36C25722R0026 0001.docx

5. PROJECT NUMBER (if applicable)

CODE

7.

ADMINISTERED BY

2. AMENDMENT/MODIFICATION NUMBER

CODE

6. ISSUED BY

8. NAME AND ADDRESS OF CONTRACTOR

4. REQUISITION/PURCHASE REQ. NUMBER

3. EFFECTIVE DATE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED

PAGE OF

PAGES

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED

BPA NO.

1. CONTRACT ID CODE

FACILITY CODE

CODE

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

E. IMPORTANT:

is extended,

(a) By completing Items 8 and 15, and returning __________ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE

OF YOUR

ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY is not extended.

12. ACCOUNTING AND APPROPRIATION DATA

(REV. 11/2016)

is required to sign this document and return ___________ copies to the issuing office.

is not, A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

15C. DATE SIGNED

B. THE ABOVE NUMBERE

D CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES

SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendmen t, and is received prior to the opening hour and date specified.

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER

Contractor

16C. DATE SIGNED

14. DESCRIPTION OF AMENDMENT/MODIFICATION

16B. UNITED

STATES OF AMERICA

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER

16A. NAME AND TITLE OF

CONTRACTING OFFICER

15B. CONTRACTOR/OFFEROR

STANDARD FORM 30

PREVIOUS EDITION NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.243 (Type or print) (Type or print) (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

(Number, street, county, State and ZIP Code) (If other than Item 6) (Specify type of modification and authority) (such as changes in paying office, appropriation date, etc.)

(If required)

(SEE ITEM 11)

(SEE ITEM 13)

(X)

CHECK

ONE

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF

SOLICITATIONS

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

(Signature of person authorized to sign) (Signature of Contracting Officer) 36C25722r0026 691-19-102 Department of Veterans Affairs Central Texas Veterans HCS 2002 Scott Blvd.

Temple TX 76504 Department of Veterans Affairs Central Texas Veterans HCS 2002 Scott Blvd.

Temple TX 76504 To all Offerors/Bidders

36C25722R0026 05-06-2022

X X X ** HOUR & DATE for Receipt of Offers is EXTENDED to:

The purpose of this amendment is to:

1) Extend the offer due date May 18, 2022 at 12:00 PM PT.

2) Answer questions asked.

3) Provide a PPQ.

1. PPQ’s required with the proposal. There is no PPQ as stated in Factor 1 of the RFP when it states PPQ is an Attachment. Does the Government intend to provide a PPQ so all proposals received have the same PPQ form? Will a time extension be granted to allow PPQ’s to then be sent out to our references to complete?

a. PPQ Attached.

2. RFI’s were due on April 11th. As of this email per SAM.gov the RFI responses are not posted. Will the government be providing RFI responses? Will the government grant a time extension to review responses and finalize proposals?

a. Proposal due date is extended to May 13th as shown in page 1.

3. SF 1442 reads deadline for questions is April 11th, SAM posted the solicitation on April 12th can you please post new deadline.

a. All questions are now due by May 9th at 12:00 PM PT.

4. Factor 1: Past Performance: Are your requiring max 5 relevant projects for our A/E and max 5 projects from us for constructions – or do you need max 5 design-build projects from us (offeror)

a. Please submit a max of five recent and relevant projects.

5. Can you please extend Phase I due date to allow us to ask questions, receive answers?

a. Please see first page.

6. 5) For Factor 1: Past Performance – are you requiring a CPAR / PPQ?, or the Project information and CPAR/PPQ – if so please provide template for project information requirements.

a. A CPARS is preferred, if a CPARS isn’t available a PPQ is acceptable. Template attached.

7. PPQ Form not attached, please provide.

a. Attached.

8. Can we use previous completed PPQs – so we don’t bother the CO again.

a. Yes

See attached document: Past Performance Questionnaire.