St. Louis_1605AE-23-B-00001_Amnd0001.pdf

(x)

1605AE-23-B-00001

x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Washington DC 20210

JCAS

N-4643 200 Constitution Ave, NW Job Corps Acquisition Services US Department of Labor

149211/04/20220001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

10/11/2022

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

IFB No. 1605AE-23-B-00001, Amendment No. 0001

St. Louis JCC Phase I-Welcome Center & Medical/Dental Buildings

(continued on next page)

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Emily M. Giardino

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

TEL: EMAIL: 215-861-5226 GIARDINO.EMILY.M@DOL.GOV

IFB No. 1605AE-23-B-00001 Amendment No. 0001

SF 30, Block 14, continued:

Project Title: St. Louis JCC Phase I – Welcome Center & Medical/Dental Buildings Project

A. The purpose of this amendment is to accomplish the following actions:

1. Update Section F.3 FAR 52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION

(below); changes in bold italics.

2. Include questions and responses from pre-bid conference and site visit (beginning page 3 of this Amendment).

3. Provide the list of pre-bid conference attendees (attached to this Amendment).

B. This amendment DOES NOT extend the bid opening date of 11/16/2022 at 2:00 PM ET.

Updated Section F.3 FAR 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of (See Below) for each calendar day of delay until the work is completed or accepted.

Project Name Amount (per day) St. Louis Welcome Center &

Medical/Dental Buildings $1139.48

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

--End of Updated Section--

QUESTIONS & ANSWERS – IFB No. 1605AE-23-B-00001, St. Louis Phase I

1. Additional Days: The activities involved are cause for concern, are added days or extended shifts allowable.

RESPONSE: The period of performance is 360 calendar days from Notice to Proceed, as stated in the Solicitation. Additional days will not be added to the period of performance at this time. Acceptable work shifts are specified in the solicitation documents. Work hours shall be from 7:00 am to 4:00 pm, Monday through Friday. Prior approval by the Contracting Officer (CO) is required for extended shifts and weekend work. The Contractor shall provide requests to CO a minimum of 48 hours in advance.

2. Temporary Access: The prospective bidder has proposed an option RE: temporary access…please advise

RESPONSE: Alternative options for temporary access are not acceptable; bidders shall bid in accordance with the plans and specifications. The Temporary Security Office shall be located at the rear entrance gate at a location within the St. Louis Job Corps property perimeter fence line. Location of the Temporary Security Office shall allow for full view and control of the rear entrance gate. Final location to be approved by the Department.

3. Storage/Staging: On-site storage and staging areas will be required, please advise with best location(s).

RESPONSE: Please refer to the phasing plans on Sheets A0.00 through A0.04 and Spec Section 015000 - Temporary Facilities and Controls, of the Construction Documents which delineate the fenced areas within which all construction activities shall take place. The exact location of storage and staging areas are not indicated on the drawings. It is considered means and methods based on sequence of work and site restrictions.

4. Specifications: Mechanical specs 23 00 10 & 23 81 26 are not understandable.

RESPONSE: The revised mechanical specification sections are attached. Also included are the revised specifications and drawings that have previously changed and were inadvertently omitted from this Construction Document release. The list of provided revised specifications is as follows:

- Spec Sect 23 00 10_General Provisions_Reprint

- Spec Sect 23 81 26_Split System Air Conditioners_Reprint

- REV A6-52 – Exterior Details Window Details_012822

- REV Spec Sect 01 22 00_Unit Prices

- REV Spec Sect 01 50 00_Temporary Facilities and Controls_013122

- REV Spec Sect 01 74 19_Construction Waste Management & Disposal_020322

- REV Spec Sect 02 41 13_Selective Site Demolition_020322

- REV Spec Sect 02 41 16_Structure Demolition_020322

- REV Spec Sect 02 41 19_Selective Demolition_020322

- REV Spec Sect 02 82 13_Asbestos Abatement_013122

END OF AMENDMENT

STLJCC Phase III and IV Center Redevelopment Project (PH1)

012200 - Page 1 02/09/2018

SECTION 012200 - UNIT PRICES

PART 1 - GENERAL

1.1 RELATED DOCUMENTS

A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification Sections, apply to this Section.

1.2 SUMMARY

A. Section includes administrative and procedural requirements for unit prices.

1.3 DEFINITIONS

A. Unit price is a price per unit of measurement for materials, equipment, or services, or a portion of the Work, added to or deducted from the Contract Sum by appropriate modification, if the scope of Work or estimated quantities of Work required by the Contract Documents are increased or decreased.

1.4 PROCEDURES

A. Unit prices include all necessary material, plus cost for delivery, installation, insurance, applicable taxes, overhead, and profit.

B. Measurement and Payment: See individual Specification Sections for work that requires establishment of unit prices. Methods of measurement and payment for unit prices are specified in those Sections.

C. Owner reserves the right to reject Contractor's measurement of work-in-place that involves use of established unit prices and to have this work measured, at Owner's expense, by an independent surveyor.

D. List of Unit Prices: A schedule of unit prices is included in Part 3. Specification Sections referenced in the schedule contain requirements for materials described under each unit price.

