36C24519Q0325-001.docx

36C24519Q0325

OF

1. REQUISITION NO.

2. CONTRACT NO.

3. AWARD/EFFECTIVE DATE

4. ORDER NO.

5. SOLICITATION NUMBER

6. SOLICITATION ISSUE DATE

a. NAME

b. TELEPHONE NO. (No Collect Calls)

8. OFFER DUE DATE/LOCAL

TIME

9. ISSUED BY

CODE

10. THIS ACQUISITION IS

UNRESTRICTED OR

SET ASIDE:

% FOR:

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL

BUSINESS PROGRAM

EDWOSB

8(A)

NAICS:

SIZE STANDARD:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13b. RATING

14. METHOD OF SOLICITATION

RFQ

IFB

RFP

15. DELIVER TO

CODE

16. ADMINISTERED BY

CODE

17a. CONTRACTOR/OFFEROR

CODE

FACILITY CODE

18a. PAYMENT WILL BE MADE BY

CODE

TELEPHONE NO.

DUNS:

DUNS+4:

PHONE:

FAX:

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER 18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW IS CHECKED

SEE ADDENDUM

19.

20.

21.

22.

23.

24.

ITEM NO.

SCHEDULE OF SUPPLIES/SERVICES

QUANTITY

UNIT

UNIT PRICE

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (For Govt. Use Only) 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

ARE

ARE NOT ATTACHED.

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

ARE

ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SI

GN THIS DOCUMENT AND RETURN _______________

29. AWARD OF CONTRACT: REF. ___________________________________ OFFER

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DATED ________________________________. YOUR OFFER ON SOLICITATION

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

SET FORTH HEREIN IS ACCEPTED AS TO ITEMS:

30a. SIGN

ATURE OF OFFEROR/CONTRACTOR

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER) 30b. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (TYPE OR PRINT) 31c. DATE SIGNED

AUTHORIZED FOR

LOCAL REPRODUCTION

(REV. 2/2012)

PREVIOUS EDITION IS NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.212

7. FOR SOLICITATION

INFORMATION CALL:

STANDARD FORM 1449

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

36C24519Q0325 05-10-2019 Kristine Stout 410-637-1507 05-31-2019 noon Department of Veterans Affairs

VAMC(

688) 50 Irving Street NW Washington DC 20422 X X 541110 $11 Million X N/A X Department of Veterans Affairs

VAMC(

688) Warehouse 50 Irving Street NW Washington DC 20422 Department of Veterans Affairs

VAMC(

688) 50 Irving Street NW Washington DC 20422

PAYMENT WILL BE MADE BY

FSC e-Invoice Payment Invoice must be submitted electronically http://www.fsc.va.gov/einvoice.asp Invoice Setup Information 1-877-489-6135 See CONTINUATION Page The Contractor shall provide to the Department of Veterans Affairs (VA) legal representation for the filing and and disposition of guardianship cases when a Veteran lacks capacity to speak on their own behalf and there is no family either willing or able to act on the Veteran’s behalf.

$0.00 See CONTINUATION Page x X Table of Contents

SECTION B - CONTINUATION OF SF 1449 BLOCKS

B.1 CONTRACT ADMINISTRATION DATA

1. Contract Administration: All contract administration matters will be handled by the following individuals:

a. CONTRACTOR:

b. GOVERNMENT: Contracting Officer 36C245 Department of Veterans Affairs

VAMC(512)

209 W. Fayette St 608 Baltimore, MD 21201

2. CONTRACTOR REMITTANCE ADDRESS: All payments by the Government to the contractor will be made in accordance with:

3. INVOICES: Invoices shall be submitted in arrears:

4. GOVERNMENT INVOICE ADDRESS: All Invoices from the contractor shall be submitted electronically in accordance with VAAR Clause 852.232-72 Electronic Submission of Payment Requests.

