36C25818R0309-0002001.pdf

ATTACHMENT 08

COMBINED SPECIFICATIONS

Table of Contents _ Section 00, 01, 10 Common Results for Plumbing_ Section 22, 05, 11

General Requirements_ Section 01, 00, 00 Common Work Results for Plumbing_ Section 22, 05, 11

Shop Drawings, Product Data, and Samples_ Section 01, 33, 23 Meters and Gauges for Plumbing Piping_ 22, 05, 19

Safety Requirements_ Section 01, 35, 26 General Duty Valves for Plumbing Piping_ 22, 05, 23

Reference Standards_ Section 01, 42, 19 Plumbing Insulation_ Section 22, 07, 11

General Commissioning Requirements_ Section 01, 91, 00 Commissioning of Plumbing System_ Section 22, 08, 00

Demolition_ Section 02, 41, 00 Facility Water Distribution_ Section 22, 11, 00

Firestopping_ Section 07, 84, 00 Requirements for Electrical Installation_ Section 26, 05, 11

605-17-417

272 pages

(Revision 1) 29 June 2018

Loma Linda, California VA Health Care System (605)

Legionella Prevention System

CONSTRUCTION

01-01-18

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 07-15 00 11 21 Request for Proposal to Design Build 11-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 10-17 01 32 16.01 Architectural and Engineering CPM Schedules 01-11 01 32 16.13 Network Analysis Schedule – Major Projects 09-15 01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 04-13 01 32 16.16 Network Analysis Schedules (Design-Build Only) 02-15 01 32 16.17 Project Schedules (Small Projects – Design/Build) 04-11 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 02-17 01 42 19 Reference Standards 05-16 01 45 00 Quality Control 01-18 01 45 29 Testing Laboratory Services 08-17 01 45 35 Special Inspections 01-18 01 57 19 Temporary Environmental Controls 01-11 01 58 16 Temporary Interior Signage 07-15 01 74 19 Construction Waste Management 09-13 01 81 13 Sustainable Construction Requirements 10-17 01 81 13.01 Sustainability Certification Requirements – LEED NC V3 09-15 01 81 13.02 Sustainability Certification Requirements – LEED NC V4 09-15 01 81 13.11 Sustainability Certification Requirements – LEED HC V3 09-15 01 81 13.21 Sustainability Certification Requirements – GREEN

GLOBES

09-15

01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 21 13 Site Surveys 08-16 02 41 00 Demolition 08-17 02 65 00 Underground Storage Tank Removal 08-16 02 82 11 Traditional Asbestos Abatement 09-15 02 82 13.13 Glovebag Asbestos Abatement 09-15 02 82 13.19 Asbestos Floor Tile and Mastic Abatement 09-15 02 82 13.21 Asbestos Roofing Abatement 09-15 02 82 13.31 Asbestos Transite Abatement 09-15 02 82 13.41 Asbestos Abatement for Total Demolition Project 04-15 02 83 33.13 Lead-Based Paint Removal and Disposal 08-16

DIVISION 03 – CONCRETE

00 01 10-2

03 23 00 Stressing Tendons 07-11 03 30 00 Cast-in-Place Concrete 12-15 03 30 53 (Short-Form) Cast-in-Place Concrete 02-16 03 37 13 Shotcrete 07-11 03 41 13 Precast Concrete Hollow Core Planks 07-11 03 41 33 Precast Structural Pretension Concrete 07-11 03 45 00 Precast Architectural Concrete 10-15 03 51 13 Cementitious Wood Fiber Decks 09-11 03 51 16 Gypsum Concrete Roof Decks 09-11 03 52 00 Lightweight Concrete Roof Insulation 05-15 03 55 11 Gypsum Concrete Floor Decks 07-11

DIVISION 04 – MASONRY

04 01 00 Maintenance of Masonry 02-16 04 05 13 Masonry Mortaring 10-17 04 05 16 Masonry Grouting 02-16 04 20 00 Unit Masonry 08-17 04 72 00 Cast Stone Masonry 02-15

DIVISION 05 – METALS

05 12 00 Structural Steel Framing 02-16 05 21 00 Steel Joist Framing 03-10 05 31 00 Steel Decking 02-16 05 36 00 Composite Metal Decking 10-15 05 40 00 Cold-Formed Metal Framing 05-16 05 50 00 Metal Fabrications 07-14 05 51 00 Metal Stairs 10-15

DIVISION 06 – WOOD,PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-17 06 16 63 Cementitious Sheathing 02-16 06 20 00 Finish Carpentry 08-16

