22-32-250 IFB Manual.pdf

DOCUMENTS AND SPECIFICATIONS

FOR

Salem Public Schools

Security and Hardware System Upgrades -

Phase 1B Salem, Massachusetts

City of Salem

Re-Bidding Documents

April 6, 2021

Prepared by:

SOCOTEC AE Consulting, LLC 250 Dorchester Avenue

Boston, Massachusetts 02127

(617) 268-8977

Fax (617) 464-2971

SOCOTEC PROJECT NUMBER CB182080.3.2

City Bid Number: 22-32-250

SECURITY AND HARDWARE SYSTEM UPGRADES - PHASE 1B SOCOTEC AE Consulting LLC SALEM PUBLIC SCHOOLS Boston, Massachusetts SALEM, MASSACHUSETTS Tel: (617) 268-8977 SOCOTEC AE JOB NO. CB182080.3.2 Fax: (617) 464-2971

TABLE OF CONTENTS

PAGE - 1

SALEM PUBLIC SCHOOLS

SECURITY AND HARDWARE SYSTEM UPGRADES - PHASE 1A # OF PAGES

TABLE OF CONTENTS 2

SECTION

BIDDING DOCUMENTS

00 11 13 - NOTICE TO BIDDERS 2

00 21 13 - INSTRUCTION TO BIDDERS 9

00 41 13 - FORM FOR GENERAL BID 6

00 43 43 - PREVAILING WAGE RATES 32

00 44 00 - BID ACCEPTANCE FORM 1

CONTRACT DOCUMENTS

00 52 13 - STANDARD FORM OF AGREEMENT 6

00 61 13 - PAYMENT BOND 7

00 61 16 - APPLICATION AND CERTIFICATE FOR PAYMENT 2

00 62 16 - CERTIFICATE OF INSURANCE 1

00 63 63 - CHANGE ORDER 1

00 65 16 - CERTIFICATE OF SUBSTANTIAL COMPLETION 1

00 65 19 - GENERAL RELEASE AND WAIVER OF LIEN-GENERAL

CONTRACTOR 1

00 72 13 - GENERAL CONDITIONS 39

00 75 00 - DRAWING LIST 1

TECHNICAL SPECIFICATIONS

DIVISION 01 GENERAL REQUIREMENTS

01 11 13 - SUMMARY OF WORK 2

01 31 13 - COORDINATION 5

01 33 00 - SUBMITTALS 10

01 35 13 - SPECIAL PROJECT PROCEDURES 8

01 40 00 - CONDUCT OF THE WORK 2

01 42 00 - DEFINITIONS AND STANDARDS 3

01 45 00 - QUALITY CONTROL 2

01 50 00 - TEMPORARY FACILITIES 8

01 51 00 - PROTECTION 4

01 52 00 - CLEANING UP 3

01 70 00 - PROJECT CLOSEOUT 2

01 72 00 - SURVEYS AND RECORD DRAWINGS 2

DIVISION 02 EXISTING CONDITIONS

02 41 00 - SELECTIVE DEMOLITION 5

TABLE OF CONTENTS

PAGE - 2

DIVISION 06 WOOD AND PLASTIC

06 10 00 - ROUGH CARPENTRY 5

DIVISION 07 THERMAL AND MOISTURE PROTECTION

07 84 00 - FIRESTOPPING 3

DIVISION 08 OPENINGS

08 71 00 – DOOR HARDWARE 32

DIVISION 09 FINISHES

09 91 00 – PAINTING 5

PAGE - 1

NOTICE TO BIDDERS

00 11 13 - PAGE 1

SECTION 00 11 13

CITY OF SALEM

SECURITY AND HARDWARE SYSTEM UPGRADES – PHASE 1B

SALEM, MASSACHUSETTS

The City of Salem, Massachusetts invites sealed proposals from Contractors for the Security and Hardware System Upgrades – Phase 1B, Salem, Massachusetts. The work includes but is not limited to installation of security systems and related work. The estimated cost of the work is $450,000.

Plans, specifications and other Contract Documents may be seen, examined or obtained at www.salem.com/bids, after 8:00 am, E.D.T., Wednesday, April 6, 2022. Documents will not be mailed.

Sealed general bids for this project will be accepted from eligible bidders at 93 Washington St., 2nd floor, Salem, Massachusetts, 01970 until 11:00 am, Thursday April 21, 2022 at which place and time they shall be publicly opened and recorded.

A pre-bid conference will be held for all interested parties on-site on Wednesday April 13 at 3:00

pm. Meet at the Main Entrance to the Salem High School, 77 Wilson Street, Salem MA 01970.

Attendance at this pre-bid conference is strongly recommended for parties submitting a bid.

Each general bid shall be accompanied by a bid deposit in the form of a bid bond, or cash, or a certified check on, or a treasurer's or cashier's check issued by a responsible bank or trust company, payable to the City of Salem in the amount of five percent (5%) of value of the bid.

Bid deposits will be dealt with as provided in Massachusetts General Laws, Chapter 149, Section 44B.

To be given consideration, all general bids must be accompanied by a copy of the Bidder's Certificate of Eligibility and an Update Statement. The General Bidder must be certified eligible in the DCAMM Prime category: Alarm Systems.

Bids shall be made on the basis of the Minimum Wage Rates as determined by the Commissioner of Labor and Industries, Pursuant to the Provisions of Chapter 149, Sections 26 to 27D inclusive of Massachusetts General Laws, a copy of which is attached to and is made a part of the Contract.

Bidders’ selection procedures and contract award shall be in conformity with applicable statues of the Commonwealth of Massachusetts.

Performance and Labor and Materials payment bonds in the full amount of the contract price will be required from the successful bidder.

00 11 13 - PAGE 2

The Awarding Authority reserves the right to reject any or all general bids, if it be in the public interest to do so, and to reject any sub-bid on any sub-trade if it determines that such sub-bid does not represent the sub-bid of a person competent to perform the work as specified or that less than three such sub-bids were received and that the prices are not reasonable for acceptance without further competition.

City of Salem

Anthony P. Delaney, MCPPO Chief Procurement Officer

END OF SECTION

INSTRUCTION TO BIDDERS

00 21 13 - PAGE 1

SECTION 00 21 13 - INSTRUCTION TO BIDDERS

PART 1 - GENERAL

1.01 SCHEDULE OF DATES

A. Plans and Specifications ready for Bidders: April 6, 2022, 8:00 AM.

B. Pre-bid walk-thru scheduled for 3:00 pm on April 13, 2022. Meet at the Main Entrance to the Salem High School, 77 Wilson Street, Salem MA 01970.

C. Addenda will be issued with interpretations as determined by the Architect.

D. General Bid Deadline: Thursday, April 21, 11:00 AM

1.02 BIDDING PROCEDURE

A. Bids for the work are subject to the provisions of General Laws, Chapter 149, Sections 44A-44L inclusive, as amended. Regulations governing the bidding procedures as set forth in the above mentioned amended General Laws must be followed.

B. In the event of any inconsistencies between any of the provisions of these Contract Documents and of the cited statute, anything herein to the contrary notwithstanding, the provisions of the said statute shall control.

