimated completion date by email.

h. Contractor shall coordinate delivery date with VA Point of Contact (POC) to occur at the convenience of the Government or no later than 30 days after notification of receipt of furniture.

i. Contractor shall obtain VA CO, COR or POC approval for any changes or corrections to all original submitted design documents. Any changes that involve money or specs not included in the SOW or attachments must go through the CO for approval.

j. Environmental Certification: Submit written certification from the manufacturer, including third party evaluation, recycling characteristics, and perpetual use certification as specified. Initial submittals, which do not include the Environmental Certification will be rejected. Materials that are simply 'PVC free' without identifying their inputs shall not qualify as meeting the intent of this specification and shall be rejected.

k. Third Party Evaluation: Provide documentation stating the shade cloth has undergone third party evaluation for all chemical inputs, down to a scale of 100 parts per million, that have been evaluated for human and environmental safety. Identify all inputs, which are known to be carcinogenic, mutagenic, teratogenic, reproductively toxic, or endocrine disrupting. Also identify items that are toxic to aquatic systems, contain heavy metals, or organ halogens. The material shall contain no inputs that are known problems to human or environmental health per the above major criteria, except for an input that is required to meet local fire codes.

Project manager (PM)

a. The Project Manager shall represent the Contractor with whom the Government has awarded the purchase order.

b. Contractor shall complete a take-off meeting with VA POC, at a minimum of (60) business days, prior to delivery.

c. Contractor shall be available and on site to coordinate and oversee the delivery of product to project site.

d. Contractor shall complete a final checklist VA POC confirming completion of all previously identified products items prior to final VA acceptance of drop-ship items.

Protection of Property

a. Contractor shall protect all items from damage that may occur during field verification on site and during delivery and unpacking of items. Contractor shall take precaution against damage to the buildings, grounds and furnishings. Contractor shall repair or replace any items related to buildings or grounds damaged accidentally, or on purpose due to actions by the Contractor, utilizing materials of the same quality, size, grade and color, to match existing work.

b. Contractor shall be responsible for security of the areas in which field verification and delivery/unpacking is being performed.

c. Contractor shall provide floor, door, and elevator wall protection while field verification and delivery/unpacking is performed at job-site. All material handling equipment shall have rubber wheels. Public elevators shall have temporary padded wall protection when freight elevator is unavailable.

Delivery

a. Contractor shall contact the POC, when complete order has been received, to schedule delivery of goods prior to schedule installation by General Contractor.

b. Contractor shall confirm the scheduled delivery date set with G.C. no less than 15 working days prior to start of General Contractor’s scheduled installation date to ensure that all parts have been received and in good condition. VA POC will confirm that space will be made available at appointed delivery date. Delivery shall not be scheduled until Contractor has confirmed the receipt of full order.

c. In the event there is a delay in delivery, Contractor shall notify the VA POC immediately.

d. Contractor shall notify the VA POC a minimum of 120 hours advance notice of the scheduled date and time of delivery.

e. Contractor shall ensure that the driver of the delivery vehicle has copies of the delivery order at time of delivery.

f. Contractor shall not attempt to deliver any items before the scheduled delivery date.

g. Contractor shall complete delivery of furnishings under this statement of work in the time period specified (07:30 am - 4:00 pm.). If unforeseen scheduling is required by the VA, Contractor shall coordinate revised scheduled, to be approved by POC.

h. Contractor shall inspect components to ensure that they are clean, dust free, free of defects and that delivery is complete and all items are ready for installation by others.

i. Contractor shall adhere to manufacturer’s specifications and not use other manufacturer’s product to interlock with new or existing product potentially invalidating warranties.

j. Contractor is responsible for removal of damaged or replaced products out of job site in accordance with Quality Control section listed below.

Receive and Unload

a. Building’s General Contractor shall verify and inspect all items at time of receipt upon arrival to the project site. Any and all deficiencies (damage/overage/shortage) shall be brought to the attention of the POC or VA Project Manager.

b. Contractor shall store damaged items in the location designated by the POC. Contractor shall maintain a complete file of all documents relating to each discrepancy and copies of all Discrepancy Reports shall be forwarded to the POC daily.

c. Contractor shall repair or coordinate for replacement of damaged, defective, or missing items

d. Conduct of Contractor delivery personnel shall always be courteous and respectful. Be particularly mindful of our Veteran’s and their needs.

