23Q0011.pdf

SEE ADDENDUM

( No Col lect Cal ls )

W51AA123Q0011 23-Aug-2023

b. TELEPHONE NUMBER

570 615 6441

8. OFFER DUE DATE/LOCAL TIME

04:30 PM 31 Aug 2023

5. SOLICITATION NUM BER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

( SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t . Use Only)

23.

CODE 10. TH IS ACQUISI TION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W51AA19. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAM E

MARIA LUCARINE

2. CONTRACT NO. 3 . AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLI CI TATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52. 212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRI ATION DATA

1. REQUISITION NUMBER

20.

ADDI TIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

W25G1V318001BH

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52. 212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDI NG ANY ADDITI ONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO I TEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THI S DOCUMENT AND RETURN

% FOR:SET ASI DE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ACC-APG TOBY HANNA DIVI SION

11 HAP ARNOLD BLVD

TOBY HANNA PA 18466

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE W25G1V 16. ADMINISTERED BY

12. DI SCOUNT TERMS11. DELIVERY FOR FOB DESTI NA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLIC ITATION

RFQ IFB RFPX

SEE BELOW FOR SEPARATE SHIPPING INSTRUCT

XXX

XXX PA 00000

TEL: FAX:

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

$40,000,000

NAICS:

532490

OFFER DATED

29. AW ARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWI SE IDENTIFI ED ABOVE AND ON ANY

COPI ES TO ISSUI NG OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN- OWNED

SM ALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF48

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEI VED INSPECTED

32b. SIGNATURE OF AUTHORI ZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATI VE

32e. MAILI NG ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORI ZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FI NALPARTIALCOMPLETE

36. PAY MENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHI P NUMBER

PARTI AL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAY MENT

41b. SIGNATURE AND TITLE OF CERTIFYI NG OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC 'D (YY/ MM/DD) 42d. TOTAL CONTAI NERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

Section SF 1449 - CONTINUATION SHEET

SPECIAL INSTRUCTIONS

This is a Firm Fixed Price one time rental for a six month period.

Period of Performance is 10/16/2023-04/16/2024 Please submit your quote for a monthly billing to allow monthly payments.

Deliver to: Tobyhanna Army Depot, Bldg. 15, 11 Hap Arnold Blvd., Tobyhanna, PA 18466 Attn: Bernadette Girgenti 570-615-9413 This is Brand Name or Equal. If submitting an equal. Please submit the specification sfor approal for bid to be accepted.

Please send all bids to maria.t.lucarine.civ@army.mil CONTRACTOR / OFFEROR SUBMISSION(S): The Government will not consider submissions that were delayed, or otherwise not timely delivered to the Purchasing Agent’s email inbox, due to complications with the contractor’s or the Government’s service providers, to include email maintenance, firewall, delivery to any other email inbox, (i.e. junk folder, spam folder, etc.). Contractors should anticipate delays in transmission and are advised to plan ahead and begin transmitting their submission in enough time to ensure successful delivery prior to the submission deadline. If the offeror does not receive written confirmation of receipt from the purchasing agent before the closing date and time, it is the responsibility of the offeror prior to the closing of the solicitation to contact the purchasing agent, to confirm that their complete offer has been received.

See 52.212-2 for Basis of Award

PERFORMANCE WORK STMT (PWS)

Performance Work

Statement

General Information

1. General: This is a non-personnel rental services contract to provide one Case 921 Wheeled Front Enter Loader and 3 Case 821 Wheeled Front Enter Loaders with a 5 yard bucket capacity or equivalent. The Government shall not exercise any supervision or control over the contract rental service providers performing the services herein. Such contract rental service providers shall be accountable solely to the Contractor who, in tum is responsible to the Government.

1.1 Description of Rental Services/Introduction: The contractor shall provide all personnel, equipment, supplies, facilities, transportation. tools, materials, supervision and other items and non-personnel rental services necessary to perform the delivery of one Case 921 Wheeled Front Enter Loader and 3 Case 821 Wheeled Front Enter Loaders with a 5-yard bucket capacity or equivalent as defined in the PWS except for those items specified as government furnished property and services. The contractor shall perform to the standards in this contract.

1.2 Objectives: The rental services described in this PWS will keep the depot running to its optimal level so that all workload requirements can be met by the Government.

1.3 Scope: Rental of one Case 921 Wheeled Front Enter Loader and 3 Case 821 Wheeled Front Enter Loaders with a 5-yard bucket capacity or equivalent.

1.3.1 Rental of the one Case 921 Wheeled Front Enter Loader and 3 Case 821 Wheeled Front Enter Loaders with a 5-yard bucket capacity or equivalent will include the delivery and pick up of the loaders to Bldg. 15, Motor Pool at Tobyhanna Army Depot.

1.4 Period of Performance: The period of performance shall be for six months starting on 16 October 2023.

1.5 General Information

1.5.1 The contractor will not be required to perform services on the following holidays: New Year's Day Labor Day Martin Luther King Jr.'s Birthday Columbus Day President's Day Veteran's Day Memorial Day Thanksgiving Day Independence Day Christmas Day

1.5.2 Hours of Operation: The contractor is responsible for conducting business between the hours of 0700 and 1530 Monday thru Friday except for Federal holidays or when the government facility is closed due to local or national emergencies, administrative closings or similar government directed facility closings. The contractor must at all times maintain an adequate workforce for the uninterrupted performance of all tasks defined within the PWS when the government facility is not closed for the above reasons.

1.5.3 Place of Performance: The rentals to be delivered under this contract will be delivered to Tobyhanna Anny Depot, Building 15.

POC is Bernadette Girgenti (570)615-9413.

W51AA123Q0011

USE THE FOLLOWING FOR REQUIREMENTS WHEN THE CONTRACTOR

EMPLOYEES WILL PERFORM WORK ON-SITE AT TYAD OR ANOTHER

GOVERNMENT SITE:

DEPOT ACCESS:

A background check and approval from TYAD Security Operations Branch is required for all contractor and subcontractor personnel prior to on-site access at TYAD. All persons seeking entrance to TYAD shall submit to and comply with all security standards and requirements in force at the time such persons are seeking entry. All contractors, regardless of resident status or citizenship, will be subject to vehicle search and intense in-processing by TYAD security personnel prior to being granted access to TYAD.

This security screening process may be time consuming and access may be delayed or denied. The contractor shall ensure ELTY Form 648-C is completed for all contractor and subcontractor personnel requiring depot access to include warranty services. The TYAD point of contact (POC) will provide ELTY Form 648-C, Request Access to Tobyhanna Army Depot, to the contractor/vendor at least ten days prior to the expected visit date for completion. The contractor/vendor shall return the completed ELTY Form 648-C to the TYAD POC in a timely manner so the same may be submitted to Security for processing no later than seven days prior to the visit. All of the required fields on the form shall be complete and accurate by the contractor/vendor for timely processing. This requirement is inclusive of on-site supervisory or managerial personnel and sub-contractor personnel that the Contractor anticipates will be performing work or visiting on-site. This security screening does not relieve the contractor of any responsibilities to conduct thorough pre-employment background checks and drug screening. Contractor workers will not be granted access to the work site until security screening is completed and access is approved. Any contractor personnel on-site who fail screening will not be permitted further access to TYAD. See “Access and General Protection/Security Policy and Procedures” below.

Please submit the completed ELTY Forms 648-C form(s) to the COR or POC.

SECURITY REQUIREMENTS

ANTITERRORISM (AT) / OPERATIONS SECURITY (OPSEC) REQUIREMENTS

All security training certificates shall be provided to the Contracting Officer’s Representative (COR)/Point of Contact (POC) and the Contract Specialist/Purchasing Agent.

Antiterrorism (AT) Level I Training. All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities, and controlled access areas shall complete AT Level I awareness training prior to contract report date. This training is required for any additional or new contractor employees, who start after that period. The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR/POC within 10 calendar days after completion of training by all employees and subcontractor personnel. AT level I awareness training is available at the following website: https://jkodirect.jten.mil for CAC holders. Non-CAC holders may go to http://jko.jten.mil/courses/atl1/launch.html for their training. Upon request, the contractor will be provided one copy of the AT level I training slides for use with employees who may not have computer access. TYAD will not be responsible for printing copies of slides for training purposes. TYAD reserves the right to provide instructor led training and will so advise the contractor within one week of the start of performance or at the time of annual training, if that will be the training approach to be utilized.

Completion of contractor employee training will be documented on ELTY form 583, TYAD On-Post Training Record, or contractor equivalent. As applicable, contractor employees must complete annual AT awareness training as it pertains the length of the contract.

iWATCH Army Training. The contractor and all associated sub-contractors shall brief all employees on the local iWATCH Army Program. This will consist of utilizing the tools and media products on the informational iWATCH Army website to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. The iWATCH training is available at the following website: https://myarmyonesource.com select Family Programs and Services, in the drop down boxes select: Go To, iWATCH Army –“See Something, Say Something”. Additional guidance and support can be provided by the TYAD Antiterrorism Officer (ATO) at the contractor’s request. The contractor shall notify the COR/POC within 10 calendar days of the completed training for any new employees or subcontractor personnel to assure the ELTY form 583 or contractor equivalent is properly documented.

TYAD reserves the right to provide instructor led training and will so advise the contractor within one week of the start of performance or at the time of annual training, if that will be the training approach to be utilized. Completion of contractor employee training will be documented on ELTY form 583, TYAD On- Post Training Record or contractor equivalent.

Operations Security (OPSEC) Training. Per AR 530-1, Operations Security, contractor employees must complete Level I OPSEC training prior to the contract report date and for any additional or new contractor employees, who start after that period. All contractor employees must also complete annual OPSEC awareness training. The training is available at the following website: http://cdsetrain.dtic.mil/opsec/index.htm.

The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR/POC within 10 calendar days after completion of training by all employees and subcontractor personnel. The contractor will be provided a copy of the OPSEC training slides for use with employees who may not have computer access. TYAD will not be responsible for printing copies of slides for training purposes. TYAD reserves the right to provide instructor led training and will so advise the contractor within one week of the start of performance or at the time of annual training, if that will be the training approach to be utilized. Completion of contractor employee training will be documented on ELTY form 583, TYAD On-Post Training Record or contractor equivalent.

Access and General Protection/Security Policy and Procedures. Contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by TYAD Security Branch. Contractor workforce must comply with all personal identity verification requirements as directed by DoD, HQDA, and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by the government representative), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

INCLUDE THE FOLLOWING IF A COMMON ACCESS CARD (CAC) AND

INFORMATION SYSTEMS/NETWORK ACCESS BY CONTRACTOR WORKERS AT

TYAD OR ANOTHER GOVERNMENT SITE IS REQUIRED:

Common Access Card (CAC) and Information Systems/Network Access by Contractor Workers. Before CAC issuance, the contractor employee requires, at a minimum, a favorably adjudicated Tier 1 (formerly National Agency Check with Inquiries (NACI)) or an equivalent or higher investigation in accordance with Army Directive 2014-05. The contractor employee will be issued a CAC only if duties involve one of the following: (1) Both physical access to a DoD facility and access, via logon, to DoD networks on-site or remotely; (2) Remote access, via logon, to a DoD network using DoD-approved remote access procedures; or (3) Physical access to multiple DoD facilities or multiple non-DoD federally controlled facilities on behalf of the DoD on a recurring basis for a period of 6 months or more. At the discretion of the sponsoring activity, an initial CAC may be issued based on a favorable review of the FBI fingerprint check and a successfully scheduled NACI at the Office of Personnel Management.

All contractor employees and associated sub-contractor employees with access to a Government Information System (IS) must be sponsored in Army Knowledge Online (AKO), registered in the ATCTS (Army Training Certification Tracking System) at commencement of services, and must successfully complete the DoD Cyber Awareness training prior to issuance of network access to the IS and then annually thereafter.

INCLUDE THE FOLLOWING IF SECURITY CLEARANCES APPLY:

Security Clearances. Performance of work will require access to classified information or equipment IAW the DD Form 254, Contract Security Classification Specification, provided as an attachment. The table below shows the required number of workers by skill set that will require a Secret or Top Secret Clearance. Contractor shall comply with FAR 52.204-2, Security Requirements. This clause involves access to information classified “Confidential,” “SECRET,” or “Top SECRET” and requires contractors to comply with— (1) The Security Agreement (DD Form 441), including the National Industrial Security Program Operating Manual (DoD 5220.22-M); any revisions to DOD 5220.22-M, notice of which has been furnished to the contractor.

Threat Awareness and Reporting Program (TARP). For all contractors with security clearances, per AR 381-12, TARP contractor employees must receive initial and annual TARP training by a CI Agent or other trainer as specified in 2-4b.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 6 Lot

FRONT END LOADER RENTAL

FFP

ONE TIME RENTAL CONTRACT FOR A SIX MONTH PERIOD STARTING

16 OCT 23.

1 EACH CASE 921 AND 3 EACH CASE 821 WHEELED FRONT END

LOADERS WITH A 5 YARD BUCKET CAPACITY OR EQUIVALENT.

TOBYHANNA ARMY DEPOT ON SITE POC: DAVE MARTZEN, 570-615-

THE COR FOR THIS RENTAL IS BERNADETTE GIRGENTI 570-615-9413

SEE ATTACHED SPECIAL INSTRUCTIONS AND PWS

FOB: Destination

NSN: AASSVC318001BH

MILSTRIP: W25G1V318001BH

PURCHASE REQUEST NUMBER: W25G1V318001BH

PSC CD: W056

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 POP 16-OCT-2023 TO

16-APR-2024

N/A SEE BELOW FOR SEPARATE SHIPPING

INSTRUCT

XXX

XXX PA 00000

FOB: Destination

W25G1V

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-22 Alternative Line Item Proposal JAN 2017 52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other Covered Entities

NOV 2021

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

NOV 2021

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-6 Brand Name or Equal AUG 1999 52.212-1 Instructions to Offerors--Commercial Products and

Commercial Services

MAR 2023

52.212-4 Contract Terms and Conditions--Commercial Products and Commercial Services

DEC 2022

52.212-5 (Dev) Contract Terms and Conditions Required to Implement Statutes or Executive Orders--Commercial Products and Commercial Services (Deviation 2018-O0021)

JUN 2023

52.219-6 Notice Of Total Small Business Set-Aside NOV 2020 52.222-3 Convict Labor JUN 2003 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-37 Employment Reports on Veterans JUN 2020 52.222-50 Combating Trafficking in Persons NOV 2021 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.233-3 Protest After Award AUG 1996 52.247-34 F.O.B. Destination NOV 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7009 Limitations on the Use or Disclosure of Third-Party

Contractor Reported Cyber Incident Information

JAN 2023

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

JAN 2023

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.225-7001 Buy American And Balance Of Payments Program--Basic JAN 2023 252.225-7002 Qualifying Country Sources As Subcontractors MAR 2022 252.225-7007 Prohibition on Acquisition of Certain Items from Communist

Chinese Military Companies

DEC 2018

252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (AUG 2020)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

(End of provision)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of clause)

52.204-20 Predecessor of Offeror (AUG 2020)

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ___ ] will, [ ___ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

(a) Definitions. As used in this clause--

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People's Republic of China.

Covered telecommunications equipment or services means--

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means--

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled--

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause:

(i) Within one business day from the date of such identification or notification: The contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: Any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products or commercial services.

52.204-26 COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT

2020)

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(c) Representations.

(1) The Offeror represents that it [ ___ ] does, [ ___ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

(a) Definitions. As used in this clause--

Covered application means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

Information technology, as defined in 40 U.S.C. 11101(6)--

(1) Means any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use-

(i) Of that equipment; or

(ii) Of that equipment to a significant extent in the performance of a service or the furnishing of a product;

(2) Includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; but

(3) Does not include any equipment acquired by a Federal contractor incidental to a Federal contract.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L. 117-328), the No TikTok on Government Devices Act, and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, "No TikTok on Government Devices" Implementation Guidance, collectively prohibit the presence or use of a covered application on executive agency information technology, including certain equipment used by Federal contractors. The Contractor is prohibited from having or using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided by the Contractor under this contract, including equipment provided by the Contractor's employees; however, this prohibition does not apply if the Contracting Officer provides written notification to the Contractor that an exception has been granted in accordance with OMB Memorandum M-23-13.

(c) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts, including subcontracts for the acquisition of commercial products or commercial services.

52.209-2 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS--

REPRESENTATION (NOV 2015)

(a) Definitions. Inverted domestic corporation and subsidiary have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10).

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.

(c) Representation. The Offeror represents that--

(1) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and

(2) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation.

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.212-2 EVALUATION--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (NOV 2021)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

BASIS OF AWARD:

THE AWARD WILL BE BASED ON THE BEST VALUE TO THE GOVERNMENT, CONSIDERING PRICE

AND PAST PERFORMANCE, TO THE RESPONSIBLE OFFEROR OTHERWISE CONFORMING TO ALL

SOLICITATION REQUIREMENTS. THE GOVERNMENT RESERVES THE RIGHT TO AWARD TO OTHER

THAT THE LOWEST PRICE.

(b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (MAR 2023)

Long-term contract means a contract of more than five years in duration, including options.