012200 - Page 2 02/09/2018

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 SCHEDULE OF UNIT PRICES

A. Unit Price 1: Removal of unsatisfactory soil and replacement with satisfactory soil material.

1. Description: Unsatisfactory soil excavation and disposal off site and replacement with satisfactory fill material or engineered fill from off site, as required, according to Section 312000 "Earth Moving."

2. Unit of Measurement: Cubic yard of soil excavated, based on survey of volume removed.

B. Unit Price No. 2: Additional receptacle/outlet needed for project

1. Description: Installed duplex receptacle/outlets including box, wire, conduit, device, plate connections, etc. as required according to section

a. 260519 “Low voltage electrical power conductors and cables”

b. 260529 “Hangers and supports for electrical systems”

c. 260533 “Raceways and boxes for electrical systems”

d. 262726 “Wiring devices”

2. Unit of Measurement: Cost is per duplex receptacle/outlet.

C. Unit Price 3: Removal of concrete foundation and floors and replacement with satisfactory soil material.

1. Description: Concrete foundation and concrete floor excavation and disposal off site and replacement with satisfactory fill material or engineered fill from off site, as required, according to Section 312000 "Earth Moving."

a. Contractor to provide estimated quantity of concrete to be removed based on the documentation that has been provided, along with associated unit price.

2. Unit of Measurement: Per Cubic Yard, based on actual cubic yards of material that is removed.

D. Unit Price 4: Removal of asbestos and hazardous materials.

1. Description: Asbestos and other hazardous materials removal and disposal off site as required, according to specification section 028213 and 028416.

2. Unit of Measurement: As indicated below per item.

a. Removal and Disposal of Floor Tile & Mastic: $/Sq. Ft.

b. Removal and Disposal of Pipe and Pipe Fitting Insulation 2”- 4”: $/Ln. Ft.

c. Removal and Disposal of Pipe and Pipe Fitting Insulation 6”-8”: $/Ln. Ft.

012200 - Page 3 02/09/2018

d. Removal and Disposal of Pipe and Pipe Fitting Insulation 10”: $/Ln. Ft.

e. Removal and Disposal of Fluorescent Light Tubes: $/Each

f. Removal and Disposal of PCB-Containing Ballasts: $/Each

g. Removal and Disposal of Fire Doors: $/Each

h. Removal and Disposal of Exit Signs: $/Each

i. Removal and Disposal of Smoke Detectors: $/Each

j. Removal and Disposal of Emergency Lighting (Mercury Containing):

$/Each

k. Removal and Disposal of Thermostats (Mercury Containing): $/Each

l. Removal and Disposal of Drinking Fountains: $/Each

m. Removal and Disposal of Fire Extinguisher: $/Each

n. Removal and Disposal of Exterior Building Lights: $/Each

o. Removal and Disposal of Pole/Parking Lights: $/Each

2.

END OF SECTION 012200

015000 - Page 1 02/09/2018 01/31/2022

SECTION 015000 - TEMPORARY FACILITIES AND CONTROLS

1.1 SUMMARY

A. Section includes requirements for temporary utilities, support facilities, and security and protection facilities.

B. Related Requirements:

1. Section 011000 "Summary" for work restrictions and limitations on utility interruptions.

2. Section 321200 "Plant Mix Bituminous Pavement" for construction and maintenance of asphalt pavement for temporary roads and paved areas.

3. Section 321313 "Concrete Paving" for construction and maintenance of cement concrete pavement for temporary roads and paved areas.

1.2 USE CHARGES

A. General: Installation and removal of and use charges for temporary facilities shall be included in the Contract Sum unless otherwise indicated. Allow other entities to use temporary services and facilities without cost, including, but not limited to, Owner's construction forces, Architect, occupants of Project, testing agencies, and authorities having jurisdiction.

B. Sewer Service: Pay sewer-service use charges for sewer usage by all entities for construction operations.

C. Water Service: Pay water-service use charges for water used by all entities for construction operations.

D. Electric Power Service: Pay electric-power-service use charges for electricity used by all entities for construction operations.

1. Temporary electrical service for all work areas are to be paid for by the contractor. This includes the cost for installation of temporary services from utility company.

1.3 INFORMATIONAL SUBMITTALS

A. Site Plan: Show temporary facilities, utility hookups, staging areas, and parking areas for construction personnel.

B. Erosion- and Sedimentation-Control Plan: Show compliance with requirements of EPA Construction General Permit or authorities having jurisdiction, whichever is more stringent.

015000 - Page 2 02/09/2018

C. Fire-Safety Program: Show compliance with requirements of NFPA 241 and authorities having jurisdiction. Indicate Contractor personnel responsible for management of fire-prevention program.

D. Moisture-Protection Plan: Describe procedures and controls for protecting materials and construction from water absorption and damage.

1. Describe delivery, handling, and storage provisions for materials subject to water absorption or water damage.

2. Indicate procedures for discarding water-damaged materials, protocols for mitigating water intrusion into completed Work, and replacing water-damaged Work.

3. Indicate sequencing of work that requires water, such as sprayed fire-resistive materials, plastering, concrete cutting, and terrazzo grinding, and describe plans for dealing with water from these operations. Show procedures for verifying that wet construction has dried sufficiently to permit installation of finish materials.