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 01 50.19 Preparation for Re-Roofing 02-16 07 08 00 Facility Exterior Closure Commissioning 11-16 07 11 13 Bituminous Dampproofing 02-16 07 12 00 Built-Up Bituminous Waterproofing 09-11 07 13 00 Sheet Waterproofing 04-13 07 13 52 Modified Bituminous Sheet Waterproofing 08-16 07 14 21 Latex Mastic Deck Covering 05-15 07 18 13 Pedestrian Traffic Coatings 05-15 07 21 13 Thermal Insulation 10-17 07 21 23 Loose-Fill Insulation 02-16 07 22 00 Roof and Deck Insulation 02-16 07 24 00 Exterior Insulation and Finish Systems 02-16 07 27 26 Fluid-Applied Membrane Air Barrier, Vapor Permeable 02-16 07 27 27 Fluid-Applied Membrane Air Barrier, Vapor Retarding 02-16

00 01 10-3

07 31 13 Asphalt Shingles 02-16 07 31 26 Slate Shingles 02-16 07 31 29.13 Wood Shingles 02-16 07 32 13 Clay Roof Tiles 02-16 07 40 00 Roofing and Siding Panels 10-15 07 51 00 Built-Up Bituminous Roofing 07-14 07 51 13.11 Hot-Applied Built-Up Asphalt Roofing 08-16 07 51 13.13 Cold-Applied Built-Up Asphalt Roofing 08-16 07 52 16.11 Cold Adhesive Styrene-Butadiene-Styrene Modified

Bituminous Membrane Roofing 08-16

07 52 16.12 Hot-Mopped Styrene-Butadiene-Styrene Modified Bituminous Membrane Roofing

08-16

07 53 23 Ethylene-Propylene-Diene-Monomer Roofing 02-16 07 54 16 Ethylene Interpolymer (KEE) Roofing 10-15 07 54 19 Polyvinyl-Chloride (PVC) Roofing 10-17 07 54 23 Thermoplastic Polyolefin (TPO) Roofing 08-16 07 56 00 Fluid-Applied Roofing 05-15 07 57 13 Sprayed Polyurethane Foam Roofing 10-15 07 60 00 Flashing and Sheet Metal 07-14 07 61 16 Batten Seam Copper Roofing 10-15 07 71 00 Roof Specialties 10-15 07 72 00 Roof Accessories 10-15 07 81 00 Applied Fireproofing 10-17 07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-17 07 95 13 Expansion Joint Cover Assemblies 02-16

DIVISION 08 - OPENINGS

08 11 13 Hollow Metal Doors and Frames 08-16 08 11 73 Sliding Metal Fire Doors 02-16 08 14 00 Interior Wood Doors 02-16 08 17 10 Integrated Door Assemblies 02-16 08 31 13 Access Doors and Frames 02-16 08 33 00 Coiling Doors and Grilles 02-16 08 33 13 Coiling Counter Doors 02-16 08 34 36 Darkroom Doors 07-15 08 34 53 Security Doors and Frames 05-15 08 34 59 Vault Doors and Day Gates 02-16 08 35 13.13 Accordion Folding Doors 05-15 08 36 13 Sectional Doors 05-15 08 38 16 Flexible Traffic Doors 02-16 08 41 13 Aluminum-Framed Entrances and Storefronts 08-16 08 42 33 Revolving Door Entrances 05-15 08 44 13 Glazed Aluminum Curtain Walls 03-17 08 51 13 Aluminum Windows 02-16 08 51 13.11 Side-Hinged Aluminum Windows 08-16 08 51 23 Steel Windows 02-16 08 51 69.11 Aluminum Storm Windows 05-15 08 56 19 Pass Windows 02-16 08 56 53 Blast Resistant Windows 02-16 08 56 59 Service and Teller Window Units 02-16 08 56 66 Detention Window Screens 02-16

00 01 10-4

08 63 00 Metal-Framed Skylights 10-15 08 71 00 Door Hardware 01-16 08 71 13 Automatic Door Operators 02-16 08 71 13.11 Low Energy Power Assist Door Operators 08-16 08 80 00 Glazing 10-15 08 90 00 Louvers and Vents 05-15

DIVISION 09 – FINISHES

09 05 16 Subsurface Preparation for Floor Finishes 02-15 09 06 00 Schedule for Finishes 04-15 09 22 16 Non-Structural Metal Framing 05-16 09 23 00 Gypsum Plastering 10-15 09 24 00 Portland Cement Plastering 10-15 09 26 00 Veneer Plastering 10-15 09 29 00 Gypsum Board 11-14 09 30 13 Ceramic/Porcelain Tiling 09-15 09 51 00 Acoustical Ceilings 12-16 09 54 23 Linear Metal Ceilings 10-15 09 63 13 Brick Flooring 02-16 09 63 40 Stone Flooring 10-15 09 65 13 Resilient Base and Accessories 02-16 09 65 16 Resilient Sheet Flooring 02-16 09 65 19 Resilient Tile Flooring 12-15 09 66 13 Portland Cement Terrazzo Flooring 10-15 09 66 16 Terrazzo Floor Tile 10-15 09 67 23.20 Resinous Epoxy Base With Vinyl Chip Broadcast (RES 2) 07-14 09 67 23.30 Resinous (Epoxy Resin Composition)Mortar Flooring (RES-

