2602RSQ_-_Professional_Construction_Manager_General_Contractor_for_New_Fire_Station_#8_Building.pdf

1. INTRODUCTION

1.1. Summary

The City of Daytona Beach is hereby soliciting responses from qualified Consultants to provide the City of Daytona Beach with professional Construction Management/General Contracting firm for a new Fire

Station/Fire Administration Building and related site improvements.

1.2. Contact Information

Purchasing Purchasing

Purchasing Agent

301 S. Ridgewood Ave.

Daytona Beach, FL 32114

Email: purchasing@daytonabeach.gov

Phone: (386) 671-8082

Department:

Fire Department

1.3. Timeline

Release Project Date October 7, 2025

Pre-Proposal Meeting (Non-Mandatory) October 15, 2025, 10:00am

Join the meeting now

Meeting ID: 297 046 491 445 8

Passcode: h4Wk6q6E

Dial in by phone

+1 312-667-7230,,401609178# United States, Chicago

Phone conference ID: 401 609 178# https://teams.microsoft.com/meet/297046491445

8?p=nORY33nAWSqH7Dql7h

Question and Request for Interpretation

Submission Deadline

October 28, 2025, 5:00pm mailto:purchasing@daytonabeach.gov tel:(386)671-8082 https://teams.microsoft.com/meet/2970464914458?p=nORY33nAWSqH7Dql7h https://teams.microsoft.com/meet/2970464914458?p=nORY33nAWSqH7Dql7h

Request For Proposal #2602RSQ Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

Proposal Submission Deadline November 4, 2025, 11:00am

Join the meeting now

Meeting ID: 249 012 970 850 6

Passcode: Fj7Zw9PT

Dial in by phone

+1 312-667-7230,,463909534# United States, Chicago

Phone conference ID: 463 909 534# https://teams.microsoft.com/meet/249012970850

6?p=46TFmHQJN32X0vpSOn

2. DEFINITIONS

As used in this RSQ, the following terms shall have the meanings set forth below:

Addenda: means written or graphic instruments issued prior to the end of the Offer Phase which clarify, correct, or change the Solicitation documents or Contract documents.

City: means The City of Daytona Beach, unless the context indicates otherwise; includes the

City’s officers, employees, and agents.

Consultant: The person with education and/or experience which uniquely qualifies him or her to perform a specialized service for the City.

Consultant's services: Those services within the scope of work of this solicitation that are in an advisory nature to support policy development, decision-making, administration, or management of the government; normally provided by persons and/or organizations considered to have prerequisite knowledge or special abilities not generally available in the government.

Contract: means the form required by the City to integrate all terms and conditions within the solicitation document, provided by the City for the Proposer’s execution. An agreement between parties with binding legal and moral force, usually providing for the exchange of goods or services for money or other considerations.

Electronic Signature: means the original signature transmitted and received via electronic transmission of a scanned document, (e.g., PDF or similar format) and are true and valid signatures for all purposes hereunder and shall bind the parties to the same extent as that of an original signature. Any such electronic counterpart shall be of sufficient quality to be legible either electronically or when printed as hardcopy. The City shall determine legibility and acceptability for public record purposes.

Local Vendor: means a person or business entity which has maintained a permanent place of business with full-time employees within the city limits for a minimum of six months prior to the date Proposals were received. Provides permanent place of business in which the goods or services are solicited, and https://teams.microsoft.com/meet/2490129708506?p=46TFmHQJN32X0vpSOn https://teams.microsoft.com/meet/2490129708506?p=46TFmHQJN32X0vpSOn

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building which at the time of the Solicitation fully complies with state and local laws, including City zoning and licensing ordinances.

Notice of Intent to Award (NOI): means a written notice given by the City stating that staff is recommending award to the listed Proposer. It includes instructions for completing and submitting any

Contract that accompanies the NOI.

Platform: means OpenGov, the proposal software currently used by the City. All Solicitation communications will be posted at www.codb.us/841/purchasing through the Public Solicitations link.

Proposal: means the offer, submission, or solicitation response submitted by a Proposer on the prescribed forms setting forth the prices for the work to be performed. Also means Response.

Proposal Deadline: means the date and time specified within the Platform in which all Proposals are due. No late submissions will be accepted.

Proposal Phase: means the time between the posting of the Solicitation and the deadline (date and time) by which Proposals must be submitted.

Proposer: means the person or firm submitting a Proposal or Offer to the City for work outlined in a

Request for Proposals. Also means Respondent.

Purchase Order: means a written document to a Supplier formalizing the terms and conditions of a proposed transaction.

Responsible: means a Proposer that has the necessary skills, ability, capacity, and capability to perform the work required under a Solicitation and is otherwise eligible for award.

