15M10319QA4100012.pdf

15M10319QA4100012 Page 1 of 18

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24 & 30

1. REQUISITION NUMBER

5. SOLICITATION NUMBER

15M10319QA4100012

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 6. SOLICITATION ISSUE

DATE

08/23/2019

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

Kate Oravitz Weeks kathryn.oravitz-weeks@usdoj.gov

b. TELEPHONE NUMBER (No collect calls) 8. OFFER DUE DATE / LOCAL

TIME

08/28/2019 10:00:00

CODE 15M103

OFFICE OF PROCUREMENT

FSD-OOP, CG-3, 4th FL - Infrastructure United States Marshals Service

WASHINGTON, DC 20530-0001

9. ISSUED BY X UNRESTRICTED OR SET ASIDE: % FOR

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

8(A)

NAICS: 561920

SIZE STANDARD: $11,000,000

10. THE ACQUISITION IS

SEE

SCHEDULE

11. DELIVERY FOR FOB DESTINATION

UNLESS BLOCK IS MARKED

NET 30

12. DISCOUNT TERMS

13a. THIS CONTRACT IS A

RATED ORDER UNDER DPAS

(15 CFR 700)

13b. RATING

X RFQ IFB RFP

14. METHOD OF SOLICITATION

15MA20CODE15. DELIVER TO

OFFICE OF THE DIRECTOR

Executive Services, CG-3, 16th FL, DIR United States Marshals Service Landover Operations Center 3601 Pennsy Drive Landover, MD 20785

Mary Clark mary.clark@usdoj.gov

CODE 15M10316. ADMINISTERED BY

OFFICE OF PROCUREMENT

FSD-OOP, CG-3, 4th FL - Infrastructure United States Marshals Service

WASHINGTON, DC 20530-0001

Kate Oravitz Weeks kathryn.oravitz-weeks@usdoj.gov

FACILITY

CODE

CODE

TELEPHONE NO.

17a. CONTRACTOR/

OFFEROR

15MA20CODE18a. PAYMENT WILL BE MADE BY

OFFICE OF THE ASSOCAITE DIRECTOR FOR ADMINSTRATION

Executive Services, CG-3, 16th FL, ADA United States Marshals Service Landover Operations Center 3601 Pennsy Drive Landover, MD 20785

Jonas Cherry jonathan.cherry@usdoj.gov

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER SEE ADDENDUM

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW IS

CHECKED

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

San Antonio - 2020 Leadership Conference DUNS:

CAGE: **Subject to the availability of funds**

Return quote to:

Khristine Jackson: Khristine.Jackson@usdoj.gov cc quotes to Kate Oravitz Weeks: kathryn.oravitz-weeks@usdoj.gov cc quotes to James Akhnana:

james.akhnana@usdoj.gov

See Continuation Sheet(s) (Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

X 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA ARE X ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN ____ COPIES TO

ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SET FORTH

OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL SHEETS SUBJECT TO THE

TERMS AND CONDITIONS SPECIFIED.

29. AWARD OF CONTRACT: REF. _____________________________ OFFER

DATED _________________ . YOUR OFFER ON SOLICITATION (BLOCK 5)

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH HEREIN,

IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30b. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 30c. DATE SIGNED 31b. NAME OF THE CONTRACTING OFFICER (TYPE OR PRINT)

Kathryn Oravitz-Weeks

31c. DATE SIGNED

07/19/2019

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

15M10319QA4100012 Page 2 of 18

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: _________________________________

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

PARTIAL FINAL

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

COMPLETE PARTIAL FINAL

36. PAYMENT 37. CHECK NUMBER

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT 42a. RECEIVED BY (Print)

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

15M10319QA4100012 Page 3 of 18

Table of Contents

Section Description Page Number

1 Solicitation/Contract Form 2 Commodity or Services Schedule 3 Contract Clauses

Performance Work Statement 2018 National Management Conference USMS-0012 Contracting Officer's Representative (COR) 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders-- Commercial Items (Jul 2018) 52.243-7 Notification of Changes (Jan 2017) 52.246-20 Warranty of Services (May 2001) 52.246-25 Limitation of Liability - Services (Feb 1997)

