Amendment 00001.pdf

R

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. X is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning 1 copy of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not X is required to sign this document and return 1 copy to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

This Amendment 0001 is being issued to incorporate the following attachments from the pre-bid site visit held on May 27, 2021; questions and answers from the site visit, sign in sheet and meeting minutes.

No further changes.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR)

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE PAGE OF PAGES 1 1

2. AMENDMENT/MODIFICATION NUMBER

00001

3. EFFECTIVE DATE

6/03/2021

4. REQUISITION/PURCHASE REQUISITION NUMBER

RP 109-21

5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

Federal Bureau of Prisons Field Acquisition Office U.S. Armed Forces Reserve Complex 346 Marine Forces Drive

Grand Prairie, TX 75051

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) ( X) 9A. AMENDMENT OF SOLICITATION NUMBER

15B40921B00000002

9B. DATED (SEE ITEM 11)

5/17/2021

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

4D4A

USP Marion : Repair Asphalt Roads : Questions and Answers from Site Visit Held May 27, 2021 ; Solicitation No: 15B40921B00000002

Q: Can we get a cleaner copy of the pdf drawings? The plans are not legible when you zoom in.

A: Better copies or new drawings will be provided to the awardee if requested.

Q: Can we get an aerial photo of the work inside the fence?

A: No aerial photos will be provided.

Q:What are the asphalt mix specifications?

A: Illinois Department of Transportation Standards & Regulations.

Q:Does Area 2, Upper Camp Parking Lot perimeter curb require painting?

A: No.

Q: What is owner’s intent where PCC concrete exists when plans show mill and overlay of bituminous asphalt?

A: Feather the up to 3 inches of asphalt as needed to match surrounding grade.

Q: Who is responsible for removal and replacement of parking curbs?

A: USP Marion Staff

Q: Who is responsible for removal and replacement of parking lot signage?

A: Institution Staff

Q: At Area 4, the 75’ x 75’ asphalt area is located on north side of road. Are plans correct? It appears that the area sits on south side of road.

A: 75’ x 75’ is correct. Split between North and South.

Q:Plans, specifications, and existing condition quantities do not match. Does project include any asphalt additions?

A: No additions. Numbers were estimates. Actual amounts may vary and should be included with submitted bids.

PRE-BID CONFERENCE MEETING MINUTES

15B40921B00000002 – REPAIR ASPHALT ROADS

USP MARION- PROJECT 4D4A

1 | P a g e

DATE: 9:00 AM, Thursday, May 27, 2021 Place: Administration Building

CONTRACTING OFFICER (Ms. Walker):

I. INTRODUCTIONS:

Round table introduction of all attendee’s.

II. PURPOSE OF MEETING:

Indicate the purpose of this meeting is to familiarize the contractor with the unique circumstances and requirements surrounding a correctional setting. This meeting is also to explain the solicitation, as issued, and not to furnish additional information.

State - nothing said here shall be interpreted as a change to the solicitation without the issuance of a formal amendment through the FAO Contracting Officer, Christy Rios. Any questions should be e-mailed to Christy Rios at crios@bop.gov no later than May 31, 2021 1:00 P.M. CST.

III. MINUTES:

Advised minutes will be recorded and posted to beta.SAM.gov.

IV. SITE VISIT INFORMATION:

Walk to selected site for Project 4D4A- Repair Asphalt Roads immediately following the meeting.

V. FRONT COVER PAGE FORMS AND INSTRUCTIONS:

Note the Instructions to Bidders. Electronic Bids are NOT authorized. All bids shall be addressed to:

FEDERAL BUREAU OF PRISONS

U.S. ARMED FORCES RESERVE COMPLEX

ATTN: Christy Rios

346 MARINE FORCES DRIVE

GRAND PRAIRIE, TX 75051

VI. TIME FRAMES AND LOCATION FOR SUBMISSION OF BIDS:

State the deadline for submission of bids for this project is June 17, 2021 by 1:00 P.M. CST. To the above mentioned address.

USP MARION- PROJECT 4D4A

2 | P a g e

VII. GENERAL TOPICS:

The following submission/completion items will be addressed:

1. From the solicitation, each bidder SHALL complete and submit the following forms, clauses, and statements with his/her bid. Failure to do so may cause your bid to be considered as non-responsive:

STANDARD FORM 1442 Pages 1 & 2: Please include DUNS number and Tax ID# and e-mail address where indicated in block 10 and complete blocks 14-20c. If your company has a “doing business as” name reflected in you SAM registration, include this name as well in Block 14.

Ensure the address typed in block 14 matches the address in your SAM registration.

PAST PERFORMANCE SUBMISSION: Please ensure the Instructions to Bidders is reviewed and complied with its entirety. References and banking questionnaire submissions must be submitted in advance of the bid opening directly from the reference to Christy Rios via email.

COMMODITY OR SERVICES SCHEDULE (PAGE 4): Complete the Unit Price (JB = job) and Amount blocks (these amounts will be the same). Note: The amounts listed in this section should be the same as the amount listed in block 17 of the SF-1442.

BID GUARANTEE: See Page 5 of the solicitation. A bid bond must be submitted in original (ink signatures) with your solicitation. The penal sum of the bond must be at least 20% of the bid price, not to exceed $3 million, whichever is less. A blank bid bond was included in the solicitation. The bid bond must be from a Government approved surety. A list of approved sureties can be located on the Department of Treasury, Bureau of the Fiscal Service website.

REPRESENTATIONS AND CERTIFICATIONS: All contractors submitting a bid must be registered in beta.SAM.gov. Since this is a small-business set-aside, you must meet the small business size standard $39.5 million which corresponds to the assigned NAICS code 237310.