PAYMENT WILL BE MADE BY

FSC e-Invoice Payment Invoice must be submitted electronically http://www.fsc.va.gov/einvoice.asp Invoice Setup Information 1-877-489-6135 ACKNOWLEDGMENT OF AMENDMENTS: The offeror acknowledges receipt of amendments to the Solicitation numbered and dated as follows:

Page 1 of

B.2 STATEMENT OF WORK

1. OBJECTIVE

The Contractor shall provide to the Department of Veterans Affairs (VA) legal representation for the filing and disposition of guardianship cases when a Veteran lacks capacity to speak on their own behalf and there is no family either willing or able to act on the Veteran’s behalf. The ordering period for these services shall be five years from the date of award, not to exceed $250,000 over the five-year period. Term will be on or about the below:

Year one – 6/17/2019 – 6/16/2020 Year two – 6/17/2020 – 6/16/2021 Year Three – 6/17/2021 – 6/16/2022 Year Four – 6/17/2022 – 6/16/2023 Year five – 6/17/2023 – 6/16/2024

2. Background The US Department of Veterans Affairs (VA) is committed to providing Veterans with high-quality health care to be provided in the most appropriate care setting. This goal is supported by VA Central Office (VACO) and the White House. The VA Maryland Health Care System (VAMHCS) is seeking a Contractor to assist with the provision of emergency petitions for guardianship. Guardianship is required to ensure that the Veteran have a legal representative to speak on their behalf, and to take the necessary steps to apply for available financial resources and to complete applications for admission into appropriate care settings when the Veteran’s care needs change. This represents one of the VA’s most significant efforts to provide care in the least restrictive environment of care. Our goal is to ensure that Veterans can receive care in an appropriate setting that meets their care needs.

The Department of Veterans Affairs Office of General Counsel and the Health Law Group have not given permission for the local Office of General Counsel to provide these services, which is why outside legal counsel is being sought.

The contractor will fill petitions with the Circuit Court of Maryland for Veterans who have been determined by two medical providers to lack the capacity to make decisions for themselves regarding their care. The providers will complete the Physician Certificates attesting to the above.

3. Description The VA Maryland Health Care System is seeking a Contractor to assist with guardianship petition process.

1. The Contractor shall file guardianship petitions to the Circuit Court of Maryland on behalf of the VAMHCS.

1. The Contractor shall submit all notifications to interested parties as part of the petition process.

1. The Contractor shall represent the VAMHCS in any court hearings related to the petition for guardianship.

1. The Contractor shall help prepare any VAMHCS staff that are required to testify at the guardianship hearings.

1. The contractor shall make available to the VA, copies of records and filings with the court.

1. VA program staff will collaborate with the contractor, who will provide required medical records and expert testimony.

1. The contractor shall comply with the VA Patient’s Bill of Rights as set forth in Section 17.34a, Title 38, Code of Federal Regulations.

1. The Contractor shall provide invoices in accordance with promote payment act, in a timely manner.

4. Task Orders Ordering officers (OOs) will be authorized to place orders against this contract. The Contracting Officer (CO) will furnish the Contractor with the names of individuals authorized as OOs, by separate memorandum upon issuance of the contract. When OOs are added after award, the CO will furnish the Contractor with the names of individuals authorized as OOs, by memorandum upon OO appointment. OOs are responsible for issuing and administering orders placed under this contract. OOs have no authority to modify any term of this basic contract. Any deviation from the terms of the basic contract must be approved in writing by the CO responsible for this contract. The Contractor shall accept orders against this contract only from the CO and/or authorized OOs. Fulfilling orders from persons other than the CO or OO may result in loss or delay in payment for supplies/services provided under such orders. In the even an OO is not available any warranted CO within NCO 5 can also place orders against the contract.

5. Confidentiality:

VA will provide the contractor access to pertinent patient medical information, within the existing privacy rules and regulations, for the purpose of providing coordinated comprehensive primary care. The contractor shall ensure the confidentiality of all patient information. Patient information is Protected Health Information (PHI). The term “Protected Health Information” or the abbreviation “PHI” shall include the term” Electronic Protected Health Information” and the abbreviation “EPHI”.