USMS-0010 CONTRACT/ORDER CLOSEOUT – FIXED-PRICE, TIME-AND-MATERIALS, OR

LABOR HOURS

USMS-0001 Release of Residual Funds ($100 or Less)

4 List of Attachments 5 Solicitation Provisions

52.233-2 Service of Protest (Sept 2006) Low Price Technically Acceptable (LPTA)

15M10319QA4100012 Page 4 of 18

Section 2 - Commodity or Services Schedule

SCHEDULE OF SUPPLIES/SERVICES

CONTINUATION SHEET

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 5.000000 EA $____________ $___________________

0002 1.000000 EA $____________ $___________________

Meeting Room

Base Period

Hotel Room Price to include a Registration/hotel booking code for all attendees.

All rooms shall be individually booked by the traveler using a government-issued travel card or a centrally-billed travel card. All rooms are tax free.

Base Period

15M10319QA4100012 Page 5 of 18

Section 3 - Contract Clauses

A.1 ADDENDUM TO FAR 52.212-4, Contract Terms and Conditions--Commercial Items (Jan 2017)

The terms and conditions for the following clauses are hereby incorporated into this solicitation and resulting contract as an addendum to FAR clause 52.212-4.

Clauses By Reference

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov

Clause Title Fill-ins (if applicable)

52.242-15 Stop-Work Order (Aug 1989)

52.202-1 Definitions (Nov 2013)

52.203-5 Covenant Against Contingent Fees (May 2014)

52.203-7 Anti-Kickback Procedures (May 2014)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To

Inform Employees of Whistleblower Rights (Apr 2014)

52.212-4 Contract Terms and Conditions--Commercial Items (Jan 2017)

52.223-6 Drug Free Workplace (May 2001)

52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013)

52.233-3 Protest after Award (Aug 1996)

52.233-4 Applicable Law for Breach of Contract Claim (Oct 2004)

52.242-1 Notice of Intent to Disallow Costs (Apr 1984)

52.244-6 Subcontracts for Commercial Items (Jul 2018)

52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short

Form) (Apr 1984)

Clauses By Full Text

Performance Work Statement 2018 National Management Conference

15M10319QA4100012 Page 6 of 18

[1] The USMS is part of the streamlined Sales and Use Tax Agreement and the Certificate of Exemption is attached.

USMS-0012 Contracting Officer's Representative (COR)

CONTRACTING OFFICER'S REPRESENTATIVE (COR) (AUG 2017)

(a) Mary Clark is hereby designated as the Contracting Officer's Representative (COR). The COR may be changed at any time by the Government without prior notice to the contractor by a unilateral modification to the contract. The COR is located at:

Phone Number:703-740-1663 E-mail:mary.clark@usdoj.gov

(b) The responsibilities and limitations of the COR are as follows:

(1) The COR is responsible for the technical aspects of the contract and serves as technical liaison with the contractor. The COR is also responsible for the final inspection and acceptance of all deliverables and such other responsibilities as may be specified in the contract.

(2) The COR is not authorized to make any commitments or otherwise obligate the Government or authorize any changes which affect the contract price, terms or conditions. Any contractor request for changes shall be referred to the Contracting Officer directly or through the COR. No such changes shall be made without the express written prior authorization of the Contracting Officer. The Contracting Officer may designate assistant or alternate COR(s) to act for the COR by naming such assistant/alternate(s) in writing and transmitting a copy of such designation to the contractor.

(End of clause)

52.243-7 Notification of Changes (Jan 2017)

(a) Definitions."Contracting Officer," as used in this clause, does not include any representative of the Contracting Officer.