E. Dust and HVAC-Control Plan: Submit coordination drawing and narrative that indicates the dust and HVAC-control measures proposed for use, proposed locations, and proposed time frame for their operation. Identify further options if proposed measures are later determined to be inadequate. Include the following:

1. Locations of dust-control partitions at each phase of work.

2. HVAC system isolation schematic drawing.

3. Location of proposed air-filtration system discharge.

4. Waste handling procedures.

5. Other dust-control measures.

6. Other measures indicated in MEP & Commissioning specifications

1.4 QUALITY ASSURANCE

A. Electric Service: Comply with NECA, NEMA, and UL standards and regulations for temporary electric service. Install service to comply with NFPA 70.

B. Tests and Inspections: Arrange for authorities having jurisdiction to test and inspect each temporary utility before use. Obtain required certifications and permits.

C. Accessible Temporary Egress: Comply with applicable provisions in the U.S.

Architectural & Transportation Barriers Compliance Board's ADA-ABA Accessibility Guidelines and ICC/ANSI A117.1.

1.5 PROJECT CONDITIONS

A. Temporary Use of Permanent Facilities: Engage Installer of each permanent service to assume responsibility for operation, maintenance, and protection of each permanent service during its use as a construction facility before Owner's acceptance, regardless of previously assigned responsibilities.

015000 - Page 3 02/09/2018

PART 2 - PRODUCTS

2.1 MATERIALS

A. Chain-Link Fencing: Minimum 2-inch, 0.148-inch-thick, galvanized-steel, chain-link fabric fencing; minimum 6 feet high with galvanized-steel pipe posts; minimum 2-3/8-inch-OD line posts and 2-7/8-inch- OD corner and pull posts, with 1-5/8-inch-OD top rails.

B. Portable Chain-Link Fencing: Minimum 2-inch, 0.148-inch-thick, galvanized-steel, chain-link fabric fencing; minimum 6 feet high with galvanized-steel pipe posts;

minimum 2-3/8-inch-OD line posts and 2-7/8-inch-OD corner and pull posts, with 1-5/8-inch-OD top and bottom rails. Provide galvanized-steel bases for supporting posts.

C. Dust-Control Adhesive-Surface Walk-off Mats: Provide mats minimum 36 by 60 inches.

D. Insulation: Unfaced mineral-fiber blanket, manufactured from glass, slag wool, or rock wool; with maximum flame-spread and smoke-developed indexes of 25 and 50, respectively.

2.2 TEMPORARY FACILITIES

A. Field Offices, General: Prefabricated or mobile units with serviceable finishes, temperature controls, and foundations adequate for normal loading.

B. Contractor-Use Field Office: Of sufficient size to accommodate needs of Contractor, and construction personnel office activities and to accommodate Project meetings specified in other Division 01 Sections. Keep office clean and orderly. Furnish and equip offices as follows:

1. Furniture required for Project-site documents including file cabinets, plan tables, plan racks, and bookcases.

2. Conference room of sufficient size to accommodate meetings of 20 individuals.

3. Provide electrical power service and 120-V ac duplex receptacles, with no fewer than one receptacle on each wall. Furnish room with conference table, chairs, and 4-foot-square tack and marker boards.

4. Drinking water and private toilet.

5. Coffee machine and supplies.

6. Heating and cooling equipment necessary to maintain a uniform indoor temperature of 68 to 72 deg F.

7. Lighting fixtures capable of maintaining average illumination of 20 fc at desk height.

8. Store Combustible materials apart from building.

C. Owner Field Representative / Architect - Use Field Office: The general contractor shall provide onsite a temporary field office for the exclusive use of the owner. The office must be located within the construction limits. The owners field office shall be approximately 300 square feet consisting of a conference /office/work area and contain the following.

015000 - Page 4 02/09/2018

1. One outside door with a security lock.

2. Minimum of two windows for ventilation, at least one shall overlook the site.

3. Provide required electrical power service and 120-V ac with minimum of eight duplex electrical convenience outlets

4. Adequate light fixtures and lamps to provide a minimum of 100-foot candles at desktop

5. One telephone on a private line, and one dedicated data line for use of a computer. The field office shall also have a dedicated password secured WIFI network for use the owner’s representative only.

6. Adequate heating and cooling facilities and sufficient ventilation to maintain a temperature of 72 degrees F.

7. One table for layout of plans approximately 3 x 7 feet and two desks, approximately 30 X 60 inches with desk chair.

8. Six side chairs

9. One plan rack

10. Two four-drawer file cabinet

11. One Copy Machine

12. A designated toilet facility – as a separate room within the field office trailer.

12.a. Toilet Facility shall be ADA Compliant, with all plumbing, electrical, & HVAC connections.

13. One bottled water dispenser

D. Temporary Security Office: The general contractor shall provide onsite a temporary field office for the exclusive use of the center operator security staff located at the rear entrance gate. The office shall be approximately 300 square feet consisting of an office/work area and contain the following.