3) 07-14

09.67.23.40 Resinous Poured In Place Resilient Flooring (RES-4) 07-14 09 67 23.50 Resinous (Epoxy Terrazzo) Flooring (RES-5) 07-14 09 67 23.60 Resinous (Urethane and Epoxy Mortar) Flooring (RES-6) 07-14 09 68 00 Carpeting 10-15 09 68 21 Athletic Carpeting 10-15 09 69 00 Access Flooring 10-15 09 72 16 Vinyl-Coated Fabric Wall Covering 10-15 09 72 31 Polypropylene Fabric Wall Covering 05-15 09 84 33 Sound-Absorbing Wall Units 10-15 09 91 00 Painting 01-16 09 94 19 Multicolor Interior Finishing 08-16 09 96 59 High-Build Glazed Coatings 07-14

DIVISION 10 – SPECIALTIES

10 11 13 Chalkboards and Markerboards 10-15 10 11 23 Tackboards 10-15 10 13 00 Directories 05-15 10 14 00 Signage 10-15 10 21 13 Toilet Compartments 12-15 10 21 16 Shower and Dressing Compartments 08-16 10 21 23 Cubicle Curtain Tracks 05-15 10 22 13 Wire Mesh Partitions 10-15

00 01 10-5

10 22 19 Demountable Partitions 04-16 10 22 26.13 Accordion Folding Partitions 05-15 10 25 13 Patient Bed Service Walls 10-15 10 26 00 Wall and Door Protection 10-15 10 28 00 Toilet, Bath, and Laundry Accessories 02-16 10 44 13 Fire Extinguisher Cabinets 08-14 10 75 00 Flagpoles 02-16

DIVISION 11 – EQUIPMENT

11 05 12 General Motor Requirements for Equipment 11-11 11 12 00 Parking Control Equipment 02-16 11 17 36 Package Transfer Units 02-13 11 26 00 Unit Kitchens 11-11 11 27 00 Photographic Processing Equipment 11-11 11 40 11 Custom Fabricated Food Service Equipment 11-11 11 40 21 Food Service Equipment-Utility Distribution System 11-11 11 41 00 Food Storage Equipment 11-11 11 41 21 Walk-In Coolers and Freezers 05-15 11 44 00 Food Cooking Equipment 11-11 11 48 00 Cleaning and Disposal Equipment 11-11 11 53 13 Laboratory Fume Hoods 05-15 11 53 23 Laboratory Refrigerators 11-11 11 53 53 Biological Safety Cabinets Laminar Airflow Stations 01-11 11 53 61 Custom Fabricated Laboratory Equipment 11-11 11 53 71 Solution Warming Cabinets 11-11 11 71 01 Medical Washing and Sterilizing Equipment 02-11 11 71 02 Laboratory Washing and Sterilizing Equipment 10-11 11 73 00 Ceiling Mounted Patient Lift System 01-17 11 78 00 Mortuary Equipment 11-11 11 78 13 Mortuary Refrigerators 11-11 11 79 13 Hydrotherapy Equipment 11-11 11 82 19 Packaged Incinerators 11-11

DIVISION 12 – FURNISHINGS

12 22 16 Drapery Track and Accessories 05-15 12 24 00 Window Shades 08-17 12 24 21 Lightproof Shades 05-15 12 31 00 Manufactured Metal Casework 05-15 12 32 00 Manufactured Wood Casework 09-15 12 34 00 Manufactured Plastic Casework 10-15 12 35 70.21 Medication Cabinet 02-16 12 36 00 Countertops 12-15 12 56 70.11 Suspended Table 02-16

DIVISION 13 - SPECIAL CONSTRUCTION

13 05 41 Seismic Restraint Requirements for Non-Structural

Components 01-14

13 17 23 Therapeutic Pools 05-15 13 17 23.11 Therapeutic Pool Accessories 05-15 13 19 13 Kennel Enclosures and Gates 02-16

00 01 10-6

13 21 29 Constant Temperature Rooms 08-16 13 34 19 Metal Building Systems 08-16 13 49 00 Radiation Protection 02-16