The contract shall be subject to the regulations issued by the Department of Health and Human Services, as mandated by the Health Insurance Portability and Accountability Act (HIPAA) of 1996, Business Associates Agreement (BAA) in accordance with IL 049-03-7 and the Privacy Act of 1974. Federal Acquisition Regulations 52.224-1 Privacy Act Notification and 52.224-2 Privacy Act are provided in full text in the Addendum to FAR clause 52.212-4. The Contractor is not authorized to release any medical record information. The VA is the sole entity authorized to release this information upon written request from the patient. Reference Policy Memorandum No. 136-48-06, dated Sept. 8, 2006, Release of Medical Information (available upon request).

6. Records:

Contractor personnel who obtain access to hardware or media which may manipulate or store drug or alcohol abuse data, sickle cell anemia treatment records, records or tests or treatment for or infection with HIV/AIDS, medical quality assurance records, or any other sensitive information protected under 38 U.S.C. Para. 4132 or Para. 3305, as defined by the Department of Veterans Affairs shall not have access to the records unless absolutely necessary to perform their contractual duties. Any individual who has access to these data shall disclose them to no one, including other employees of the contractor not involved in the performance of the particular contractual duty for which access was obtained. Violation of these statutory provisions, as stated in department regulations by which the contractor’s employees must agree to abide may involve imposition of criminal penalties.

7. Contract Performance Assessment Reporting System (CPARS) This contract will require reporting in Contractor Performance Assessment Reporting System (CPARS); therefore, the contractor shall provide a Point of Contact (POC) to the contracting officer at time of award who will be responsible for managing reports/CPARs on this contract and will be assigned the role as “contractor representative” within CPARS.

This system is used Federal-agency wide as a solution for the collection of Contractor Past Performance Information (PPI). This is being implemented throughout Veterans Health Administration (VHA) in an attempt to be in compliance with the requirements of FAR part 42 for documenting contractor performance assessments and evaluations.

Past performance information is relevant information for future source selection purposes regarding a contractor’s actions under previously awarded contracts. It includes, for example, the contractor’s record of conforming to contract requirements and to standards of good workmanship; the contractor’s record of forecasting and controlling costs; the contractor’s adherence to contract schedules, including the administrative aspects of performance; the contractor’s history of reasonable and cooperative behavior and commitment to customer satisfaction; the contractor’s record of integrity and business ethics, and generally, the contractor’s business-like concern for the interest of the customer. Each contractor is required to register in the Contractor Performance Assessment Reporting System (CPARS) @ https://www.cpars.gov. The Contracting Officer/Contracting Officer Representative will evaluate the contractor's performance annually. The report shall be assigned in CPARS to the contractor's designated representative (contractor representative) for comment. The contractor representative will have thirty (30) days to submit any comments and then re-assign the report to the VA Contracting Officer acting as the Assessing Official within CPARS. Failure to register and respond within the thirty days will result in the Government's evaluation being placed on file in the database with a statement that the contractor failed to respond.

8.Technical Evaluation The contractor shall must be licensed to practice as a lawyer in the State of Maryland and demonstrate experience with filing guardianship petitions with the Circuit Court on behalf of health care organizations.

1. Inherently Government Functions Statement The services to be procured do not include inherently governmental functions pursuant to the definition of an inherently governmental function in paragraph 3 of Office of Federal Procurement Policy (OFPP) Policy Letter 11-01, do not appear on the list of inherently governmental functions in Appendix A of the Policy Letter, and do not otherwise qualify as an inherently governmental function taking into consideration the tests for identifying inherently governmental functions in paragraph 5-1 of the Policy Letter. The function to be contracted for is not closely associated with an inherently governmental one and the required services are not critical as defined in paragraph 3 of the Policy Letter.

B.3 PRICE/COST SCHEDULE

ITEM INFORMATION

Legal fees to process the petitions for guardianship; to include appearance in court.