C. No General Bid received by the Awarding Authority after the time respectively established herein for the opening of General Bids will be considered, regardless of the cause for the delay in the receipt of any such bid.

1.03 WITHDRAWAL OF BIDS

A. Bids may be withdrawn prior to the time respectively established for the opening of General Bids only on written request to the Awarding Authority.

1.04 INTERPRETATION OF CONTRACT DOCUMENTS

A. No oral interpretation will be made to any bidder. All questions or requests for interpretations must be made in writing to the Architect.

B. Every interpretation made to a bidder will be in the form of an Addendum, to the drawings and/or specifications, which will be made available to all persons to whom Contract Documents have been issued.

C. Failure of the Awarding Authority to send, or of any bidder to receive any such addendum shall not relieve any bidder form obligation under his bid as submitted.

00 21 13 - PAGE 2

D. All such addenda shall become a part of the Contract Documents.

1.05 EXAMINATION OF SITE AND CONTRACT DOCUMENTS

A. Each bidder shall visit the site of the proposed work and fully acquaint himself with conditions as they exist, and shall also thoroughly examine the Contract Documents. Failure of any bidder to visit the site and acquaint himself with the Contract Documents shall not relieve any bidder from any obligation with respect to his bid.

B. By submitting a bid, the bidder agrees that the Contract Documents are adequate and that the required result can be produced. The successful bidder shall furnish any and all labor, materials, insurance, permits and all other items needed to produce the required result to the satisfaction of the Awarding Authority.

1.06 BID SECURITY

A. The General Contractor's bid must be accompanied by bid security in the amount of five percent (5%) of the bid.

B. At the option of the bidder, the security may be bid bond, cash, certified, treasurer's or cashier's check issued by a responsible bank or trust company. No other type of bid security is acceptable.

Bid Bonds shall be issued by a Surety Company qualified to do business under the laws of the Commonwealth of Massachusetts.

C. Certified, Treasurer's or Cashier's check shall be made payable to the City of Salem.

D. The bid security shall secure the execution of the Contract and the furnishing of a Performance and Payment Bond by the successful General Bidder.

E. Should any General Bidder to whom an award is made fail to enter into a contract therefore within five (5) days, Saturdays, Sundays and Legal Holidays, excluded, after notice of award has been mailed to him or fail within such time to furnish a Performance Bond and also a Labor and Materials or Payment Bond as required, the amount so received from such General Bidder through his Bid Bond, Cash, Certified, Treasurer's or Cashier's check as bid deposit shall become the property of the City of Salem, Massachusetts as liquidated damages; provided that, the amount of the bid deposit which becomes the property of the City of Salem, Massachusetts shall not in any event exceed the difference between his bid price and the bid price of the next lowest responsible and eligible bidder; and provided further that, in case of death, disability, bona fide clerical error or mechanical error of a substantial nature, or other unforeseen circumstances affecting the General Bidder, his deposit shall be returned to him.

00 21 13 - PAGE 3

1.07 BID FORM

A. General Bids shall be submitted on the "FORM FOR GENERAL BID" enclosed.

Erasures or other changes must be explained or noted over the signature of the bidder.

B. Bid forms must be completely filled in. Bids which are incomplete, conditional, or obscure, or which contain additions not called for will be rejected.

C. General Bidders shall submit one set of executed bid forms to the Awarding Authority.

1.08 SUBMISSION OF BIDS AND BID SECURITIES

A. Each bid submitted by a General Contractor shall be enclosed in a sealed envelope which shall be placed with the bid security in an outer envelope. The outer envelope shall be sealed and clearly marked as follows:

(Firm Name):

General Bid and Bid Security for:

Salem Public Schools Security and Hardware Upgrades - Phase 1B, Salem, MA

00 21 13 - PAGE 4

1.09 AWARD OF CONTRACT

A. The Contract shall be awarded to the lowest responsible and eligible General Bidder on the basis of competitive bids in accordance with the procedure set forth in the provision of Section 44B-44L inclusive, as amended or inserted, by Chapter 149 of the General Laws of the Commonwealth of Massachusetts.

B. If the bidder selected as the General Contractor fails to perform his agreement to execute a contract in accordance with the terms of his General Bid, and furnish a Performance Bond and also a Labor and Materials or Payment Bond, as stated in his General Bid in accordance with Section 44F, an award shall be made to the next lowest responsible and eligible bidder.

C. The words "lowest responsible and eligible bidder" shall be the bidder whose name is the lowest of those bidders possessing the skill, ability and integrity necessary to the faithful performance of the work and who shall certify that he is able to furnish labor that can work in harmony with all other elements of labor employed, or to be employed, on the work. Essential information in regard to such qualifications shall be submitted in such form as the Awarding Authority may require.

D. Action on the award will be taken within thirty (30) days, Saturdays, Sundays and Legal Holidays excluded after the opening of the bids.

1.10 SECURITY FOR FAITHFUL PERFORMANCE

A. The successful bidder must deliver to the Awarding Authority simultaneously with his delivery of the executed contract, an executed Performance Bond, and also a Labor and Materials or Payment Bond, each of a surety company qualified to do business under the laws of the Commonwealth and satisfactory to the Awarding Authority and each in the sum of One Hundred Percent (100%) of the Contract Price, as surety for the faithful performance of his contract, and for the payment of all persons performing labor or furnishing materials in connections therewith. Said bonds shall provide that, if the General Contractor fails or refuses to complete the Contract, the Surety Company will be obligated to do so.

B. Premiums are to be paid by the General Contractor, and are to be included in the Contract Price.

1.11 EQUAL OPPORTUNITY

A. The City of Salem is an Equal Opportunity employer.

00 21 13 - PAGE 5

1.12 PRE-BID WALK-THRU

A. Pre-bid walk-thru is scheduled for 3:00 pm on April 13, 2022. Meet at the Main Entrance to the Salem High School, 77 Wilson Street, Salem MA 01970.

1.13 CONTRACT DOCUMENTS

A. Contract Documents may be obtained on or after Wednesday April 6, 8:00 AM.

1.14 EQUALITY

A. Except where otherwise specifically provided to the contrary, the words "or equal" are hereby inserted immediately following the name or description of each article, assembly, system, or any component part thereof, in the Contract Documents. It is the contractor's responsibility to provide all the research and documentation that would prove a product or assembly is "equal". Failure to provide research or documentation does not alleviate the contractor's responsibility to meet the schedule.

1.15 TAX FREE NUMBER

A. The City of Salem has a tax free number

1.16 ARBITRATION

A. The City of Salem does not use Arbitration. Any and all references to arbitration shall be stricken from the contract.

1.17 SCHEDULE

A. All work shall be substantially completed at the High School by August 15, 2022, and at the Salerno Center and Middle School by October 15, 2022

B. The Contractor is advised that because of the bidding schedule, there is more than enough time to order all the material in advance of the work so that all the construction can occur between April 25, 2022 and August 15, 2022. Special notice is given that all the long lead time items can and must be ordered well in advance of site mobilization in order to meet the schedule. No exceptions will be made nor allowed if the contractor fails to properly plan the procurement of all items in advance of the work. Late fees will be imposed if the construction is not done on time.