Responsive: means a proposal that fully conforms in all material respects to the solicitation and all of its requirements, including all form and substance.

3. SCOPE OF WORK

3.1. GENERAL

The City of Daytona Beach is seeking the services of a professional Construction Management

Contractor/General Contractor for a new Fire Station 8 Building and related site improvements.

• The principal purpose of the new Fire Station 8 Building is to serve as a fully operational and efficient satellite for the Daytona Beach Fire Department, which currently operates one main fire station and six satellite fire stations strategically located throughout the City.

• Estimated construction budget is $8 million to $10 million.

• The Fire Station 8 Building project shall include the following features:

• A 10,000 +/- square foot, single-story Fire Station building with three-lane apparatus bay, chief office, station office, nine individual dorm rooms, day/dining room, commercial style kitchen with commercial natural gas appliances, secure lobby, six http://www.codb.us/841/purchasing

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building full-restrooms, lockers, storage, utility room, communication room, workout room, parking, emergency generator, gear storage/ extractor, decontamination room, site utilities, and separate three bay garage/storage building.

o The new Fire Station 8 Building is proposed to be constructed on approximately

3.41+/- acres of undeveloped land (approx. 1.6+/- acres of upland) located at

1380 N. Clyde Morris Blvd Daytona Beach, FL 32117. Parcel is located on the northwest corner of Cornerstone Blvd and N. Clyde Morris Blvd.

• The City has completed a preliminary programming concept and general conceptual site plan.

o The conceptual site plan is intended for demonstration purposes and it is intended the selected design firm will present alternative concepts for consideration.

• The Fire Station 8 Building structure and components shall be a hardened to meet required wind resistance and strive to meet the fire station standards of the

National Fire Protection Administration. The facility is intended to operate on a continuous 24-hour basis.

• The building will be designed and constructed in the spirit of current energy efficient and environmental design best practices when/where financially practical.

• Professional Architectural Engineering Services will be provided under separate contract with the City. It is intended that the Construction Manager/General

Contractor (CM/GC) firm will work directly with the Architectural/Engineering

Service firm beginning in the early design phase through project completion.

• Construction duration is estimated at approximately 10 months.

3.2. PART A - PRECONSTRUCTION PHASE SERVICES

The Pre-Design Phase Scope of Services shall consist of, but not be limited to the following:

• Attend project meetings.

• Work side by side with the City project manager, City staff and the architect/ engineer consultant throughout.

• Make recommendations regarding alternative construction materials, methods or concepts that may be of benefit to the City.

• Review architect/ engineer submittals and make recommendations relating to cost, constructability, and other such technical and economical characteristics of a particular design or material selection.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

• Provide cost estimates for various design schemes and construction assembly options.

• Assist City and architect/ engineer consultant by making recommendations for environmental design features, materials and methods.

• Submit detailed cost estimates, critical path method calendar schedules and reports at phased levels of completion.

• Solicit and evaluate subcontractor qualifications.

• Solicit, schedule and lead pre-bid meetings.

• Prepare subcontract bid packages utilizing the architect/ engineer consultant drawings and specification.

• Solicit and evaluate subcontract bids.

• Develop bid alternates and value engineering options to meet established construction budget.

• Prepare guaranteed maximum price (GMP) proposal.

3.3. PART B - CONSTRUCTION PHASE SERVICES

• Construction Management/General Contracting Services for Construction of the Project per the agreed Guaranteed Maximum Price proposal.

4. PROPOSAL SUBMITTAL AND REQUIREMENTS

4.1. OVERALL QUALIFICATIONS OF PROPOSER

The Proposer shall be a Construction Manager/General Contractor whose overall qualifications meet the

City's specified needs for this project.

The Proposer shall be a certified general contractor licensed by the state of Florida - Proof of License

Must be furnished with Proposal Submission

• Provide a statement not exceeding two (2) pages, which serves as a letter of interest and introduction to the submittal.

o If sub-contractors are proposed, each sub-consultant may elect to provide a similar letter, not exceeding one (1) page from each sub-consultant.

• Provide a narrative, not exceeding two (2) pages of the corporate history of the firm.

• Provide a description of Proposer's experience on past projects of similar scope and size that have been completed within the last ten (10) years.

o Past projects of similar scope and size must show fire station experience.

• Showcase, in detail, three (3) examples of recently completed projects as follows:

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building o Provide the following information at a minimum for each project listed:

▪ Name of Owner and contact information

▪ Contract Value

▪ Dates works was performed.

▪ Permitted design capacity of facility.

▪ Project Description

▪ How Consultant's experience on the example project will be applied to this Scope of

Services

▪ Detail all construction change order in excess of 5% of the base bid value and indicate if change orders were owner directed.