1. Provide anchoring/foundations as required to stabilize the unit.

2. One outside door with a security lock with ADA ramp to gain access to office.

3. Minimum of two windows for ventilation, at least one shall overlook the entrance drive.

4. Provide required electrical power service and 120-V ac with minimum of eight duplex electrical convenience outlets.

5. Adequate light fixtures and lamps to provide a minimum of 100-foot candles at

6. One telephone on a private line, and one dedicated data line for use of a computer.

7. Adequate heating and cooling facilities and sufficient ventilation to maintain a

8. A designated toilet facility – as a separate room within the field office trailer.

8. Toilet Facility shall be ADA Compliant, with all plumbing, electrical, & HVAC connections.

9. One bottled water dispenser

E. Temporary Classroom & Office Space: The general contractor shall provide onsite a temporary office for the exclusive use of the center operator staff and students located at an area to be determined by the center operator on campus. The office shall be approximately 500 square feet consisting of an open office/work area to accommodate 6 desks, 2 meetings rooms and contain the following.

1. One outside door with a security lock with ADA ramp to gain access.

015000 - Page 5 02/09/2018

2. Minimum of two windows for ventilation.

3. Provide required electrical power service and 120-V ac with minimum of eight duplex electrical convenience outlets.

4. Adequate light fixtures and lamps to provide a minimum of 100-foot candles at

5. One telephone on a private line, and one dedicated data line for use by all computers in the space.

6. Adequate heating and cooling facilities and sufficient ventilation to maintain a

7. A designated toilet facility

8. One bottled water dispenser

E. The general contractor shall pay the cost of all utilities, including local telephone services and custodial services, as required for the maintenance of the temporary field offices until completion of the project.

F. The security office and the field use office toilet facilities are to be maintained, serviced, and cleaned by the contractor.

G. The general contractor shall also move the temporary field offices as needed for the phasing of the project.

2.3 EQUIPMENT

A. Fire Extinguishers: Portable, UL rated; with class and extinguishing agent as required by locations and classes of fire exposures.

B. HVAC Equipment: Unless Owner authorizes use of permanent HVAC system, provide vented, self-contained, liquid-propane-gas or fuel-oil heaters with individual space thermostatic control. Refer to specification section 019113 “General Commissioning Requirement’s” for additional requirements.

1. Use of gasoline-burning space heaters, open-flame heaters, or salamander-type heating units is prohibited.

2. Heating Units: Listed and labeled for type of fuel being consumed, by a qualified testing agency acceptable to authorities having jurisdiction, and marked for intended location and application.

3. Permanent HVAC System: If Owner authorizes use of permanent HVAC system for temporary use during construction, provide filter with MERV of 8 at each return-air grille in system and remove at end of construction and clean HVAC system as required in Section 017700 "Closeout Procedures"

C. Air-Filtration Units: Primary and secondary HEPA-filter-equipped portable units with four-stage filtration. Provide single switch for emergency shutoff. Configure to run continuously.

015000 - Page 6 02/09/2018

3.1 INSTALLATION, GENERAL

A. Locate facilities where they will serve Project adequately and result in minimum interference with performance of the Work. Relocate and modify facilities as required by progress of the Work.

1. Locate facilities to limit site disturbance as specified in Section 011000 "Summary."

2. Provide architect and center operator information on where the proposed locations are to be, for review for any possible disruption to the center’s daily operation.

B. Provide each facility ready for use when needed to avoid delay. Do not remove until facilities are no longer needed or are replaced by authorized use of completed permanent facilities.

3.2 TEMPORARY UTILITY INSTALLATION

A. General: Install temporary service or connect to existing service.

1. Arrange with utility company and Center for time when service can be interrupted, if necessary, to make connections for temporary services.

B. Sewers and Drainage: Provide temporary utilities to remove effluent lawfully.

1. Connect temporary sewers to municipal system as directed by authorities having jurisdiction.

C. Water Service: Connect to Owner's existing water service facilities. Clean and maintain water service facilities in a condition acceptable to Owner. At Substantial Completion, restore these facilities to condition existing before initial use.

D. Sanitary Facilities: Provide temporary toilets, wash facilities, and drinking water for use of construction personnel. Comply with requirements of authorities having jurisdiction for type, number, location, operation, and maintenance of fixtures and facilities.

E. Heating: Provide temporary heating required by construction activities for curing or drying of completed installations or for protecting installed construction from adverse effects of low temperatures or high humidity. Select equipment that will not have a harmful effect on completed installations or elements being installed.

F. Isolation of Work Areas in Occupied Facilities: Prevent dust, fumes, and odors from entering occupied areas.

1. Prior to commencing work, isolate the HVAC system in area where work is to be performed according to coordination drawings.

015000 - Page 7 02/09/2018

a. Disconnect supply and return ductwork in work area from HVAC systems servicing occupied areas.

b. Maintain negative air pressure within work area using HEPA-equipped air-filtration units, starting with commencement of temporary partition construction, and continuing until removal of temporary partitions is complete.

2. Maintain dust partitions during the Work. Use vacuum collection attachments on dust-producing equipment. Isolate limited work within occupied areas using portable dust-containment devices.

3. Perform daily construction cleanup and final cleanup using approved, HEPA-filter-equipped vacuum equipment.

G. Ventilation and Humidity Control: Provide temporary ventilation required by construction activities for curing or drying of completed installations or for protecting installed construction from adverse effects of high humidity. Select equipment that will not have a harmful effect on completed installations or elements being installed.