Contract Hours The normal work hours will be business hours (7:30am-4:30pm) Monday through Friday. The Government has the option to modify the normal work week, days and hours, as necessary to meet the mission of the VAPAHCS. Contractor shall be flexible if a change in work hours is necessary to complete the project in order to accomplish the mission of VAPAHCS.

Work Required by Others All work required by other trades shall be identified under this section by the Bidder.

Attachments

a. Manufacturer’s Installation and Parts Drawing.

B.2 PRICE/COST SCHEDULE

ITEM INFORMATION

Qty 5 (total) - Skyfold Zenith 48 Automatic Vertically Retractable Acoustical Wall, in standard Dune fabric, to be placed in group rooms in the new Stokcton COBC 3 each 24'L X 9'H, located on the 2nd,3rd and 4th floor 2 each 23'L X 9'H, located on the 1st floor

0001AA

Skyfold Zenith 48 Automatic Vertically Retractable Acoustical Wall, in premium XOREL fabric, 24'L X 9'H, located on the 2nd,3rd and 4th floor Line Item OEM Name: ____________________ Line Item OEM DUNS #: ____________________ Line Item OEM Country of Origin: ____________________ Manufacturer Part Number: ____________________ Distributer/Reseller Catalog #: ____________________ Line Item NAICS Code: ____________________ Line Item Product Service Code: ____________________

0001AB

Skyfold Zenith 48 Automatic Vertically Retractable Acoustical Wall, in premium XOREL fabric, 23'L X 9'H, located on the 1st floor Line Item OEM Name: ____________________ Line Item OEM DUNS #: ____________________ Line Item OEM Country of Origin: ____________________ Manufacturer Part Number: ____________________ Distributer/Reseller Catalog #: ____________________ Line Item NAICS Code: ____________________ Line Item Product Service Code: ____________________

B.3 DELIVERY SCHEDULE

5.00

0001AA

3.00

0001AB

2.00

SECTION C - CONTRACT CLAUSES

C.1 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL ITEMS (OCT 2018)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights—

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include—

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.—

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause;

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments

(9) The specification.

(t) [Reserved]

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause) ADDENDUM to FAR 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL ITEMS Clauses that are incorporated by reference (by Citation Number, Title, and Date), have the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

The following clauses are incorporated into 52.212-4 as an addendum to this contract:

C.2 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Clause)

C.3 VAAR 852.212-70 PROVISIONS AND CLAUSES APPLICABLE TO VA ACQUISITION OF COMMERCIAL ITEMS (APR 2020)

(a) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The following provisions and clauses that have been checked by the Contracting Officer are incorporated by reference.

[X] 852.203–70, Commercial Advertising.

[] 852.209–70, Organizational Conflicts of Interest.

[X] 852.211–70, Equipment Operation and Maintenance Manuals.

[] 852.214–71, Restrictions on Alternate Item(s).

[] 852.214–72, Alternate Item(s). [Note: this is a fillable clause.] [] 852.214–73, Alternate Packaging and Packing.

[] 852.214–74, Marking of Bid Samples.

[] 852.215–70, Service-Disabled Veteran-Owned and Veteran-Owned Small Business Evaluation Factors.

[] 852.215–71, Evaluation Factor Commitments.

[] 852.216–71, Economic Price Adjustment of Contract Price(s) Based on a Price Index.

[] 852.216–72, Proportional Economic Price Adjustment of Contract Price(s) Based on a Price Index.

[] 852.216–73, Economic Price Adjustment—State Nursing Home Care for Veterans.

[] 852.216–74, Economic Price Adjustment—Medicaid Labor Rates.

[] 852.216–75, Economic Price Adjustment—Fuel Surcharge.

[] 852.219–9, VA Small Business Subcontracting Plan Minimum Requirements.

[] 852.219–10, VA Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside.

[] 852.219–11, VA Notice of Total Veteran-Owned Small Business Set-Aside.

[] 852.222–70, Contract Work Hours and Safety Standards—Nursing Home Care for Veterans.

[] 852.228–70, Bond Premium Adjustment.

[] 852.228–71, Indemnification and Insurance.

[] 852.228–72, Assisting Service-Disabled Veteran-Owned and Veteran-Owned Small Businesses in Obtaining Bonds.