15M10319QA4100012 Page 7 of 18

"Specifically Authorized Representative (SAR)," as used in this clause, means any person the Contracting Officer has so designated by written notice (a copy of which shall be provided to the Contractor) which shall refer to this paragraph and shall be issued to the designated representative before the SAR exercises such authority.

(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change to this contract. Except for changes identified as such in writing and signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing promptly, within See PWS for timeline (to be negotiated) calendar days from the date that the Contractor identifies any Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice shall state--

(1) The date, nature, and circumstances of the conduct regarded as a change;

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

(3) The identification of any documents and the substance of any oral communication involved in such conduct;

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose;

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including--

(i) What line items have been or may be affected by the alleged change;

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change;

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may be caused by the alleged change;

(iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged change are estimated; and

(6) The Contractor's estimate of the time by which the Government must respond to the Contractor's notice to minimize cost, delay or disruption of performance.

(c) Continued performance. Following submission of the notice required by paragraph (b) of this clause, the Contractor shall diligently continue performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, however, that if the Contractor regards the direction or communication as a change as described in paragraph (b) of this clause, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing promptly and copies furnished to the Contractor and to the Contracting Officer. The Contracting Officer shall promptly countermand any action which exceeds the authority of the SAR.

(d) Government response. The Contracting Officer shall promptly, within five (to be negotiated) calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either--

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

(2) Countermand any communication regarded as a change;

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

(4) In the event the Contractor's notice information is inadequate to make a decision under paragraphs (d)(1), (2), or (3) of this clause, advise the Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond.

(e) Equitable adjustments.

15M10319QA4100012 Page 8 of 18

(1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made--

(i) In the contract price or delivery schedule or both; and

(ii) In such other provisions of the contract as may be affected.

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in paragraphs (b) and (c) of this clause.

Note: The phrases "contract price" and "cost" wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof.

(End of clause)

52.246-20 Warranty of Services (May 2001)

(a) Definition. "Acceptance," as used in this clause, means the act of an authorized representative of the Government by which the Government assumes for itself, or as an agent of another, ownership of existing and identified supplies, or approves specific services, as partial or complete performance of the contract.

(b) Notwithstanding inspection and acceptance by the Government or any provision concerning the conclusiveness thereof, the Contractor warrants that all services performed under this contract will, at the time of acceptance, be free from defects in workmanship and conform to the requirements of this contract. The Contracting Officer shall give written notice of any defect or nonconformance to the Contractor as outlined in the PWS

This notice shall state either--

(1) That the Contractor shall correct or reperform any defective or nonconforming services; or

(2) That the Government does not require correction or reperformance.

(c) If the Contractor is required to correct or reperform, it shall be at no cost to the Government, and any services corrected or reperformed by the Contractor shall be subject to this clause to the same extent as work initially performed. If the Contractor fails or refuses to correct or reperform, the Contracting Officer may, by contract or otherwise, correct or replace with similar services and charge to the Contractor the cost occasioned to the Government thereby, or make an equitable adjustment in the contract price.

(d) If the Government does not require correction or reperformance, the Contracting Officer shall make an equitable adjustment in the contract price.

(End of clause)

52.246-25 Limitation of Liability - Services (Feb 1997)

(a) Except as provided in paragraphs (b) and (c) of this clause, and except to the extent that the Contractor is expressly responsible under this contract for deficiencies in the services required to be performed under it (including any materials furnished in conjunction with those services), the Contractor shall not be liable for loss of or damage to property of the Government that-

(1) Occurs after Government acceptance of services performed under this contract; and

15M10319QA4100012 Page 9 of 18

(2) Results from any defects or deficiencies in the services performed or materials furnished.

(b) The limitation of liability under paragraph (a) of this clause shall not apply when a defect or deficiency in, or the Government's acceptance of, services performed or materials furnished results from willful misconduct or lack of good faith on the part of any of the Contractor's managerial personnel. The term "Contractor's managerial personnel," as used in this clause, means the Contractor's directors, officers, and any of the Contractor's managers, superintendents, or equivalent representatives who have supervision or direction of-

(1) All or substantially all of the Contractor's business;

(2) All or substantially all of the Contractor's operations at any one plant, laboratory, or separate location at which the contract is being performed; or

(3) A separate and complete major industrial operation connected with the performance of this contract.

(c) If the Contractor carries insurance, or has established a reserve for self-insurance, covering liability for loss or damage suffered by the Government through the Contractor's performance of services or furnishing of materials under this contract, the Contractor shall be liable to the Government, to the extent of such insurance or reserve, for loss of or damage to property of the Government occurring after Government acceptance of, and resulting from any defects and deficiencies in, services performed or materials furnished under this contract.

(End of clause)

USMS-0010 CONTRACT/ORDER CLOSEOUT – FIXED-PRICE, TIME-AND-MATERIALS, OR LABOR HOURS

Timely contract closeout is a priority under this contract/order. The Contractor shall submit a final invoice within thirty (30) calendar days after the expiration of this contract/order, unless the Contractor requests and is granted an extension by the Contracting Officer, in writing. In addition, and concurrent with the submission of the final invoice, the Contractor shall notify the Contracting Officer of the amount of excess funds that can be deobligated from this contract/order so the closeout process can begin as soon as possible upon expiration of this contract/order. A bilateral contract/order closeout modification will be forwarded to the Contractor by the Contracting Officer and must be signed by the Contractor and returned to the Contracting Officer within thirty (30) calendar days of issuance of the modification. A Contractor’s failure to respond and/or sign the bilateral closeout modification within thirty (30) calendar days of receipt will constitute approval of the terms of the modification and the modification will subsequently be processed unilaterally by the Contracting Officer to deobligate excess funds and close this contract/order.

If this contract/order contains option periods, the Contractor is required to submit an invoice within sixty (60) calendar days after expiration of the base period of performance and the expiration of each exercised option period of performance to allow for deobligation of excess funds that were obligated in those respective periods of performance.

USMS-0001 Release of Residual Funds ($100 or Less)

The contractor is advised when submitting the final invoice under this contract to submit an information copy of the invoice to the Contracting Officer. The invoice must be marked “Information Copy – Final Invoice.” If residual funds on the contract total $100 or less, the government will automatically deobligate the residual funds without further communication with the vendor. Upon receipt and payment of the final invoice, it is understood and agreed that all outstanding obligations incurred on the above referenced contract have been satisfied. Therefore, it is further understood and agreed that the government shall not be liable for the payment of any future invoices that may be submitted under the above referenced contract. (Applies to all contracts) (End of Clause)

[END OF ADDENDUM TO FAR 52.212-4]

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders-- Commercial Items (Jul 2018)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

15M10319QA4100012 Page 10 of 18

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(4) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(5) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C.

6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3.

__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (Jan 2011) of 52.219-4.

__ (13) [Reserved]

__ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644).

__ (ii) Alternate I (Nov 2011).

__ (iii) Alternate II (Nov 2011).

15M10319QA4100012 Page 11 of 18

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

__ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Nov 2016) of 52.219-9.

__ (v) Alternate IV (Nov 2016) of 52.219-9.

__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

__ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages--Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f).

__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

__ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

__ (26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Jan 2018) (E.O. 13126).

__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

__ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

__ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).

__ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

__ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

__ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

X (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c) (3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

15M10319QA4100012 Page 12 of 18

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O.

13693).

__ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

__ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

__ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513).

__ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

__ (44) 52.223-21, Foams (Jun 2016) (E.O. 13693).

__ (45)(i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

__ (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

__ (47)(i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (48) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

__ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

__ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

__ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

15M10319QA4100012 Page 13 of 18

__ (55) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (56) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017)(15 U.S.C. 637(d)(12)).

__ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495).

__ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

__ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-- Requirements (May 2014) (41 U.S.C. chapter 67).

__ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

__ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

__ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

__ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating

15M10319QA4100012 Page 14 of 18 to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause--

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(iv) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(v) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph

(l) of FAR clause 52.222-17.

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)

(vii) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(viii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(x) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212)

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

(xiii) __(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627).

__(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

(xvi) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989).

(xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

(xix)(A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

15M10319QA4100012 Page 15 of 18

(B) Alternate I (Jan 2017) of 52.224-3.

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C.

2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

15M10319QA4100012 Page 16 of 18

Section 4 - List of Attachments

This Section Is Intentionally Left Blank

15M10319QA4100012 Page 17 of 18

Section 5 - Solicitation Provisions

A.2 ADDENDUM TO FAR 52.212-1, Instructions to Offerors--Commercial Items (Jan 2017)

The terms and conditions for the following provisions are hereby incorporated into this solicitation as an addendum to FAR provision 52.212-1.

Provisions By Reference

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer.

In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): www.acquisition.gov

Provision Title Fill-ins (if applicable)

52.204-19 Incorporation by Reference of Representations and Certifications (Dec

2014)

52.212-3 Offeror Representations and Certifications--Commercial Items (Nov

2017)

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran--Representation and Certifications

(Oct 2015)

USMS-0006 Federal Workplace Responses to Domestic Violence, Sexual Assault, and Stalking - Provision (2014)

52.212-1 Instructions to Offerors--Commercial Items (Jan 2017)

52.212-2 Evaluation - Commercial Items (Oct 2014)

Provisions By Full Text

52.233-2 Service of Protest (Sept 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from kathryn.oravitz-weeks@usdoj.gov.

15M10319QA4100012 Page 18 of 18

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

Low Price Technically Acceptable (LPTA)

Quotes shall be submitted in three(2) separate volumes as follows:

Format:

Volume 1 – Technical Capability of the Conference Center Volume 1 shall not exceed five (5)pages. Pages shall be single sided, 8-1/2” x 11”, no foldouts, no embedded documents, 12 point font or larger, single spaced with a minimum of 1” blank margins all around. Provide DUNS Number, Tax ID Number, GSA Schedule and Cage Code.

Volume 2- Proposed dates in accordance with the PWS in San Antonio, TX Volume 2 shall not exceed two (2)pages. Pages shall be single sided, 8-1/2” x 11”, no foldouts, no embedded documents, 12 point font or larger, single spaced with a minimum of 1” blank margins all around. Provide DUNS Number, Tax ID Number, GSA Schedule and Cage Code.

Volume 3 – Pricing with signed SF 1449 Volume 3 shall not exceed two (2)pages (not including the signed SF 1449). Pages shall be single sided, 8-1/2” x 11”, no foldouts, no embedded documents, 12 point font or larger, single spaced with a minimum of 1” blank margins all around. Provide DUNS Number, Tax ID Number, GSA Schedule and Cage Code.

The firm-fixed prices are considered payment in full for all labor, profit, overhead, G&A, fringe benefits, reports, logs, postage, advertisements, printing, photographs, tools, machinery, equipment, supplies, materials, oils, fuel, lubricants, insurance, and all other costs associated with the management conference.

Government expects proposals to reflect substantial discounts.

Reps & Certs

Provide or notate successful online completion of Offeror Representations and Certifications-Commercial Items in accordance with the provision at FAR 52.212-3.

In accordance with FAR 52.204-7, all perspective contractors shall be registered in the System for Award Management (SAM) Database prior to award of a contract or agreement.

BASIS OF EVALUATION (FAR 52.212-2 Evaluation—Commercial Items)

Evaluation:

The offers will be evaluated using a Lowest Price Technically Acceptable process. This process is appropriate because selection based on Lowest Price Technically Acceptable is most often used when the requirement is clearly defined, and the risk of unsuccessful contract performance is minimal, when the proposal are all technically acceptable.

[END OF ADDENDUM TO FAR 52.212-1]