Coordinate ventilation requirements to produce ambient condition required and minimize energy consumption.

1. Provide dehumidification systems when required to reduce substrate moisture levels to level required to allow installation or application of finishes.

H. Electric Power Service: Connect to Owner's existing electric power service. Maintain equipment in a condition acceptable to Owner.

I. Electric Power Service: Provide electric power service and distribution system of sufficient size, capacity, and power characteristics required for construction operations.

1. Install electric power service underground unless otherwise indicated.

2. General contractor to pay for the cost of the installation and use of the electrical power service.

J. Lighting: Provide temporary lighting with local switching that provides adequate illumination for construction operations, observations, inspections, and traffic conditions.

1. Install and operate temporary lighting that fulfills security and protection requirements without operating entire system.

2. Install lighting for Project identification sign.

K. Telephone Service: Provide temporary telephone service in common-use facilities for use by all construction personnel. Install one telephone line(s) for each field office.

1. Provide additional telephone lines for the following:

a. Provide a dedicated telephone line for each facsimile machine in each field office.

b. Provide one telephone line(s) for Owner's use.

2. At each telephone, post a list of important telephone numbers.

015000 - Page 8 02/09/2018

a. Police and fire departments.

b. Ambulance service.

c. Contractor's emergency after-hours telephone number.

d. Architect's office.

e. Owner's office and field representative

f. Principal subcontractors' field and home offices.

g. Center Operators Designated Representative

3. Provide superintendent with cellular telephone or portable two-way radio for use when away from field office.

L. Electronic Communication Service: Provide a desktop computer in the Owner Field Representative / Architect - Use Field Office adequate for use by Architect and Owner to access Project electronic documents and maintain electronic communications. Equip computer with not less than the following:

1. Processor: Intel Pentium D or Intel CoreDuo, 3.0 GHz processing speed.

2. Memory: 8 gigabyte.

3. Disk Storage: 500 gigabyte hard-disk drive and combination DVD-RW/CD-RW drive.

4. Display: 22-inch LCD monitor with 256-Mb dedicated video RAM.

5. Full-size keyboard and mouse.

6. Network Connectivity: 02/110 BaseT Ethernet.

7. Operating System: Microsoft Windows 7 Professional or newer operating system

8. Productivity Software:

a. Microsoft Office Professional, XP or higher, including Word, Excel, and Outlook.

b. Adobe Reader 7.0 or higher.

c. WinZip 7.0 or higher.

9. Printer: "All-in-one" unit equipped with printer server, combining color printing, photocopying, scanning, and faxing, or separate units for each of these three functions.

10. Internet Service: Broadband modem, router and ISP, equipped with hardware firewall, providing minimum 25 Mbps upload and 50 Mbps download speeds at each computer.

11. Internet Security: Integrated software, providing software firewall, virus, spyware, phishing, and spam protection in a combined application.

12. Backup: External hard drive, minimum 1 Terabyte, with automated backup software providing daily backups.

3.3 SUPPORT FACILITIES INSTALLATION

A. General: Comply with the following:

1. Provide construction for temporary offices, shops, and sheds located within construction area or within 30 feet of building lines that is noncombustible according to ASTM E 136. Comply with NFPA 241.

015000 - Page 9 02/09/2018

2. Maintain support facilities until Architect Schedules Substantial Completion inspection. Remove before Substantial Completion. Personnel remaining after Substantial Completion will be permitted to use permanent facilities, under conditions acceptable to Owner.

B. Temporary Roads and Paved Areas: Construct and maintain temporary roads and paved areas adequate for construction operations. Locate temporary roads and paved areas within construction limits indicated on Drawings.

1. Provide dust-control treatment that is nonpolluting and nontracking. Reapply treatment as required to minimize dust.

C. Temporary Use of Permanent Roads and Paved Areas: Locate temporary roads and paved areas in same location as permanent roads and paved areas. Construct and maintain temporary roads and paved areas adequate for construction operations.

Extend temporary roads and paved areas, within construction limits indicated, as necessary for construction operations.

1. Coordinate elevations of temporary roads and paved areas with permanent roads and paved areas.

2. Prepare subgrade and install subbase and base for temporary roads and paved areas according to Section 312000 "Earthwork"

3. Delay installation of final course of permanent hot-mix asphalt pavement until immediately before Substantial Completion. Repair hot-mix asphalt base-course pavement before installation of final course according to Section 321200 "Plant Mix Bituminous Pavment"

D. Parking: Provide temporary parking areas for construction personnel.

1. All parking for construction personnel must be off site or within the construction limits as defined in the construction phasing documents.

E. Dewatering Facilities and Drains: Comply with requirements of authorities having jurisdiction. Maintain Project site, excavations, and construction free of water.

1. Dispose of rainwater in a lawful manner that will not result in flooding Project or adjoining properties or endanger permanent Work or temporary facilities.

2. Remove snow and ice as required to minimize accumulations.

F. Project Signs: Provide Project signs as indicated. Unauthorized signs are not permitted.

1. Identification Signs: Provide Project identification signs as allowed by governing bodies.

a. Project sign shall be made of a printed graphic made for exterior exposure constructed of 3/4" thick exterior grade plywood. The Job Sign is to be provided, installed, and maintained by the general contractor, an approximate minimum size of 48" by 96" but must fit all the following information. The size of text for the information provide below shall follow the hierarchy as listed.