4.2. KEY PERSONNEL & SUBCONTRACTORS

Identify a Project Manager who will serve as primary team member and point of contact for this project.

• Project Manager shall have minimum of 10 years construction project management experience in the design and construction of fire station facilities and vertical construction.

• Resume for Project Manager shall be included with submittal.

• Included in his/ her experience, the Project Manager shall demonstrate experience with completion of no less than three (3) fire station construction projects with the past five (5) years.

Provide an organizational chart that indicates additional individuals that are key to the successful completion of the project (i.e., Key Personnel). Clearly dictate each team member's role for Part A and

Part B of this project.

Personnel Information to be provided:

• Individual resumes are limited to two pages and should include the following information:

o Description of the individual’s proposed Project role o Number of years of experience o Education, professional licenses and/or certifications o Experience relevant to the individual’s proposed role on the Project, the individual’s title and role on each listed project, and how the previous project experience will be applied to this Scope of Services o The physical location of Project Manager and Key Personnel with regard to proximity to the

City of Daytona Beach will be taken into consideration.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

4.3. PROJECT APPROACH

• Explain how Proposer's approach to Scope of Services will be inclusive of fire station design best practices, emerging trends, and other industry standards.

• Describe, in detail, Proposer's Communcations Plan between internal personnel and City staff.

• Explain their internal process for ensuring quality of completed subcontract construction work, real time vs. substantial punch list.

• Describe their secure/confidential document control protocol.

o A list of projects where secure/confidential document control protocol was implemented and describe Respondent’s means and methods utilized shall be provided.

• Compare/contrast their preconstruction cost estimating methods vs. actual subcontractor bids.

• Describe innovative construction materials/methods for environmental conscience practices that would be of benefit to the City if utilized on the Fire Station/Fire Administration Building

• Describe their job site controls regarding damage to existing infrastructure adversely affecting neighboring properties and/ or occurring after business hours

• Explain Proposer's best management practice for mitigating schedule and budget overruns.

• Provide Proposer's job site safety performance metric.

4.4. REFERENCES

Provide three (3) references (DO NOT include The City of Daytona Beach) who can attest to Consultant's role on similar projects.

• These references may be in conjunction with or in addition to projects listed within Section 1 -

Overall Qualifications of Proposer

• Describe the work performed and include the name, job title, address, telephone number and e-mail address of a contact person for each reference.

5. EVALUATION PHASES

The proposed evaluation is an initial process to elicit a short list of Proposers; with the contract awarded not necessarily to the consultant of least cost, but rather to the consultant with the best combination of attributes (i.e., qualifications and experience, technical approach, and cost), based upon the evaluation factors specifically established for this solicitation.

The weighted evaluation criteria in the EVALUATION CRITERIA will be used to evaluate Offers and develop a recommendation to the City Manager. Each criterion will be scored between 0 and 5; 0=non-responsive

1=poor, 2=below average, 3=average, 4=above average, 5=excellent. Scores will be multiplied by the criterion weight for a weighted score; weighted scores will be totaled for the weighted total score.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

No. Evaluation Criteria Scoring Method Weight (Points)

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

1. OVERALL QUALIFICATIONS OF PRIME

PROPOSER

The Proposer is a Construction

Manager/General Contractor whose overall qualifications meet the City's specified needs for this project.

The Proposer is a certified general contractor licensed by the state of Florida

• Proof of license has been furnished with Proposal Submission

A statement not exceeding two (2) pages, which serves as a letter of interest and introduction to the submittal has been provided.

Proposer has provided a narrative, not exceeding two (2) pages of the corporate history of the firm.

Proposer has provided a description of

Proposer's experience on past projects of similar scope and size that have been completed within the last ten (10) years.

Past projects of similar scope and size show fire station experience.

Proposer has showcased, in detail, three (3) examples of recently completed projects as follows:

• The following information at a minimum has been listed for each project:

• Name of Owner and contact information

• Contract Value

• Dates works was performed

• Permitted design capacity of facility

• Project Description

• How Proposer's experience on the example project will be applied to this Scope of Services

• Construction change orders in excess of 5% of the base bid value have

Points Based 30 (30% of Total)

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building been provided and it has been indicated whether change orders were owner directed.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

2. KEY PERSONNEL

Proposer has identified a Project Manager who will serve as primary team member and point of contact for this project.

Project Manager has minimum of 10 years construction project management experience in the design and construction of fire station facilities and vertical construction.

Resume for Project Manager has included with submittal.

• Included in his/ her experience, the

Project Manager has demonstrated experience with completion of no less than three (3) fire station construction projects with the past five (5) years.