PSC R418

Contract Period:

POP Begin: 06-17-2019 POP End: 06-16-2020

Court Fees for Baltimore County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee Contract Period:

Court Fees for Cecil County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Process Service/ Notice, to be charged per person requiring notification, this should include any shipping cost associated with notifying the person.

copies - to be produced double sided on postconsumer fiber content paper in accodance with FAR 52.204-4

Legal fees to process the petitions for guardianship; to include appearance in court.

Contract Period:

POP Begin: 06-17-2020 POP End: 06-16-2021

Court Fees for Baltimore County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Court Fees for Cecil County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Process Service/ Notice, to be charged per person requiring notification, this should include any shipping cost associated with notifying the person.

copies - to be produced double sided on postconsumer fiber content paper in accodance with FAR 52.204-4

Legal fees to process the petitions for guardianship; to include appearance in court.

Contract Period:

POP Begin: 06-17-2021 POP End: 06-16-2022

Court Fees for Baltimore County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Court Fees for Cecil County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Process Service/ Notice, to be charged per person requiring notification, this should include any shipping cost associated with notifying the person.

copies - to be produced double sided on postconsumer fiber content paper in accodance with FAR 52.204-4

Legal fees to process the petitions for guardianship; to include appearance in court.

Contract Period:

POP Begin: 06-17-2022 POP End: 06-16-2023

Court Fees for Baltimore County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Court Fees for Cecil County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Process Service/ Notice, to be charged per person requiring notification, this should include any shipping cost associated with notifying the person.

copies - to be produced double sided on postconsumer fiber content paper in accodance with FAR 52.204-4

Legal fees to process the petitions for guardianship; to include appearance in court.

Contract Period:

POP Begin: 06-17-2023 POP End: 06-16-2024

Court Fees for Baltimore County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Court Fees for Cecil County - These fees are set by the court and will be adjusted, once notified by the contractor, if the court changes the fee

Process Service/ Notice, to be charged per person requiring notification, this should include any shipping cost associated with notifying the person.

copies - to be produced double sided on postconsumer fiber content paper in accodance with FAR 52.204-4

***All quantities listed in the schedule are for price reasonableness purposes and are only estimates of usage in a given year. The actual quantity will vary depending on the VA need, and only the minimum guarantee of $800 is guaranteed to the awardee. This will be obligated at the time of award, however that obligation will be canceled once the first task order is issued. Regardless of totals achieved in the Grand Total at no time will the combined total of all orders under this IDIQ exceed $250,000.

SECTION C - CONTRACT CLAUSES

C.1 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL ITEMS (OCT 2018)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights—

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include—

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.—

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall—

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause;

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments

(9) The specification.

(t) [Reserved]

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an “I agree” click box or other comparable mechanism (e.g., “click-wrap” or “browse-wrap” agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause) ADDENDUM to FAR 52.212-4 CONTRACT TERMS AND CONDITIONS—COMMERCIAL ITEMS Clauses that are incorporated by reference (by Citation Number, Title, and Date), have the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

The following clauses are incorporated into 52.212-4 as an addendum to this contract:

C.2 52.216-18 ORDERING (OCT 1995)

(a) Any supplies and services to be furnished under this contract shall be ordered by issuance of delivery orders or task orders by the individuals or activities designated in the Schedule. Such orders may be issued from Award through 6/16/2024.

(b) All delivery orders or task orders are subject to the terms and conditions of this contract. In the event of conflict between a delivery order or task order and this contract, the contract shall control.

(c) If mailed, a delivery order or task order is considered "issued" when the Government deposits the order in the mail. Orders may be issued orally, by facsimile, or by electronic commerce methods only if authorized in the Schedule.

(End of Clause)

C.3 52.216-19 ORDER LIMITATIONS (OCT 1995)

(a) Minimum order. When the Government requires supplies or services covered by this contract in an amount of less than $800, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those supplies or services under the contract.

(b) Maximum order. The Contractor is not obligated to honor—

(1) Any order for a single item in excess of $4000;

(2) Any order for a combination of items in excess of $250,000; or

(3) A series of orders from the same ordering office within 5 days that together call for quantities exceeding the limitation in paragraph (b)(1) or (2) of this section.

(c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) of this section.

(d) Notwithstanding paragraphs (b) and (c) of this section, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 2 days after issuance, with written notice stating the Contractor's intent not to ship the item (or items) called for and the reasons. Upon receiving this notice, the Government may acquire the supplies or services from another source.

(End of Clause)

C.4 52.216-22 INDEFINITE QUANTITY (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum." The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum."

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after 9/30/2024.

(End of Clause)

C.5 52.217-8 OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 days.

(End of Clause)

C.6 52.232-19 AVAILABILITY OF FUNDS FOR THE NEXT FISCAL YEAR (APR 1984)

Funds are not presently available for performance under this contract beyond 9/30/2019. The Government's obligation for performance of this contract beyond that date is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise for performance under this contract beyond 9/30/2019, until funds are made available to the Contracting Officer for performance and until the Contractor receives notice of availability, to be confirmed in writing by the Contracting Officer.

(End of Clause)

C.7 VAAR 852.203-70 COMMERCIAL ADVERTISING (MAY 2018)

The Contractor shall not make reference in its commercial advertising to Department of Veterans Affairs contracts in a manner that states or implies the Department of Veterans Affairs approves or endorses the Contractor’s products or services or considers the Contractor’s products or services superior to other products or services.

(End of Clause) C.8 VAAR 852.219-10 VA NOTICE OF TOTAL SERVICE-DISABLED VETERAN-OWNED SMALL BUSINESS SET-ASIDE (JUL 2016)(DEVIATION)

(a) Definition. For the Department of Veterans Affairs, “Service-disabled veteran-owned small business concern or SDVSOB”:

(1) Means a small business concern:

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans or eligible surviving spouses (see VAAR 802.201 Surviving Spouse definition);

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans (or eligible surviving spouses) or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran;

(iii) The business meets Federal small business size standards for the applicable North American Industry Classification System (NAICS) code identified in the solicitation document;

(iv) The business has been verified for ownership and control pursuant to 38 CFR 74 and is so listed in the Vendor Information Pages database, (https://www.vip.vetbiz.gov); and

(v) The business will comply with subcontracting limitations in 13 CFR 125.6, as applicable

(2) “Service-disabled veteran” means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

(b) General.

(1) Offers are solicited only from verified service-disabled veteran-owned small business concerns. Offers received from concerns that are not verified service-disabled veteran-owned small business concerns shall not be considered.

(2) Any award resulting from this solicitation shall be made to a verified service-disabled veteran-owned small business concern.

(c) Agreement. A service-disabled veteran-owned small business concern agrees that in the performance of the contract, the concern will comply with the limitation on subcontracting requirements in 13 CFR §125.6.

(d) A joint venture may be considered a service-disabled veteran owned small business concern if the joint venture complies with the requirements in 13 CFR 125.15, provided that any reference therein to SDVO SBC is to be construed to apply to a VA verified SDVOSB as appropriate.

(e) Any service-disabled veteran-owned small business concern (non-manufacturer) must meet the requirements in FAR 19.102(f) of the Federal Acquisition Regulation to receive a benefit under this program.

(End of Clause) C.9 VAAR 852.219-74 LIMITATIONS ON SUBCONTRACTING—MONITORING AND COMPLIANCE (JUL 2018)

(a) This solicitation includes VAAR 852.219-10 VA Notice of Total Service- Disabled Veteran-Owned Small Business Set-Aside.

(b) Accordingly, any contract resulting from this solicitation is subject to the limitation on subcontracting requirements in 13 CFR 125.6, or the limitations on subcontracting requirements in the FAR clause, as applicable. The Contractor is advised that in performing contract administration functions, the Contracting Officer may use the services of a support contractor(s) retained by VA to assist in assessing the Contractor's compliance with the limitations on subcontracting or percentage of work performance requirements specified in the clause. To that end, the support contractor(s) may require access to Contractor's offices where the Contractor's business records or other proprietary data are retained and to review such business records regarding the Contractor's compliance with this requirement.

(c) All support contractors conducting this review on behalf of VA will be required to sign an “Information Protection and Non-Disclosure and Disclosure of Conflicts of Interest Agreement” to ensure the Contractor's business records or other proprietary data reviewed or obtained in the course of assisting the Contracting Officer in assessing the Contractor for compliance are protected to ensure information or data is not improperly disclosed or other impropriety occurs.

(d) Furthermore, if VA determines any services the support contractor(s) will perform in assessing compliance are advisory and assistance services as defined in FAR 2.101, Definitions, the support contractor(s) must also enter into an agreement with the Contractor to protect proprietary information as required by FAR 9.505-4, Obtaining access to proprietary information, paragraph (b). The Contractor is required to cooperate fully and make available any records as may be required to enable the Contracting Officer to assess the Contractor's compliance with the limitations on subcontracting or percentage of work performance requirement.

(End of Clause)

C.10 VAAR 852.232-72 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (NOV 2018)

(a) Definitions. As used in this clause—

(1) Contract financing payment has the meaning given in FAR 32.001;

(2) Designated agency office means the office designated by the purchase order, agreement, or contract to first receive and review invoices. This office can be contractually designated as the receiving entity. This office may be different from the office issuing the payment;

(3) Electronic form means an automated system transmitting information electronically according to the accepted electronic data transmission methods and formats identified in paragraph (c) of this clause. Facsimile, email, and scanned documents are not acceptable electronic forms for submission of payment requests;

(4) Invoice payment has the meaning given in FAR 32.001; and

(5) Payment request means any request for contract financing payment or invoice payment submitted by the contractor under this contract.

(b) Electronic payment requests. Except as provided in paragraph (e) of this clause, the contractor shall submit payment requests in electronic form. Purchases paid with a Government-wide commercial purchase card are considered to be an electronic transaction for purposes of this rule, and therefore no additional electronic invoice submission is required.

(c) Data transmission. A contractor must ensure that the data transmission method and format are through one of the following:

(1) VA’s Electronic Invoice Presentment and Payment System at the current website address provided in the contract.

(2) Any system that conforms to the X12 electronic data interchange (EDI) formats established by the Accredited Standards Center (ASC) and chartered by the American National Standards Institute (ANSI).

(d) Invoice requirements. Invoices shall comply with FAR 32.905.

(e) Exceptions. If, based on one of the circumstances in this paragraph (e), the Contracting Officer directs that payment requests be made by mail, the Contractor shall submit payment requests by mail through the United States Postal Service to the designated agency office. Submission of payment requests by mail may be required for—

(1) Awards made to foreign vendors for work performed outside the United States;

(2) Classified contracts or purchases when electronic submission and processing of payment requests could compromise the safeguarding of classified or privacy information;

(3) Contracts awarded by contracting officers in the conduct of emergency operations, such as responses to national emergencies;

(4) Solicitations or contracts in which the designated agency office is a VA entity other than the VA Financial Services Center in Austin, Texas; or

(5) Solicitations or contracts in which the VA designated agency office does not have electronic invoicing capability as described above.

(End of Clause)

C.11 VAAR 852.237-70 CONTRACTOR RESPONSIBILITIES (APR 1984)

The contractor shall obtain all necessary licenses and/or permits required to perform this work. He/she shall take all reasonable precautions necessary to protect persons and property from injury or damage during the performance of this contract. He/she shall be responsible for any injury to himself/herself, his/her employees, as well as for any damage to personal or public property that occurs during the performance of this contract that is caused by his/her employees fault or negligence, and shall maintain personal liability and property damage insurance having coverage for a limit as required by the laws of the State of Maryland.