RLP w. Attachments 2KS0136 Parking Wichita.pdf

GSA TEMPLATE R103 (10/24)

GSA REQUEST

FOR LEASE

PROPOSALS

NO. 2KS0136

Wichita, KS

Offers due by 04/30/2025

In order to be considered for award, offers conforming to the requirements of the RLP shall be received no later than 5 PM, Central on the date above. See “Receipt Of Lease Proposals” herein for additional information.

This Request for Lease Proposals ("RLP") sets forth instructions and requirements for proposals for a Lease described in the RLP documents. Proposals conforming to the RLP requirements will be evaluated in accordance with the Basis of Award set forth herein to select an Offeror for award. The Government will award the Lease to the selected Offeror, subject to the conditions herein.

The information collection requirements contained in this Solicitation/Contract, that are not required by regulation, have been approved by the Office of Management and Budget pursuant to the Paperwork Reduction Act and assigned the OMB Control No.

3090-0086.

SMALL RLP

TABLE OF CONTENTS

SECTION 1 - STATEMENT OF REQUIREMENTS

1.01 GENERAL INFORMATION (SMALL) (OCT 2023)

1.02 AMOUNT AND TYPE OF SPACE AND LEASE TERM (SLAT) (OCT 2020)

1.03 NORTH AMERICAN INDUSTRY CLASSIFICATION SYSTEM (NAICS) CODE AND SMALL BUSINESS SIZE

STANDARD (OCT 2023)

SECTION 2 - SOLICITATION PROVISIONS

2.01 INCORPORATED SOLICITATION PROVISIONS (SMALL) (OCT 2024)

2.02 FLOOD PLAINS (OCT 2022)

SECTION 3 - ELIGIBILITY AND PREFERENCES FOR AWARD

3.01 BASIS OF AWARD (OCT 2023)

3.02 INTENTIONALLY DELETED

3.03 INTENTIONALLY DELETED

3.04 INTENTIONALLY DELETED

3.05 INTENTIONALLY DELETED

3.06 INTENTIONALLY DELETED

3.07 HUBZONE SMALL BUSINESS CONCERN PRICE PREFERENCE WAIVER (SMALL) (OCT 2023)

SECTION 4 - HOW TO OFFER

4.01 RECEIPT OF LEASE PROPOSALS (SMALL) (OCT 2023)

4.02 PROPOSAL CONTENTS FOR SMALL LEASES (OCT 2024)

4.03 INTENTIONALLY DELETED

4.04 INTENTIONALLY DELETED

4.05 INTENTIONALLY DELETED

RLP NO. 2KS0136, PAGE 0 GSA TEMPLATE R103 (10/24)

SECTION 1 - STATEMENT OF REQUIREMENTS

1.01 GENERAL INFORMATION (SMALL) (OCT 2023)

A. This Request for Lease Proposals (RLP) sets forth instructions and requirements for proposals for a Lease described in the RLP documents.

The Government will evaluate proposals conforming to the RLP requirements in accordance with the Basis of Award set forth below to select an Offeror for award. The Government will award the Lease to the selected Offeror, subject to the conditions below.

B. Included in the RLP documents are the GSA Form 3626 (U.S. GOVERNMENT LEASE FOR REAL PROPERTY (Short Form)) which serves as an offer form and lease contract award document Supplemental Lease Requirements document, and GSA 3517A, General Clauses.

C. The Offeror's executed GSA Form 3626 shall constitute a firm offer. No Lease shall be formed until the Lease Contracting Officer (LCO) executes the GSA Form 3626 and delivers a signed copy to the Offeror.

D. Offeror may not use Federal agency name(s) and/or acronym(s), e.g., General Services Administration, GSA, in the entity name that owns and/or leases the Space to GSA.

1.02 AMOUNT AND TYPE OF SPACE AND LEASE TERM (SLAT) (OCT 2020)

CITY, STATE WICHITA, KS

DELINEATED AREA WITHIN .25 WALKABLE MILES OF 100 W 3RD ST N WICHITA, KS

67202

SPACE TYPE(S) N/A

MINIMUM SQ. FT. (ABOA) 0 SF

MAXIMUM SQ. FT. (ABOA) 0 SF

RESERVED PARKING SPACES (TOTAL) 51

RESERVED PARKING SPACES (SURFACE) 51

RESERVED PARKING SPACES (STRUCTURE) 0

INITIAL FULL TERM 60 MONTHS

TERMINATION RIGHTS 90 DAYS NOTICE

INITIAL FIRM TERM 36 MONTHS

OPTION TERM N/A

ADDITIONAL REQUIREMENTS N/A

1.03 NORTH AMERICAN INDUSTRY CLASSIFICATION SYSTEM (NAICS) CODE AND SMALL BUSINESS SIZE STANDARD (OCT 2023)

A. The North American Industry Classification System (NAICS) code for this acquisition is 531120 (Exception).

B. The small business size standard for the applicable NAICS code is found at HTTPS://WWW.SBA.GOV/DOCUMENT/SUPPORT-TABLE-SIZE-

STANDARDS STANDARDS.

https://www.sba.gov/document/support-table-size-standards https://www.sba.gov/document/support-table-size-standards

RLP NO. 2KS0136, PAGE 1 GSA TEMPLATE R103 (10/24)

SECTION 2 - SOLICITATION PROVISIONS

2.01 INCORPORATED SOLICITATION PROVISIONS (SMALL) (OCT 2024)

GSA 3516A, SOLICITATION PROVISIONS (For Simplified Acquisition of Leasehold Interests in Real Property) are attached to this RLP.