Proposer has provided an organizational chart that indicates at least eight (8) additional individuals that are key to the successful completion of the project (i.e., Key Personnel).

• Each team member's role for Part A and Part B of this project has been clearly identified.

Individual resumes are limited to two pages that include the following information:

• Description of the individual’s proposed Project role

• Number of years of experience

• Education, professional licenses and/or certifications

• Experience relevant to the individual’s proposed role on the

Project, the individual’s title and role on each listed project, and how the previous project experience will be applied to this Scope of Services

• The physical location of Project

Manager and Key Personnel with regard to proximity to the City of

Daytona Beach for consideration.

Points Based 30 (30% of Total)

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

3. PROJECT APPROACH

Proposer's approach to Scope of Services will be inclusive of fire station design best practices, emerging trends, and other industry standards.

Proposer's Communcations Plan between internal personnel and City staff has been described.

Proposer has explained their internal process for ensuring quality of completed subcontract construction work, real time vs. substantial punch list.

Describe their secure/confidential document control protocol has been identified.

A list of projects where secure/confidential document control protocol was implemented and describe Respondent’s means and methods utilized has been provided.

Proposer has Compared/contrasted their preconstruction cost estimating methods vs.

actual subcontractor bids.

Proposer has described innovative construction materials/ methods for environmental conscience practices that would be of benefit to the City if utilized on the Fire

Station/Fire Administration Building

Job site controls regarding damage to existing infrastructure adversely affecting neighboring properties and/ or occurring after business hours has been outlined.

Proposer's best management practice for mitigating schedule and budget overruns has been explained.

Proposer has provided job site safety performance metric.

Points Based 25 (25% of Total)

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

4. REFERENCES

Proposer has provided three (3) references

(NOT INCLUDING The City of Daytona Beach) who can attest to Proposer's role on similar projects.

• These references are conjunction with or in addition to projects listed within Section 1 - Overall

Qualifications of Prime Proposer.

• The work performed has been described and includes the name, job title, address, telephone number and e-mail address of a contact person for each reference.

Points Based 15 (15% of Total)

6. GENERAL CONDITIONS

This is a Request for Statement of Qualifications issued in accordance with The City of Daytona Beach

Code Chapter 30, Division 3, “Source Selection and Contract Formation”. The Request for Qualifications specifies the product(s) or services needed and lists the criteria upon which the Proposals will be evaluated. When received, Proposals will be reviewed and ranked in order, beginning with the one deemed most advantageous to the City. Negotiations will commence with the selected

Proposer(s). Upon completion of satisfactory negotiations, the Contract negotiated as the best will be recommended to the City Commission. A copy of Chapter 30 may be obtained upon request.

This solicitation is made in accordance with the provisions of Chapter 287.055, Laws of Florida, known as the Consultants’ Competitive Negotiation Act (CCNA).

6.1. GENERAL CONDITIONS

THIS IS NOT A BID.

This is a Request for Statement of Qualifications issued in accordance with The City of Daytona Beach

Code Chapter 30, Division 3, “Source Selection and Contract Formation”. The solicitation specifies the product(s) or services needed and lists the criteria upon which the Proposals will be evaluated. When received, Proposals will be reviewed and ranked in order, beginning with the one deemed most advantageous to the City. Negotiations will commence with the selected Proposer(s). Upon completion of satisfactory negotiations, the Contract negotiated as the best will be recommended to the City

Commission. A copy of Chapter 30 may be obtained upon request.

6.2. REQUESTS FOR INTERPRETATIONS

If the Proposer is in doubt as to the meaning of any of the Solicitation Documents or other Exhibits included in this Solicitation, the Proposer may submit a question through the Platform. Such requests must be received by the deadline communicated in the Timeline in the INTRODUCTION in order to be considered. The City is not obligated to respond to such requests. Any clarification or interpretation issued

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building by the City in the form of a written Addendum will be deemed to be a part of the Solicitation Documents.

No oral clarification or interpretation will be binding.

6.3. ADDENDA TO SOLICITATION DOCUMENTS

Prior to Solicitation opening, the City may, on the City’s own initiative or in response to a request for clarification, furnish Addenda, or answer questions via the Platform for additions or alterations to the

Solicitation Documents previously supplied by the City. In addition, the City may by Addendum extend the date scheduled for Solicitation opening. The Purchasing representative will make reasonable efforts through the Platform to notify all potential Suppliers of the issuance of an Addendum. The City’s

Purchasing web site address is www.codb.us/841/Purchasing; Addenda may be found under the “Public

Solicitations” link.

Any clarification or interpretation issued by the City in the form of a written Addendum will be deemed to be a part of the Solicitation Documents. No oral clarification or interpretation will be binding. However, the Proposer is solely responsible for ensuring that the Proposal submitted reflects all such

Addenda/Questions and Answers.