DIVISION 14– CONVEYING EQUIPEMENT

14 12 11 Electric Traction and Winding Drum Dumbwaiter 09-17 14 21 00 Electric Traction Elevator 09-17 14 21 11 Electric Traction Cartlift 12-17 14 24 00 Electric Hydraulic Elevator 09-17 14 24 11 Electric Hydraulic Cartlift 12-17 14 24 24 Renovation Hydraulic Elevator (Custom Written by VACO) 14 26 26 Renovation Traction Elevator (Custom Written by VACO) 14 91 33 Laundry and Linen Chutes 06-12 14 91 82 Trash Chutes 06-12

DIVISION 21- FIRE SUPPRESSION

21 08 00 Commissioning of Fire Suppression System 11-16 21 12 00 Manual Dry Standpipe Systems 06-15 21 13 13 Wet-Pipe Sprinkler Systems 06-15 21 13 16 Dry-Pipe Sprinkler Systems 01-15 21-22-00 Clean Agent Fire Suppression Systems 05-15 21-30-13 Electric-Driven, Fire Pumps 05-15 21-30-16 Diesel-Driven, Fire Pumps 05-15

DIVISION 22 – PLUMBING

22 05 11 Common Work Results for Plumbing 07-16 22 05 12 General Motor Requirements for Plumbing Equipment 09-15 22 05 19 Meters and Gages for Plumbing Piping 09-15 22 05 23 General-Duty Valves for Plumbing Piping 09-15 22 05 33 Heat Tracing for Plumbing Piping 09-15 22 07 11 Plumbing Insulation 09-15 22 08 00 Commissioning of Plumbing Systems 11-16 22 11 00 Facility Water Distribution 09-15 22 11 23 Domestic Water Pumps 09-15 22 12 16 Facility Elevated, Potable-Water Storage Tanks 09-15 22 13 00 Facility Sanitary and Vent Piping 09-15 22 13 23 Sanitary Waste Interceptors 09-15 22 13 29 Sanitary Sewerage Pumps 09-15 22 13 29.13 Wet-Pit Mounted, Vertical Sewerage Pumps 09-15 22 13 33 Packaged, Submersible Sewerage Pump Units 09-15 22 14 00 Facility Storm Drainage 09-15 22 14 29 Sump Pumps 09-15 22 14 33 Packaged, Pedestal Drainage Pump Units 09-15 22 14 36 Packaged, Submersible, Drainage Pump Units 09-15 22 15 00 General Service Compressed-Air Systems 09-15 22 31 11 Water Softeners 09-15 22 33 00 Electric Domestic Water Heaters 09-15 22 34 00 Fuel-Fired Domestic Water Heaters 09-15 22 35 00 Domestic Water Heat Exchangers 12-16

00 01 10-7

22 40 00 Plumbing Fixtures 09-15 22 42 26 Commercial Disposers 09-15 22 61 13.74 Dental Compressed-Air Piping 09-15 22 61 19.74 Dental Compressed-Air Equipment 09-15 22 62 00 Vacuum Systems for Laboratory and Healthcare Facilities 09-15 22 62 19.74 Dental Vacuum and Evacuation Equipment 09-15 22 63 00 Gas Systems for Laboratory and Healthcare Facilities 09-15 22 66 00 Chemical-Waste Systems for Laboratory and Healthcare

Facilities 09-15

22 67 19.16 Reverse-Osmosis Water Equipment 09-15 22 67 21 Water Dealkalizing System 09-15

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 10 Common Work Results for Boiler Plant and Steam

Generation 08-17

23 05 11 Common Work Results for HVAC 08-17 23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment 08-17

23 05 41 Noise and Vibration Control for HVAC Piping and Equipment

02-15

23 05 51 Noise and Vibration Control for Boiler Plant 08-17 23 05 93 Testing, Adjusting, and Balancing for HVAC 02-15 23 07 11 HVAC and Boiler Plant Insulation 02-15 23 08 00 Commissioning of HVAC Systems 11-16 23 08 11 Demonstrations and Tests for Boiler Plant 08-17 23 09 11 Instrumentation and Control for Boiler Plant 08-17 23 09 23 Direct-Digital Control System for HVAC 09-11 23 10 00 Facility Fuel Systems 08-17 23 11 23 Facility Natural-Gas Piping 08-17 23 21 11 Boiler Plant Piping Systems 09-17 23 21 13 Hydronic Piping 08-17 23 21 23 Hydronic Pumps 08-17 23 22 13 Steam and Condensate Heating Piping 08-17 23 22 23 Steam Condensate Pumps 08-17 23 23 00 Refrigerant Piping 02-15 23 25 00 HVAC Water Treatment 02-15 23 31 00 HVAC Ducts and Casings 03-13 23 34 00 HVAC Fans 02-15 23 36 00 Air Terminal Units 02-15 23 37 00 Air Outlets and Inlets 02-15 23 38 13 Commercial-Kitchen Hoods 01-11 23 40 00 HVAC Air Cleaning Devices 02-12 23 50 11 Boiler Plant Mechanical Equipment 11-17 23 51 00 Breechings, Chimneys, and Stacks 08-17 23 52 25 Low-Pressure Water Heating Boilers 08-17 23 52 28 Low Pressure Steam Boilers 08-17 23 52 33 Water-Tube Boilers 08-17 23 52 39 Fire-Tube Boilers 08-17 23 56 00 Solar Energy Heating System 06-16 23 57 33 Geothermal Energy – Direct Use (Heating Applications) 06-16 23 64 00 Packaged Water Chillers 04-11

