36C25218R0482-008.pdf

Indefinite Delivery Indefinite Quantity (IDIQ) Contracts Solicitation 36C25218R0482

Solicitation Attachment 7

PRICING SCHEDULE (MATOC SEED PROJECT)

VA Project Number: 585-14-105; Renovate Building 4 for Accessibility

Price Range: $250,000 to $500,000.

Base Proposal: Contractor shall provide for and furnish all labor, materials, equipment, qualified supervision, and other items designated in this contract in accordance with the specifications and drawings to complete Project # 585-14-105; Renovate Building 4 for

Accessibility at the Oscar G. Johnson VA Medical Center in Iron Mountain, Michigan.

All work shall be completed within 120 calendar days after receiving Notice to Proceed.

Base Proposal LUMP SUM: _______________________________

NOTICE TO OFFERORS: Seed Project Award will be made to the lowest priced proposal from the successful MATOC award recipients.

NOTICE TO OFFERORS: At times, the contractor will be working in occupied buildings and the hospital. Work plans for VA review/approval are required before any work can begin associated with any of the tasks. Outages and shut-downs will need to take this information into account. Off-shift scheduling (nights/weekends) is required for outages, shutdowns, and work directly impacting patient care. The contractor will be required to keep all other non-impacted roads, walks and entrances to grounds, parking, and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles. Submittals regarding staging of equipment, crane placement, storage of supplies, etc. are required. Off-hours and/or week-end deliveries of construction equipment or materials may be required.

NOTICE TO OFFERORS: An approved cost-loaded, Critical Path Method (CPM) construction schedule is required prior to commencement of construction. See specifications for details. CPM schedule shall be approved by the Contracting Officer or the Contracting Officer’s

Representative. See specifications for details.

NOTICE TO OFFERORS: Additional information regarding the general and specific scope of work is defined in the specifications and drawings. This PRICING SCHEDULE and SCOPE OF

WORK is in addition to and augments the specifications and drawings. ONLY ONE TASK

ORDER AWARD WILL BE MADE AS A RESULT OF THIS SOLICITATION.