015000 - Page 10 02/09/2018

1) Project Name & Address

2) Owner Name, Address & Logo

3) Regional Office of Job Corps Name, Address & Logo

4) Center Operator Name, Address & Logo

5) Architects Name, Address, & Logo

6) Each A/E Consultant Name and Logo

7) General Contractors Name, Address, & Logo

8) Sub Contractors Name, Address & Logo as desired by General

Contractor

9) Rendered Image of final project provided by Architect. (Image size to fill 1/4 of sign area)

2. Temporary Signs: Provide other signs as indicated and as required to inform public and individuals seeking entrance to Project.

a. Provide temporary, directional signs for construction personnel and visitors.

1) This includes signage to distinguish were construction traffic and center operations traffic shall go and enter the campus.

2) The signage shall also distinguish where all construction deliveries, construction office, and construction site visitors, etc. shall go before entering the construction areas.

3) On campus pedestrian signage shall also be provide to indicate the areas of construction that only construction personnel are authorized to be present.

3. Maintain and touchup signs so they are legible at all times.

G. Waste Disposal Facilities: Comply with requirements specified in Section 017419 "Construction Waste Management and Disposal."

H. Lifts and Hoists: Provide facilities necessary for hoisting materials and personnel.

1. Truck cranes and similar devices used for hoisting materials are considered "tools and equipment" and not temporary facilities.

2. Use of cranes on site shall be coordinated with center operator to provide minimal disruption to center operations and provide safety to students and staff.

I. Temporary Stairs: Until permanent stairs are available, provide temporary stairs where ladders are not adequate.

3.4 SECURITY AND PROTECTION FACILITIES INSTALLATION

A. Protection of Existing Facilities: Protect existing vegetation, equipment, structures, utilities, and other improvements at Project site and on adjacent properties, except those indicated to be removed or altered. Repair damage to existing facilities.

B. Environmental Protection: Provide protection, operate temporary facilities, and conduct construction as required to comply with environmental regulations and that minimize

015000 - Page 11 02/09/2018 possible air, waterway, and subsoil contamination or pollution or other undesirable effects.

1. Comply with work restrictions specified in Section 011000 "Summary."

C. Temporary Erosion and Sedimentation Control: Comply with requirements of 2003 EPA Construction General Permit or authorities having jurisdiction, whichever is more stringent and requirements specified in Section 311000 "Site Clearing" & 312500 “Erosion Control”

D. Stormwater Control: Comply with requirements of authorities having jurisdiction.

Provide barriers in and around excavations and subgrade construction to prevent flooding by runoff of stormwater from heavy rains.

E. Tree and Plant Protection: Comply with requirements specified in Section 310510 "Site Preparation."

F. Pest Control: Engage pest-control service to recommend practices to minimize attraction and harboring of rodents, roaches, and other pests and to perform extermination and control procedures at regular intervals so Project will be free of pests and their residues at Substantial Completion. Perform control operations lawfully, using environmentally safe materials.

G. Site Enclosure Fence: Before construction operations begin, furnish and install site enclosure fence in a manner that will prevent people and animals from easily entering site except by entrance gates.

1. Extent of Fence: As required to enclose entire Project site or portion determined sufficient to accommodate construction operations, and as indicated on the construction phasing plans.

2. Maintain security by limiting number of keys and restricting distribution to authorized personnel. Furnish one set of keys to Owner.

H. Security Enclosure and Lockup: Install temporary enclosure around partially completed areas of construction. Provide lockable entrances to prevent unauthorized entrance, vandalism, theft, and similar violations of security. Lock entrances at end of each work day.

1. Provide an appropriate security system and facilities to protect WORK from unauthorized entry, vandalism, and theft.

2. Employ such services or measures as needed to properly protect and safe guard WORK. Provide protection for materials, tools, and equipment employed on project, including workmen's tools. At no time during this construction duration, up to and including the acceptance of the substantial completion walk through, will the department of Labor entertain request for additional security measures.

3. Owner shall not be held to have incurred any liability for loss of, and damage to, materials, tools, and equipment of contractor by contract or otherwise. Owner shall not in any way be liable or responsible for damage or loss to work due to trespass or theft.

015000 - Page 12 02/09/2018

4. The contractor shall in no way assume or ask the existing center operator security staff to provide security to the areas of construction. Security of the areas under construction is the full responsibility of the contractor.

I. Barricades, Warning Signs, and Lights: Comply with requirements of authorities having jurisdiction for erecting structurally adequate barricades, including warning signs and lighting.

J. Temporary Enclosures: Provide temporary enclosures for protection of construction, in progress and completed, from exposure, foul weather, other construction operations, and similar activities. Provide temporary weathertight enclosure for building exterior.

1. Where heating or cooling is needed and permanent enclosure is incomplete, insulate temporary enclosures.

2. Construct vestibule and airlock at each entrance through temporary partition with not less then 48 inches between doors. Maintain water-dampened foot mats in vestibule.