00 21 13 - PAGE 6

1.18 WEEKLY JOB MEETINGS

A. There will be a weekly job meeting at the site on the same agreed upon day and time to discuss and view the progress of the work and to answer questions. The Contractor's job superintendent and Project Manager shall attend each meeting.

1.19 PROJECT SUPERINTENDENT

A. The Contractor shall provide the same person as Superintendent for the entire duration of the project. Failure to maintain the same person in this position shall result in a $1,000 penalty (per incident) which shall cover the Architect's time to re-orient new personnel.

1.20 AWARD

A. The awarding authority reserves the right to reject any or all bids, if it be in the public interest to do so, and to act upon the bids and make its award in any lawful manner.

1.21 MINIMUM WAGE SCHEDULE

A. Bids shall be made on the basis of the Minimum Wage Schedule, as determined by the Commissioner of Labor and Industries, pursuant to the provision of Chapter 149, Section 26 to 27D inclusive, of the Massachusetts General Laws.

B. All Bids including shall be accompanied by the Bidder's Certification regarding payment of prevailing wage rates on the form included with the Form for General Bid and the Sub-Bid Form.

1.22 CONFLICT OF INTEREST

A. A bidder filing a proposal thereby certifies that the proposal is made in good faith, without fraud, collusion, or connection of any kind with any other bidder for the same work, and that the bidder is completing solely on its own behalf without connection with, or obligation to, any undisclosed person or firm.

1.23 PROCEED ORDERS

A. No bidder is to proceed without a proceed order as set out in the contract.

1.24 STAGING

A. The General Contractor shall provide all the vertical access (which includes staging, vertical lifts, etc.) and hoisting for all the work of the Contract over 8’-0” above grade. Both the Security Contractor and the Door Hardware Contractor shall each provide complete coverage of all wall areas receiving work and shall

00 21 13 - PAGE 7

provide full decks and complete access for subcontractors, as well as the Architect.

B. Access is included in the base contract. Access shall be granted to the Architect at any time.

1.25 CONSTRUCTION BARRICADES

A. The General Contractor shall provide all barricades to enclose the work area to prevent unauthorized access to the site.

1. The barricades shall provide enough room for all construction activities to be performed while separated from pedestrians, students, and staff on site.

2. Safety is the sole responsibility of the Contractor and any barricades necessary to protect the work and the public shall be provided.

3. Provide entrance tunnel protection.

1.26 OSHA TRAINING

A. The bidder certifies that all employees to be employed at the worksite shall have successfully completed a course in construction safety and health approved by the United States Occupational Safety and Health Administration that is at least ten

(10) hours in duration at the time the employee begins work and shall furnish documentation of successful completion of said course with the first certified payroll report for each employee (Chapter 306 of the Acts of 2004).

1.27 INSURANCE

A. The contractor shall purchase and maintain, at his expense all insurance required by the Contract. Documents and all insurance required by the applicable laws of Massachusetts, including but not limited to, General Laws, Chapter 146, in connection with all hoisting equipment.

B. The Contractor shall purchase and maintain such insurance as will protect him from claims under workmen’s compensation acts and from claims for damages because of bodily injury, including death and all property damage including, without limitation, damage to buildings and adjoining the site of construction which might arise from and during operations under this contract, whether such operations be by himself or by any subcontractor or anyone directly or indirectly employed by either of them including:

1. Statutory Worker’s Compensation and Employer’s Liability

00 21 13 - PAGE 8

The contractor shall provide insurance for the payment of compensation and the furnishing of other benefits under Chapter 152 of the General Laws (so-called Worker’s Compensation Act) to all persons to be employed under this contract and shall continue in force such insurance as aforesaid shall be deemed a material breach of this Contract and shall operate as an immediate termination thereof. The contractor shall, without limiting the generality of the foregoing, conform to the provisions of Section 34A of Chapter 149 of the General Laws, which Section is incorporated herein by reference and made a part of hereof.

2. Comprehensive General Liability Insurance

Minimum bodily injury limits of $ 500,000 per person and $ 1,000,000 per accident, and property damage limits of $ 500,000 per accident and $ 1,000,000 aggregate during any 12 month period, shall include the following:

a. Public liability (bodily injury and property damage)

b. X.C.U. (explosion, collapse, and underground utilities)

c. Independent contractor’s protective liability.

d. Products and completed operations.

e. Save harmless agreement for Owner and Architects set forth in ARTICLE 10.11 of the GENERAL CONDITIONS.

3. Comprehensive All Risk Motor Vehicle Liability Insurance

Minimum bodily injury limits of $ 500,000 per person, $ 1,000,000 per accident, and property damage limit of $ 1,000,000 per accident.

4. All Risk Insurance

Covering all Contractor’s equipment with a provision for Waiver of Subrogation against the Owner.

5. Excess Liability Insurance in Umbrella Form with combined Bodily Injury and Property Damage Limit of $ 1,000,000.

6. City of Salem and SOCOTEC AE Consulting LLC. shall be listed as Additional Insured with a Waiver of Subrogation on the insurance policy for this project.

7. The selected bidder shall take out and maintain during the life of this contract Workers’ Compensation Insurance for all employees employed

00 21 13 - PAGE 9

on the site of this project, in a manner and to the extent provided by Chapter 152 of the General Laws, and shall provide the City with written evidence showing compliance with this statute at the time of award.

8. The selected Bidder shall indemnify and save the City harmless from and against all claims, suits, damages and outlays resulting from or by reason of loss, damage or injury of or to any person or property, wherever located which shall be caused by any action or operation under this agreement.

1.28 SITE ACCESS

A. The General Contractor shall gain access to the site via routes approved by the Owner.

1. The General Contractor as part of the bid price will restore all roads, curbs, driveways, walks and grassed or landscaped areas damaged during construction.

1.29 CONTRUCTION TRAILER

A. The General Contractor shall locate the construction trailer at locations approved by the Owner.

B. The General Contractor shall locate all on site stored or staged materials within the enclosed area designated by the Owner.

1.30 BUILDING PERMIT FEES

A. All Municipal permit fees will be waived for this project.

1.31 EQUAL OPPORTUNITY

A. The City of Salem is an equal opportunity employer.

1.32 COMPLETE BID FORMS

A. Please Note: Each bidder must fill in all the blanks on all the bid forms, even if the information is “zero dollars” or “not applicable”. Also, please acknowledge all Addenda even if they do not pertain to your trade.

00 21 13 - PAGE 10

1.33 COMPLIANCE WITH MASSACHUSETTS GENERAL LAWS

A. Before a contract may be executed by the City, the successful Bidder will be required, in accordance with the provisions of M.G.L. Chapter 62C, Section 49A, to execute and file with the City the following certificate:

B. “Pursuant to Massachusetts General Laws, Chapter 62C, Section 49A, I certify under the penalty of perjury that I, to the best of my knowledge and belief have filed all state tax returns and paid all the state taxes required under law.