00 01 10-8

23 65 00 Cooling Towers 02-15 23 72 00 Air-to-Air Energy Recovery Equipment 05-11 23 73 00 Indoor Central-Station Air-Handling Units 04-11 23 74 13 Packaged, Outdoor, Central-Station Air-Handling Units 04-11 23 81 00 Decentralized Unitary HVAC Equipment 02-11 23 81 23 Computer-Room Air-Conditioners 04-11 23 81 43 Air-Source Unitary Heat Pumps 04-11 23 81 46 Water-Source Unitary Heat Pumps 04-11 23 81 49 Ground-Source Heat Pump 06-16 23 82 00 Convection Heating and Cooling Units 04-11 23 82 16 Air Coils 04-11 23 84 00 Humidity Control Equipment 05-11

DIVISION 25 – INTEGRATED AUTOMATION

25 10 10 Advanced Utility Metering System 02-10

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 13 Medium-Voltage Cables 01-17 26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17 26 05 26 Grounding and Bonding for Electrical Systems 01-17 26 05 33 Raceway and Boxes for Electrical Systems 01-18 26 05 36 Wireways for Radiology Equipment 01-18 26 05 39 Underfloor Raceways for Electrical Systems 01-18 26 05 41 Underground Electrical Construction 01-17 26 05 73 Overcurrent Protective Device Coordination Study 01-18 26 08 00 Commissioning of Electrical Systems 11-16 26 09 23 Lighting Controls 01-18 26 11 16 Secondary Unit Substations 01-18 26 12 19 Pad-Mounted, Liquid-Filled, Medium-Voltage Transformers 01-18 26 13 13 Medium-Voltage Circuit Breaker Switchgear 01-17 26 13 16 Medium-Voltage Fusible Interrupter Switches 01-17 26 20 11 Isolated Power Systems 01-18 26 22 00 Low-Voltage Transformers 01-18 26 23 00 Low-Voltage Switchgear 01-17 26 23 13 Generator Paralleling Controls 01-17 26 24 13 Distribution Switchboards 01-18 26 24 16 Panelboards 01-18 26 24 19 Motor Control Centers 01-18 26 25 11 Busways 01-17 26 26 00 Power Distribution Units for Static Uninterruptible

Power Systems 01-18

26 27 26 Wiring Devices 01-18 26 29 11 Motor Controllers 01-18 26 29 21 Enclosed Switches and Circuit Breakers 01-17 26 32 13 Engine Generators 01-18 26 33 53 Static Uninterruptible Power Supply 01-17 26 35 26 Harmonic Filters 01-18 26 36 23 Automatic Transfer Switches 01-17 26 41 00 Facility Lightning Protection 01-17 26 42 00 Cathodic Protection 01-17

00 01 10-9

26 43 13 Surge Protective Devices 01-17 26 51 00 Interior Lighting 01-18 26 55 71 Medical and Surgical Lighting Fixtures 01-18 26 56 00 Exterior Lighting 01-18

DIVISION 27 – COMMUNICATIONS

27 05 11 Requirements for Communications Installations 06-15 27 05 26 Grounding and Bonding for Communications Systems 06-15 27 05 33 Raceways and Boxes for Communications Systems 06-15 27 05 61 Leased Space, Communication Equipment and Systems 06-15 27 08 00 Commissioning of Communications Systems 11-16 27 10 00 Control, Communication and Signal Wiring 06-15 27 11 00 Communications Equipment Room Fittings 06-15 27 15 00 Communications Structured Cabling 01-16 27 31 00 Voice Communications Switching and Routing Equipment 06-15 27 31 31 Voice Communications Switching and Routing Equipment -