K. Temporary Partitions: Provide floor-to-ceiling dustproof partitions to limit dust and dirt migration and to separate areas occupied by Owner and tenants from fumes and noise.

1. Construct dustproof partitions with gypsum wallboard with joints taped on occupied side, and fire-retardant-treated plywood on construction operations side.

2. Where fire-resistance-rated temporary partitions are indicated or are required by authorities having jurisdiction, construct partitions according to the rated assemblies.

3. Insulate partitions to control noise transmission to occupied areas.

4. Seal joints and perimeter. Equip partitions with gasketed dustproof doors and security locks where openings are required.

5. Protect air-handling equipment.

6. Provide walk-off mats at each entrance through temporary partition.

3.5 MOISTURE AND MOLD CONTROL

A. Contractor's Moisture-Protection Plan: Avoid trapping water in finished work. Document visible signs of mold that may appear during construction.

B. Exposed Construction Phase: Before installation of weather barriers, when materials are subject to wetting and exposure and to airborne mold spores, protect as follows:

1. Protect porous materials from water damage.

2. Protect stored and installed material from flowing or standing water.

3. Keep porous and organic materials from coming into prolonged contact with concrete.

4. Remove standing water from decks.

5. Keep deck openings covered or dammed.

015000 - Page 13 02/09/2018

C. Partially Enclosed Construction Phase: After installation of weather barriers but before full enclosure and conditioning of building, when installed materials are still subject to infiltration of moisture and ambient mold spores, protect as follows:

1. Do not load or install drywall or other porous materials or components, or items with high organic content, into partially enclosed building.

2. Keep interior spaces reasonably clean and protected from water damage.

3. Periodically collect and remove waste containing cellulose or other organic matter.

4. Discard or replace water-damaged material.

5. Do not install material that is wet.

6. Discard, replace, or clean stored or installed material that begins to grow mold.

7. Perform work in a sequence that allows any wet materials adequate time to dry before enclosing the material in drywall or other interior finishes.

D. Controlled Construction Phase of Construction: After completing and sealing of the building enclosure but prior to the full operation of permanent HVAC systems, maintain as follows:

1. Control moisture and humidity inside building by maintaining effective dry-in conditions.

2. Use permanent HVAC system to control humidity. As permitted by the owner and commissioning specifications.

3. Comply with manufacturer's written instructions for temperature, relative humidity, and exposure to water limits.

a. Hygroscopic materials that may support mold growth, including wood and gypsum-based products, that become wet during the course of construction and remain wet for 48 hours are considered defective.

b. Measure moisture content of materials that have been exposed to moisture during construction operations or after installation. Record readings beginning at time of exposure and continuing daily for 96 hours. Identify materials containing moisture levels higher than allowed. Report findings in writing to Architect.

c. Remove materials that cannot be completely restored to their manufactured moisture level within 48 hours.

3.6 OPERATION, TERMINATION, AND REMOVAL

A. Supervision: Enforce strict discipline in use of temporary facilities. To minimize waste and abuse, limit availability of temporary facilities to essential and intended uses.

B. Maintenance: Maintain facilities in good operating condition until removal.

1. Maintain operation of temporary enclosures, heating, cooling, humidity control, ventilation, and similar facilities on a 24-hour basis where required to achieve indicated results and to avoid possibility of damage.

C. Operate Project-identification-sign lighting daily from dusk until dawn.

015000 - Page 14 02/09/2018

D. Temporary Facility Changeover: Do not change over from using temporary security and protection facilities to permanent facilities until Substantial Completion.

E. Termination and Removal: Remove each temporary facility when need for its service has ended, when it has been replaced by authorized use of a permanent facility, or no later than Substantial Completion. Complete or, if necessary, restore permanent construction that may have been delayed because of interference with temporary facility. Repair damaged Work, clean exposed surfaces, and replace construction that cannot be satisfactorily repaired.

1. Materials and facilities that constitute temporary facilities are property of Contractor. Owner reserves right to take possession of Project identification signs.

2. Remove temporary roads and paved areas not intended for or acceptable for integration into permanent construction. Where area is intended for landscape development, remove soil and aggregate fill that do not comply with requirements for fill or subsoil. Remove materials contaminated with road oil, asphalt and other petrochemical compounds, and other substances that might impair growth of plant materials or lawns. Replace street paving, curbs, and sidewalks at temporary entrances, as required by authorities having jurisdiction or that have been damaged during the course of construction activities.

3. At Substantial Completion, repair, renovate, and clean permanent facilities used during construction period. Comply with final cleaning requirements specified in Section 017700 "Closeout Procedures."

END OF SECTION 015000

017419 - Page 1 02/09/2018

SECTION 017419 - CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

Supplementary Conditions and other Division 01 Specification Sections, apply to this

A. Section includes administrative and procedural requirements for the following:

1. Salvaging nonhazardous demolition and construction waste.

2. Recycling nonhazardous demolition and construction waste.

3. Disposing of nonhazardous demolition and construction waste.

1. Section 024116 "Structure Demolition" for disposition of waste resulting from demolition of buildings, structures, and site improvements.

2. Section 024119 "Selective Demolition" for disposition of waste resulting from partial demolition of buildings, structures, and site improvements.