6.4. EXECUTION OF OFFER

The City will only accept Offers online through the Platform. No paper Offers will be accepted.

All electronic files uploaded must be in a common format accessible by software programs the City uses. Those common formats are generally described as Microsoft Word (.doc or .docx), Microsoft Excel

(.xls or .xlsx), Microsoft Power Point (.ppt or pptx), or Adobe Portable Document Format (.pdf.). Bidders will not secure, password protect or lock uploaded files; the City must be able to open and view the contents of the file. Bidders will not disable or restrict the ability of the City to print the contents of an uploaded file. Scanned documents or images must be of sufficient quality, no less than 150 dpi, to allow for reading or interpreting the words, drawings, images or sketches. The City may disqualify any Offer that does not meet the criteria stated in this paragraph.

6.5. WITHDRAWAL OF OFFERS

The Proposer may withdraw their submission and resubmit anytime until the specified opening date and time, (i.e., the end of the Offer Phase). Once the Offer Phase has ended the City will be able to view the submissions and begin the evaluation of all Proposals received.

Mere negligence on the part of the Proposer in preparing the Offer does not constitute a right to withdraw the Proposal after opening.

6.6. OPENING DATE

The opening of Proposals will be scheduled at the date and time specified by the Solicitation, or as changed by Addenda or response that the City may issue. At opening, the City will open and record the Proposals so long as they are proper and have been timely submitted. In recording the Proposals, the City will state the name of the Proposer. The Tabulation Sheet will be created on the Platform by the Purchasing representative. The Proposer is solely responsible to ensure that the Proposal is submitted online prior to the end of the Offer Phase. Late Submissions will not be accepted.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

6.7. OPENING RESULTS

Proposers may secure information pertaining to opening results on the Purchasing Department's webpage www.codb.us/841/Purchasing, or by emailing a request to purchasing@codb.us. Copies of

Tabulation Sheets will be furnished upon request and receipt of a valid email address.

6.8. GENERAL REVIEW PROCEDURES

The Purchasing Code, Chapter 30, Code of the City of Daytona Beach, sets forth the general review procedures for competitive sealed Offers. Under the Purchasing Code, the City Manager is required to evaluate and rank Responsive Proposals in accordance with the criteria identified in the Solicitation.

Before submitting a recommendation for final action on this Solicitation to the City Commission, the City

Manager is authorized to “shortlist’ and negotiate with one or more of the Proposers who submitted the highest ranked Proposals. As part of these negotiations, the City Manager may request revised Offers from shortlisted Proposers.

The City Manager has adopted a policy delegating the task of initially ranking Responsive Offers to a

Selection Committee. The Selection Committee may require personal interviews with Proposers before submitting its recommendations to the City Manager.

6.9. REJECTION OF OFFERS

The City reserves the right to reject any or all Proposals in whole or in part and to award by items, parts of items, or by any aggregate group of items specified. The City also reserves the right to waive technical defect when in its judgment the best interests of the City thereby will be served.

6.10. AWARD

The award will be made by the City to the Proposer most qualified and offering the best value to the City, which will be determined by evaluation of Proposals using the evaluation criteria contained in the

Solicitation, and in accordance with applicable rules and regulations governing the purchase and Contract adopted and established by the City, and the State of Florida.

Any Contract resulting from this Solicitation may, in the alternative, be awarded by the City of Daytona

Beach Community Redevelopment Agency (CRA). Therefore, any Offers submitted in response to this

Solicitation shall be deemed to be Offers to the CRA as well as the City. Any final written contract may be with the CRA instead of the City, and in such instances, any required insurance, performance and payment bonds, may be required to run in favor of the CRA in addition to or in lieu of the City.

6.11. REFERENCES

The contact person(s) listed as a reference shall be someone who has personal knowledge of the

Proposer’s performance during the referenced project. Contact persons must have been informed that they are being used as a reference and that the City may be calling them. More than one person can be listed but all must have knowledge of the project. DO NOT list principals or officers who will not be able to answer specific questions regarding the project.

http://www.codb.us/841/Purchasing mailto:purchasing@codb.us

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

6.12. SELECTION PROCESS

For the purpose of selecting the most qualified Proposal, the City will use a competitive selection process as set forth in pertinent City and State procurement requirements. The procedure will involve the following steps:

The City will advertise and email notice of formal Requests For Proposals to interested Proposers. The

City’s Selection Committee will review, rank, and shortlist all Proposals received by the established deadline for submission. Oral presentations by the short-listed Proposers to clarify their Offers may be required. These presentations will serve to explain implementation techniques integral to the written

Proposal. Subsequent to the receipt of Proposals, the City may schedule a time for each requested oral presentation at a place convenient to the City.