Extension 06-15

27 32 41 Two-Way Radio Equipment and Systems 10-15 27 41 31 Master Antenna Television Equipment and Systems 06-15 27 51 16 Public Address and Mass Notification Systems 10-15 27 51 23 Intercommunications and Program Systems 06-15 27 52 23 Nurse Call and Code Blue Systems 10-15 27 52 41 Miscellaneous Medical Systems 06-15 27 53 19 Distributed Radio Antenna (Within Building) Equipment and System 09-12

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 09-11 28 05 13 Conductors and Cables for Electronic Safety and

Security 09-11

28 05 26 Grounding and Bonding for Electronic Safety and Security

09-11

28 05 28.33 Conduits and Backboxes for Electronic Safety and Security

09-11

28 08 00 Commissioning of Electronic Safety and Security Systems 11-16 28 13 00 Physical Access Control System 10-11 28 13 16 Physical Access Control System and Database Management 09-11 28 13 53 Security Access Detection 09-11 28 16 00 Intrusion Detection System 10-11 28 23 00 Video Surveillance 09-11 28 26 00 Electronic Personal Protection System 09-11 28 31 00 Fire Detection and Alarm 10-11 28 52 31 Emergency Call System 06-15

DIVISION 31 – EARTHWORK

31 20 00 Earthwork 07-16 31 20 11 Earthwork (Short Form) 10-12 31 23 19 Dewatering 10-12 31 23 23.33 Flowable Fill 10-12 31 32 23 Pressure Grouting Soil Stabilization 10-12

00 01 10-10

31 62 00 Driven Piles 10-12 31 63 16 Auger Cast Grout Piles 10-12 31 63 26 Drilled Caissons 10-12

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 05 23 Cement and Concrete for Exterior Improvements 08-16 32 12 16 Asphalt Paving 09-15 32 14 16 Brick Unit Paving 08-16 32 17 23 Pavement Markings 08-16 32 31 13 Chain Link Fences and Gates 08-16 32 31 40 High Security Fences and Gates 08-16 32 84 00 Planting Irrigation 08-16 32 90 00 Planting 08-16

DIVISION 33 – UTILITIES

33 08 00 Commissioning of Site Utility Systems 11-16 33 10 00 Water Utilities 03-17 33 30 00 Sanitary Sewer Utilities 06-13 33 40 00 Storm Sewer Utilities 12-17 33 46 13 Foundation Drainage 10-11 33 51 00 Natural-Gas Distribution 10-11 33 63 00 Steam Energy Distribution 09-17

DIVISION 34 – TRANSPORTATION

34 71 13 Vehicle Barriers 08-16 34 75 13.13 Active Vehicle Barriers 08-16

DIVISION 48 – Electrical Power Generation

48 14 00 Solar Energy Electrical Power Generation System 10-17 48 15 00 Wind Energy Electrical Power Generation System 10-17 48 16 23 Geothermal Energy Electrical Power Generation System 10-17

10-01-17 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS .................................................................................... Error! Bookmark not defined.

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.11 PHYSICAL DATA

1.12 PROFESSIONAL SURVEYING SERVICES ................................. Error! Bookmark not defined.

1.13 LAYOUT OF WORK .......................................................................... Error! Bookmark not defined.

1.14 AS-BUILT DRAWINGS

1.15 USE OF ROADWAYS ........................................................................ Error! Bookmark not defined.

1.16 RESIDENT ENGINEER'S FIELD OFFICE ............................... Error! Bookmark not defined.

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT .... Error! Bookmark not defined.

1.18 TEMPORARY USE OF EXISTING ELEVATORS

1.19 TEMPORARY USE OF NEW ELEVATORS .................................... Error! Bookmark not defined.

1.20 TEMPORARY TOILETS ................................................................... Error! Bookmark not defined.

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

1.22 NEW TELEPHONE EQUIPMENT .................................................... Error! Bookmark not defined.

ii

1.23 TESTS

1.24 INSTRUCTIONS

1.25 GOVERNMENT-FURNISHED PROPERTY ...................................... Error! Bookmark not defined.

1.26 RELOCATED // EQUIPMENT // ITEMS // .......................... Error! Bookmark not defined.

1.27 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT ........ Error!

Bookmark not defined.

1.28 CONSTRUCTION SIGN ................................................................... Error! Bookmark not defined.

1.29 SAFETY SIGN ................................................................................. Error! Bookmark not defined.

1.30 PHOTOGRAPHIC DOCUMENTATION

1.31 FINAL ELEVATION Digital Images .................................... Error! Bookmark not defined.

1.32 HISTORIC PRESERVATION ......................................................... Error! Bookmark not defined.

1.33 VA TRIRIGA CPMS ........................................................................ Error! Bookmark not defined.

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for the Legionella Mitigation project as required by drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the

Medical Center Project Manager.