3. Section 042200 "Concrete Unit Masonry" for disposal requirements for masonry waste.

4. Section 311000 "Site Clearing" for disposition of waste resulting from site clearing and removal of above- and below-grade improvements.

5. Section 028213 "Asbestos Abatement" & 028416 “Removal and Disposal of Universal Waste and Florescent Lamps” for removal and disposal of hazardous materials.

A. Construction Waste: Building and site improvement materials and other solid waste resulting from construction, remodeling, renovation, or repair operations. Construction waste includes packaging.

B. Demolition Waste: Building and site improvement materials resulting from demolition or selective demolition operations.

C. Disposal: Removal off-site of demolition and construction waste and subsequent sale, recycling, reuse, or deposit in landfill or incinerator acceptable to authorities having jurisdiction.

017419 - Page 2 02/09/2018

D. Recycle: Recovery of demolition or construction waste for subsequent processing in preparation for reuse.

E. Salvage: Recovery of demolition or construction waste and subsequent sale or reuse in another facility.

F. Salvage and Reuse: Recovery of demolition or construction waste and subsequent incorporation into the Work.

1.4 PERFORMANCE REQUIREMENTS

A. General: Achieve end-of-Project rates for salvage/recycling of 75 percent by weight of total non-hazardous solid waste generated by the Work. Practice efficient waste management in the use of materials in the course of the Work. Use all reasonable means to divert construction and demolition waste from landfills and incinerators.

Facilitate recycling and salvage of materials, including the following:

1. Demolition Waste:

a. Asphalt paving.

b. Concrete.

c. Concrete reinforcing steel.

d. Brick.

e. Concrete masonry units.

f. Wood studs.

g. Wood joists.

h. Plywood and oriented strand board.

i. Wood trim.

j. Structural and miscellaneous steel.

k. Roofing.

l. Doors and frames.

m. Door hardware.

n. Metal studs.

o. Gypsum board.

p. Acoustical tile and panels.

q. Carpet.

r. Carpet pad.

s. Equipment.

t. Cabinets.

u. Plumbing fixtures.

v. Piping.

w. Supports and hangers.

x. Valves.

y. Sprinklers.

z. Mechanical equipment.

aa. Refrigerants.

bb. Electrical conduit.

cc. Copper wiring.

dd. Lighting fixtures.

ee. Lamps.

017419 - Page 3 02/09/2018

ff. Ballasts.

gg. Electrical devices.

hh. Switchgear and panelboards.

ii. Transformers.

jj. Kitchen Equipment

kk. Or any other material that is recyclable.

2. Construction Waste:

a. Masonry and CMU.

b. Lumber.

c. Wood sheet materials.

d. Wood trim.

e. Metals.

f. Roofing.

g. Insulation.

h. Carpet and pad.

i. Gypsum board.

j. Piping.

k. Electrical conduit.

l. Packaging: Regardless of salvage/recycle goal indicated in "General"

Paragraph above, salvage or recycle 100 percent of the following uncontaminated packaging materials:

1) Paper.

2) Cardboard.

3) Boxes.

4) Plastic sheet and film.

5) Polystyrene packaging.

6) Wood crates.

7) Plastic pails.

m. Or any other material that is recyclable.

1.5 ACTION SUBMITTALS

A. Waste Management Plan: Submit plan within 30 days of date established for the Notice to Proceed.

1.6 INFORMATIONAL SUBMITTALS

A. Waste Reduction Progress Reports: Concurrent with each Application for Payment, submit report. Use Form CWM-7 for construction waste and Form CWM-8 for demolition waste. Include the following information:

1. Material category.

2. Generation point of waste.

3. Total quantity of waste in tons.

4. Quantity of waste salvaged, both estimated and actual in tons.

5. Quantity of waste recycled, both estimated and actual in tons.

6. Total quantity of waste recovered (salvaged plus recycled) in tons.

017419 - Page 4 02/09/2018

7. Total quantity of waste recovered (salvaged plus recycled) as a percentage of total waste.

B. Waste Reduction Calculations: Before request for Substantial Completion, submit calculated end-of-Project rates for salvage, recycling, and disposal as a percentage of total waste generated by the Work.

C. Records of Donations: Indicate receipt and acceptance of salvageable waste donated to individuals and organizations. Indicate whether organization is tax exempt.

D. Recycling and Processing Facility Records: Indicate receipt and acceptance of recyclable waste by recycling and processing facilities licensed to accept them. Include manifests, weight tickets, receipts, and invoices.

E. Statement of Refrigerant Recovery: Signed by refrigerant recovery technician responsible for recovering refrigerant, stating that all refrigerant that was present was recovered and that recovery was performed according to EPA regulations. Include name and address of technician and date refrigerant was recovered.

1.7 QUALITY ASSURANCE

A. Refrigerant Recovery Technician Qualifications: Certified by EPA-approved certification program.

B. Regulatory Requirements: Comply with hauling and disposal regulations of authorities

B.C. All materials are to be tested by the contractor to meet the EPA approved landfill and recycling MFG plants requirements.

C.D. Waste Management Conference: Conduct conference at Project site to comply with requirements in Section 013100 "Project Management and Coordination."…