Signature of Individual or Corporate Name

By:

(Signature of Corporate Officer if applicable)

Title:

Social Security Number of Federal Identification Number

END OF SECTION

FORM FOR GENERAL BID

00 41 13 - PAGE 1

SECTION 00 41 13 FORM FOR GENERAL BID

SALEM PUBLIC SCHOOLS SECURITY AND HARDWARE SYSTEM UPGRADES -

PHASE 1B

SALEM, MASSACHUSETTS

April 21, 2022

Salem City Hall 93 Washington Street, 2nd Floor Salem, Massachusetts, 01970

City of Salem:

A. Basic Price

The undersigned, having visited the site of the above project and having familiarized myself with the local conditions affecting the cost of the work and with the contract documents, including Amendments and Addenda Nos. , hereby proposes to furnish all labor, materials, tools, equipment, insurance, permits, taxes, and to do and lawfully perform all things as provided in the specifications, all in accordance with the contract documents, for the sum of:

Dollars, $

B. The subdivision of the proposed contract price is as follows:

Item 1. The work of the General Contractor, being all work other than that covered by Item 2. $

Item 2. Sub Bids as follows:

Sub-Trade Number of Sub-Bidder Amount Bonds required indicated by "Yes" or "No"

Total of Item 2 $

00 41 13 - PAGE 2

C. The undersigned agree that each of the above the named sub-bidders will be used for the work indicated at the amount stated, unless a substitution is made. The undersigned further agrees to pay the premiums for the performance and payment bonds furnished by sub-bidders as requested herein and that all of the cost of all such premiums is included in the amount set forth in item 1 of this bid.

D. The undersigned agrees that if he is selected as general contractor, he will promptly confer with the awarding authority on the question of sub-bidders; and that the awarding authority may substitute for any sub-bid listed above a sub-bid filed with the awarding authority by another sub-bidder for the sub-trade against whose standing and ability the undersigned makes no objection; and that the undersigned will use all such finally selected sub-bidders at the amounts named in their respective sub-bids and be in every way as responsible for them and their work as if they had been originally names in this general bid. , the total contract price being adjusted to confirm thereto.

E. The undersigned agrees that, if s/he is selected as general contractor, he will within five days, Saturdays, Sundays and legal holidays excluded, after presentation thereof by the Awarding Authority, execute a contract in accordance with the terms of this bid and furnish a performance bond and also a labor and materials or payment bond, each of a surety company qualified to do business under the laws of the Commonwealth and satisfactory to the Awarding Authority and each in the sum of the contract price, the premiums for which are to be paid by the general contractor and are included in the contract price; provided however, that if there is more than 1 surety company, the surety companies shall be jointly and severally liable.

F. The undersigned hereby certifies that he is able to furnish labor that can work in harmony with all other elements of labor employed or to be employed in the work; that all employees to be employed at the worksite will have successfully completed a course in construction safety and health approved by the United States Occupational Safety and Health Administration that is at least 10 hours in duration at the time the employee begins work and who shall furnish documentation of successful completion of said course with the first certified payroll report for each employees; and the he will comply with all laws and regulations applicable to awards made subject to section 44A.

G. The undersigned as Bidder certifies that if this proposal is accepted, s/he will furnish to the City of Salem with the invoice for the material or equipment supplied two copies of any and all Material Safety Data Sheets applicable to such material or equipment, as required by M.G.L. Chapter 111F, so called "Right to Know Law".

H. The undersigned certifies under penalties of perjury that this bid is in all respects bona fide, fair and made without collusion or fraud with any other person. As

00 41 13 - PAGE 3

under in this section, the work "person" shall mean any natural person, joint venture, partnership, corporation, or other business or legal entity.

I. The undersigned further certifies under penalty of perjury that the said undersigned is not presently debarred from doing public construction work in the commonwealth under the provisions of section twenty-nine F of chapter twenty-nine, or any other applicable debarment provisions of any other chapter of the General Laws or any rule of regulation promulgated thereunder.

J. Substantial Completion

Substantial completion to be by August 15, 2022 (High School), and October 15, 2022 (Salerno Center and Collins Middle School).

Sincerely, (Bidder)

(Address of Bidder) By:

(Title - Owner*, Partner*) (Seal, if Corporation) By:

(If Corporation - Name and Office)

* If the business owned by the individual or partnership is conducted under a trade or assumed name, a certified copy of doing business under an assumed name should be annexed.

00 41 13 - PAGE 4

K. BIDDER’S CERTIFICATION REGARDING PAYMENT OF PREVAILING

WAGE RATES

The undersigned bidder hereby certifies, under the pains and penalties of perjury, that the foregoing bid is based upon the payment to laborers to be employed on the project of wages in an amount no less than the applicable prevailing wage rates established for the project by the Massachusetts Department of Labor and Industries. The undersigned bidder agrees to indemnify the Awarding Authority for, from and against any loss, expense, damages, actions or claims, including any expense incurred in connection with any delay or stoppage of the project work, arising out of or as a result of (1) the failure of the said bid to be based upon the payment of the said applicable prevailing wage rates or (2) the failure of the bidder, if selected as the contractor, to pay laborers employed on the project the said applicable prevailing wage rates.

DATED: NAME OF BIDDER:

BY:

NAME:

TITLE:

00 41 13 - PAGE 5

Acknowledgment of Principal, if a Corporation

State of )

:SS:

County of )

On this day of 20 before me personally came to me known, who, being by me duly sworn, did depose and say that he/she resides at , that he/she is the of the corporation described herein and which executed the foregoing instrument; that he/she knows the seal of said corporation; that one of the seals affixed to said instrument is such seal; that it was so affixed by order of the directors of said corporation, and that he/she signed his/her name thereto by like order.

(Notary Public)

Acknowledgment of Principal, if a Partnership

State of )

:SS:

County of )

On this day of 20 before me personally came to me known, and known to me to be one of the members of the firm of who executed the foregoing instrument and he/she acknowledged to me that he/she executed the same as and for the act of said firm.

00 41 13 - PAGE 6

Acknowledgment of Principal, if an Individual

State of )

:SS:

County of )

On this day of 20 before me personally came to me known, and known to me to be the person described herein and who executed the foregoing instrument and he/she acknowledged to me that he/she executed the same.

(If bidder is a partnership, state here the name and residence of each member thereof)

Name of Partners Residence Address

(If bidder is a corporation, state here the title, name, and residence of each member thereof)

Title Name Residence Address

Organized under the laws of the state of

Date:

BID ACCEPTANCE FORM

00 44 00 - PAGE 1

SECTION 00 44 00 - BID ACCEPTANCE FORM - NOTICE OF AWARD

A. Acceptance

1. The foregoing proposal of Salem Public Schools Security and Hardware System Upgrades - Phase 1A, Salem, Massachusetts, dated _______________in the amount of

Dollars ($ ) is hereby accepted as of .

2. This Proposal contains the following Alternates:

(describe the Alternates)

3. Signed By:

for City of Salem

Attest:

THE COMMONWEALTH OF MASSACHUSETTS

DEPARTMENT OF LABOR STANDARDS

As determined by the Director under the provisions of the

Massachusetts General Laws, Chapter 149, Sections 26 to 27H

EXECUTIVE OFFICE OF LABOR AND WORKFORCE DEVELOPMENT

Prevailing Wage Rates

CHARLES D. BAKER ROSALIN ACOSTA

SecretaryGovernor

MICHAEL FLANAGAN

Providing security updates, cameras, systems.