C. Offices of Facilities Management Service as Design Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

E. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Work includes general construction, alterations, plumbing and electrical work necessary removal of existing structures and construction and certain other items.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

01 00 00 -2

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give four weeks’ notice to the Contracting Officer so that security escort arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

D. Key Control:

1. The General Contractor shall provide locks or door knobs with figure

8 Core. VA Project Manager will request for core assignment exclusively for contractor working on the project. VA assigned core will be accessible to VA Maintenance and Operation section, Police and project manager.

E. Document Control:

01 00 00 -3

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of

“sensitive information” as applicable.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

4. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

F. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of permits shall be issued for General Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the

Contracting Officer and shall be built with labor and materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandoned and need not be removed.

01 00 00 -4

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The

Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

D. Working space and space available for storing materials shall be as determined by the Project Manager/COR.

E. Workmen are subject to rules of Medical Center applicable to their conduct.

F. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by Project Manager/COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not more than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

G. Utilities Services: Where necessary to cut existing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire

01 00 00 -5 protection systems or communications systems (except telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by Project Manager/COR. All such actions shall be coordinated with the COR.

H. Phasing:

The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

To insure such executions, Contractor shall furnish the Project

Manager/COR with a schedule of approximate dates on which the

Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the

Project Manager/COR three weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such dates to insure accomplishment of this work in successive phases mutually agreeable to Medical Center Director, Project Manager/COR and Contractor.

I. When a construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance.

J. Utilities Services: Maintain existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by Project Manager/COR.

01 00 00 -6

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of Project Manager/COR and Chief

Engineer or Chief of Facilities Management. Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval. Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON WORK RESULTS FOR

ELECTRONIC SAFETY AND SECURITY for additional requirements.

2. Contractor shall submit a request to interrupt any such services to

Project Manager/COR, in writing, 21 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 21 calendar days prior to the desired time and shall be performed as directed by the Project Manager/COR.

5. In case of a contract construction emergency, service will be interrupted on approval of Project Manager/COR. Such approval will be confirmed in writing as soon as practical.

K. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

01 00 00 -7

L. Coordinate the work for this contract with other construction operations as directed by Project Manager/COR.

1.7 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the

Contractor fails or refuses to repair the damage promptly, the

Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the

Project Manager/COR. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the Project

Manager/COR before it is disturbed. Materials and workmanship used in

01 00 00 -8 restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING SITE CONDITIONS" (FAR

52.236-2).

1.11 PHYSICAL DATA

A. Data and information furnished or referred to below is for the

Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

1. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by Facilities

Management Service.

1.12 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

01 00 00 -9

B. All variations shall be shown in the same general detail as used in the contract drawings. To insure compliance, as-built drawings shall be made available for the Project Manager/COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the Project

Manager/COR within 15 calendar days after each completed phase and after the acceptance of the project by the Project Manager/COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.13 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing elevators for handling building materials and

Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the Project Manager/COR for use of designated elevators. The Project Manager/COR will ascertain that elevators are in proper condition.

2. Contractor covers and provides maximum protection of following elevator components:

a. Entrance jambs, heads soffits and threshold plates.

b. Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

c. Finish flooring.

1.14 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract.

B. Electricity (for Construction and Testing): Furnish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system.

01 00 00 -10

F. Water (for Construction and Testing): Furnish temporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Provide reduced pressure backflow preventer at each connection as per code. Water is available at no cost to the

Contractor.

2. Maintain connections, pipe, fittings and fixtures and conserve water-use so none is wasted. Failure to stop leakage or other wastes will be cause for revocation at Project Manager/COR discretion of use of water from Medical Center's system.

1.15 TESTS

A. As per specification section 23 05 93 the contractor shall provide a written testing and commissioning plan complete with component level, equipment level, sub-system level and system level breakdowns. The plan will provide a schedule and a written sequence of what will be tested, how and what the expected outcome will be. This document will be submitted for approval prior to commencing work. The contractor shall document the results of the approved plan and submit for approval with the as built documentation.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such systems before requesting final tests. Final test will not be conducted unless pre-tested.

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Contracting Officer.

Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

D. Mechanical and electrical systems shall be balanced, controlled and coordinated. A system is defined as the entire system which must be coordinated to work together during normal operation to produce results for which the system is designed. For example, air conditioning supply air is only one part of entire system which provides comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, controls and electricity, etc. Another example of a system which involves several components of

01 00 00 -11 different disciplines is a boiler installation. Efficient and acceptable boiler operation depends upon the coordination and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be completed within a reasonably period of time during which operating and environmental conditions remain reasonably constant and are typical of the design conditions.

F. Individual test result of any component, where required, will only be accepted when submitted with the test results of related components and of the entire system.