[X] 852.232–72, Electronic Submission of Payment Requests.

[] 852.233–70, Protest Content/Alternative Dispute Resolution.

[] 852.233–71, Alternate Protest Procedure.

[] 852.237–70, Indemnification and Medical Liability Insurance.

[X] 852.246–71, Rejected Goods.

[] 852.246–72, Frozen Processed Foods.

[] 852.246–73, Noncompliance with Packaging, Packing, and/or Marking Requirements.

[] 852.270–1, Representatives of Contracting Officers.

[] 852.271–72, Time Spent by Counselee in Counseling Process.

[] 852.271–73, Use and Publication of Counseling Results.

[] 852.271–74, Inspection.

[] 852.271–75, Extension of Contract Period.

[] 852.273–70, Late Offers.

[] 852.273–71, Alternative Negotiation Techniques.

[] 852.273–72, Alternative Evaluation.

[] 852.273–73, Evaluation—Health-Care Resources.

[] 852.273–74, Award without Exchanges.

(b) All requests for quotations, solicitations, and contracts for commercial item services to be provided to beneficiaries must include the following clause:

[] 852.237–74, Nondiscrimination in Service Delivery.

(End of Clause)

C.4 VAAR 852.247-71 DELIVERY LOCATION (OCT 2018)

Shipment of deliverable items, other than reports, shall be to:

Department of Veterans Affairs VA Sierra Nevada Health Care System 975 Kirman Avenue

NV 89502

(End of Clause)

C.5 VAAR 852.247-73 PACKING FOR DOMESTIC SHIPMENT (OCT 2018)

Material shall be packed for shipment in such a manner that will insure acceptance by common carriers and safe delivery at destination. Containers and closures shall comply with regulations of carriers as applicable to the mode of transportation.

(End of Clause) (End of Addendum to 52.212-4)

C.6 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS—COMMERCIAL ITEMS (JAN 2021) (JUL 2020) (DEVIATION)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204–23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115–91).

(3) 52.204–25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115–232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(6) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[] (1) 52.203–6, Restrictions on Subcontractor Sales to the Government (JUN 2020), with Alternate I (OCT 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

[] (2) 52.203–13, Contractor Code of Business Ethics and Conduct (JUN 2020) (41 U.S.C. 3509).

[] (3) 52.203–15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

[X] (4) 52.204–10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN 2020) (Pub. L. 109–282) (31 U.S.C. 6101 note).

[] (5) [Reserved] [] (6) 52.204–14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111–117, section 743 of Div. C).

[] (7) 52.204–15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT 2016) (Pub. L. 111–117, section 743 of Div. C).

[X] (8) 52.209–6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (JUN 2020) (31 U.S.C. 6101 note).

[] (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

[] (10) [Reserved] [] (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (MAR 2020) (15 U.S.C. 657a).

[] (ii) Alternate I (MAR 2020) of 52.219-3.

[] (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (MAR 2020) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

[] (ii) Alternate I (MAR 2020) of 52.219-4.

[] (13) [Reserved] [] (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

[] (ii) Alternate I (MAR 2020) of 52.219-6.

[] (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) (15 U.S.C. 644).

[] (ii) Alternate I (MAR 2020) of 52.219-7.

[] (16) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)).

[] (17)(i) 52.219–9, Small Business Subcontracting Plan (JUN 2020) (15 U.S.C. 637(d)(4)).

[] (ii) Alternate I (NOV 2016) of 52.219-9.

[] (iii) Alternate II (NOV 2016) of 52.219-9.

[] (iv) Alternate III (JUN 2020) of 52.219–9.

[] (v) Alternate IV (JUN 2020) of 52.219–9.

[] (18)(i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) (15 U.S.C. 644(r)).

[] (ii) Alternate I (MAR 2020) of 52.219-13.

[] (19) 52.219-14, Limitations on Subcontracting (MAR 2020) (15 U.S.C. 637(a)(14)).

[] (20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

[] (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (MAR 2020) (15 U.S.C. 657f).

[X] (22)(i) 52.219-28, Post Award Small Business Program Rerepresentation (NOV 2020) (15 U.S.C 632(a)(2)).

[] (ii) Alternate I (MAR 2020) of 52.219-28.

[] (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (MAR 2020) (15 U.S.C. 637(m)).