2.02 FLOOD PLAINS (OCT 2022)

A. A Lease will not be awarded for any offered Property located within a 1-percent-annual-chance floodplain (formerly referred to as 100-year floodplain) unless the Government has determined that there is no practicable alternative. An Offeror may offer less than its entire site in order to exclude a portion of the site that falls within a floodplain, so long as the portion offered meets all the requirements of this RLP and does not impact the Government’s full use and enjoyment of the Premises. If an Offeror intends that the offered Property that will become the Premises for purposes of this Lease will be something other than the entire site as recorded in tax or other property records the Offeror shall clearly demarcate the offered Property on its site plan/map submissions and shall propose an adjustment to property taxes on an appropriate pro rata basis. For such an offer, the Government may determine that the offered Property does not adequately avoid development in a 1-percent-annual-chance floodplain.

B. In addition, a Lease will not be awarded for any offered Property adjacent to 1-percent-annual-chance floodplain, where such an adjacency would, as determined by the Government, restrict ingress or egress to the Premises in the event of a flood, unless there is no practicable alternative.

RLP NO. 2KS0136, PAGE 2 GSA TEMPLATE R103 (10/24)

SECTION 3 - ELIGIBILITY AND PREFERENCES FOR AWARD

3.01 BASIS OF AWARD (OCT 2023)

A. Lowest Price Technically Acceptable Approach. The Lease will be awarded to the responsible Offeror whose offer conforms to the requirements of this RLP and Lease documents and is the lowest priced technically acceptable offer submitted, based on the lowest price per square foot, according to the ANSI/BOMA Z65.1-2017 definition for Occupant Area, which means “the total aggregated area used by an Occupant before Load Factors are applied, consisting of Tenant Area and Tenant Ancillary Area.” The Method A – Multiple Load Factor Method shall apply.

B. Price evaluation will be based on the lowest price per square foot, according to the ANSI/BOMA Z65.1-2017 definition for Occupant Area, which means “the total aggregated area used by an Occupant before Load Factors are applied, consisting of Tenant Area and Tenant Ancillary Area.”

The Method A – Multiple Load Factor Method shall apply.

C. See FAR Clause 52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns, as listed under the attached GSA

3517A, General Clauses.

D. If an offer contains terms taking exception to or modifying any Lease provision, the Government will not be under any obligation to award a Lease in response to that offer.

3.02 INTENTIONALLY DELETED

3.03 INTENTIONALLY DELETED

3.04 INTENTIONALLY DELETED

3.05 INTENTIONALLY DELETED

3.06 INTENTIONALLY DELETED

3.07 HUBZONE SMALL BUSINESS CONCERN PRICE PREFERENCE WAIVER (SMALL) (OCT 2023)

A HUBZone small business concern (SBC) Offeror may elect to waive the price evaluation preference provided in the “Basis of Award” paragraph. In such a case, no price evaluation preference shall apply to the evaluation of the HUBZone SBC.

RLP NO. 2KS0136, PAGE 3 GSA TEMPLATE R103 (10/24)

SECTION 4 - HOW TO OFFER

4.01 RECEIPT OF LEASE PROPOSALS (SMALL) (OCT 2023)

A. Offeror is authorized to transmit its lease proposal as an attachment to an email. Offeror's email shall include the name, address and telephone number of the Offeror, and identify the name and title of the individual signing on behalf of the Offeror. Offeror's signed Lease proposal must be saved in a generally accessible format (such as portable document format (pdf)), which displays a visible image of all original document signatures and must be transmitted as an attachment to the email. Only emails transmitted to, and received at, the GSA email address identified in the RLP will be accepted. Offeror submitting a Lease proposal by email shall retain in its possession, and make available upon GSA's request, its original signed proposal. Offeror choosing not to submit its proposal via email may still submit its lease proposal, by United States mail, or other express delivery service of Offeror's choosing.

B. In order to be considered for award, offers conforming to the requirements of the RLP shall be received no later than 5 PM central on the date specified below at the following designated office and address, or email address:

Date: April 30, 2025

Office Address:

General Services Administration Attn: Andrew Moeller 2300 Main St., 7SE, Kansas City, MO 64108

Email Address: Andrew.Moeller@gsa.gov

C. Offers sent by United States mail or hand delivered (including delivery by commercial carrier) shall be deemed late if delivered to the address of the office designated for receipt of offers after the date and time established for receipt of offers.

D. Offers transmitted through email shall be deemed late if received at the designated email address after the date and time established for receipt of offers unless it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one Working Day prior to the date specified for receipt of proposals.

E. Offers may be also deemed timely if there is acceptable evidence to establish that it was received at the Government installation designated for receipt of proposals and was under the Government’s control prior to the time set for receipt of proposals; or if it was the only proposal received.

F. There will be no public opening of offers, and all offers will be confidential until the Lease has been awarded. However, the Government may release proposals outside the Government such as to support contractors to assist in the evaluation of offers. Such Government contractors shall be required to protect the data from unauthorized disclosure.

4.02 PROPOSAL CONTENTS FOR SMALL LEASES (OCT 2024)

The proposal shall consist of the following documents:

DOCUMENT NAME OR DESCRIPTION

U.S. Government Lease For Real Property (Short Form) (GSA Form 3626), completed and signed by Offeror GSA 3517A, General Clauses, initialed by Offeror Registration in the System for Award Management (SAM) prior to the Lease Award Date, including completion of all required representations and certifications. This registration service is free of charge.

Evidence of ownership or control of Building or site, including a copy of the Property deed Authorization from the ownership entity to submit an offer on the ownership entity’s behalf, if the offeror is not the owner of the Property Proof of signing authority (see GSA 3516A, Solicitation Provisions) FAR 52.204-24, Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment

4.03 INTENTIONALLY DELETED

4.04 INTENTIONALLY DELETED

4.05 INTENTIONALLY DELETED

GENERAL SERVICES ADMINISTRATION GSA FORM 3626 (REV 10/21)

U.S. GOVERNMENT LEASE FOR REAL PROPERTY

(Short Form) 1a. LEASE NUMBER

LKS00559

1b. BUILDING NUMBER N/A

PART I - OFFER (Offeror completes Section A, C and D; Government shall complete Section B)

NOTE: All offers are subject to the terms and conditions outlined in Request for Lease Proposals No. 2KS0136 , Supplemental Lease Requirements document, General Clauses (GSA Form 3517A), and any other attachments included herein.

A. LOCATION AND DESCRIPTION OF PREMISES OFFERED FOR LEASE BY GOVERNMENT

1. NAME AND ADDRESS OF

BUILDING (Include nine-digit ZIP Code)

2. LOCATION(S) IN BUILDING

South West Corner of 3rd

Street and North Main

Wichita, Kansas 67202-

2a. FLOOR(S)

N/A

2b. ROOM NUMBER(S)

2e NUMBER OF PARKING SPACES

OFFERED

STRUCTURED 0

SURFACE 51

ANNUAL PARKING RATES (IF NOT

INCLUDED IN RATES UNDER PART C

BELOW)

STRUCTURED /space

SURFACE /space

2c. SQ. FT.

RENTABLE N/A

ABOA N/A

Common Area Factor

N/A

2d. TYPE

GENERAL OFFICE

WAREHOUSE

OTHER (Specify) Only parking

B. TERM

3a. To have and to hold the said Premises with its appurtenances for the term beginning upon acceptance of the Premises as required by this Lease and continuing for a period of 5 Years, 5 Years firm, subject to termination and renewal rights as may be hereinafter set forth. The commencement date of this Lease, along with any applicable termination and renewal rights, shall be more specifically set forth in a Lease Amendment upon substantial completion and acceptance of the Space by the Government.

3b. The Government may terminate this Lease, in whole or in parts, at any time effective after the Firm Term of this Lease, by providing not less than 60 days prior written notice to the Lessor. The effective date of the termination shall be the day following the expiration of the required notice period or the termination date set forth in the notice, whichever is later. No rental shall accrue after the effective date of termination.

C. RENTAL

4. Rent shall be payable in arrears and will be due on the first workday of each month. When the date for commencement of the lease falls after the 15th day of the month, the initial rental payment shall be due on the first workday of the second month following the commencement date. Rent for a period of less than a month shall be prorated. Rent shall not be adjusted for changes in real estate taxes or operating costs.

5a. AMOUNT OF ANNUAL RENT

5b. RATE PER MONTH

RENTAL RATE BREAKDOWN FIRM TERM

($/RSF/YEAR)

NON-FIRM TERM

($/RSF/YEAR)

RENEWAL TERM

($/RSF/YEAR)

6. BUILDING SHELL RENT

(INCL. REAL ESTATE TAXES)

6a. N/A

6b. N/A 6c. N/A

7. OPERATING RENT 7a. N/A

7b. N/A 7b. N/A

8. TURNKEY TENANT

IMPROVEMENT RENT

(See blocks 12 and 13 below for additional breakdown of cost and amortization rate )

8a. N/A

8b. N/A 8c. N/A

9. BUILDING SPECIFIC

AMORTIZED CAPITAL (IF

APPLICABLE)

9a. N/A

9b. N/A 9c. N/A

10. TOTAL RENT 10a. $

10b. N/A 10c. N/A

11. TENANT IMPROVEMENT COSTS

12. INTEREST RATE TO AMORTIZE TENANT

IMPROVEMENTS

13. HVAC OVERTIME RATE PER HOUR N/A 14. ADJUSTMENT FOR VACANT PREMISES RATE

($/ABOA SF/YEAR) N/A

D. OWNER IDENTIFICATION AND CERTIFICATION

GENERAL SERVICES ADMINISTRATION GSA FORM 3626 (REV 10/21)

15. RECORDED OWNER

15a. Name City of Wichita

15b. Unique Entity Identifier (UEI)

ZK7SHNPA2LQ3

15c. Address 455 North Main

15d. City Wichita

15e. State Kansas

15f. ZIP + 4 67202 + 1600

16. BY SUBMITTING THIS OFFER, THE OFFEROR AGREES UPON ACCEPTANCE OF THIS PROPOSAL BY HEREIN SPECIFIED DATE, TO LEASE TO THE UNITED STATES OF AMERICA, THE PREMISES DESCRIBED, UPON THE TERMS AND CONDITIONS AS SPECIFIED HEREIN, IN FULL COMPLIANCE WITH AND ACCEPTANCE OF THE AFOREMENTIONED RLP, WITH ATTACHMENTS.

I have read the RLP with attachments in its entirety and am requesting no deviations

17. OFFEROR’S INTEREST IN PROPERTY

OWNER AUTHORIZED AGENT OTHER (Specify)

18. OFFEROR Check if same as Recorded Owner 18a. NAME

18b. ADDRESS

18c. CITY

18d. STATE

18e. ZIP + 4

18f. Title

18g. E-mail address

18h. Telephone Number

18i. OFFEROR’S SIGNATURE

18j. DATE SIGNED

PART II - AWARD (To be completed by Government)

1. Your offer is hereby accepted. This award consummates the Lease, which consists of the following attached documents: (a) this GSA Form 3626,

(b) Supplemental Lease Requirements, (c) Security Requirements, (d) Agency Specific Requirements, (e) Floor Plan delineating the Premises, (f) GSA Form 3517A, General Clauses (Acquisition of Leasehold Interests in Real Property for Small Leases), and (g) the following building improvements, changes or additions made or agreed to by you (for example, energy efficiency and conservation improvements, ABAAS upgrades, Seismic Form C - Building Retrofit or New Construction Pre-Award Commitment (if applicable)):

2. THIS DOCUMENT IS NOT BINDING ON THE GOVERNMENT OF THE UNITED STATES OF AMERICA UNLESS SIGNED BELOW BY

AUTHORIZED LEASE CONTRACTING OFFICER.

3a. NAME OF LEASE CONTRACTING OFFICER (Type or Print)

3b. SIGNATURE OF LEASE

CONTRACTING OFFICER

3c. DATE

LESSOR:______ GOVERNMENT:______ GSA Template 3517A –

REV (02/25)

GENERAL CLAUSES

(Acquisition of Leasehold Interests in Real Property for Leases at or Below the Simplified Lease Acquisition Threshold - SLAT)

CLAUSE NO. 48 CFR REF. CLAUSE TITLE

1 GSAR 552.270-4 DEFINITIONS (DEVIATION)

2 GSAR 552.270-6 MAINTENANCE OF THE PROPERTY, RIGHT TO INSPECT

(DEVIATION)

3 GSAR 552.270-7 FIRE AND CASUALTY DAMAGE (DEVIATION)

4 GSAR 552.270-9 INSPECTION – RIGHT OF ENTRY

5 GSAR 552.270-10 DEFAULT BY LESSOR (DEVIATION)

6 GSAR 552.270-20 PAYMENT (DEVIATION)

7 GSAR 552.270-27 INTEGRATED AGREEMENT (DEVIATION)

8 GSAR 552.270-14 CHANGES (DEVIATION)

9 GSAR 552.270-8 COMPLIANCE WITH APPLICABLE LAW (DEVIATION)

10 FAR 52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR

INFORMATION SYSTEMS

11 FAR 52.204-30 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT

ORDERS – PROHIBITION

12 FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE

13 Clauses incorporated by reference include:

FAR 52.204-2 SECURITY REQUIREMENTS

FAR 52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR

PERSONNEL

FAR 52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST TIER

SUBCONTRACT AWARDS

FAR 52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE

FAR 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS

AND CERTIFICATIONS

FAR 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE,

SOFTWARE, AND SERVICES DEVELOPED OR PROVIDED BY

KASPERSKY LAB AND OTHER COVERED ENTITIES

FAR 52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN

TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES OR EQUIPMENT

FAR 52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION

FAR 52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN

SUBCONTRACTING WITH CONTRACTORS DEBARRED,

SUSPENDED, OR PROPOSED FOR DEBARMENT

FAR 52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR

PRICING DATA

FAR 52.215-12 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA

FAR 52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR

HUBZONE SMALL BUSINESS CONCERNS

FAR 52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN

FAR 52.219-16 LIQUIDATED DAMAGES – SUBCONTRACTING PLAN

FAR 52.219-28 POST-AWARD SMALL BUSINESS REREPRESENTATION

FAR 52.222-35 EQUAL OPPORTUNITY FOR VETERANS

FAR 52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES

FAR 52.222-37 EMPLOYMENT REPORTS ON VETERANS

FAR 52.226-7 DRUG-FREE WORKPLACE

FAR 52.232-23 ASSIGNMENT OF CLAIMS

FAR 52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER SYSTEM –

SYSTEM FOR AWARD MANAGEMENT

FAR 52.233-1 DISPUTES

GSAR 552.204-9 PERSONAL IDENTITY VERIFICATION REQUIREMENTS

GSAR 552.270-12 ALTERATIONS

GSAR 552.270-16 ADJUSTMENT FOR VACANT PREMISES

GSAR 552.270-28 MUTUALITY OF OBLIGATION

GSAR 552.270-31 PROMPT PAYMENT

1. GSAR 552.270-4 DEFINITIONS (AUG 2023) (DEVIATION)

When a solicitation or contract uses a word or term that is defined in the Federal Acquisition Regulation (FAR) or General Services Acquisition Manual (GSAM), the word or term has the same meaning as the definition in FAR 2.101, GSAM 502.101, or GSAM 570.102 in effect at the time the solicitation was issued or lease contract was awarded, unless -

(a) The solicitation, amended solicitation, or lease contract provides a different definition (e.g., R100, L100);

(b) An applicable part, subpart, or section of the FAR or GSAM provides a different meaning.

2. GSAR 552.270-6 MAINTENANCE OF THE PROPERTY, RIGHT TO INSPECT (SEP 2022)

(DEVIATION)

The Lessor shall maintain the property, including the building, building systems, and all equipment, fixtures, and appurtenances furnished by the Lessor under this lease, in good repair and tenantable condition so that they are suitable in appearance and capable of supplying such heat, air conditioning, light, ventilation, safety systems, access and other things to the premises, without reasonably preventable or recurring disruption, as is required for the Government’s access to, occupancy, possession, use and enjoyment of the premises as provided in this lease.

(a) For the purpose of so maintaining the premises, the Lessor may at reasonable times enter the premises with the approval of the authorized Government representative in charge.

(b) Upon request of the Lease Contracting Officer (LCO), the Lessor shall provide written documentation that building systems have been properly maintained, tested, and are operational within manufacturer's warranted operating standards.

(c) The Lessor shall maintain the premises in a safe and healthful condition according to applicable OSHA standards and all other requirements of this lease, including standards governing indoor air quality, existence of mold and other biological hazards, presence of hazardous materials, etc.

(d) The Government shall have the right, at any time after the lease award date and during the term of the lease, to inspect all areas of the property to which access is necessary for the purpose of determining the Lessor’s compliance with this clause.

3. GSAR 552.270-7 FIRE AND CASUALTY DAMAGE (SEP 2022) (DEVIATION)

(a) If the building in which the premises are located is totally destroyed or damaged by fire or other casualty, this lease shall immediately terminate.

(b) If the building in which the premises are located are only partially destroyed or damaged, so as to render the premises untenantable, or not usable for their intended purpose:

(1) The Lessor shall have the option to elect to repair and restore the premises or terminate the lease.

(2) Unless otherwise approved by the Lease Contracting Officer, the Lessor shall be permitted a reasonable amount of time, not to exceed 270 days from the event of destruction or damage, to repair or restore the premises, provided that the Lessor submits to the Government a reasonable schedule for repair of the premises within 60 days of the event of destruction or damage.

(i) If the Lessor fails to timely submit a reasonable schedule for completing the work, the Government may elect to terminate the lease effective as of the date of the event of destruction or damage.

(ii) If the Lessor elects to repair or restore the premises, but fails to repair or restore the premises within 270 days from the event of destruction or damage, or fails to diligently pursue such repairs or restoration so as to render timely completion commercially impracticable, the Government may terminate the lease effective as of the date of the destruction or damage.

(3) During the time that the premises are unoccupied, rent shall be abated. Termination of the lease by either party under this clause shall not give rise to liability for either party.

(4) Nothing in this lease shall be construed as relieving Lessor from liability for damage to or destruction of property of the United States of America caused by the willful or negligent act or omission of Lessor.

4. GSAR 552.270-9 INSPECTION – RIGHT OF ENTRY (SEP 1999)

a) At any time and from time to time after receipt of an offer (until the same has been duly withdrawn or rejected), after acceptance thereof and during the term, the agents, employees and contractors of the Government may, upon reasonable prior notice to Offeror or Lessor, enter upon the offered premises or the premises, and all other areas of the building access to which is necessary to accomplish the purposes of entry, to determine the potential or actual compliance by the Offeror or Lessor with the requirements of the solicitation or this lease, which purposes shall include, but not be limited to:

(1) Inspecting, sampling and analyzing suspected asbestos-containing materials and air monitoring for asbestos fibers;

(2) Inspecting the heating, ventilation and air conditioning system, maintenance records, and mechanical rooms for the offered premises or the premises;

(3) Inspecting for any leaks, spills, or other potentially hazardous conditions which may involve tenant exposure to hazardous or toxic substances; and

(4) Inspecting for any current or past hazardous waste operations, to ensure that appropriate mitigative actions were taken to alleviate any environmentally unsound activities in accordance with Federal, State and local law.

b) Nothing in this clause shall be construed to create a Government duty to inspect for toxic materials or to impose a higher standard of care on the Government than on other lessees.

The purpose of this clause is to promote the ease with which the Government may inspect the building. Nothing in this clause shall act to relieve the Lessor of any duty to inspect or liability which might arise as a result of Lessor’s failure to inspect for or correct a hazardous condition.

5. GSAR 552.270-10 DEFAULT BY LESSOR (JUL 2023) (DEVIATION)

Occurrence of the following constitutes default by the Lessor and gives rise to the following rights and remedies of the Government:

(a) Prior to acceptance of the space. Failure by the Lessor to perform diligently any obligations required for acceptance of the space or other required improvements within the times specified, other than due to an excusable delay, shall constitute a default by the Lessor.

Subject to provision of notice of default to the Lessor, and provision of a reasonable opportunity for the Lessor to cure its default, the Government may, in its sole discretion, terminate the lease on account of the Lessor's default.

(b) After acceptance of the space. Failure by the Lessor to perform any service, to provide any item, or satisfy any requirement of this lease, other than due to an excusable delay, constitutes a default by the Lessor. Subject to provision of notice of default to the Lessor, and provision of a reasonable opportunity for the Lessor to cure its default, the Government may, in its sole discretion, take one or more of the following actions:

(1) Perform the service, provide the item, or obtain satisfaction of the requirement by its own employees or contractors. If the Government elects to take such action, the Government may deduct from rental payments its costs, including administrative costs, incurred in connection with taking the action;

(2) Reduce the rent by an amount reasonably calculated to approximate the cost or value of the service not performed, item not provided, or requirement not satisfied, such reduction effective as of the date of the commencement of the default condition.

If default renders the leased premises untenable, the reduction of rent may be calculated as the prorated portion of the monthly rent represented by all such days the leased premises is untenantable;

(3) Terminate the lease if:

(i) The Lessor's default persists notwithstanding provision of notice and reasonable opportunity to cure by the Government, or

(ii) The Lessor fails to take such actions as are necessary to prevent the recurrence of default conditions, and such conditions substantially impair the safe and healthful occupancy of the premises, or render the premises unusable for its intended purposes.

(c) Damages. The Lessor and the Lessor sureties, if any, are jointly and severally liable for any damages to the Government resulting from default or termination, as provided in this clause.

(1) Damages include all costs associated with the replacement lease(s), which include but are not limited to the following: the Government’s aggregate rent, estimated real estate taxes, operating costs, administrative costs, or other reprocurement costs.

(2) If the Government procures replacement premises for a term (including all option terms) in excess of this lease term, the Lessor is not liable for excess Government rent or adjustments during such excess lease term.

(3) Damages to which the Government is entitled to under this clause are due and payable thirty (30) days following the date the Lessor receives notice from the Contracting Officer specifying such damages.

(d) Excusable delays.

(1) The Government shall not terminate this lease under this clause nor charge the Lessor with damages under this clause, if:

(i) the delay in substantially completing any work or performing any services arises from excusable delays, and

(ii) the Lessor, within ten (10) days from the beginning of any such delay (unless extended in writing by the Contracting Officer) provides notice to the Contracting Officer of the causes of delay.

(2) The Contracting Officer shall ascertain the facts and the extent of delay. If the facts warrant, the Contracting Officer shall extend the delivery date commensurate with the delay at no additional costs to the Government. A time extension is the sole remedy of the Lessor.

(e) No deduction from rent, termination of lease, or any other action pursuant to this clause will constitute a default by the Government under this lease.

(f) The rights and remedies specified in this clause are in addition to any and all remedies to which the Government may be entitled as a matter of law.

6. GSAR 552.270-20 PAYMENT (AUG 2023) (DEVIATION)

(a) When space is offered and accepted, ANSI/BOMA Occupant Area (ABOA) square footage delivered will be confirmed by either:

(1) The Government’s measurement of plans submitted by the successful offeror as approved by the Government, and an inspection of the space to verify that the delivered space conforms with such plans; or

(2) A mutual on-site measurement of the space if the Contracting Officer determines it necessary.

(b) The Government will not pay for space in excess of the amount of ABOA square footage stated in the lease.

(c) If the amount of ABOA square footage delivered is less than the amount agreed to in the lease, the lease will be modified to reflect the amount of ABOA space delivered and the annual rental will be adjusted as follows:

ABOA square feet not delivered multiplied by one plus the common area factor (CAF), multiplied by the rate per rentable square foot (RSF). That is:

(d) Common Area Factor (CAF). The CAF is expressed as a percentage of the difference between the amount of rentable square feet (SF) and ABOA SF, divided by the ABOA SF. For example 11,500 RSF and 10,000 ABOA SF will have a CAF of 15% (11,500 RSF-10,000 ABOA SF)/10,000 ABOA SF.

(e) Rentable Square Footage (RSF). The RSF is calculated using the following formula for each type of space (e.g., office, warehouse, etc.) included in the premises: ABOA SF of Space x (1 + CAF) = RSF.

7. GSAR 552.270-27 INTEGRATED AGREEMENT (SEP 2022) (DEVIATION)

This lease, upon execution, contains the entire agreement of the parties and no prior written or oral agreement, express or implied, shall be admissible to contradict the provisions of the lease. Except as expressly attached to and made a part of the lease, neither the request for lease proposals nor any pre-award communications by either party shall be incorporated in the lease.

8. GSAR 552.270-14 CHANGES (SEP 2022) (DEVIATION)

(a) The Lease Contracting Officer (LCO) may at any time, by written order, direct changes to the tenant improvements within the space, building security requirements, or the services required under the lease.

(b) If any such change causes an increase or decrease in Lessor’s cost or time required for performance of its obligations under this lease, whether or not changed by the order, the Lessor shall be entitled to an amendment to the lease providing for one or more of the following:

(1) An adjustment of the delivery date.

(2) An equitable adjustment in the rental rate.

(3) A lump sum equitable adjustment. or

(4) An adjustment of the operating cost base, if applicable.

(c) The Lessor must assert its right to an amendment under this clause within 30 days from the date of receipt of the change order and must submit a proposal for adjustment. Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, the pendency of an adjustment or existence of a dispute shall not excuse the Lessor from proceeding with the change as directed.

(d) Absent a written change order from the LCO, or from a Government official to whom the LCO has explicitly and in writing delegated the authority to direct changes, the Government is not liable to Lessor under this clause.

9. GSAR 552.270-8 COMPLIANCE WITH APPLICABLE LAW (SEP 2022) (DEVIATION)

Lessor shall comply with all Federal, state, tribal, and local laws applicable to its ownership and leasing of the property, including, without limitation, laws applicable to the construction, ownership, alteration or operation of all buildings, structures, and facilities located thereon, and obtain all necessary permits, licenses and similar items at its own expense. The Government will comply with all Federal, state, tribal, and local laws applicable to and enforceable against it as a tenant under this lease, provided that nothing in this lease shall be construed as a waiver of the sovereign immunity of the Government. This lease shall be governed by Federal law.

10. FAR 52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR

INFORMATION SYSTEMS (NOV 2021)

(a) Definitions. As used in this clause—

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information ( 44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial products or commercial services, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

11. FAR 52.204-30 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS –

PROHIBITION (DEC 2023)

(a) Definitions. As used in this clause—

Covered article, as defined in 41 U.S.C. 4713(k), means—

(1) Information technology, as defined in 40 U.S.C. 11101, including cloud computing services of all types;

(2) Telecommunications equipment or telecommunications service, as those terms are defined in section 3 of the Communications Act of 1934 (47 U.S.C. 153);

(3) The processing of information on a Federal or non-Federal information system, subject to the requirements of the Controlled Unclassified Information program (see 32 CFR part 2002); or

(4) Hardware, systems, devices, software, or services that include embedded or incidental information technology.

FASCSA order means any of the following orders issued under the Federal Acquisition Supply Chain Security Act (FASCSA) requiring the removal of covered articles from executive agency information systems or the exclusion of one or more named sources or named covered articles from executive agency procurement actions, as described in 41 CFR 201– 1.303(d) and (e):

(1) The Secretary of Homeland Security may issue FASCSA orders applicable to civilian agencies, to the extent not covered by paragraph (2) or (3) of this definition. This type of FASCSA order may be referred to as a Department of Homeland Security (DHS) FASCSA order.

(2) The Secretary of Defense may issue FASCSA orders applicable to the Department of Defense (DoD) and national security systems other than sensitive compartmented information systems. This type of FASCSA order may be referred to as a DoD FASCSA order.

(3) The Director of National Intelligence (DNI) may issue FASCSA orders applicable to the intelligence community and sensitive compartmented information systems, to the extent not covered by paragraph (2) of this definition. This type of FASCSA order may be referred to as a DNI FASCSA order.

Intelligence community, as defined by 50 U.S.C. 3003(4), means the following—

(1) The Office of the Director of National Intelligence;

(2) The Central Intelligence Agency;

(3) The National Security Agency;

(4) The Defense Intelligence Agency;

(5) The National Geospatial-Intelligence Agency;

(6) The National Reconnaissance Office;

https://www.govinfo.gov/link/uscode/41/4713 https://www.govinfo.gov/link/uscode/40/11101 https://www.govinfo.gov/link/uscode/47/153 https://www.ecfr.gov/current/title-32/part-2002 https://www.ecfr.gov/current/title-41/section-201-1.303#p-201-1.303(d) https://www.ecfr.gov/current/title-41/section-201-1.303#p-201-1.303(d) https://www.ecfr.gov/current/title-41/section-201-1.303#p-201-1.303(e) https://www.govinfo.gov/link/uscode/50/3003

(7) Other offices within the Department of Defense for the collection of specialized national intelligence through reconnaissance programs;

(8) The intelligence elements of the Army, the Navy, the Air Force, the Marine Corps, the Coast Guard, the Federal Bureau of Investigation, the Drug Enforcement Administration, and the Department of Energy;

(9) The Bureau of Intelligence and Research of the Department of State;

(10) The Office of Intelligence and Analysis of the Department of the Treasury;

(11) The Office of Intelligence and Analysis of the Department of Homeland Security; or

(12) Such other elements of any department or agency as may be designated by the President, or designated jointly by the Director of National Intelligence and the head of the department or agency concerned, as an element of the intelligence community.

National security system, as defined in 44 U.S.C. 3552, means any information system (including any telecommunications system) used or operated by an agency or by a contractor of an agency, or other organization on behalf of an agency—

(1) The function, operation, or use of which involves intelligence activities; involves cryptologic activities related to national security; involves command and control of military forces; involves equipment that is an integral part of a weapon or weapons system; or is critical to the direct fulfillment of military or intelligence missions, but does not include a system that is to be used for routine administrative and business applications (including payroll, finance, logistics, and personnel management applications); or

(2) Is protected at all times by procedures established for information that have been specifically authorized under criteria established by an Executive order or an Act of Congress to be kept classified in the interest of national defense or foreign policy.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of any covered articles, or any products or services produced or provided by a source. This applies when the covered article or the source is subject to an applicable FASCSA order. A reasonable inquiry excludes the need to include an internal or third-party audit.

Sensitive compartmented information means classified information concerning or derived from intelligence sources, methods, or analytical processes, which is required to be handled within formal access control systems established by the Director of National Intelligence.

Sensitive compartmented information system means a national security system authorized to process or store sensitive compartmented information.

Source means a non-Federal supplier, or potential supplier, of products or services, at any tier.

(b) Prohibition.

(1) Unless an applicable waiver has been issued by the issuing official, Contractors shall not provide or use as part of the performance of the contract any covered article, or any products or services produced or provided by a source, if the https://www.govinfo.gov/link/uscode/44/3552 covered article or the source is prohibited by an applicable FASCSA orders as follows:

(i) For solicitations and contracts awarded by a Department of Defense contracting office, DoD FASCSA orders apply.

(ii) For all other solicitations and contracts DHS FASCSA orders apply.

(2) The Contractor shall search for the phrase “FASCSA order” in the System for Award Management (SAM) at https://www.sam.gov to locate applicable FASCSA orders identified in paragraph (b)(1).

(3) The Government may identify in the solicitation additional FASCSA orders that are not in SAM, which are effective and apply to the solicitation and resultant contract.

(4) A FASCSA order issued after the date of solicitation applies to this contract only if added by an amendment to the solicitation or modification to the contract (see FAR 4.2304(c)). However, see paragraph (c) of this clause.

(5)

(i) If the contractor wishes to ask for a waiver of the requirements of a new

FASCSA order being applied through modification, then the Contractor shall disclose the following:

(A) Name of the product or service provided to the Government;

(B) Name of the covered article or source subject to a FASCSA order;

(C) If applicable, name of the vendor, including the Commercial and Government Entity code and unique entity identifier (if known), that supplied or supplies the covered article or the product or service to the Offeror;

(D) Brand;

(E) Model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

(F) Item description;

(G) Reason why the applicable covered article or the product or service is being provided or used;

(ii) Executive agency review of disclosures. The contracting officer will review disclosures provided in paragraph (b)(5)(i) to determine if any waiver is warranted. A contracting officer may choose not to pursue a waiver for covered articles or sources otherwise covered by a FASCSA order and to instead pursue other appropriate action.

(c) Notice and reporting requirement.

(1) During contract performance, the Contractor shall review SAM.gov at least once every three months, or as advised by the Contracting Officer, to check for covered https://www.sam.gov/ https://www.acquisition.gov/far/4.2304#FAR_4_2304 articles subject to FASCSA order(s), or for products or services produced by a source subject to FASCSA order(s) not currently identified under paragraph (b) of this clause.

(2) If the Contractor identifies a new FASCSA order(s) that could impact their supply chain, then the Contractor shall conduct a reasonable inquiry to identify whether a covered article or product or service produced or provided by a source subject to the FASCSA order(s) was provided to the Government or used during contract performance.

(3)

(i) The Contractor shall submit a report to the contracting office as identified in paragraph (c)(3)(ii) of this clause, if the Contractor identifies, including through any notification by a subcontractor at any tier, that a covered article or product or service produced or provided by a source was provided to the Government or used during contract performance and is subject to a FASCSA order(s) identified in paragraph (b) of this clause, or a new FASCSA order identified in paragraph (c)(2) of this clause. For indefinite delivery contracts, the Contractor shall report to both the contracting office for the indefinite delivery contract and the contracting office for any affected order.

(ii) If a report is required to be submitted to a contracting office under (c)(3)(i) of this clause, the Contractor shall submit the report as follows:

(A) If a Department of Defense contracting office, the Contractor shall report to the website at https://dibnet.dod.mil.

(B) For all other contracting offices, the Contractor shall report to the Contracting Officer.

(4) The Contractor shall report the following information for each covered article or each product or service produced or provided by a source, where the covered article or source is subject to a FASCSA order, pursuant to paragraph (c)(3)(i) of this clause:

(i) Within 3 business days from the date of such identification or notification:

(A) Contract number;

(B) Order number(s), if applicable;

(C) Name of the product or service provided to the Government or used during performance of the contract;

(D) Name of the covered article or source subject to a FASCSA order;

(E) If applicable, name of the vendor, including the Commercial and Government Entity code and unique entity identifier (if known), that supplied the covered article or the product or service to the Contractor;

(F) Brand;

https://dibnet.dod.mil/

(G) Model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

(H) Item description; and

(I) Any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (c)(4)(i) of this clause:

(A) Any further available information about mitigation actions undertaken or recommended.

(B) In addition, the Contractor shall describe the efforts it undertook to prevent submission or use of the covered article or the product or service produced or provided by a source subject to an applicable FASCSA order, and any additional efforts that will be incorporated to prevent future submission or use of the covered article or the product or service produced or provided by a source that is subject to an applicable FASCSA order.

(d) Removal. For Federal Supply Schedules, Governmentwide acquisition contracts, multi-agency contracts or any other procurement instrument intended for use by multiple agencies, upon notification from the Contracting Officer, during the performance of the contract, the Contractor shall promptly make any necessary changes or modifications to remove any product or service produced or provided by a source that is subject to an applicable FASCSA order.

(e) Subcontracts.

(1) The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (c)(1) of this clause, in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products and commercial services.

(2) The Government may identify in the solicitation additional FASCSA orders that are not in SAM, which are effective and apply to the contract and any subcontracts and other contractual instruments under the contract. The Contractor or higher-tier subcontractor shall notify their subcontractors, and suppliers under other contractual instruments, that the FASCSA orders in the solicitation that are not in SAM apply to the contract and all subcontracts.

12. FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/browse/index/gsam.

https://www.acquisition.gov/browse/index/far https://www.acquisition.gov/browse/index/gsam

13. The following clauses are incorporated by reference:

FAR 52.204-2 SECURITY REQUIREMENTS (MAR 2021) (Applicable when the contract may require access to classified information.)

FAR 52.204-9 PERSONAL IDENTITY…