1.16 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals (hard copies and electronic) and verbal instructions when required by the various sections of the specifications and as hereinafter specified.

B. Manuals: Maintenance and operating manuals and one compact disc (four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the Project Manager/COR coincidental with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipment. They shall include complete information necessary for starting, adjusting, maintaining in continuous operation for long periods of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrations. Illustrations shall include "exploded" views showing and identifying each separate item. Emphasis shall be placed on the use of special tools and instruments. The function of each piece of equipment, component, accessory and control shall be clearly and thoroughly explained. All necessary precautions for the operation of the equipment and the reason for each precaution shall be clearly set forth. Manuals must reference the exact model, style and size of the piece of equipment and system being furnished. Manuals referencing equipment

01 00 00 -12 similar to but of a different model, style, and size than that furnished will not be accepted.

C. Instructions: Contractor shall provide qualified, factory-trained manufacturers' representatives to give detailed training to assigned

Department of Veterans Affairs personnel in the operation and complete maintenance for each piece of equipment. All such training will be at the job site. These requirements are more specifically detailed in the various technical sections. Instructions for different items of equipment that are component parts of a complete system, shall be given in an integrated, progressive manner. All instructors for every piece of component equipment in a system shall be available until instructions for all items included in the system have been completed.

This is to assure proper instruction in the operation of inter-related systems. All instruction periods shall be at such times as scheduled by the Project Manager/COR and shall be considered concluded only when the

Project Manager/COR is satisfied in regard to complete and thorough coverage. The contractor shall submit a course outline with associated material to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the contractual requirements. The Department of Veterans Affairs reserves the right to request the removal of, and substitution for, any instructor who, in the opinion of the Project Manager/COR, does not demonstrate sufficient qualifications in accordance with requirements for instructors above.

1.17 PHOTOGRAPHIC DOCUMENTATION

A. During the construction period through completion, provide photographic documentation of construction progress and at selected milestones including electronic indexing, navigation, storage and remote access to the documentation, as per these specifications. Provide monthly electronic copy of photographs of completed work within pay period.

- - - E N D - - -

05-01-17

01 33 23 - 1

SECTION 01 33 23

SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES

PART 1 – GENERAL

1.1 DESCRIPTION

A. This specification defines the general requirements and procedures for submittals. A submittal is information submitted for VA review to establish compliance with the contract documents.

B. Detailed submittal requirements are found in the technical sections of the contract specifications. The Contracting Officer may request submittals in addition to those specified when deemed necessary to adequately describe the work covered in the respective technical specifications at no additional cost to the government.

C. VA approval of a submittal does not relieve the Contractor of the responsibility for any error which may exist. The Contractor is responsible for fully complying with all contract requirements and the satisfactory construction of all work, including the need to check, confirm, and coordinate the work of all subcontractors for the project.

Non-compliant material incorporated in the work will be removed and replaced at the Contractor’s expense.

1.2 DEFINITIONS

A. Preconstruction Submittals: Submittals which are required prior to issuing contract notice to proceed or starting construction. For example, Certificates of insurance; Surety bonds; Site-specific safety plan; Construction progress schedule; Schedule of values; Submittal register; List of proposed subcontractors.

B. Shop Drawings: Drawings, diagrams, and schedules specifically prepared to illustrate some portion of the work. Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be integrated and coordinated.

C. Product Data: Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions, and brochures, which describe and illustrate size, physical appearance, and other characteristics of materials, systems, or equipment for some portion of the work. Samples of warranty language when the contract requires extended product warranties.

01 33 23 - 2

D. Samples: Physical examples of materials, equipment, or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged. Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project. Field samples and mock-ups constructed to establish standards by which the ensuing work can be judged.

E. Design Data: Calculations, mix designs, analyses, or other data pertaining to a part of work.

F. Test Reports: Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work. Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

G. Certificates: Document required of Contractor, or of a manufacturer, supplier, installer, or subcontractor through Contractor. The purpose is to document procedures, acceptability of methods, or personnel qualifications for a portion of the work.

H. Manufacturer's Instructions: Pre-printed material describing installation of a product, system, or material, including special notices and MSDS concerning impedances, hazards, and safety precautions.

I. Manufacturer's Field Reports: Documentation of the testing and verification actions taken by manufacturer's representative at the job site on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must indicate whether the material, product, or system has passed or failed the test.

J. Operation and Maintenance Data: Manufacturer data that is required to operate, maintain, troubleshoot, and repair equipment, including manufacturer's help, parts list, and product line documentation. This data shall be incorporated in an operations and maintenance manual.

K. Closeout Submittals: Documentation necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a phase of construction on a multi-phase contract.

1.3 SUBMITTAL REGISTER

A. The submittal register will list items of equipment and…