The City’s Selection Committee will then rank each Proposal and prepare a recommendation for approval by the City Manager. Upon receipt of the City Manager’s approval, City staff shall negotiate a contract with the highest ranked Proposer(s) approved by the City Manager. Should the

City staff be unable to negotiate a satisfactory contract with any of the shortlisted Proposers, the City

Manager, or designee, shall terminate such negotiations with any or all of the shortlisted Proposers and begin negotiations with remaining Proposers based on ranking, until negotiations are successful or this

Solicitation is cancelled.

The City Commission has the sole authority to bind the City to the terms and conditions of a contract that has been approved in a public meeting of the City Commission. The City Commission reserves the right to modify or reject any contract for the acquisition of goods and/or services submitted to it for consideration.

6.13. LICENSES, PERMITS, AND FEES

All Proposals submitted shall include in the price the cost of any business or professional licenses, permits or fees required by the City and any agency having jurisdiction over the Services solicited through this Request for Proposal.

6.14. PATENT INFRINGEMENT

By submission of a Proposal, the Proposer certifies that the Services to be furnished will not infringe any valid patent, copyright, or trademark and the successful Proposer shall, at his/her own expense, defend any and all actions or suits charging such infringement and hold the City harmless in case of any such infringements.

6.15. TAXES

All Proposals shall be exclusive of federal taxes. Tax exemption certificates will be furnished upon request.

6.16. FLORIDA PUBLIC RECORDS LAW

Sealed Offers received by the City pursuant to the Request for Proposals will be temporarily exempt from disclosure in accordance with Florida’s Public Records Laws. F.S. §119, states that Offers are not public record for 30 days from the date of the opening of the Offers or the date a Notice of Intent to

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

Award is posted, whichever is first. Thereafter, all Offers will be open for a personal inspection by any person pursuant to Public Records Law.

If the Proposer believes that the Offer or any portion thereof is permanently exempt from disclosure under the public records laws, the Proposer must state the grounds for this position in CAPITAL LETTERS in a certified letter addressed to the Purchasing Agent and received at least 3 days prior to the Offer opening. The Proposer will be contacted prior to the opening of the Offer and a determination will be made as to whether or not it is exempt prior to opening. If a determination is made that it is not exempt from disclosure, the Proposer may in writing request the return of the sealed Proposal.

6.17. QUALIFYING PROPOSALS

Prior to awarding of Offer, the City may require submission by Proposer of complete financial statement and questionnaire describing Proposer’s financial ability and experience in performance of similar work.

6.18. RULES AND REGULATIONS

All work performed under this agreement shall be in strict compliance with local, State and Federal laws, rules and regulations. Proposer shall assume all liability for fines and penalties assessed by the authorities for any infractions.

6.19. NO COSTS

The City of Daytona Beach bears no responsibility for any costs incurred in the preparation of the

Proposal.

6.20. INTERNET/WEB SERVICES

For the purposes of this paragraph, any Services or products offered to the public via the internet or online must comply with WCAG 2.0 AA in order to be deemed ADA compliant. The City will provide

Contractor with prompt written notice with respect to any ADA deficiencies of which the City is aware and Contractor will promptly correct such deficiencies. If the County, the Department of Justice, or other governmental entity tasked with the enforcement of the ADA ("Enforcement Agency") notes any deficiency in the facilities, practices, services, or operations of the Contractor furnished or provided in connection with this Agreement, Contractor shall, at no additional charge or cost to the City, immediately cure any such deficiencies without delay to the satisfaction of such Enforcement Agency.

Contractor further agrees that it shall, to the extent permitted by law, indemnify, defend, and hold harmless the City against any and all claims, sanctions, or penalties assessed against the City, which claims, sanctions, or penalties arise or otherwise result from the Contractor's failure to comply with the

ADA or WCAG 2.0 AA, for online or internet services or products.

6.21. DRUG FREE WORKPLACE

The selected Proposer must provide the Drug Free Workplace Form in accordance with Florida Statute

287.087, prior to Contract award.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

6.22. PROHIBITION OF LOBBYING

Except for negotiations authorized by the City Purchasing Code, the Consultants Competitive

Negotiations Act, or other state or federal law, lobbying by the Proposer, or the Proposer’s principals, officers, employees, attorneys, or other agents, is strictly prohibited during the Blackout Period.

Lobbying in violation of this section may cause the Offer to be rejected. “Lobbying” means influencing or attempting to influence action or non-action in connection with this Solicitation or the Offer, through direct or indirect oral or written communication with the Mayor, any member of the City Commission, the City Manager, or any other City employee.

The following activities are not within the definition of “lobbying,” and are permitted: requests for clarification submitted to the Purchasing Agent in accordance with this Solicitation, discussions with the

Selection Committee as part of the selection process, the submission of additional information in response to a request by the City and addressing the City Commission during the City Commission meeting at which the Contract is awarded, or all Offers are rejected.

The Blackout Period begins on the date that this Solicitation is issued and ends when the Contract is awarded or all Offers are rejected.

7. FEDERAL CONTRACT PROVISIONS

7.1. FEDERAL CONTRACT PROVISIONS

This is an acknowledgment that FEMA financial assistance may be used to fund the agreement. The

Contractor will comply with all applicable federal laws, regulations, and Executive Orders, including

FEMA policies, procedures, and directives. The Contractor shall comply with all uniform administrative requirements, cost principles, and audit requirements for federal awards. The Contractor shall ensure that all subcontracts comply with all applicable federal laws, regulations, and Executive Orders, including

FEMA policies, procedures, and directives.

A. Contract Work Hours and Safety Standards Act. This requirement applies to all FEMA contracts awarded by the non-federal entity in excess of $100,000 under grant and cooperative agreement programs that involve the employment of mechanics or laborers. It is applicable to construction work. These requirements do not apply to the purchase of supplies or material or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.

Compliance with the Contract Work Hours and Safety Standards Act.

Overtime requirements. No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of forty hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of forty hours in such workweek.

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the clause set forth in paragraph (b)(1) of this section the contractor and any subcontractor responsible therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the

United States (in the case of work done under contract for the District of Columbia or a territory, to such

District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (b)(1) of this section, in the sum of $27 for each calendar day on which such individual was required or permitted to work in excess of the standard work week of forty hours without payment of the overtime wages required by the clause set forth in paragraph (b)(1) of this section.

Withholding for unpaid wages and liquidated damages. The City of Daytona Beach or State of Florida shall upon its own action or upon written request of an authorized representative of the Department of

Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety

Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (b)(2) of this section.

Subcontracts. The contractor or subcontractor shall insert in any subcontracts the clauses set forth in paragraph (b)(1) through (4) of this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in paragraphs (b)(1) through

(4) of this section.

• Rights to Inventions Made Under a Contract or Agreement. This requirement applies to

"funding agreements," but it DOES NOT apply to the Public Assistance, Hazard Mitigation Grant

Program, Fire Management Assistance Grant Program, Crisis Counseling Assistance and Training

Grant Program, Disaster Case Management Grant Program, and Federal Assistance to

Individuals and Households - Other Needs Assistance Grant Program, as FEMA awards under these programs do not meet the definition of "funding agreement." The Contractor must comply with the requirements of 37 C.F.R. Part 401, "Rights to Inventions Made by Nonprofit

Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative

Agreements ," and any implementing regulations issued by the awarding agency.

If the FEMA award meets the definition of "funding agreement" under 37 C.F.R. § 401 .2(a) and the non-

Federal entity wishes to enter into a contract with a small business firm or nonprofit organization regarding the substitution of parties, assignment or performance of experimental, developmental, or research work under that "funding agreement," the non- Federal entity must comply with the requirements of 37 C.F.R. Part 401 (Rights to Inventions Made by Nonprofit Organizations and Small

Business Firms Under Government Grants, Contracts and Cooperative Agreements), and any implementing regulations issued by FEMA See 2 C.F.R. Part 200, Appendix ll(F)

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

C. Clean Air Act. This requirement applies to contracts awarded by a non-federal entity of amounts in excess of $150,000 under a federal grant. The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. §

7401 et seq.

The contractor agrees to report each violation to The City of Daytona Beach and understands and agrees that the City will, in turn, report each violation as required to assure notification to the Federal

Emergency Management Agency, and the appropriate Environmental Protection Agency Regional

Office.

The contractor agrees to include these requirements in each subcontract exceeding $150,000 financed in whole or in part with Federal assistance provided by FEMA.

D. Federal Water Pollution Control Act. The contractor agrees to comply with all applicable standards, orders, or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq.

The contractor agrees to report each violation to The City of Daytona Beach (City) and understands and agrees that the City will, in turn, report each violation as required to assure notification to the Federal

Emergency Management Agency, and the appropriate Environmental Protection Agency Regional

Office.

The Contractor agrees to include these requirements in each subcontract exceeding $150,000 financed in whole or in part with Federal assistance provided by FEMA.

E. Suspension and Debarment. This requirement applies to all FEMA grant and cooperative agreement programs. This contract is a covered transaction for purposes of 2 C.F.R. pt. 180 and

2 C.F.R. pt. 3000. As such, the contractor is required to verify that none of the contractor's principals (defined at 2 C.F.R. § 180.995) or its affiliates (defined at 2 C.F.R. § 180.905) are excluded (defined at 2 C.F.R. § 180.940) or disqualified (defined at 2 C.F.R. §180.935). The contractor must comply with 2 C.F.R. pt. 180, subpart C and2 C.F.R. pt. 3000, subpart C, and must include a requirement to comply with these regulations in any lower tier covered transaction it enters into. This certification is a material representation of fact relied upon by

State of Florida, The City of Daytona Beach, and The City of Port Orange. If it is later determined that the contractor did not comply with 2 C.F.R. pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart

C, in addition to remedies available to State of Florida and The City of Daytona Beach, the

Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. The bidder or proposer agrees to comply with the requirements of 2 C.F.R.

pt. 180, subpart C and 2 C.F.R. pt. 3000, subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower-tier-covered transactions.

F. Byrd Anti-Lobbying Amendment. This requirement applies to all FEMA grant and cooperative agreement programs. Contractors that apply or bid for a contract of $100,000 or more under a

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building federal grant must file the required certification. See 2 C.F.R. Part 200, Appendix 11(1); 31 U.S.C

§ 1352; and 44 C.F.R. Part 18.

Byrd Anti-Lobbying Amendment, 31 U.S.C. § 1352 (as amended)

Contractors who apply or bid for an award of $100,000 or more shall file the required certification. Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a

Member of Congress, officer or employee of Congress, or an employee of a Member of Congress in connection with obtaining any Federal contract, grant, or any other award covered by 31 U.S.C. § 1352.

Each tier shall also disclose any lobbying with non-Federal funds that takes place in connection with obtaining any Federal award. Such disclosures are forwarded from tier to tier up to the recipient who in turn will forward the certification(s) to the awarding agency.

Contractors must sign and submit APPENDIX A, 44.C.F.R PART 18 - CERTIFICATION REGARDING

LOBBYING with each bid or offer exceeding $100,000.00.

G. Procurement Of Recovered Materials. This requirement applies to all contracts awarded by a nonfederal entity under FEMA grant and cooperative agreement programs.

In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired-

• Competitively within a timeframe providing for compliance with the contract performance schedule;

• Meeting contract performance requirements; or

• At a reasonable price.

Information about this requirement, along with the list of EPA- designated items, is available at EPA's

Comprehensive Procurement Guidelines web site, https://www.epa.gov/smm/comprehensive-procurement guideline-cpg-program.

The Contractor also agrees to comply with all other applicable requirements of Section 6002 of the Solid

Waste Disposal Act.

H. Prohibition on Contracting for Covered Telecommunications Equipment or Services

(a) Definitions. As used in this clause, the terms backhaul; covered foreign country; covered telecommunications equipment or services; interconnection arrangements; roaming ; substantial or essential component; and telecommunications equipment or services have the meaning as defined in

FEMA Policy 405-143-1, Prohibitions on Expending FEMA Award Funds for Covered Telecommunications

Equipment or Services (Interim), as used in this clause:

(b) Prohibitions. Section 889(b) of the John S. McCain National Defense Authorization Act for Fiscal Year

2019, Pub. L. No. 115- 232, and 2 C.F.R. § 200.216 prohibit the head of an executive agency on or after

Aug.13, 2020, from obligating or expending grant, cooperative agreement, loan, or loan guarantee funds on certain telecommunications products or from certain entities for national security reasons.

https://www.epa.gov/smm/comprehensive-

Title: 2602RSQ - Professional Construction Manager/General Contractor for New Fire Station #8 Building

Unless an exception in paragraph (c) of this clause applies, the contractor and its subcontractors may not use grant, cooperative agreement, loan, or loan guarantee funds from the Federal Emergency

Management Agency to:

i. Procure or obtain any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology of any system.

ii. Enter into, extend, or renew a contract to procure or obtain any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology of any system.

iii. Enter into, extend, or renew contracts with entities that use covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system; or

iv. Provide, as part of its performance of this contract, subcontract, or other contractual instrument, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

(c) Exceptions. This clause does not prohibit contractors from providing:

A. A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

B. Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles

By necessary implication and regulation, the prohibitions also do not apply to:

ii. Covered telecommunications equipment or services that are not used as a substantial or essential component of any system; and ii. Are not used as critical technology of any system

iii. Other telecommunications equipment or services that are not considered covered telecommunications equipment or services.

(d) Reporting requirement. In the event the contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the contractor is notified of such by a subcontractor at any tier or by any other source, the contractor shall report the information in paragraph (d)(2) of this clause to the recipient or subrecipient, unless elsewhere in this contract are established procedures for reporting the…