Director

Awarding Authority: City of Salem

City/Town:Contract Number: SALEM

Description of Work:

Job Location: 77 Wilson Street Salem, MA

Information about Prevailing Wage Schedules for Awarding Authorities and Contractors

• This wage schedule applies only to the specific project referenced at the top of this page and uniquely identified by the

“Wage Request Number” on all pages of this schedule.

• An Awarding Authority must request an updated wage schedule from the Department of Labor Standards (“DLS”) if it has not opened bids or selected a contractor within 90 days of the date of issuance of the wage schedule. For CM AT RISK projects

(bid pursuant to G.L. c.149A), the earlier of: (a) the execution date of the GMP Amendment, or (b) the bid for the first construction scope of work must be within 90-days of the wage schedule issuance date.

• The wage schedule shall be incorporated in any advertisement or call for bids for the project as required by M.G.L. c. 149, § 27. The wage schedule shall be made a part of the contract awarded for the project. The wage schedule must be posted in a conspicuous place at the work site for the life of the project in accordance with M.G.L. c. 149 § 27. The wages listed on the wage schedule must be paid to employees performing construction work on the project whether they are employed by the prime contractor, a filed sub-bidder, or any sub-contractor.

• All apprentices working on the project are required to be registered with the Massachusetts Department of Labor

Standards, Division of Apprentice Standards (DLS/DAS). Apprentice must keep his/her apprentice identification card on his/her person during all work hours on the project. An apprentice registered with DAS may be paid the lower apprentice wage rate at the applicable step as provided on the prevailing wage schedule. Any apprentice not registered with DLS/DAS regardless of whether or not they are registered with any other federal, state, local, or private agency must be paid the journeyworker's rate for the trade.

• The wage rates will remain in effect for the duration of the project, except in the case of multi-year public construction projects. For construction projects lasting longer than one year, awarding authorities must request an updated wage schedule.

Awarding authorities are required to request these updates no later than two weeks before the anniversary of the date the contract was executed by the awarding authority and the general contractor. For multi-year CM AT RISK projects, awarding authority must request an annual update no later than two weeks before the anniversary date, determined as the earlier of: (a) the execution date of the GMP Amendment, or (b) the execution date of the first amendment to permit procurement of construction services. Contractors are required to obtain the wage schedules from awarding authorities, and to pay no less than these rates to covered workers. The annual update requirement is not applicable to 27F “rental of equipment” contracts.

• Every contractor or subcontractor which performs construction work on the project is required to submit weekly payroll reports and a Statement of Compliance directly to the awarding authority by mail or email and keep them on file for three years.

Each weekly payroll report must contain: the employee’s name, address, occupational classification, hours worked, and wages paid. Do not submit weekly payroll reports to DLS. A sample of a payroll reporting form may be obtained at http://www.mass.gov/dols/pw.

• Contractors with questions about the wage rates or classifications included on the wage schedule have an affirmative obligation to inquire with DLS at (617) 626-6953.

• Employees not receiving the prevailing wage rate set forth on the wage schedule may report the violation to the Fair Labor

Division of the office of the Attorney General at (617) 727-3465.

• Failure of a contractor or subcontractor to pay the prevailing wage rates listed on the wage schedule to all employees who perform construction work on the project is a violation of the law and subjects the contractor or subcontractor to civil and criminal penalties.

KARYN E. POLITO

Lt. Governor

Classification Total RateBase Wage Health Pension Supplemental

Unemployment Effective Date

Construction

(2 AXLE) DRIVER - EQUIPMENT

TEAMSTERS JOINT COUNCIL NO. 10 ZONE B

$65.37 12/01/2021 $13.41 $0.00 $35.95 $16.01

(3 AXLE) DRIVER - EQUIPMENT

TEAMSTERS JOINT COUNCIL NO. 10 ZONE B

$65.44 12/01/2021 $13.41 $0.00 $36.02 $16.01

(4 & 5 AXLE) DRIVER - EQUIPMENT

TEAMSTERS JOINT COUNCIL NO. 10 ZONE B

$65.56 12/01/2021 $13.41 $0.00 $36.14 $16.01

ADS/SUBMERSIBLE PILOT

PILE DRIVER LOCAL 56 (ZONE 1)

$135.57 08/01/2020 $9.40 $0.00 $103.05 $23.12

For apprentice rates see "Apprentice- PILE DRIVER"

AIR TRACK OPERATOR

LABORERS - ZONE 2

$61.90 12/01/2021 $9.10 $0.00 $36.16 $16.64

$62.80 06/01/2022 $9.10 $0.00 $37.06 $16.64

$63.65 12/01/2022 $9.10 $0.00 $37.91 $16.64

$64.55 06/01/2023 $9.10 $0.00 $38.81 $16.64

$65.45 12/01/2023 $9.10 $0.00 $39.71 $16.64 For apprentice rates see "Apprentice- LABORER"

AIR TRACK OPERATOR (HEAVY & HIGHWAY)

LABORERS - ZONE 2 (HEAVY & HIGHWAY)

$61.90 12/01/2021 $9.10 $0.00 $36.16 $16.64

For apprentice rates see "Apprentice- LABORER (Heavy and Highway)

ASBESTOS REMOVER - PIPE / MECH. EQUIPT.

HEAT & FROST INSULATORS LOCAL 6 (BOSTON)

$60.35 12/01/2020 $12.80 $0.00 $38.10 $9.45

ASPHALT RAKER

LABORERS - ZONE 2

$61.40 12/01/2021 $9.10 $0.00 $35.66 $16.64

$62.30 06/01/2022 $9.10 $0.00 $36.56 $16.64

$63.15 12/01/2022 $9.10 $0.00 $37.41 $16.64

$64.05 06/01/2023 $9.10 $0.00 $38.31 $16.64

$64.95 12/01/2023 $9.10 $0.00 $39.21 $16.64 For apprentice rates see "Apprentice- LABORER"

ASPHALT RAKER (HEAVY & HIGHWAY)

LABORERS - ZONE 2 (HEAVY & HIGHWAY)

$61.40 12/01/2021 $9.10 $0.00 $35.66 $16.64

For apprentice rates see "Apprentice- LABORER (Heavy and Highway)

ASPHALT/CONCRETE/CRUSHER PLANT-ON SITE

OPERATING ENGINEERS LOCAL 4

$81.43 12/01/2021 $14.00 $0.00 $51.38 $16.05

For apprentice rates see "Apprentice- OPERATING ENGINEERS"

BACKHOE/FRONT-END LOADER

OPERATING ENGINEERS LOCAL 4

$81.43 12/01/2021 $14.00 $0.00 $51.38 $16.05

For apprentice rates see "Apprentice- OPERATING ENGINEERS"

BARCO-TYPE JUMPING TAMPER

LABORERS - ZONE 2

$61.40 12/01/2021 $9.10 $0.00 $35.66 $16.64

$62.30 06/01/2022 $9.10 $0.00 $36.56 $16.64

$63.15 12/01/2022 $9.10 $0.00 $37.41 $16.64

$64.05 06/01/2023 $9.10 $0.00 $38.31 $16.64

$64.95 12/01/2023 $9.10 $0.00 $39.21 $16.64 For apprentice rates see "Apprentice- LABORER"

BLOCK PAVER, RAMMER / CURB SETTER

LABORERS - ZONE 2

$61.90 12/01/2021 $9.10 $0.00 $36.16 $16.64

$62.80 06/01/2022 $9.10 $0.00 $37.06 $16.64

$63.65 12/01/2022 $9.10 $0.00 $37.91 $16.64

$64.55 06/01/2023 $9.10 $0.00 $38.81 $16.64

$65.45 12/01/2023 $9.10 $0.00 $39.71 $16.64 For apprentice rates see "Apprentice- LABORER"

Issue Date: Wage Request Number:03/10/2022 Page 2 of 3220220310-048

Unemployment Effective Date

BLOCK PAVER, RAMMER / CURB SETTER (HEAVY &

HIGHWAY)

LABORERS - ZONE 2 (HEAVY & HIGHWAY)

$61.90 12/01/2021 $9.10 $0.00 $36.16 $16.64

For apprentice rates see "Apprentice- LABORER (Heavy and Highway)

BOILER MAKER

BOILERMAKERS LOCAL 29

$71.15 01/01/2020 $7.07 $0.00 $46.10 $17.98

BOILERMAKER - Local 29Apprentice -

01/01/2020

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $29.97 $7.07 $11.69 $0.00 $48.73 65

2 $29.97 $7.07 $11.69 $0.00 $48.73 65

3 $32.27 $7.07 $12.59 $0.00 $51.93 70

4 $34.58 $7.07 $13.49 $0.00 $55.14 75

5 $36.88 $7.07 $14.38 $0.00 $58.33 80

6 $39.19 $7.07 $15.29 $0.00 $61.55 85

7 $41.49 $7.07 $16.18 $0.00 $64.74 90

8 $43.80 $7.07 $17.09 $0.00 $67.96 95

Notes:

Apprentice to Journeyworker Ratio:1:4

BRICK/STONE/ARTIFICIAL MASONRY (INCL. MASONRY

WATERPROOFING)

BRICKLAYERS LOCAL 3 (LYNN)

$90.88 02/01/2022 $11.39 $0.00 $57.15 $22.34

BRICK/PLASTER/CEMENT MASON - Local 3 LynnApprentice -

02/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $28.58 $11.39 $22.34 $0.00 $62.31 50

2 $34.29 $11.39 $22.34 $0.00 $68.02 60

3 $40.01 $11.39 $22.34 $0.00 $73.74 70

4 $45.72 $11.39 $22.34 $0.00 $79.45 80

5 $51.44 $11.39 $22.34 $0.00 $85.17 90

Apprentice to Journeyworker Ratio:1:5

BULLDOZER/GRADER/SCRAPER

OPERATING ENGINEERS LOCAL 4

$80.88 12/01/2021 $14.00 $0.00 $50.83 $16.05

For apprentice rates see "Apprentice- OPERATING ENGINEERS"

CAISSON & UNDERPINNING BOTTOM MAN

LABORERS - FOUNDATION AND MARINE

$69.15 12/01/2021 $9.10 $0.00 $42.33 $17.72

For apprentice rates see "Apprentice- LABORER"

CAISSON & UNDERPINNING LABORER

LABORERS - FOUNDATION AND MARINE

$68.00 12/01/2021 $9.10 $0.00 $41.18 $17.72

Issue Date: Wage Request Number:03/10/2022 Page 3 of 3220220310-048

Unemployment Effective Date

For apprentice rates see "Apprentice- LABORER"

CAISSON & UNDERPINNING TOP MAN

LABORERS - FOUNDATION AND MARINE

$68.00 12/01/2021 $9.10 $0.00 $41.18 $17.72

For apprentice rates see "Apprentice- LABORER"

CARBIDE CORE DRILL OPERATOR

LABORERS - ZONE 2

$61.40 12/01/2021 $9.10 $0.00 $35.66 $16.64

$62.30 06/01/2022 $9.10 $0.00 $36.56 $16.64

$63.15 12/01/2022 $9.10 $0.00 $37.41 $16.64

$64.05 06/01/2023 $9.10 $0.00 $38.31 $16.64

$64.95 12/01/2023 $9.10 $0.00 $39.21 $16.64 For apprentice rates see "Apprentice- LABORER"

CARPENTER

CARPENTERS -ZONE 2 (Eastern Massachusetts)

$73.18 03/01/2022 $8.68 $0.00 $44.53 $19.97

$73.83 09/01/2022 $8.68 $0.00 $45.18 $19.97

$74.43 03/01/2023 $8.68 $0.00 $45.78 $19.97

CARPENTER - Zone 2 Eastern MAApprentice -

03/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $22.27 $8.68 $1.73 $0.00 $32.68 50

2 $26.72 $8.68 $1.73 $0.00 $37.13 60

3 $31.17 $8.68 $14.78 $0.00 $54.63 70

4 $33.40 $8.68 $14.78 $0.00 $56.86 75

5 $35.62 $8.68 $16.51 $0.00 $60.81 80

6 $35.62 $8.68 $16.51 $0.00 $60.81 80

7 $40.08 $8.68 $18.24 $0.00 $67.00 90

8 $40.08 $8.68 $18.24 $0.00 $67.00 90

09/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $22.59 $8.68 $1.73 $0.00 $33.00 50

2 $27.11 $8.68 $1.73 $0.00 $37.52 60

3 $31.63 $8.68 $14.78 $0.00 $55.09 70

4 $33.89 $8.68 $14.78 $0.00 $57.35 75

5 $36.14 $8.68 $16.51 $0.00 $61.33 80

6 $36.14 $8.68 $16.51 $0.00 $61.33 80

7 $40.66 $8.68 $18.24 $0.00 $67.58 90

8 $40.66 $8.68 $18.24 $0.00 $67.58 90

Notes:

% Indentured After 10/1/17; 45/45/55/55/70/70/80/80

Step 1&2 $30.45/ 3&4 $36.57/ 5&6 $56.36/ 7&8 $62.54

Apprentice to Journeyworker Ratio:1:5

CARPENTER WOOD FRAME

CARPENTERS-ZONE 3 (Wood Frame)

$35.17 04/01/2021 $7.21 $0.00 $23.16 $4.80

$35.67 04/01/2022 $7.21 $0.00 $23.66 $4.80

$36.17 04/01/2023 $7.21 $0.00 $24.16 $4.80 All Aspects of New Wood Frame Work

Issue Date: Wage Request Number:03/10/2022 Page 4 of 3220220310-048

Unemployment Effective Date

CARPENTER (Wood Frame) - Zone 3Apprentice -

04/01/2021

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $13.90 $7.21 $0.00 $0.00 $21.11 60

2 $13.90 $7.21 $0.00 $0.00 $21.11 60

3 $15.05 $7.21 $0.00 $0.00 $22.26 65

4 $16.21 $7.21 $0.00 $0.00 $23.42 70

5 $17.37 $7.21 $3.80 $0.00 $28.38 75

6 $18.53 $7.21 $3.80 $0.00 $29.54 80

7 $19.69 $7.21 $3.80 $0.00 $30.70 85

8 $20.84 $7.21 $3.80 $0.00 $31.85 90

04/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $14.20 $7.21 $0.00 $0.00 $21.41 60