[] (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (MAR 2020) (15 U.S.C. 637(m)).

[] (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR 2020) (15 U.S.C. 644(r)).

[] (26) 52.219-33, Nonmanufacturer Rule (MAR 2020) (15 U.S.C. 637(a)(17)) [] (27) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

[X] (28) 52.222–19, Child Labor—Cooperation with Authorities and Remedies (JUL 2020) (DEVIATION) (E.O. 13126).

[X] (29) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

[X] (30)(i) 52.222–26, Equal Opportunity (SEP 2016) (E.O. 11246).

[] (ii) Alternate I (FEB 1999) of 52.222-26.

[X] (31)(i) 52.222–35, Equal Opportunity for Veterans (JUN 2020) (38 U.S.C. 4212).

[] (ii) Alternate I (JULY 2014) of 52.222-35.

[X] (32)(i) 52.222–36, Equal Opportunity for Workers with Disabilities (JUN 2020) (29 U.S.C. 793).

[] (ii) Alternate I (JULY 2014) of 52.222-36.

[X] (33) 52.222–37, Employment Reports on Veterans (JUN 2020) (38 U.S.C. 4212).

[] (34) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496).

[X] (35)(i) 52.222-50, Combating Trafficking in Persons (OCT 2020) (22 U.S.C. chapter 78 and E.O. 13627).

[] (ii) Alternate I (MAR 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

[] (36) 52.222-54, Employment Eligibility Verification (OCT 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

[] (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C.6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[] (ii) Alternate I (MAY 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

[] (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016) (E.O. 13693).

[] (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

[] (40)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014) (E.O.s 13423 and 13514).

[] (ii) Alternate I (OCT 2015) of 52.223-13.

[] (41)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s 13423 and 13514).

[] (ii) Alternate I (JUN 2014) of 52.223-14.

[] (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (MAY 2020) (42 U.S.C. 8259b).

[] (43)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514).

[] (ii) Alternate I (JUN 2014) of 52.223-16.

[X] (44) 52.223–18, Encouraging Contractor Policies to Ban Text Messaging While Driving (JUN 2020) (E.O. 13513).

[] (45) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

[] (46) 52.223-21, Foams (JUN 2016) (E.O. 13693).

[] (47) (i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

[] (ii) Alternate I (JAN 2017) of 52.224-3.

[X] (48) 52.225-1, Buy American—Supplies (JAN 2021) (41 U.S.C. chapter 83).

[] (49)(i) 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act (JUL 2020) (DEVIATION) (19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

[] (ii) Alternate II (JUL 2020) (DEVIATION) of 52.225-3.

[] (iii) Alternate III (JUL 2020) (DEVIATION) of 52.225-3.

[] (50) 52.225–5, Trade Agreements (JUL 2020) (DEVIATION) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

[X] (51) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

[] (52) 52.225–26, Contractors Performing Private Security Functions Outside the United States (OCT 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

[] (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

[] (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

[X] (55) 52.229–12, Tax on Certain Foreign Procurements (JUN 2020).

[] (56) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

[] (57) 52.232-30, Installment Payments for Commercial Items (JAN 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

[X] (58) 52.232-33, Payment by Electronic Funds Transfer—System for Award Management (Oct 2018) (31 U.S.C. 3332).

[] (59) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

[] (60) 52.232-36, Payment by Third Party (MAY 2014) (31 U.S.C. 3332).

[] (61) 52.239-1, Privacy or Security Safeguards (AUG 1996) (5 U.S.C. 552a).

[] (62) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C. 637(d)(13)).

[] (63)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

[] (ii) Alternate I (Apr 2003) of 52.247-64.

[] (iii) Alternate II (FEB 2006) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[X] (1) 52.222-41, Service Contract Labor Standards (AUG 2018) (41 U.S.C. chapter 67).

[X] (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

[] (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards—Price Adjustment (Multiple Year and Option Contracts) (AUG 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

[] (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards—Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67).

[] (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Requirements (MAY 2014) (41 U.S.C. chapter 67).

[] (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Requirements (MAY 2014) (41 U.S.C. chapter 67).

[X] (7) 52.222-55, Minimum Wages Under Executive Order 13658 (NOV 2020).

[X] (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

[] (9) 52.226–6, Promoting Excess Food Donation to Nonprofit Organizations (JUN 2020) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed…