2021.12.16 (ISSUE FOR BID - UPDATED PER ICRA).pdf

NOT TO SCALE

SITE MAP1

G-001

BLDG. 3

32 11

4 13

55.2

55.1

FIRE ZO

N

E

FIRE ZO

N E

N

S

W

E

G

G

GS

AREA OF WORK

PARKING AREA

G-001 COVER SHEET

A-506

SP-001

FA-101

FA-301

AUDIOLOGY BOOTH - EXAM ROOM VIEWS A-D (FOR REFERENCE ONLY)

SPRINKLER SPECIFICATIONS

FIRE ALARM DEMOLITION & CONSTRUCTION PLANS

FIRE ALARM DETAILS I

A-001 ARCHITECTURAL NOTES AND LEGENDS

A-505 AUDIOLOGY BOOTH - EXTERIOR ELEVATION (FOR REFERENCE ONLY)

SP-101 SPRINKLER DEMOLITION & CONSTRUCTION PLANS

AD-100 ARCHITECTURAL DEMOLITION PLANS

GI-101 LIFE SAFETY CODE NOTES AND PLANS

A-504 AUDIOLOGY BOOTH - ROOF LAYOUTS (FOR REFERENCE ONLY)

GI-100 GENERAL REQUIREMENTS NOTES

A-507 AUDIOLOGY BOOTH - CONTROL ROOM VIEWS A-D (FOR REFERENCE ONLY)

FA-001 FIRE ALARM SPECIFICATIONS

AS-101 FACILITY TRUCK ROUTE

AS-102 ARCHITECTURAL SITE PLAN

AC-100 ARCHITECTURAL FLOOR PLAN AND REFLECTED CEILING PLAN

A-301 ARCHITECTURAL DETAILS I

AC-101 ARCHITECTURAL CONSTRUCTION PLANS

AC-200 NEW INTERIOR CASEWORK ELEVATIONS AND INTERIOR ELEVATIONS

A-302 ARCHITECTURAL DETAILS II

A-401 ARCHITECTURAL DOOR SCHEDULE, HARDWARE & DETAILS

A-503 AUDIOLOGY BOOTH - ROOM LAYOUTS (FOR REFERENCE ONLY)

A-502 AUDIOLOGY BOOTH - WALL LAYOUT (FOR REFERENCE ONLY)

A-501 AUDIOLOGY BOOTH -GENERAL NOTES AND SCOPE (FOR REFERENCE ONLY)18

SP-301 SPRINKLER DETAILS I

SP-302 SPRINKLER DETAILS II

GI-201 INFECTION CONTROL PLAN - GROUND FLOOR

SHUTTLE ROUTE TO/FROM PARKING AREA TO CONSTRUCTION SITE

32 P-001 PLUMBING NOTES, SYMBOLS & LEGEND

M-001

P-301

P-302

MECHANICAL NOTES, SYMBOLS & LEGEND

PLUMBING DETAILS I & SCHEDULE

PLUMBING DETAILS II

P-303 ANTISCALD VALVE DETAILS

MD-101 MECHANICAL STEAM DISTRIBUTION - OVERALL

42 MC-101 MECHANICAL STEAM DEMOLITION AND CONSTRUCTION DRAWINGS

MC-102 MECHANICAL HVAC DEMOLITION AND CONSTRUCTION DRAWINGS

M-301 MECHANICAL DETAILS I

M-302 MECHANICAL DETAILS II

PD-101 PLUMBING SANITARY, VENT, HOT WATER & COLD WATER DEMOLITION PLANS

M-401 MECHANICAL SCHEDULES

E-001 ELECTRICAL NOTES AND ABBREVIATIONS

E-100 ELECTRICAL SYSTEMS OVERVIEW

49 ED-101 ELECTRICAL POWER AND LIGHTING DEMOLITION PLANS

EC-101 ELECTRICAL POWER AND LIGHTING CONSTRUCTION PLANS

EY-101 ELECTRICAL SPECIAL SYSTEMS PLANS

E-301 ELECTRICAL DETAILS I

E-302 ELECTRICAL DETAILS II

PC-101 PLUMBING AIR, GAS & VACUUM DEMOLITION & CONSTRUCTION PLANS

PC-102 PLUMBING SANITARY, VENT, HOT WATER & COLD WATER CONSTRUCTION PLANS

P-401 PLUMBING DEMOLITION & CONSTRUCTION RISER DIAGRAMS (ALL TRADES)

E-401 ELECTRICAL SYMBOLS AND SCHEDULES

SI-100 EXISTING STRUCTURAL PLAN (FOR REFERENCE ONLY)

SI-600 EXISTING STRUCTURAL BEAM, FOOTING, COLUMN & SLAB SCHEDULES

AC-102 INTERIOR DESIGN PLAN, SCHEDULES, LOCATIONS & SIGN DETAILS

A-303 ARCHITECTURAL DETAILS III - WALL PARTITIONS

HC-101 ASBESTOS AND LEAD PLANS

ENTRY TO MONTROSE VAMC FROM ALBANY POST ROAD

321 4 5 6 7

Office of Construction and Facilities Management

U.S. Department of Veterans Affairs of

LocationPhase

Project Number

Building Number

Drawing Number

Project Title

STAMPARCHITECT/ENGINEER OF RECORD

Date:Revisions:

Issue Date

Approved By: Approved By:

Approved By:Approved By:

Approved By:

Approved By: Approved By:

Approved By:

Drawing Title

Checked Drawn

CONSULTANT

620-20-205620-20-205 Renovate Building 3 Audiology

FDR VA HOSPITAL MONTROSE, NY

2021.11.18 N/A MA&MM

BID DOCUMENTSRevisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyyAPPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

Rev.

COVER SHEET

SCALE: NOT TO SCALE1

G-001 1 0

FD

R

-0

COVER SHEET

AutoCAD SHX Text F

AutoCAD SHX Text A

AutoCAD SHX Text D

AutoCAD SHX Text I

AutoCAD SHX Text E

AutoCAD SHX Text T

AutoCAD SHX Text D

AutoCAD SHX Text S

AutoCAD SHX Text T

AutoCAD SHX Text N

AutoCAD SHX Text U

AutoCAD SHX Text E

AutoCAD SHX Text T

AutoCAD SHX Text M

AutoCAD SHX Text A

AutoCAD SHX Text P

AutoCAD SHX Text R

AutoCAD SHX Text E

AutoCAD SHX Text N

AutoCAD SHX Text T

AutoCAD SHX Text O

AutoCAD SHX Text S

AutoCAD SHX Text A

AutoCAD SHX Text T

AutoCAD SHX Text S

AutoCAD SHX Text E

AutoCAD SHX Text F

AutoCAD SHX Text O

AutoCAD SHX Text R

AutoCAD SHX Text E

AutoCAD SHX Text M

AutoCAD SHX Text A

AutoCAD SHX Text C

AutoCAD SHX Text I

AutoCAD SHX Text N

AutoCAD SHX Text V

AutoCAD SHX Text E

AutoCAD SHX Text R

AutoCAD SHX Text A

AutoCAD SHX Text T

AutoCAD SHX Text E

AutoCAD SHX Text A

AutoCAD SHX Text F

AutoCAD SHX Text A

AutoCAD SHX Text I

AutoCAD SHX Text R

AutoCAD SHX Text F

AutoCAD SHX Text S

AutoCAD SHX Text

AutoCAD SHX Text

NO PARKING

AutoCAD SHX Text

NO PARKING

AutoCAD SHX Text

NO PARKING

AutoCAD SHX Text

POND

AutoCAD SHX Text

POND

AutoCAD SHX Text

FUEL TANK

AutoCAD SHX Text

VA HUDSON VALLEY HEALTH CARE SYSTEM

AutoCAD SHX Text

RENOVATE BUILDING 3 AUDIOLOGY

AutoCAD SHX Text

2094 ALBANY POST ROAD, MONTROSE, NEW YORK 10548

AutoCAD SHX Text

NOVEMBER 18, 2021

AutoCAD SHX Text

AT

AutoCAD SHX Text

FRANKLIN DELANO ROOSEVELT HOSPITAL

AutoCAD SHX Text

PROJECT 620-20-205

AutoCAD SHX Text

%%UDRAWING LIST:

AutoCAD SHX Text

%%UDRAWING LIST:

GENERAL REQUIREMENTS:

1. ALL WORK SHALL CONFORM TO FEDERAL, STATE LOCAL RULES, LAWS, REGULATIONS,

VETERANS AFFAIRS (VA) SPECIFICATION. ALL PLUMBING WORK SHALL CONFORM TO

NATIONAL PLUMBING CODE, ALL ELECTRICAL WORK SHALL CONFORM TO NATIONAL

ELECTRICAL CODE, AND ALL HEATING AND VENTILATING WORK SHALL COMPLY WITH

AMERICAN SOCIETY OF HEATING, REFRIGERATING AND AIR-CONDITIONING ENGINEERS

(ASHRAE) STANDARDS.

2. BEFORE BEGINNING ANY CUTTING OR DEMOLITION WORK, THE CONTRACTOR SHALL

CAREFULLY SURVEY THE EXISTING CONDITIONS AND DETERMINE THE EXTENT OF THE

WORK TO BE DONE. THE CONTRACTOR SHALL ENSURE THAT STRUCTURAL ITEMS ARE

NOT WEAKENED AND SHALL BE RESPONSIBLE FOR INCREASING OR ADDING

STRUCTURAL SUPPORTS AS MAY BE REQUIRED AS A RESULT OF ANY CUTTING,

REMOVAL OR DEMOLITION WORK.

3. CONTRACTOR SHALL TERMINATE AND REMOVE COMPLETELY BACK TO THE SOURCE, ALL

MECHANICAL, ELECTRICAL OR PLUMBING ITEMS AND ASSOCIATED WIRING, DUCT WORK,

AND PIPING THAT MAY NOT BE FULLY INDICATED OR NECESSARY FOR THE

FUNCTIONALITY OF THE NEW DESIGN.

4. CONTRACTOR SHALL PROVIDE AND COORDINATE THE LOCATION OF ALL NEW OPENINGS

IN ANY EXISTING WALLS OR FLOORS AS INDICATED ON THESE DRAWINGS OR AS

NECESSARY FOR THE COMPLETION OF NEW WORK SHOWN OR IMPLIED.

5. FOR SHUT-DOWN AND TIE-INS, CONTRACTOR SHALL AT MINIMUM, SUBMITA 72 HOUR

NOTICE TO THE CONTRACTING OFFICER IN WRITING FOR ALL SHUT-DOWNS OR TIE-INS

AND SHALL BE DONE AT SUCH TIMES AND HOURS AS NOTED AND SHALL NOT INTERFERE

WITH THE VETERANS AFFAIRS OPERATION. ALL OVERTIME EXPENSES REQUIRED FOR

SHUT-DOWNS AND TIE-INS SHALL BE BORNE BY THE CONTRACTOR.

6. ALL QUANTITIES SHOWN ON THE DRAWING ARE ESTIMATED QUANTITIES ONLY. IT SHALL

BE THE RESPONSIBILITY OF THE CONTRACTOR TO FIELD VERIFY AND ASCERTAIN ALL

EXISTING CONDITIONS, DIMENSIONS AND QUANTITIES THAT MAY NOT BE SHOWN. ANY

AND ALL DISCREPANCIES BETWEEN ACTUAL CONDITIONS AND DRAWINGS AND

SPECIFICATIONS SHALL BE REPORTED TO THE CONTRACTING OFFICER OR

CONSTRUCTION OFFICER REPRESENTATIVE IN WRITING FOR CLARIFICATION. WORK

SHALL NOT PROCEED UNTIL SUCH CLARIFICATION HAS BEEN RECEIVED.

7. SHOULD UNFORESEEN CONDITIONS OR OTHER CAUSES NECESSITATE CONSTRUCTION

DETAILS NOT IN ACCORDANCE WITH THESE PLANS, THE CONTRACTOR SHALL NOTIFY

THE CONTRACTING OFFICER AND SUBMIT THEIR DETAILS SHOWING THE PROPOSED

METHODS TO ACCOMPLISH THE REQUIRED RESULTS.

6. REMOVALS SHALL BE PERFORMED WITHOUT DAMAGE TO ADJACENT RETAINED WORK,

HOWEVER WHERE SUCH WORK IS DAMAGED, THE CONTRACTOR SHALL PATCH, REPAIR

OR OTHERWISE RESTORE DAMAGED ITEMS TO THE SATISFACTION OF THE

CONTRACTING OFFICER. THE CONTRACTOR SHALL BE RESPONSIBLE FOR ALL

PATCHING, REPAIRING AND FINISHING OF ALL DISTURBED AREAS. PATCHING OF

SURROUNDING AREAS SHALL BE WITH MATERIALS TO MATCH EXISTING.

7. THE CONTRACTOR SHALL BE RESPONSIBLE FOR ADEQUATELY BRACING AND

PROTECTING ALL WORK DURING CONSTRUCTION AGAINST STRUCTURAL DAMAGE,

BREAKAGE, COLLAPSE, DISTORTIONS AND MISALIGNMENT ACCORDING TO APPLICABLE

CODES, STANDARDS AND PRACTICE.

8. THE CONTRACTOR SHALL CARRY NEW WALL FINISHING WORK (PAINTING, ETC.) TO AN

APPROPRIATE STOPPING POINT (CHANGE IN WALL DIRECTION).

9. PROTECTION OF PERSONNEL: WHERE THE SAFETY OF PEDESTRIANS AND DRIVERS ARE

ENDANGERED IN THE AREA OF REMOVAL WORK, BARRICADES FOR TRAFFIC SHALL BE

USED AND ADVANCE NOTICE SHALL BE GIVEN TO THE CONTRACTING OFFICER PRIOR TO

BEGINNING ANY SUCH WORK.

10. THE CONTRACTOR SHALL MAINTAIN ACCESS TO EXISTING EXITS OR CREATE NEW EXITS

AS REQUIRED BY THE CONTRACTING OFFICER FOR THE SAFETY OF BUILDING

OCCUPANTS.

11. CONTRACTOR RESTRICTIONS: THE CONTRACTOR SHALL CHECK WITH AND RECEIVE

APPROVAL FROM THE CONTRACTING OFFICER FOR ROUTES OF ACCESS AND SUPPLY

STORAGE AREAS REGARDING THE GENERAL WORK AREA WITHIN THIS CONTRACT. V.A.

DOES NOT PROVIDE STORAGE AREAS FOR CONTRACTORS TO STORE MATERIAL ON SITE.

12. SUBSTITUTION OF MATERIALS: WHERE EXISTING MATERIALS OF ANY KIND MUST BE

REPLACED FOR ANY REASON AS A RESULT OF THE WORK HERE UNDER AND EXACT

DUPLICATES ARE NOT AVAILABLE, THEIR FUNCTIONAL EQUIVALENTS MAY BE

SUBSTITUTED UPON RECEIPT OF PRIOR WRITTEN APPROVAL FROM THE CONTRACTING

OFFICER.

13. ALL BIDDERS ARE HIGHLY RECOMMENDED TO VISIT THE SITE BEFORE SUBMITTING BIDS,

TO INSPECT THE PREMISES AND VIEW THE EXISTING CONDITIONS TO VERIFY ALL

CONDITIONS, SIZES AND QUANTITIES. PLANS ARE FURNISHED TO INDICATE THE SCOPE

OF THE INTENDED CONTRACT WORK. EXISTING CONDITIONS WHICH MIGHT PRECLUDE

OR INTERFERE WITH THE PROPOSED WORK AS DRAWN OR SPECIFIED SHALL BE

BROUGHT TO THE ATTENTION OF THE CONTRACTING OFFICER FOR RESOLVING.

RELOCATIONS MUST BE CHECKED TO VERIFY THEIR FEASIBILITY IN ACCORDANCE WITH

THE NEW REQUIREMENTS.

14. ALL NEW PENETRATIONS THRU EXISTING CONSTRUCTION SHALL BE SEALED AND/OR

FILLED WITH APPROVED FIRESTOPPING MATERIALS.

15. THE ARCHITECTURAL DRAWINGS SHOW PRINCIPAL AREAS WHERE WORK MUST BE

ACCOMPLISHED UNDER THIS CONTRACT. INCIDENTAL WORK MAY ALSO BE NECESSARY

IN AREAS NOT SHOWN ON THE ARCHITECTURAL DRAWINGS DUE TO CHANGES

AFFECTING EXISTING MECHANICAL, ELECTRICAL, PLUMBING, OR OTHER SYSTEMS. SUCH

INCIDENTAL WORK IS ALSO A PART OF THIS CONTRACT. INSPECT THOSE AREAS, AND

ASCERTAIN WORK NEEDED, AND DO THAT WORK IN ACCORDANCE WITH THE CONTRACT

REQUIREMENTS, AT NO ADDITIONAL COST.

16. TRADE, PRODUCT, OR MANUFACTURER'S NAMES OR CATALOG NUMBERS SHOWN ON THE

DRAWINGS FOR NEW PRODUCTS ARE TO ESTABLISH QUALITY REQUIRED. IN EACH CASE

ADD, BY INFERENCE, AFTER TRADE, PRODUCT, OR MANUFACTURER'S NAME, THE

PHRASE "OR APPROVED EQUAL".

17. EXCEPT IN SPACES WHERE NO WORK UNDER THIS CONTRACT IS REQUIRED, ENCLOSE

EXISTING AND NEW CONDUITS, DUCTS, PIPES, AND SIMILAR ITEMS IN FURRING WHERE

SUCH ITEMS PASS THROUGH FINISHED SPACES WHETHER OR NOT FURRING IS

INDICATED.

18. WHERE CONDUITS, DUCTS, PIPES AND SIMILAR ITEMS ARE SHOWN TO BE INSTALLED IN

EXISTING WALLS OR PARTITIONS, NEATLY CHASE THE WALLS OR PARTITIONS, INSTALL

THE ITEMS, AND PATCH THE WALLS OR PARTITIONS TO MAKE THE INSTALLATION NOT

DISCERNIBLE IN THE FINISHED WORK.

19. SEAL TIGHT AND PROTECT WITH FIRE SHAFTS EXISTING AND NEW SLEEVES AND

OPENINGS THROUGH FLOORS. FIRE SHAFTS SHALL BE A MINIMUM 2 HOUR RATED FOR

ALL APPLICATIONS AND LOCATIONS.

20. WHERE A NEW CEILING IS NOT SCHEDULED, INSTALL NEW CONDUITS AND PIPES IN NEW

CHASE, AND NEW DUCTS WHERE POSSIBLE, ABOVE THE EXISTING CEILING. REMOVE

EXISTING CEILING AS NECESSARY. AFTER INSTALLATION OF CONCEALED WORK,

REINSTALL REMOVED CEILING AND PATCH AND REFINISH TO MATCH ADJACENT

UNREMOVED CEILINGS.

21. FUR TO CONCEAL HORIZONTAL DUCTS PASSING THROUGH EXISTING OR NEW SPACES

WHERE IT IS NOT POSSIBLE TO INSTALL THE DUCTS ABOVE THE CEILING. USE GYPSUM

BOARD FOR SUCH FURRING.

22. WHERE PERMANENT REMOVAL OF EXISTING MILLWORK, CASEWORK,CABINETWORK,

ACCESSORIES, EQUIPMENT OR FURNISHINGS IS REQUIRED, AND PREVIOUSLY

CONCEALED SURFACES ARE TO REMAIN EXPOSED, PATCH PREVIOUSLY CONCEALED

SURFACES TO MATCH ADJACENT EXPOSED SURFACES. WHERE SUCH SURFACES ARE

SCHEDULED TO RECEIVE NEW FINISHES, PREPARE THE SURFACES TO RECEIVE THE NEW

FINISHES.

23. WHERE CUTTING OF EXISTING SURFACES OR REMOVAL OF EXISTING FINISHES IS

REQUIRED TO PERFORM THE WORK UNDER THIS CONTRACT, AND A NEW FINISH IS NOT

INDICATED, FILL RESULTING OPENINGS AND PATCH THE SURFACE AFTER DOING THE

WORK, AND FINISH TO MATCH ADJACENT EXISTING SURFACES.

24. ALL WORK SHALL BE PERFORMED, MONDAY THRU FRIDAY, DURING NORMAL BUSINESS

HOURS OF 8:00AM - 4:30PM. SATURDAY, SUNDAY AND HOLIDAYS, ARE TO BE REQUESTED

TO AND APPROVED BY THE CONTRACTING OFFICER. SEE SPECIFICATIONS FOR W.H.E.N.

REQUESTS. THE CONTRACTOR SHALL BE REQUIRED TO WORK PRIME TIME AND

OVERTIME TO COMPLETE OR CONSTRUCT PORTIONS OF THIS WORK OUTSIDE NORMAL

BULSINESS HOURS. THIS SHALL BE AS DIRECTED BY THE CONTRACTING OFFICER AT NO

ADDITIONAL COST TO THE GOVERNMENT.

25. CONTRACTOR SHALL ABIDE AT THEIR OWN EXPENSE TO THE LATEST EDITIONS OF ALL

OSHA REGULATIONS AND REQUIREMENTS.

26. CONTRACTOR SHALL BE RESPONSIBLE TO VERIFY AND ASCERTAIN IN THE FIELD, ALL

EXISTING UTILITIES, EXISTING CONDITIONS, FIELD MEASUREMENTS, DIMENSIONS,

QUANTITIES, RELATED TO THE PROJECT.

27. CONTRACTOR SHALL SUBMIT FOR APPROVAL ALL MATERIALS USED FOR CONSTRUCTION

AND ALL EQUIPMENT INTENDED FOR INSTALLATION IN THIS PROJECT.

28. THE CONTRACTOR SHALL BE RESPONSIBLE TO VERIFY AND ASCERTAIN THE LOCATION,

DIRECTION, SIZE, OF ANY AND ALL UTILITIES EXISTING IN THE GENERAL VICINITY OF THE

WORK AREA.

29. IT SHALL BE THE CONTRACTOR'S RESPONSIBILITY TO REPAIR ANY UTILITY DISRUPTED,

BROKEN, OR OTHERWISE RENDERED NON-FUNCTIONABLE DUE TO THE WORK

PERFORMED AT NO ADDITIONAL COST TO THE GOVERNMENT DURING THIS COURSE OF

WORK.

30. THE CONTRACTOR SHALL IDENTIFY ANY NON-FUNCTIONING UTILITY/SYSTEM, PRIOR TO

THE START OF WORK TO THE CONTRACTING OFFICER. IDENTIFICATION OF SUCH AFTER

THE START OF WORK SHALL BE DEEMED AS DISTURBED/DAMAGED BY THE CONTRACTOR

AND SHALL BE REPAIRED AT THE EXPENSE OF THE CONTRACTOR.

31. IT SHALL BE THE CONTRACTOR'S RESPONSIBILITY TO PROPERLY SUPPORT ANY UTILITY

ENCOUNTERED IN THE COURSE OF THIS WORK.

32. THE CONTRACTOR SHALL LEAVE THE WORK SITE CLEAN AND SECURED AT THE END OF

EACH WORKING DAY. THE WORK SITE SHALL NOT BE LEFT UNATTENDED AT ANY TIME BY

THE CONTRACTOR, UNLESS THE WORK AREA IS PROPERLY SECURED BY THE

CONTRACTOR.

33. THE CONTRACTOR IS ADVISED THAT THEY ARE SOLELY RESPONSIBLE FOR THE SAFETY

OF THE WORK SITE AND TAKE ALL ACTIONS TO ELIMINATE ANY SAFETY HAZARDS THAT

SHALL EXIST AND POSE A THREAT OF HARM TO PATIENTS, EMPLOYEES OF THE

GOVERNMENT, EMPLOYEES OF THE CONTRACTOR OR OTHER(S). IT SHALL BE THE SOLE

RESPONSIBILITY OF THE CONTRACTOR TO TAKE IMMEDIATE ACTION TO ALLEVIATE ANY

SAFETY HAZARD THAT MAY EXIST WITHOUT DIRECTION FROM THE CONTRACTING

OFFICER OR HIS DESIGNEE. THE CONTRACTOR SHALL TAKE IMMEDIATE CORRECTIVE

ACTION TO ALLEVIATE ANY SAFETY HAZARD, CONDITION, ETC., AS INDICATED BY THE

CONTRACTING OFFICER.

34. THERE SHALL BE NO CLAIMS AGAINST THE DEPARTMENT OF VETERANS AFFAIRS FOR

WORK STOPPAGES DUE TO ACTS OF GOD, WEATHER CONDITIONS, STOP WORK ORDERS

(VERBAL AND/OR WRITTEN), UNDERESTIMATION OF WORK, ESTIMATED QUANTITIES,

MATERIALS, SUPPLIES, TOOLS, CORRECTION OF SAFETY PROBLEMS, OR ANY OTHER

REASON.

35. AT THE COMPLETION OF THE PROJECT, THE CONTRACTOR SHALL PROVIDE TO THE

VETERANS AFFAIRS A "AS BUILT" FOR THE WORK. THIS DRAWING SHALL BE SUBMITTED

ON 30" BY 42", COMPLETE WITH 2 COPIES. THIS DRAWING SHALL BE TECHNICALLY

CORRECT AND DRAWN ACCORDING TO SOUND ENGINEERING PRINCIPLES. THIS SHALL

SHOW ALL ELEVATIONS, DISTANCES, DIAMETERS, SCHEDULES, MATERIALS INSTALLED,

SEQUENCE OF OPERATIONS OF ANY AND ALL ITEMS TO THE DEPARTMENT OF VETERANS

AFFAIRS. CONTRACTOR IS ADVISED THAT THEY ARE RESPONSIBLE TO MAINTAIN ALL

MEASUREMENTS DURING THE COURSE OF THIS PROJECT AND DIMENSIONS MISSING ON

THE AS-BUILT DRAWINGS SHALL NOT BE ACCEPTABLE. FINAL PAYMENT SHALL NOT BE

PROVIDED UNTIL THIS DRAWING IS SUBMITTED AND APPROVED. A COMPLETE,

ACCEPTABLE, SEPARATE, ENGINEERING "AS BUILT" IS REQUIRED FOR EACH UTILITY.

36. CONTRACTOR SHALL SAW CUT WITH PROPER BLADE ANY CONCRETE ENCOUNTERED IN

THE COURSE OF THIS WORK. ALL HOLES SHALL BE CORED DRILLED WITH DIAMOND

CORE BITS. THE USE OF JACK HAMMERS IS PROHIBITED.

37. CONTRACTOR SHALL BE RESPONSIBLE TO REMOVE ANY AND ALL DEBRIS FROM THE

MEDICAL CENTER DAILY AND DISPOSE OF IN ACCORDANCE TO VA SPECIFICATIONS.

38. CONTRACTOR SHALL PROVIDE FOR OWN STORAGE SPACE AND SECURITY FOR SAME.

CONTRACTOR SHALL BE PROHIBITED FROM USING VA SPACE FOR STORAGE. LOCATION

TO BE COORDINATED WITH COR AFTER NOTICE TO PROCEED HAS BEEN ISSUED.

39. ALL WORK SHALL BE PERFORMED BY THOSE WHO ARE SKILLED AND LICENSED IN THEIR

TRADES. THE CONTRACTOR IS ADVISED THAT WORK DEEMED UNSUITABLE,

UNACCEPTABLE BY THE VETERANS AFFAIRS SHALL BE DEEMED NON-ACCEPTABLE AND

THE CONTRACTOR SHALL REMOVE, REPLACE, AND RE-DO TO THE SATISFACTION OF THE

DEPARTMENT OF VETERANS AFFAIRS, THE UNACCEPTABLE WORK IS AT NO ADDITIONAL

COST TO THE GOVERNMENT. THERE SHALL BE NO ADDITIONAL CLAIMS AGAINST THE

DEPARTMENT OF VETERANS AFFAIRS FOR THE ABOVE.

40. THE CONTRACTOR SHALL BE RESPONSIBLE TO REROUTE ANY UTILITY ENCOUNTERED IN

THE COURSE OF THIS PROJECT. THE CONTRACTOR IS ADVISED THAT THE VETERANS

AFFAIRS HAS MADE THE ATTEMPT TO IDENTIFY MAJOR UTILITIES TO BE REROUTED. THE

CONTRACTOR SHALL SUBMIT "SHOP DRAWINGS" IN ACCORDANCE TO SPECIFICATIONS

PROVIDING THE VA ON ANY REROUTING OF UTILITIES AND HOW THE WORK WILL BE

COORDINATED FOR PRIOR APPROVAL BY THE VA.

41. THE GOVERNMENT SHALL NOT BE LIABLE FOR EXTRA PAYMENT SHOULD THE

CONTRACTOR UNDERESTIMATE QUANTITIES OF MATERIALS OF CONSTRUCTION.

42. THE CONTRACTOR SHALL BE ADVISED THAT ALL UTILITIES ARE TO BE VERIFIED AND

ASCERTAINED IN THE FIELD BY THE CONTRACTOR PRIOR TO ANY WORK.

43. CONTRACTOR SHALL BE RESPONSIBLE FOR ANY DAMAGE CAUSED TO THE EXISTING

PHONE SYSTEM, CAUSED BY CONSTRUCTION AND SHALL REPAIR ANY DAMAGE AT THE

CONTRACTOR'S EXPENSE. ANY AND ALL TELEPHONE WORK SHALL BE COORDINATED

WITH THE VA IRM TELECOMMUNICATION SERVICE AT THE MEDICAL CENTER.

44. CONTRACTOR SHALL INSTALL AND MAINTAIN DUST BARRIERS OR TEMPORARY

CONSTRUCTION WALLS AS DIRECTED BY THE CONTRACTING OFFICER. REFER TO

DEMOLITION PLAN FOR LOCATION, SEE SHEET "AD 100". SEE PARTITION DETAIL 4 ON

SHEET "AI 100" FOR DUST BARRIER OR TEMPORARY CONSTRUCTION WALL DETAILS AND

LOCATIONS.

45. THE GOVERNMENT SHALL NOT BE LIABLE TO THE CONTRACTOR FOR DELAYS DUE TO

NON-DELIVERY OF MATERIALS, WEATHER DELAYS, MANPOWER SHORTAGE, SUBMITTAL

DELAYS, SUBMITTAL RETURNS, WORK STOPPAGES BY REPRESENTATIVES OF THE

GOVERNMENT, FOR ANY REASON, SAFETY DELAYS, WORK DEEMED NON-ACCEPTABLE

BY THE GOVERNMENT.

46. PRIOR TO ANY WELDING, CUTTING, BRAZING, SOLDERING, THE CONTRACTOR SHALL

OBTAIN A "HOT WORK PERMIT" FROM THE DEPARTMENT OF VETERANS AFFAIRS FIRE

DEPARTMENT. WITHOUT THIS PERMIT, HOT WORK SHALL NOT BE PERMITTED BY THE

GOVERNMENT.

47. THE CONTRACTOR SHALL MAINTAIN SECURITY FOR THE WORK AREA AND PROVIDE KEYS

TO THE CONTRACTING OFFICER FOR ACCESS.

48. THE CONTRACTOR SHALL NOT LEAVE THE WORK AREA UNATTENDED FOR ANY REASON,

UNLESS SAFETY PARTITIONS, SAFETY FENCING ARE INSTALLED AND SECURED.

49. THE CONTRACTOR SHALL PARK IN APPROVED PARKING SPACES ONLY.

50. THE CONTRACTOR SHALL BE ADVISED THAT THERE MAY BE ASBESTOS ENCOUNTERED

AT ANY TIME ON THE SITE. THE CONTRACTOR SHALL BE ADVISED THAT IT IS THE

RESPONSIBILITY OF THE CONTRACTOR TO REMOVE ANY ASBESTOS ENCOUNTERED AND

DISPOSE OF IT PROPERLY OFF THE SITE AND IN ACCORDANCE WITH ALL LOCAL, CITY,

STATE, FEDERAL, VA RULES REGULATIONS, LAWS, STATUTES AND OTHERS.

51. THE CONTRACTOR SHALL TURN OVER, TO THE GOVERNMENT, A WASTE DISPOSAL

MANIFEST FOR EACH DUMPSTER REMOVED FROM THE CONSTRUCTION SITE. MANIFESTS

SHALL BE DELIVERED ON A MONTHLY BASIS.

52. GC IS RESPONSIBLE FOR FOLLOWING ALL MONTROSE VAMC ENGINEERING DIRECTIVES

AND POLICIES TITLED BELOW AND PROVIDED IN FULL WITH THE PROJECT

SPECIFICATIONS:

52.1. SOP 138-12HV

52.2. SOP 138-13HV

52.3. SOP 13A-01HV

52.4. SOP 138-15HV

52.5. SOP 138-22HV

52.6. SOP 138-58HV

52.7. SOP 138-60HV

52.8. SOP 138-62HV

52.9. SOP 138-69HV

52.10. VA FORM 2237 KEY REQUEST

52.11. VA SF 85 ID BADGE FORMS

52.12. VA HVHCS 11IC-05HV INFECTION CONTROL

52.13. VA HVHCS CONTRACTOR ORIENTATION MANUAL

52.14. VA HVHCS SAFETY MANUAL

52.15. VA HVHCS ASBESTOS PERMIT

52.16. VA HVHCS REQUEST TO WORK W.H.E.N. HOURS

52.17. VA WASTE MANIFEST REPORT

321 4 5 6 7

Office of Construction and Facilities Management

U.S. Department of Veterans Affairs of

LocationPhase

Project Number

Building Number

Drawing Number

Project Title

STAMPARCHITECT/ENGINEER OF RECORD

Date:Revisions:

Issue Date

Approved By: Approved By:

Approved By:Approved By:

Approved By:

Approved By: Approved By:

Approved By:

Drawing Title

Checked Drawn

CONSULTANT

620-20-205620-20-205 Renovate Building 3 Audiology

FDR VA HOSPITAL MONTROSE, NY

2021.11.18 N/A MA&MM

BID DOCUMENTSRevisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyyAPPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

Rev.

GENERAL REQUIREMENTS NOTES

SCALE: NOT TO SCALE1

FD

R

-0

GI-100

GENERAL REQUIREMENTS NOTES

N

S

W

E

N

S

W

E

321 4 5 6 7

Office of Construction and Facilities Management

U.S. Department of Veterans Affairs of

LocationPhase

Project Number

Building Number

Drawing Number

Project Title

STAMPARCHITECT/ENGINEER OF RECORD

Date:Revisions:

Issue Date

Approved By: Approved By:

Approved By:Approved By:

Approved By:

Approved By: Approved By:

Approved By:

Drawing Title

Checked Drawn

CONSULTANT

620-20-205620-20-205 Renovate Building 3 Audiology

FDR VA HOSPITAL MONTROSE, NY

2021.11.18 N/A MA&MM

BID DOCUMENTSRevisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyyAPPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

Rev.

LIFE SAFETY PLAN AND NOTES GROUND FLOOR- EXISTING

SCALE: 1/8" = 1'-0"1

LIFE SAFETY PLAN AND NOTES

GROUND FLOOR- NEW AND

EXISTING

FD

R

-0

GI-101

LIFE SAFETY PLAN AND NOTES GROUND FLOOR - NEW

SCALE: 1/8" = 1'-0"2

KEY PLAN KEY PLAN

AutoCAD SHX Text

UP

AutoCAD SHX Text

CORRIDOR 19Z

AutoCAD SHX Text LIFE SAFETY CODE REQUIREMENTS: 1. BUILDING 03 OCCUPANCY CLASSIFICATION: BUILDING 03 OCCUPANCY CLASSIFICATION: BUSINESS (B) 2. BUILDING IS FULLY SPRINKLED. BUILDING IS FULLY SPRINKLED. 3. EXISTING GROUND FLOOR IS BUSINESS OCCUPANCY IN ACCORDANCE TO NFPA 101, CHAPTERS 39 & EXISTING GROUND FLOOR IS BUSINESS OCCUPANCY IN ACCORDANCE TO NFPA 101, CHAPTERS 39 & 40. 4. GROUND FLOOR HAZARDS: LOW RISK. GROUND FLOOR HAZARDS: LOW RISK. 5. REFER TO TABLE 7.3.1.2 OF THE N.F.P.A 101 LIFE SAFETY CODE. REFER TO TABLE 7.3.1.2 OF THE N.F.P.A 101 LIFE SAFETY CODE. OCCUPANCY LOAD: BUSINESS: 100 GROSS SQ. FT. PER PERSON 100 GROSS SQ. FT. PER PERSON 6. TRAVEL DISTANCE TO EXITS, CHAPTERS 39.2.6.1; COMMON TRAVEL PATH, CHAPTERS 39.2.5.3; TRAVEL DISTANCE TO EXITS, CHAPTERS 39.2.6.1; COMMON TRAVEL PATH, CHAPTERS 39.2.5.3; DEAD-END CORRIDORS, CHAPTERS 39.2.5.2 ; REQUIRES CRITICAL PATHS SHALL NOT EXCEED AS NOTED BELOW: BUSINESS (B): 300 FT. TRAVEL DISTANCE TO EXITS. 300 FT. TRAVEL DISTANCE TO EXITS. 100 FT. COMMON PATH OF TRAVEL. 50 FT. DEAD-END CORRIDORS. EXISTING ACTUAL 99'-8" TRAVEL DISTANCE "A" 99'-8" TRAVEL DISTANCE "A" 110'-5" TRAVEL DISTANCE "B" 72'-6" COMMON PATH 0'-0" DEAD END TRAVEL NEW DISTANCES 97'-2" TRAVEL DISTANCE "A" 97'-2" TRAVEL DISTANCE "A" 91'-8" TRAVEL DISTANCE "B" 67'-10" COMMON PATH 0'-0" DEAD END TRAVEL GENERAL INFECTION CONTROL NOTES: 1. PROVIDE ACTIVE MEANS TO PREVENT AIR-BORNE DUST FROM DISPENSING INTO THE ATMOSPHERE, PROVIDE ACTIVE MEANS TO PREVENT AIR-BORNE DUST FROM DISPENSING INTO THE ATMOSPHERE, WHICH MAY INCLUDE A USE OF A CONTROL CUBE. 2. WATER MIST WORK SURFACES TO CONTROL DUST WHILE CUTTING. WATER MIST WORK SURFACES TO CONTROL DUST WHILE CUTTING. 3. SEAL ANY UNUSED DOORS WITH MASKING TAPE. SEAL ANY UNUSED DOORS WITH MASKING TAPE. 4. BLOCK OFF AND SEAL ANY AIR VENTS TO PREVENT SPREAD OF CONSTRUCTION DEBRIS FROM THE BLOCK OFF AND SEAL ANY AIR VENTS TO PREVENT SPREAD OF CONSTRUCTION DEBRIS FROM THE WORK AREA. 5. ALL DOORS AND WINDOWS WITHIN THE WORK AREA ARE TO REMAIN CLOSED AT ALL TIMES EXCEPT ALL DOORS AND WINDOWS WITHIN THE WORK AREA ARE TO REMAIN CLOSED AT ALL TIMES EXCEPT DURING INGRESS OR EGRESS. 6. PLACE ADHESIVE MATS AT ENTRANCES AND EXITS OF WORK AREA AS NECESSARY. PLACE ADHESIVE MATS AT ENTRANCES AND EXITS OF WORK AREA AS NECESSARY. 7. COVER TRANSPORT RECEPTACLES OR CARTS. COVER TRANSPORT RECEPTACLES OR CARTS. 8. CONTAIN CONSTRUCTION WASTE BEFORE TRANSPORT IN TIGHTLY COVERED CONTAINERS. CONTAIN CONSTRUCTION WASTE BEFORE TRANSPORT IN TIGHTLY COVERED CONTAINERS. 9. USE DESIGNATED ROUTES / ELEVATORS FOR REMOVAL OF DEBRIS. USE DESIGNATED ROUTES / ELEVATORS FOR REMOVAL OF DEBRIS. 10. WET MOP AND VACUUM WITH HEPA FILTERED VACUUM AT END OF THE JOB OR END OF WORK SHIFT. WET MOP AND VACUUM WITH HEPA FILTERED VACUUM AT END OF THE JOB OR END OF WORK SHIFT. AREA SHALL BE FREE OF DUST AND CONSTRUCTION DEBRIS. CONSTRUCTION BARRIER NOTES: 1. ALL CONSTRUCTION BARRIERS MUST BE BUILT, INSPECTED AND APPROVED BY COR AND VA FIRE ALL CONSTRUCTION BARRIERS MUST BE BUILT, INSPECTED AND APPROVED BY COR AND VA FIRE DEPARTMENT BEFORE START OF DEMOLITION WORK. BEFORE START OF DEMOLITION WORK. START OF DEMOLITION WORK. 2. FOR GENERAL REQUIREMENTS, SEE SHEET "GI 100". FOR GENERAL REQUIREMENTS, SEE SHEET "GI 100". 3. FIREPROOF AND FIRESTOP ALL EXISTING WALLS ADJACENT TO OCCUPIED ROOMS TO CREATE A ONE FIREPROOF AND FIRESTOP ALL EXISTING WALLS ADJACENT TO OCCUPIED ROOMS TO CREATE A ONE (1) HOUR SEPERATION DURING CONSTRUCTION AT ALL TIMES. ALL CONSTRUCTION BARRIERS MUST EXTEND TO UNDERSIDE OF EXISTING STRUCTURE ABOVE.

AutoCAD SHX Text

TRAVEL DISTANCE "A" 99'-8"

AutoCAD SHX Text

TRAVEL DISTANCE "B" 110'-5"

AutoCAD SHX Text

COMMON PATH 72'-6"

AutoCAD SHX Text SPEECH PATHOLOGY 155 Sq. Ft. 037B

AutoCAD SHX Text SWING OFFICE 124 Sq. Ft. 037G

AutoCAD SHX Text AUDIOMETRIX LAB 01 255 Sq. Ft. 037C

AutoCAD SHX Text OFFICE 127 Sq. Ft. 037F

AutoCAD SHX Text AUDIO AID LAB. 147 Sq. Ft. 037D

AutoCAD SHX Text AUDIO LAB. 399 Sq. Ft. 037E

AutoCAD SHX Text AUDIO DEVICE STORAGE 92 Sq. Ft. 037D1

AutoCAD SHX Text WAITING AREA 182 Sq. Ft. 037

AutoCAD SHX Text AUDIOLOGY SERVICE 215 Sq. Ft. 037Z

AutoCAD SHX Text ELEC. CL. 17.5 Sq. Ft. 037A

AutoCAD SHX Text

CORRIDOR 19Z

AutoCAD SHX Text

TRAVEL DISTANCE "A" 97'-2"

AutoCAD SHX Text

TRAVEL DISTANCE "B" 91'-8"

AutoCAD SHX Text

COMMON PATH 67'-10"

AutoCAD SHX Text

ELEC. CLOSET 4

AutoCAD SHX Text

RECORDS 5C

AutoCAD SHX Text

RECEP. AREA 5A

AutoCAD SHX Text

FILM PROC. 5E1

AutoCAD SHX Text

TOILET 5B

AutoCAD SHX Text

TOILET 5U

AutoCAD SHX Text

WAITING AREA 5V

AutoCAD SHX Text

SOILED LINEN 6

AutoCAD SHX Text

CONN. CORR. TO BLDG. 4

AutoCAD SHX Text

STAIR HALL A 8 (N.I.C)

AutoCAD SHX Text N

AutoCAD SHX Text N

AutoCAD SHX Text F

AutoCAD SHX Text

FLOOR TO DECK PARTITION

AutoCAD SHX Text

2HR RATED (EXISTING)

AutoCAD SHX Text V

AutoCAD SHX Text V

AutoCAD SHX Text

FEC

AutoCAD SHX Text

EXTEND WALL 8" FOR ACCEPTANCE OF NEW SEMI-RECESSED FEC.

AutoCAD SHX Text V

F

W

E

UP

321 4 5 6 7

Office of Construction and Facilities Management

U.S. Department of Veterans Affairs of

LocationPhase

Project Number

Building Number

Drawing Number

Project Title

STAMPARCHITECT/ENGINEER OF RECORD

Date:Revisions:

Issue Date

Approved By: Approved By:

Approved By:Approved By:

Approved By:

Approved By: Approved By:

Approved By:

Drawing Title

Checked Drawn

CONSULTANT

620-20-205620-20-205 Renovate Building 3 Audiology

FDR VA HOSPITAL MONTROSE, NY

2021.11.18 N/A MA&MM

BID DOCUMENTSRevisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyyAPPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

Rev.

INFECTION CONTROL PLAN - GROUND FLOOR

SCALE: 1/8" = 1'-0"1

FD

R

-0

GI-201

INFECTION CONTROL PLAN -

GROUND FLOOR

AutoCAD SHX Text

ELEV. 1

AutoCAD SHX Text

ELEV. 2

AutoCAD SHX Text

UP

AutoCAD SHX Text

UP

AutoCAD SHX Text

UP

AutoCAD SHX Text

UP

AutoCAD SHX Text

DN

AutoCAD SHX Text

692 SF

AutoCAD SHX Text

PRIMARY CARE WAITING

AutoCAD SHX Text

AutoCAD SHX Text

355 SF

AutoCAD SHX Text

H.A.S. CHECK-IN

AutoCAD SHX Text

AutoCAD SHX Text

50 SF

AutoCAD SHX Text

PAT. TLT

AutoCAD SHX Text

AutoCAD SHX Text

145 SF

AutoCAD SHX Text

SHARED WOMEN'S HEALTH EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

48 SF

AutoCAD SHX Text

PRIVATE PAT. TLT

AutoCAD SHX Text 018A

AutoCAD SHX Text

159 SF

AutoCAD SHX Text

SHARED WOMEN'S HEALTH EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

175 SF

AutoCAD SHX Text H.A.S.

AutoCAD SHX Text 051L

AutoCAD SHX Text

484 SF

AutoCAD SHX Text H.A.S.

AutoCAD SHX Text

AutoCAD SHX Text

122 SF

AutoCAD SHX Text

SUPERVISOR

AutoCAD SHX Text 057A

AutoCAD SHX Text

123 SF

AutoCAD SHX Text

TRAVEL

AutoCAD SHX Text 051L1

AutoCAD SHX Text

130 SF

AutoCAD SHX Text

CVT/EXAM

AutoCAD SHX Text

AutoCAD SHX Text

39 SF

AutoCAD SHX Text

CLEAN STOR.

AutoCAD SHX Text

AutoCAD SHX Text

125 SF

AutoCAD SHX Text

PACT TEAM #3 EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

81 SF

AutoCAD SHX Text

PYXIS ROOM

AutoCAD SHX Text

AutoCAD SHX Text

130 SF

AutoCAD SHX Text

PACT TEAM #1 EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

125 SF

AutoCAD SHX Text

PSYCHOLOGIST/ PRIMARY CARE/ MENTAL HEALTH EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

126 SF

AutoCAD SHX Text

SPRINKLER RM

AutoCAD SHX Text

AutoCAD SHX Text

125 SF

AutoCAD SHX Text

MEN'S STAFF LOCKER RM

AutoCAD SHX Text 037D

AutoCAD SHX Text

50 SF

AutoCAD SHX Text

STAFF TLT

AutoCAD SHX Text

AutoCAD SHX Text

161 SF

AutoCAD SHX Text

NEW ELEC RM

AutoCAD SHX Text

AutoCAD SHX Text

23 SF

AutoCAD SHX Text

ELEC

AutoCAD SHX Text

AutoCAD SHX Text

23 SF

AutoCAD SHX Text

JAN.

AutoCAD SHX Text

AutoCAD SHX Text

74 SF

AutoCAD SHX Text

CLEAN STOR./ FORMER AMBULATORY

AutoCAD SHX Text 051H

AutoCAD SHX Text

88 SF

AutoCAD SHX Text

SOILED UTILITY RM

AutoCAD SHX Text 051F

AutoCAD SHX Text

437 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

165 SF

AutoCAD SHX Text

EXAM RM

AutoCAD SHX Text 051C

AutoCAD SHX Text

149 SF

AutoCAD SHX Text

EXAM RM

AutoCAD SHX Text 051D

AutoCAD SHX Text

97 SF

AutoCAD SHX Text

STAFF/ OFFICE/ FORMER AMBULATORY

AutoCAD SHX Text 051E

AutoCAD SHX Text

122 SF

AutoCAD SHX Text

EXAM RM/ FORMER AMBULATORY

AutoCAD SHX Text 051I

AutoCAD SHX Text

65 SF

AutoCAD SHX Text

TLT

AutoCAD SHX Text 051A

AutoCAD SHX Text

186 SF

AutoCAD SHX Text

ENTRANCE

AutoCAD SHX Text

90 SF

AutoCAD SHX Text

EMS CL

AutoCAD SHX Text

AutoCAD SHX Text

151 SF

AutoCAD SHX Text

OFFICE

AutoCAD SHX Text

AutoCAD SHX Text

157 SF

AutoCAD SHX Text

RESIDENT BEDROOM

AutoCAD SHX Text

AutoCAD SHX Text

125 SF

AutoCAD SHX Text

OFFICE

AutoCAD SHX Text

AutoCAD SHX Text

83 SF

AutoCAD SHX Text

OFFICE

AutoCAD SHX Text 051M4

AutoCAD SHX Text

104 SF

AutoCAD SHX Text

OFFICE

AutoCAD SHX Text 051M3

AutoCAD SHX Text

54 SF

AutoCAD SHX Text

TLT

AutoCAD SHX Text 051M2

AutoCAD SHX Text

136 SF

AutoCAD SHX Text

EXIST ELEC RM

AutoCAD SHX Text

AutoCAD SHX Text

507 SF

AutoCAD SHX Text

MECH RM

AutoCAD SHX Text

AutoCAD SHX Text

127 SF

AutoCAD SHX Text

PSYCHOLOGIST/ PRIMARY CARE/ MENTAL HEALTH EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

280 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

102 SF

AutoCAD SHX Text

TLT

AutoCAD SHX Text

AutoCAD SHX Text

59 SF

AutoCAD SHX Text

TLT

AutoCAD SHX Text 048B

AutoCAD SHX Text

279 SF

AutoCAD SHX Text

ELEV LOBBY

AutoCAD SHX Text

740 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

335 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

25 SF

AutoCAD SHX Text

MED STOR.

AutoCAD SHX Text 019A

AutoCAD SHX Text

64 SF

AutoCAD SHX Text

SHOWER/ SEARCH RM

AutoCAD SHX Text 051M1

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

127 SF

AutoCAD SHX Text

STAIR HALL #1

AutoCAD SHX Text

179 SF

AutoCAD SHX Text

MECH

AutoCAD SHX Text

AutoCAD SHX Text

230 SF

AutoCAD SHX Text

STARBUCKS

AutoCAD SHX Text

AutoCAD SHX Text

61 SF

AutoCAD SHX Text

PAT. TLT

AutoCAD SHX Text

AutoCAD SHX Text

193 SF

AutoCAD SHX Text

SHARED TREATMENT

AutoCAD SHX Text

AutoCAD SHX Text

49 SF

AutoCAD SHX Text

PRIVATE PAT. TLT

AutoCAD SHX Text 020A

AutoCAD SHX Text

51 SF

AutoCAD SHX Text

PUBLIC TLT

AutoCAD SHX Text

AutoCAD SHX Text

56 SF

AutoCAD SHX Text

PUBLIC TLT

AutoCAD SHX Text

AutoCAD SHX Text

46 SF

AutoCAD SHX Text

STAFF TLT

AutoCAD SHX Text 027A

AutoCAD SHX Text

167 SF

AutoCAD SHX Text

PACT TEAM #1 COMMON RM

AutoCAD SHX Text

AutoCAD SHX Text

19 SF

AutoCAD SHX Text

TOILET

AutoCAD SHX Text 014A

AutoCAD SHX Text

190 SF

AutoCAD SHX Text

PACT TEAM #2 COMMON RM

AutoCAD SHX Text

AutoCAD SHX Text

33 SF

AutoCAD SHX Text

SOILED HOLDING

AutoCAD SHX Text

AutoCAD SHX Text

454 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

139 SF

AutoCAD SHX Text

EXAM RM

AutoCAD SHX Text 051J

AutoCAD SHX Text

116 SF

AutoCAD SHX Text

MED 3 NEW

AutoCAD SHX Text 051K

AutoCAD SHX Text

336 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

177 SF

AutoCAD SHX Text

WAITING RM

AutoCAD SHX Text 051M

AutoCAD SHX Text

840 SF

AutoCAD SHX Text

WAITING RM

AutoCAD SHX Text

AutoCAD SHX Text

1332 SF

AutoCAD SHX Text

LOBBY AND WAITING

AutoCAD SHX Text

47 SF

AutoCAD SHX Text

AMBASSADOR

AutoCAD SHX Text

88 SF

AutoCAD SHX Text

VESTIBULE

AutoCAD SHX Text

364 SF

AutoCAD SHX Text

ATRIUM

AutoCAD SHX Text

150 SF

AutoCAD SHX Text

STAIR HALL #5

AutoCAD SHX Text 15H

AutoCAD SHX Text

146 SF

AutoCAD SHX Text

STAIR HALL #4

AutoCAD SHX Text

18 SF

AutoCAD SHX Text

TELE CL

AutoCAD SHX Text

AutoCAD SHX Text

30 SF

AutoCAD SHX Text

TLT

AutoCAD SHX Text 044A

AutoCAD SHX Text

20 SF

AutoCAD SHX Text

CL

AutoCAD SHX Text 043A

AutoCAD SHX Text

124 SF

AutoCAD SHX Text

PACT TEAM #2 EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

124 SF

AutoCAD SHX Text

CONF RM

AutoCAD SHX Text

AutoCAD SHX Text

601 SF

AutoCAD SHX Text

CORRIDOR

AutoCAD SHX Text

94 SF

AutoCAD SHX Text

DETAILS

AutoCAD SHX Text

AutoCAD SHX Text

210 SF

AutoCAD SHX Text

STAIR HALL #2

AutoCAD SHX Text

206 SF

AutoCAD SHX Text

STAIR HALL #3

AutoCAD SHX Text

141 SF

AutoCAD SHX Text

PACT TEAM #3 EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

122 SF

AutoCAD SHX Text

PACT TEAM #2 EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

186 SF

AutoCAD SHX Text

PACT TEAM #3 COMMON RM

AutoCAD SHX Text

AutoCAD SHX Text

105 SF

AutoCAD SHX Text

SOCIAL WORKER

AutoCAD SHX Text

AutoCAD SHX Text

124 SF

AutoCAD SHX Text

PHARMACIST

AutoCAD SHX Text

AutoCAD SHX Text

CONN. CORR. TO BLDG 4

AutoCAD SHX Text 05L8

AutoCAD SHX Text

CONN. CORR. TO BLDG 2, 15

AutoCAD SHX Text 05L9

AutoCAD SHX Text

122 SF

AutoCAD SHX Text

PACT TEAM #1 EXAM RM

AutoCAD SHX Text

AutoCAD SHX Text

68 SF

AutoCAD SHX Text

ELEV 1

AutoCAD SHX Text

AutoCAD SHX Text

99 SF

AutoCAD SHX Text

ELEV 2

AutoCAD SHX Text

AutoCAD SHX Text

62 SF

AutoCAD SHX Text

EXIST ELEC

AutoCAD SHX Text

AutoCAD SHX Text

10 SF

AutoCAD SHX Text

CRASH CART

AutoCAD SHX Text

TRIAGE 1

AutoCAD SHX Text 051B

AutoCAD SHX Text

127 SF

AutoCAD SHX Text

WOMEN'S STAFF LOCKER RM

AutoCAD SHX Text 037C

AutoCAD SHX Text

207 SF

AutoCAD SHX Text

STAFF LOUNGE

AutoCAD SHX Text 037B

AutoCAD SHX Text

78 SF

AutoCAD SHX Text

IT CLOSET.

AutoCAD SHX Text

AutoCAD SHX Text

8 SF

AutoCAD SHX Text

ELEC. CL.

AutoCAD SHX Text

AutoCAD SHX Text

AUDIOLOGY

AutoCAD SHX Text

AutoCAD SHX Text

207 SF

AutoCAD SHX Text

CLOSET

AutoCAD SHX Text 037A

AutoCAD SHX Text

4 SF

AutoCAD SHX Text

ELEC. CL.

AutoCAD SHX Text

AutoCAD SHX Text

36 SF

AutoCAD SHX Text

CLOSET

AutoCAD SHX Text

AutoCAD SHX Text

4 SF

AutoCAD SHX Text

CLOSET.

AutoCAD SHX Text

AutoCAD SHX Text

SUITE

AutoCAD SHX Text

AutoCAD SHX Text

PLUMBG CL

AutoCAD SHX Text

AutoCAD SHX Text 051G

AutoCAD SHX Text 048A

AutoCAD SHX Text

CLOSET

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

DEMOLITION DEBRIS AND INFECTION CONTROL NOTES:

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text DEMOLITION TO BE COORDINATED AMONG ALL TRADES. ISSUES TO BE BROUGHT TO THE ATTENTION OF THE COR PRIOR TO START OF WORK.

AutoCAD SHX Text COORDINATE PATH OF DEBRIS REMOVAL WITH THE COR AND BUILDING STAFF. PROTECT ELEVATOR, FLOORS, WALLS AND CEILING AS NEEDED TO PREVENT DAMAGE DURING REMOVAL OF DEBRIS AND CONSTRUCTION THROUGHOUT PROJECT.

AutoCAD SHX Text

AutoCAD SHX Text CONSTRUCTION BARRIER MUST BE APPROVED BY COR AND VA FIRE DEPARTMENT PRIOR TO START OF DEMOLITION WORK. 6 MIL. FIRE RETARDANT POLY EXTENDED TO UNDERSIDE OF STRUCTURE ABOVE TAPED AND SEALED AT ALL EDGES AND AROUND ALL PENETRATIONS. PROVIDE STICKY MATS ON BOTH SIDES OF NEW POLY ZIP DOORS.

AutoCAD SHX Text

AutoCAD SHX Text PATH OF DEMOLITION DEBRIS REMOVAL AND GENERAL CONSTRUCTION ACCESS. ALL MATERIALS ARE TO BE LOADED ONTO CART AND COVERED PRIOR TO EXITING CONSTRUCTION AREA. DO NOT BLOCK PATH OF EGRESS OR EXISTING SIDEWALK. IF NEEDED, POUR ASPHALT PATH TO TAKE DEBRIS TO/FROM DUMPSTER AREA. REPAIR ANY DAMAGE TO EXISTING SIDEWALK AND BREAKUP AND REMOVE ASPHALT AFTER CONSTRUCTION.

AutoCAD SHX Text

AutoCAD SHX Text DUMPSTER TO BE COVERED WITH TARP FASTENED DOWN AT ALL TIMES TO PREVENT DEBRIS, DUST, ETC. FROM BEING BLOWN ONTO THE GROUNDS OF THE FACILITY. DEMOLITION MATERIALS SUCH AS LIGHT BULBS AND METALS AND OTHER HAZARDOUS MATERIALS ARE TO BE SORTED AND DISCARDED OR RECYCLED PER VA HAZARDOUS WASTE MANAGEMENT SPECIFICATIONS. ALL DUMPSTER MANIFESTS SHALL BE SUBMITTED TO THE VA RESIDENT ENGINEER FOR RECORD.

AutoCAD SHX Text

AutoCAD SHX Text FIREPROOF/FIRESTOP THROUGHOUT EXISTING FLOOR TO MAINTAIN INTEGRITY OF 2HR FIRE RATING FOR FLOOR AND 1 HOUR FIRE RATING FOR WALLS WHERE ANY PENETRATIONS EXIST OR WHERE ANY ITEMS HAVE BEEN REMOVED. PRIME CONTRACTOR TO INSPECT WORK DAILY FOR NEW PENETRATIONS AND PERFORM THIS WORK.

AutoCAD SHX Text

AutoCAD SHX Text PROTECT FLOORS AND WALLS THAT ARE EXISTING TO REMAIN IN AREA OF WORK WITH PARTICLE HARDBOARD TAPED AT SEAMS.

AutoCAD SHX Text

AutoCAD SHX Text CLASS IV ICRA CLASSIFICATION PRECAUTIONS TO BE TAKEN DURING CONSTRUCTION: 1. ISOLATE HVAC SYSTEM IN AREA WHERE WORK IS BEING DONE TO PREVENT CONTAMINATION OF DUCT SYSTEM. MAINTAIN ISOLATE HVAC SYSTEM IN AREA WHERE WORK IS BEING DONE TO PREVENT CONTAMINATION OF DUCT SYSTEM. MAINTAIN UNTIL BARRIER IS REMOVED AT COMPLETION OF PROJECT. 2. DESIGNATE ENTRY AND EXIT TRAFFIC PATTERN, UNAUTHORIZED PERSONNEL ARE NOT PERMITTED TO ENTER WORK DESIGNATE ENTRY AND EXIT TRAFFIC PATTERN, UNAUTHORIZED PERSONNEL ARE NOT PERMITTED TO ENTER WORK ZONE, TRAFFIC CONTROL SIGNS PLACED. 3. COMPLETE ALL CRITICAL BARRIERS (I.E. SHEETROCK, PLYWOOD, PLASTIC) TO SEAL AREA FROM NON-WORK AREA AND COMPLETE ALL CRITICAL BARRIERS (I.E. SHEETROCK, PLYWOOD, PLASTIC) TO SEAL AREA FROM NON-WORK AREA AND IMPLEMENT CONTROL CUB CART (CART WITH PLASTIC COVERING AND SEALED CONNECTION TO WORK SITE WITH HEPA VACUUM FOR VACUUMING PRIOR TO EXIT) BEFORE CONSTRUCTION BEGINS. 4. MAINTAIN NEGATIVE AIR PRESSURE WITHIN WORK SITE AND UTILIZE HEPA EQUIPPED NEGATIVE AIR FILTRATION UNITS. MAINTAIN NEGATIVE AIR PRESSURE WITHIN WORK SITE AND UTILIZE HEPA EQUIPPED NEGATIVE AIR FILTRATION UNITS. BOTH WILL BE MAINTAINED UNTIL PROJECT AND TERMINAL CLEANING ARE COMPLETED AND INFECTION CONTROL AUTHORIZES REMOVAL. 5. AIR PRESSURE TO BE MONITORED AND DOCUMENTED AT LEAST DAILY. AIR PRESSURE TO BE MONITORED AND DOCUMENTED AT LEAST DAILY. 6. ADHESIVE MATS PLACED AT ALL ENTRANCES AND EXITS OF WORK AREA. ADHESIVE MATS PLACED AT ALL ENTRANCES AND EXITS OF WORK AREA. 7. THE CONTRACTOR WILL MAINTAIN THE CONSTRUCTION ZONE IN A CLEAN MANNER. THE CONTRACTOR WILL MAINTAIN THE CONSTRUCTION ZONE IN A CLEAN MANNER. 7.1. THE AREA WILL BE HEPA-VACUUMED, OR DAMP MOPPED DAILY OR MORE OFTEN AS NECESSARY TO MINIMIZE THE AREA WILL BE HEPA-VACUUMED, OR DAMP MOPPED DAILY OR MORE OFTEN AS NECESSARY TO MINIMIZE DUST. 7.2. DAILY CLEANUP OF DEBRIS, MATERIAL AND WASTE SHALL BE COMPLETED. DAILY CLEANUP OF DEBRIS, MATERIAL AND WASTE SHALL BE COMPLETED. 7.3. ADHESIVE MATS MONITORED AND CHANGED ON A REGULAR BASIS SO THAT THEY REMAIN EFFECTIVE. ADHESIVE MATS MONITORED AND CHANGED ON A REGULAR BASIS SO THAT THEY REMAIN EFFECTIVE. 7.4. ANY DUST OR CONSTRUCTION DEBRIS TRACKED OUTSIDE OF WORK AREA WILL BE PROMPTLY CLEANED. ANY DUST OR CONSTRUCTION DEBRIS TRACKED OUTSIDE OF WORK AREA WILL BE PROMPTLY CLEANED. 8. THE TERMINAL CLEANING WILL BE INSPECTED BY THE OWNER PRIOR TO AUTHORIZATION FOR THE BARRIER REMOVAL. THE TERMINAL CLEANING WILL BE INSPECTED BY THE OWNER PRIOR TO AUTHORIZATION FOR THE BARRIER REMOVAL. 9. AIR SAMPLED MAY BE PERFORMED FOLLOWING IC/SAFETY PROTOCOL. AIR SAMPLED MAY BE PERFORMED FOLLOWING IC/SAFETY PROTOCOL. 10. BARRIERS WILL BE REMOVED CAREFULLY TO MINIMIZE SPREADING OF CONSTRUCTION DUST AND DEBRIS. BARRIERS WILL BE REMOVED CAREFULLY TO MINIMIZE SPREADING OF CONSTRUCTION DUST AND DEBRIS. 11. SEAL ALL HOLES, PIPES AND CONDUIT PENETRATION IN WORK AREA. SEAL ALL HOLES, PIPES AND CONDUIT PENETRATION IN WORK AREA. 12. CONSTRUCT ANTEROOM FOR STAGING OF EQUIPMENT AND DONNING OF COVERALLS. CONSTRUCT ANTEROOM FOR STAGING OF EQUIPMENT AND DONNING OF COVERALLS. 13. WORKED WILL WEAR COVERALLS IN WORK AREA. UPON COMPLETION OF MAJOR DUST GENERATING ACTIVITIES, COVERALL WORKED WILL WEAR COVERALLS IN WORK AREA. UPON COMPLETION OF MAJOR DUST GENERATING ACTIVITIES, COVERALL REQUIREMENT IS REMOVED. 14. COVERALLS ARE REMOVED IN WORK ZONE BEFORE ENTERING ANTEROOM. COVERALLS ARE REMOVED IN WORK ZONE BEFORE ENTERING ANTEROOM. 15. ANY RESIDUAL DUST LEFT ON WORKED SHALL BE REMOVED BY VACUUM. ANY RESIDUAL DUST LEFT ON WORKED SHALL BE REMOVED BY VACUUM. 16. SHOE COVERS WILL BE WORN BY WORKED AND REMOVED IN THE ANTEROOM WHEN EXITING AREA. SHOE COVERS WILL BE WORN BY WORKED AND REMOVED IN THE ANTEROOM WHEN EXITING AREA. 17. ALL RENOVATION, CONSTRUCTION, MAINTENANCE AND TOOL CARTS LEAVING AREA MUST BE COVERED AND THE WHEELS ALL RENOVATION, CONSTRUCTION, MAINTENANCE AND TOOL CARTS LEAVING AREA MUST BE COVERED AND THE WHEELS WIPED DOWN WITH A DISINFECTANT SOLUTION. 18. CONTRACTOR WILL VACUUM OR DAMP MOP THE AREA OUTSIDE AND ADJACENT TO THE WORK ZONE AS FREQUENTLY CONTRACTOR WILL VACUUM OR DAMP MOP THE AREA OUTSIDE AND ADJACENT TO THE WORK ZONE AS FREQUENTLY AS NEEDED TO MAINTAIN CLEAN AREA. 19. PRIOR TO PROJECT COMPLETION: VACUUM AND WET MOP WORK AREA WITH DISINFECTANT, REMOVE ISOLATION OF HVAC PRIOR TO PROJECT COMPLETION: VACUUM AND WET MOP WORK AREA WITH DISINFECTANT, REMOVE ISOLATION OF HVAC SYSTEM, AND ALLOW INFECTION CONTROL AND SAFETY OFFICE TO INSPECT AREA BEFORE TAKING DOWN BARRIERS.

AutoCAD SHX Text

1. OBTAIN VA HUDSON VALLEY HCS POLICY 11IC-05HV ATTACHMENT A "INFECTION CONTROL RISK ASSESSMENT WORK OBTAIN VA HUDSON VALLEY HCS POLICY 11IC-05HV ATTACHMENT A "INFECTION CONTROL RISK ASSESSMENT WORK PERMIT" PRIOR TO START OF ANY WORK ON THIS PROJECT. 2. EXECUTE WORK BY METHODS TO MINIMIZE RAISING DUST FROM CONSTRUCTION OPERATIONS. EXECUTE WORK BY METHODS TO MINIMIZE RAISING DUST FROM CONSTRUCTION OPERATIONS. 3. IMMEDIATELY REPLACE ANY CEILING TILE DISPLACED FOR VISUAL INSPECTION. IMMEDIATELY REPLACE ANY CEILING TILE DISPLACED FOR VISUAL INSPECTION. 4. PROVIDE ACTIVE MEANS TO PREVENT AIRBORNE DUST FROM DISPERSING INTO ATMOSPHERE. PROVIDE ACTIVE MEANS TO PREVENT AIRBORNE DUST FROM DISPERSING INTO ATMOSPHERE. 5. WATER MIST WORK SURFACES TO CONTROL DUST WHILE CUTTING DRY WALL FOR ANY REASON. WATER MIST WORK SURFACES TO CONTROL DUST WHILE CUTTING DRY WALL FOR ANY REASON. 6. SEAL UNUSED DOORS WITH MASKING TAPE. SEAL UNUSED DOORS WITH MASKING TAPE. 7. BLOCK OFF AND SEAL AIR VENTS PRIOR TO START OF WORK. BLOCK OFF AND SEAL AIR VENTS PRIOR TO START OF WORK. 8. PLACE DUST MAT AT EVERY ENTRANCE AND EXIT OF WORK AREA. DOORS WITHIN WORK AREAS ARE TO REMAIN CLOSED PLACE DUST MAT AT EVERY ENTRANCE AND EXIT OF WORK AREA. DOORS WITHIN WORK AREAS ARE TO REMAIN CLOSED AT ALL TIMES EXCEPT DURING INGRESS/EGRESS. 9. REMOVE OR ISOLATE HVAC SYSTEM IN AREA WHERE WORK IS BEING DONE TO PREVENT CONTAMINATION OF DUCT SYSTEM. REMOVE OR ISOLATE HVAC SYSTEM IN AREA WHERE WORK IS BEING DONE TO PREVENT CONTAMINATION OF DUCT SYSTEM. MAINTAIN UNTIL BARRIER IS REMOVED AT COMPLETION OF PROJECT. 10. DESIGNATE ENTRY AND EXIT TRAFFIC PATTERN. UNAUTHORIZED PERSONNEL ARE NOT PERMITTED TO ENTER WORK ZONE, DESIGNATE ENTRY AND EXIT TRAFFIC PATTERN. UNAUTHORIZED PERSONNEL ARE NOT PERMITTED TO ENTER WORK ZONE, PLACE TRAFFIC CONTROL SIGNS. 11. REMOVE CONSTRUCTION WASTE AND CLEANUP DEBRIS, MATERIAL AND WASTE DAILY. INSPECT ICRA COMPLIANCE DAILY. REMOVE CONSTRUCTION WASTE AND CLEANUP DEBRIS, MATERIAL AND WASTE DAILY. INSPECT ICRA COMPLIANCE DAILY. KEEP A DAILY LOG OF VA HUDSON VALLEY HCS POLICY 11IC-05HV ATTACHMENT D "DAILY CONSTRUCTION - INFECTION CONTROL INTERVENTIONS COMPLIANCE MONITOR" AND SUBMIT LOG WEEKLY TO VA RESIDENT ENGINEER FOR RECORD. 12. PROVIDE TEMPORARY CONSTRUCTION PARTITIONS FOR ANY PERIMETER DOORS BEING REMOVED (DRYWALL/SHEETROCK) PROVIDE TEMPORARY CONSTRUCTION PARTITIONS FOR ANY PERIMETER DOORS BEING REMOVED (DRYWALL/SHEETROCK) AND SEAL UNUSED DOORS AND WINDOWS AT PERIMETER OF THE WORK AREA WITH DUCT TAPE TO SEAL AREA FROM NON-WORK AREA BEFORE CONSTRUCTION BEGINS. 13. MAINTAIN NEGATIVE AIR PRESSURE WITHIN WORK SITE UTILIZING WINDOW EXHAUST FANS STRATEGICALLY LOCATED WITH MAINTAIN NEGATIVE AIR PRESSURE WITHIN WORK SITE UTILIZING WINDOW EXHAUST FANS STRATEGICALLY LOCATED WITH HEPA FILTER EQUIPPED AIR FILTRATION UNITS. 14. CONTAIN CONSTRUCTION WASTE BEFORE TRANSPORT IN TIGHTLY COVERED CONTAINERS OR BY COVERING IN PLASTIC AND CONTAIN CONSTRUCTION WASTE BEFORE TRANSPORT IN TIGHTLY COVERED CONTAINERS OR BY COVERING IN PLASTIC AND SEALING WITH DUCT TAPE. REFER TO GENERAL REQUIREMENTS FOR REMOVAL OF WASTE. 15. USE ROUTE AGREED UPON BY THE ICRA TEAM AND COR FOR TRANSPORT OF DEBRIS, CONSTRUCTION WASTE, USE ROUTE AGREED UPON BY THE ICRA TEAM AND COR FOR TRANSPORT OF DEBRIS, CONSTRUCTION WASTE, CONSTRUCTION EQUIPMENT, CONTAINERS, ETC... THROUGH THE FACILITY. 16. SEAL HOLES, PIPES, CONDUITS, AND PUNCTURES AIRTIGHT. SEAL HOLES, PIPES, CONDUITS, AND PUNCTURES AIRTIGHT. 17. ALL NEW AND DEMO MATERIALS THAT MUST BE TRANSPORTED THROUGH OCCUPIED AREAS INCLUDING COMMON CORRIDORS ALL NEW AND DEMO MATERIALS THAT MUST BE TRANSPORTED THROUGH OCCUPIED AREAS INCLUDING COMMON CORRIDORS AND ANY OTHER AREA, ARE TO BE TRANSPORTED INSIDE COVERED CARTS DURING W.H.E.N. (WEEKEND, HOLIDAY, EVENING, NIGHT) HOURS. 18. ANY WORK TO OCCUR IN OCCUPIED AREAS INCLUDING COMMON CORRIDORS AND ANY OTHER AREA NOT SPECIFICALLY ANY WORK TO OCCUR IN OCCUPIED AREAS INCLUDING COMMON CORRIDORS AND ANY OTHER AREA NOT SPECIFICALLY SHOWN, IS TO RECEIVE TEMPORARY PARTITIONS AND BE PERFORMED DURING W.H.E.N. HOURS INSIDE TEMPORARY NON-RATED PARTITIONS MEETING THE REQUIREMENTS OF DETAIL 2 ICRA TEMPORARY BARRIER ON SHEET A-501. 19. SEE NOTE 9 ON THIS SHEET FOR PROJECT CLOSEOUT PROCEDURE.SEE NOTE 9 ON THIS SHEET FOR PROJECT CLOSEOUT PROCEDURE.

AutoCAD SHX Text PATIENT RISK GROUP: HIGH RISK HIGH RISK CONSTRUCTION PROJECT TYPE: D D CLASS: IVIV

AutoCAD SHX Text

INFECTION CONTROL POLICY

AutoCAD SHX Text

(PRECAUTIONS DURING CONSTRUCTION)

AutoCAD SHX Text

AutoCAD SHX Text

19. PRIOR TO PROJECT COMPLETION: VACUUM AND WET MOP WORK AREA WITH DISINFECTANT, REMOVE ISOLATION OF HVAC PRIOR TO PROJECT COMPLETION: VACUUM AND WET MOP WORK AREA WITH DISINFECTANT, REMOVE ISOLATION OF HVAC SYSTEM, AND ALLOW INFECTION CONTROL AND SAFETY OFFICE TO INSPECT AREA BEFORE TAKING DOWN BARRIERS.

AutoCAD SHX Text

AutoCAD SHX Text EXAMPLES OF PRODUCTS AND MATERIALS FOR ICRA CONTAINMENT: 1. BARRIER TYPES: FIRE RETARDANT POLYETHYLENE, 6-MIL THICKNESS MINIMUM, GYPSUM WALL BOARD, FIRE RATED BARRIER TYPES: FIRE RETARDANT POLYETHYLENE, 6-MIL THICKNESS MINIMUM, GYPSUM WALL BOARD, FIRE RATED FIBERGLASS REINFORCED PLASTIC (SIMILAR TO FIRE-X GLASSBOARD), PLYWOOD AND MASONITE PAINTED W/ FIRE RESISTANT PAINT (FLAM CONTROL COATINGS #320A OR SIMILAR) 2. CARPET VACUUM: NOBLE ULTRA-GLIDE 18" W/ DUAL MOTORS & HEPA FILTERS OR EQUIVALENT CARPET VACUUM: NOBLE ULTRA-GLIDE 18" W/ DUAL MOTORS & HEPA FILTERS OR EQUIVALENT 3. DOOR TYPES: ZIPPER DOOR IN POLYETHYLENE, OR AN OVERLAPPED POLYETHYLENE ENTRANCE AS SPECIFIED IN ICRA DOOR TYPES: ZIPPER DOOR IN POLYETHYLENE, OR AN OVERLAPPED POLYETHYLENE ENTRANCE AS SPECIFIED IN ICRA WORK PERMIT 4. EXHAUST HOSES: HEAVY DUTY FLEXIBLE STEEL-REINFORCED; VENTILATION BLOWER HOSE QPG AS MANUFACTURED BY EXHAUST HOSES: HEAVY DUTY FLEXIBLE STEEL-REINFORCED; VENTILATION BLOWER HOSE QPG AS MANUFACTURED BY FEDERAL HOSE MTG. OR SIMILAR 5. NEGATIVE AIR MACHINE: HEPA FILTER EQUIPPED AND PROVIDE ROUGHING FILTERS, PRIMARY FILTERS, AND HEPA FINAL NEGATIVE AIR MACHINE: HEPA FILTER EQUIPPED AND PROVIDE ROUGHING FILTERS, PRIMARY FILTERS, AND HEPA FINAL FILTERS WITH A RATING OF 200 TO 2000 CFM. HEPA FILTERS MINIMUM 99.97% EFFICIENT. HEPA FILTER FACTORY SCAN TESTED & ACCEPTED AFTER MANUFACTURE. NO LEAKS GREAT THAN 0.01 OF UPSTREAM CONCERNTRATION AT RATED CAPACITY OF 2000 CFM. INITIAL CLEAN RESISTANCE SHALL BE NO MORE THAN 1.35" W.C. @ 2000 CFM. SUPPLIER: AIRBORNE CONTAMINATION IDENTIFICATION ASSOCIATES, OR SIMILAR 6. WALK-OFF MATS: PROVIDE MINIMUM SIZE ADHESIVE MATS OF 18"x24" AS MANFUCATURED BY 3M, ST. PAUL, MN OR WALK-OFF MATS: PROVIDE MINIMUM SIZE ADHESIVE MATS OF 18"x24" AS MANFUCATURED BY 3M, ST. PAUL, MN OR SIMILAR.

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text

AREA OF NEW WORK

AutoCAD SHX Text

AutoCAD SHX Text

AutoCAD SHX Text GC RESPONSIBLE FOR EXISTING AUDIOLOGY BOOTH TO BE BROKEN DOWN FROM CURRENT TEMPORARY LOCATION AND INSTALLED IN NEW LOCATION AS SHOWN ON PLANS AND PER MANUFACTURER GUIDELINES.

AutoCAD SHX Text EXISTING LOCATION OF TEMPORARY AUDIOLOGY SUITE. TO MINIMIZE FACILITY DOWNTIME, TEMPORARY SUITE WILL REMAIN ACTIVE UNTIL NEW SITE LOCATION IS PREPARED FOR ACCEPTANCE OF EXISTING AUDIOLOGY BOOTH. COORDINATE PHASING WITH PROJECT ENGINEER / COR.

AutoCAD SHX Text

AutoCAD SHX Text MAINTAIN EXISTING 1-HOUR RATED FIRE BARRIER WALL. ALLOW FOR (20) PENETRATIONS TO BE FIRESTOPPED PRIOR TO START OF WORK. PROVIDE AND INSTALL NEW 3/4-HOUR, SELF-CLOSING, SELF-LATCHING TEMPORARY DOOR.

AutoCAD SHX Text

W

E

QUANTITIES - ACM MATERIALS

AREAS ANTICIPATED TO BE IN-SCOPE OF REQUIRED MODIFICATION, COORDINATE

WITH DEMOLITION AND NEW WORK TO DETERMINE SPECIFIC EXTENTS.

30LF ± OF PIPE TO BE ABATED

LEGEND

PIPES, STEAM

HISTORICALLY RECORDED ACM

N

S

W

E

321 4 5 6 7

Office of Construction and Facilities Management

U.S. Department of Veterans Affairs of

LocationPhase

Project Number

Building Number

Drawing Number

Project Title

STAMPARCHITECT/ENGINEER OF RECORD

Date:Revisions:

Issue Date

Approved By: Approved By:

Approved By:Approved By:

Approved By:

Approved By: Approved By:

Approved By:

Drawing Title

Checked Drawn

CONSULTANT

620-20-205620-20-205 Renovate Building 3 Audiology

FDR VA HOSPITAL MONTROSE, NY

2021.11.18 N/A MA&MM

BID DOCUMENTSRevisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyy

Revisions: mm/dd/yyyyAPPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

APPROVED_BY

Rev.

ASBESTOS ABATEMENT PLAN - PIPING

SCALE: 1/8" = 1'-0"1

ASBESTOS AND LEAD PLANS

FD

R

-0

HC-101

KEY PLAN

LEAD-CONTAINING PAINT FINISH PLAN

SCALE: 1/8" = 1'-0"2

KEY PLAN

AutoCAD SHX Text

UP

AutoCAD SHX Text ASBESTOS ABATEMENT GENERAL NOTES 1.