2 $14.20 $7.21 $0.00 $0.00 $21.41 60

3 $15.38 $7.21 $0.00 $0.00 $22.59 65

4 $16.56 $7.21 $0.00 $0.00 $23.77 70

5 $17.75 $7.21 $3.80 $0.00 $28.76 75

6 $18.93 $7.21 $3.80 $0.00 $29.94 80

7 $20.11 $7.21 $3.80 $0.00 $31.12 85

8 $21.29 $7.21 $3.80 $0.00 $32.30 90

Notes:

% Indentured After 10/1/17; 45/45/55/55/70/70/80/80

Step 1&2 $17.63/ 3&4 $19.95/ 5&6 $27.22/ 7&8 $29.54

Apprentice to Journeyworker Ratio:1:5

CEMENT MASONRY/PLASTERING

BRICKLAYERS LOCAL 3 (LYNN)

$84.85 01/01/2020 $12.75 $0.62 $49.07 $22.41

CEMENT MASONRY/PLASTERING - Eastern Mass (Lynn)Apprentice -

01/01/2020

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $24.54 $12.75 $15.41 $0.00 $52.70 50

2 $29.44 $12.75 $17.41 $0.62 $60.22 60

3 $31.90 $12.75 $18.41 $0.62 $63.68 65

4 $34.35 $12.75 $19.41 $0.62 $67.13 70

5 $36.80 $12.75 $20.41 $0.62 $70.58 75

6 $39.26 $12.75 $21.41 $0.62 $74.04 80

7 $44.16 $12.75 $22.41 $0.62 $79.94 90

Steps 3,4 are 500 hrs. All other steps are 1,000 hrs.

Apprentice to Journeyworker Ratio:1:3

Issue Date: Wage Request Number:03/10/2022 Page 5 of 3220220310-048

Unemployment Effective Date

CHAIN SAW OPERATOR

LABORERS - ZONE 2

$61.40 12/01/2021 $9.10 $0.00 $35.66 $16.64

$62.30 06/01/2022 $9.10 $0.00 $36.56 $16.64

$63.15 12/01/2022 $9.10 $0.00 $37.41 $16.64

$64.05 06/01/2023 $9.10 $0.00 $38.31 $16.64

$64.95 12/01/2023 $9.10 $0.00 $39.21 $16.64 For apprentice rates see "Apprentice- LABORER"

CLAM SHELLS/SLURRY BUCKETS/HEADING MACHINES

OPERATING ENGINEERS LOCAL 4

$82.43 12/01/2021 $14.00 $0.00 $52.38 $16.05

For apprentice rates see "Apprentice- OPERATING ENGINEERS"

COMPRESSOR OPERATOR

OPERATING ENGINEERS LOCAL 4

$63.74 12/01/2021 $14.00 $0.00 $33.69 $16.05

For apprentice rates see "Apprentice- OPERATING ENGINEERS"

DELEADER (BRIDGE)

PAINTERS LOCAL 35 - ZONE 2

$85.36 01/01/2022 $8.65 $0.00 $53.66 $23.05

$86.56 07/01/2022 $8.65 $0.00 $54.86 $23.05

$87.76 01/01/2023 $8.65 $0.00 $56.06 $23.05

$88.96 07/01/2023 $8.65 $0.00 $57.26 $23.05

$90.16 01/01/2024 $8.65 $0.00 $58.46 $23.05

$91.36 07/01/2024 $8.65 $0.00 $59.66 $23.05

$92.56 01/01/2025 $8.65 $0.00 $60.86 $23.05

Issue Date: Wage Request Number:03/10/2022 Page 6 of 3220220310-048

Unemployment Effective Date

PAINTER Local 35 - BRIDGES/TANKSApprentice -

01/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $26.83 $8.65 $0.00 $0.00 $35.48 50

2 $29.51 $8.65 $6.27 $0.00 $44.43 55

3 $32.20 $8.65 $6.84 $0.00 $47.69 60

4 $34.88 $8.65 $7.41 $0.00 $50.94 65

5 $37.56 $8.65 $19.63 $0.00 $65.84 70

6 $40.25 $8.65 $20.20 $0.00 $69.10 75

7 $42.93 $8.65 $20.77 $0.00 $72.35 80

8 $48.29 $8.65 $21.91 $0.00 $78.85 90

07/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $27.43 $8.65 $0.00 $0.00 $36.08 50

2 $30.17 $8.65 $6.27 $0.00 $45.09 55

3 $32.92 $8.65 $6.84 $0.00 $48.41 60

4 $35.66 $8.65 $7.41 $0.00 $51.72 65

5 $38.40 $8.65 $19.63 $0.00 $66.68 70

6 $41.15 $8.65 $20.20 $0.00 $70.00 75

7 $43.89 $8.65 $20.77 $0.00 $73.31 80

8 $49.37 $8.65 $21.91 $0.00 $79.93 90

Steps are 750 hrs.

Apprentice to Journeyworker Ratio:1:1

DEMO: ADZEMAN

LABORERS - ZONE 2

$68.00 12/01/2021 $9.10 $0.00 $41.33 $17.57

$69.00 06/01/2022 $9.10 $0.00 $42.33 $17.57

$70.00 12/01/2022 $9.10 $0.00 $43.33 $17.57

$71.00 06/01/2023 $9.10 $0.00 $44.33 $17.57

$72.25 12/01/2023 $9.10 $0.00 $45.58 $17.57 For apprentice rates see "Apprentice- LABORER"

DEMO: BACKHOE/LOADER/HAMMER OPERATOR

LABORERS - ZONE 2

$69.00 12/01/2021 $9.10 $0.00 $42.33 $17.57

$70.00 06/01/2022 $9.10 $0.00 $43.33 $17.57

$71.00 12/01/2022 $9.10 $0.00 $44.33 $17.57

$72.00 06/01/2023 $9.10 $0.00 $45.33 $17.57

$73.25 12/01/2023 $9.10 $0.00 $46.58 $17.57 For apprentice rates see "Apprentice- LABORER"

DEMO: BURNERS

LABORERS - ZONE 2

$68.75 12/01/2021 $9.10 $0.00 $42.08 $17.57

$69.75 06/01/2022 $9.10 $0.00 $43.08 $17.57

$70.75 12/01/2022 $9.10 $0.00 $44.08 $17.57

$71.75 06/01/2023 $9.10 $0.00 $45.08 $17.57

$73.00 12/01/2023 $9.10 $0.00 $46.33 $17.57

Issue Date: Wage Request Number:03/10/2022 Page 7 of 3220220310-048

Unemployment Effective Date

DEMO: CONCRETE CUTTER/SAWYER

LABORERS - ZONE 2

$69.00 12/01/2021 $9.10 $0.00 $42.33 $17.57

$70.00 06/01/2022 $9.10 $0.00 $43.33 $17.57

$71.00 12/01/2022 $9.10 $0.00 $44.33 $17.57

$72.00 06/01/2023 $9.10 $0.00 $45.33 $17.57

$73.25 12/01/2023 $9.10 $0.00 $46.58 $17.57 For apprentice rates see "Apprentice- LABORER"

DEMO: JACKHAMMER OPERATOR

LABORERS - ZONE 2

$68.75 12/01/2021 $9.10 $0.00 $42.08 $17.57

$69.75 06/01/2022 $9.10 $0.00 $43.08 $17.57

$70.75 12/01/2022 $9.10 $0.00 $44.08 $17.57

$71.75 06/01/2023 $9.10 $0.00 $45.08 $17.57

$73.00 12/01/2023 $9.10 $0.00 $46.33 $17.57 For apprentice rates see "Apprentice- LABORER"

DEMO: WRECKING LABORER

LABORERS - ZONE 2

$68.00 12/01/2021 $9.10 $0.00 $41.33 $17.57

$69.00 06/01/2022 $9.10 $0.00 $42.33 $17.57

$70.00 12/01/2022 $9.10 $0.00 $43.33 $17.57

$71.00 06/01/2023 $9.10 $0.00 $44.33 $17.57

$72.25 12/01/2023 $9.10 $0.00 $45.58 $17.57 For apprentice rates see "Apprentice- LABORER"

DIRECTIONAL DRILL MACHINE OPERATOR

OPERATING ENGINEERS LOCAL 4

$80.88 12/01/2021 $14.00 $0.00 $50.83 $16.05

For apprentice rates see "Apprentice- OPERATING ENGINEERS"

DIVER

PILE DRIVER LOCAL 56 (ZONE 1)

$101.22 08/01/2020 $9.40 $0.00 $68.70 $23.12

For apprentice rates see "Apprentice- PILE DRIVER"

DIVER TENDER

PILE DRIVER LOCAL 56 (ZONE 1)

$81.59 08/01/2020 $9.40 $0.00 $49.07 $23.12

For apprentice rates see "Apprentice- PILE DRIVER"

DIVER TENDER (EFFLUENT)

PILE DRIVER LOCAL 56 (ZONE 1)

$106.12 08/01/2020 $9.40 $0.00 $73.60 $23.12

For apprentice rates see "Apprentice- PILE DRIVER"

DIVER/SLURRY (EFFLUENT)

PILE DRIVER LOCAL 56 (ZONE 1)

$135.57 08/01/2020 $9.40 $0.00 $103.05 $23.12

For apprentice rates see "Apprentice- PILE DRIVER"

DRAWBRIDGE OPERATOR (Construction)

DRAWBRIDGE - SEIU LOCAL 888

$37.53 07/01/2020 $6.67 $0.16 $26.77 $3.93

ELECTRICIAN

ELECTRICIANS LOCAL 103

$91.14 03/01/2022 $13.00 $0.00 $57.32 $20.82

$92.62 09/01/2022 $13.00 $0.00 $58.76 $20.86

$94.34 03/01/2023 $13.00 $0.00 $60.43 $20.91

Issue Date: Wage Request Number:03/10/2022 Page 8 of 3220220310-048

Unemployment Effective Date

ELECTRICIAN - Local 103Apprentice -

03/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $22.93 $13.00 $0.69 $0.00 $36.62 40

2 $22.93 $13.00 $0.69 $0.00 $36.62 40

3 $25.79 $13.00 $15.62 $0.00 $54.41 45

4 $25.79 $13.00 $15.62 $0.00 $54.41 45

5 $28.66 $13.00 $16.10 $0.00 $57.76 50

6 $31.53 $13.00 $16.58 $0.00 $61.11 55

7 $34.39 $13.00 $17.04 $0.00 $64.43 60

8 $37.26 $13.00 $17.52 $0.00 $67.78 65

9 $40.12 $13.00 $17.98 $0.00 $71.10 70

10 $42.99 $13.00 $18.46 $0.00 $74.45 75

09/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $23.50 $13.00 $0.71 $0.00 $37.21 40

2 $23.50 $13.00 $0.71 $0.00 $37.21 40

3 $26.44 $13.00 $15.64 $0.00 $55.08 45

4 $26.44 $13.00 $15.64 $0.00 $55.08 45

5 $29.38 $13.00 $16.12 $0.00 $58.50 50

6 $32.32 $13.00 $16.60 $0.00 $61.92 55

7 $35.26 $13.00 $17.07 $0.00 $65.33 60

8 $38.19 $13.00 $17.55 $0.00 $68.74 65

9 $41.13 $13.00 $18.01 $0.00 $72.14 70

10 $44.07 $13.00 $18.49 $0.00 $75.56 75

Notes: :

App Prior 1/1/03; 30/35/40/45/50/55/65/70/75/80

Apprentice to Journeyworker Ratio:2:3***

ELEVATOR CONSTRUCTOR

ELEVATOR CONSTRUCTORS LOCAL 4

$101.86 01/01/2022 $16.03 $0.00 $65.62 $20.21

Issue Date: Wage Request Number:03/10/2022 Page 9 of 3220220310-048

Unemployment Effective Date

ELEVATOR CONSTRUCTOR - Local 4Apprentice -

01/01/2022

Health Pension Supplemental

UnemploymentStep Apprentice Base Wage Total Ratepercent

Effective Date -

1 $32.81 $16.03 $0.00 $0.00 $48.84 50

2 $36.09 $16.03 $20.21 $0.00 $72.33 55

3 $42.65 $16.03 $20.21 $0.00 $78.89 65

4 $45.93 $16.03 $20.21 $0.00 $82.17 70

5 $52.50 $16.03 $20.21 $0.00 $88.74 80

Steps 1-2 are 6 mos.; Steps 3-5 are 1 year

ELEVATOR CONSTRUCTOR HELPER

ELEVATOR CONSTRUCTORS LOCAL 4

$82.17 01/01/2022 $16.03 $0.00 $45.93 $20.21

For apprentice rates see "Apprentice - ELEVATOR CONSTRUCTOR"

FENCE & GUARD RAIL ERECTOR (HEAVY & HIGHWAY)

LABORERS - ZONE 2 (HEAVY & HIGHWAY)

$61.40 12/01/2021 $9.10 $0.00 $35.66 $16.64

For apprentice rates see "Apprentice- LABORER (Heavy and Highway)

FIELD ENG.INST.PERSON-BLDG,SITE,HVY/HWY

OPERATING ENGINEERS LOCAL 4

$76.08 11/01/2021 $13.75 $0.00 $46.53 $15.80

$77.41 05/01/2022 $13.75 $0.00 $47.86 $15.80 For apprentice rates see "Apprentice- OPERATING ENGINEERS"

FIELD ENG.PARTY CHIEF-BLDG,SITE,HVY/HWY

OPERATING ENGINEERS LOCAL 4

$77.61 11/01/2021 $13.75 $0.00 $48.06 $15.80

$78.77 05/01/2022 $13.75 $0.00 $49.22 $15.80 For apprentice rates see "Apprentice- OPERATING ENGINEERS"

FIELD ENG.ROD PERSON-BLDG,SITE,HVY/HWY

OPERATING ENGINEERS LOCAL 4

$52.71 11/01/2021 $13.75 $0.00…