See provision 52.219-1 in the Representations & Certifications section of your beta.SAM.gov registration.

Various provisions from pages 26-31 of the solicitation require bidders to mark selections within the provisions. Please review the Instructions to Bidders and complete the highlighted areas within the solicitation.

AMENDMENTS: Amendments (if any) must be acknowledged and submitted with the bid by one of the methods as described in item eleven of the Standard Form 30.

USP MARION- PROJECT 4D4A

3 | P a g e

2. Other general items to be addressed:

CONSTRUCTION WAGE RATES: This contract is subject to the Construction Wage Rate Requirements (formerly Davis-Bacon Act). General Decision IL20210002 is applicable for this area and has been included in Section 5 - Attachments. All applicable workers must be paid according to the terms of the wage decision.

GOALS FOR MINORITY AND FEMALE PARTICIPIATION: Participation goals for this project are 11.4% for minorities and 6.9% for females – A “Good Faith” effort should be put forth by the contractor to achieve these goals (see provision 52.222-23).

LICENSING AND PERMITS: All required licensing and permits are required to be obtained by the contractor who receives contract award.

MAGNITUDE: The magnitude of the project is between $500,000 and $1,000,000.

WORK HOURS: Work hours within the secure perimeter shall be between 7:00 am and 3:30 pm Monday through Friday excluding weekends and federal holidays.

COR: The Contracting Officer’s Representative (COR) is Mr. Dane Castellano, Engineering Technician, USP Marion.

PERIOD OF PERFORMANCE: The completion period is 74 days after issuance of notice to proceed.

TIME EXTENSIONS: Time extensions for inclement weather will not be granted unless the weather is unusually severe and abnormal in comparison to prior years.

LIQUIDATED DAMAGES: Liquidated damages for this project are in the amount of $914.46 per calendar day of delay after expiration of the completion period.

PRE-CONSTRUCTION CONFERENCE: A Pre-Construction conference is required after the contract is awarded and will be scheduled accordingly.

PROGRESS SCHEDULE: A copy of the progress schedule is to be provided to the Contracting Officer and COR as soon as possible. Each time the progress schedule is updated, it must be provided to both the Contracting Officer and COR. It’s suggested an updated document be provided by the Prime Contractor at the mandatory monthly progress meetings. Changes to the schedule must be approved in advance by the Contracting Officer (thru the COR) and must remain within the contract completion period.

PROGRESS MEETINGS: Progress meetings are mandatory and will be scheduled monthly.

PAYMENT REQUESTS: Applications for payment are to be submitted on AIA G702 (with continuation page) or the contractor’s own form as long as the information is similar to the G702

USP MARION- PROJECT 4D4A

4 | P a g e

(see FAO-0007 on page 10 of the solicitation). Contactors can get these forms from the following website www.aiabookstore.com

QUESTIONS: Questions asked at the pre-bid conference/site visit of a technical nature are not acceptable due to the possibility of misunderstanding or misinterpretation among all bidders. All questions shall be sent in Microsoft Word format to Christy Rios, FAO Contracting Officer, via email at crios@bop.gov. In order to provide sufficient response time prior to the bid due date, the Government has established that questions be submitted no later than May 31, 2021 at 1:00 P.M.

(CST).

ACCESS TO SITE/PARKING OF VEHICLES: Parking will be provided for employee vehicles and contractor work vehicles.

STORAGE OF MATERIALS: Storage of materials will be coordinated with the COR.

CONTRACTOR TEMPORARY OFFICE: No temporary office space will be provided.

INSPECTIONS: "Punch List" items generated by inspections will be corrected and discrepancy items re-inspected and approved before contract closure takes place. Should any work be covered without proper notification, the contractor shall uncover that work for inspection at his own expense.

3. SAFETY POINTS:

The contractor is responsible for providing required protective gear to all contractor workers, should it be required. Contractor will ensure that all workers have proper safety gear at all times.

Contractor is responsible for the prevention of accidents on the project site and has spill kit onsite and containment procedures. OSHA requirements will be adhered to.

The Contractor will have a Safety Representative on site at all times during the completion of this project.

Proper storage of any chemicals in lay down yard with SDS present.

4. SECURITY

ADVERSE WEATHER: Whenever adverse weather conditions or other institution emergency contingencies are in effect, contract workers will not be permitted passage into the secure institution. Should emergency conditions be implemented while contract workers are inside the secure perimeter, they will be required to secure their tools, remove vehicles and equipment, and leave the institution grounds until the emergency situation has been resolved.

Depending upon the nature of the emergency, this normally will not affect any construction

USP MARION- PROJECT 4D4A

5 | P a g e outside of the secure perimeter. Contractor is reminded that fog days will be treated like rain days. The performance period of 74 days will allow adequate time to complete the job, and no consideration will be allowed for normal rain days and normal fog days. The normal rain, snow or fog days will be based on the average over the last ten (10) years for the local community.

SECURITY CLEARANCES: Contract workers are subject to security investigative procedures.

Please refer to the solicitation for details. Please refer to Page 7 of the solicitation.

EMPLOYEE IDENTIFICATION: Contractor personnel working on project site must bring valid photo identification to the institution each day. The identification will be surrendered upon entry to, and returned upon exit from institution property.

TOOL ACCOUNTABILITY: Strict accountability and control of all contractor tools and hazardous materials must be maintained at all times. All contractor tools to be used inside the secure perimeter must be inventoried and accounted for at the conclusion of the work day Contractor tools may not be stored on-site overnight. The contractor should provide for enough time at the conclusion of the work day for the return and accounting of all tools issued during the work day.

Lost or missing tools must be reported to the COR the Captain immediately.

ILLEGAL ITEMS ON FEDERAL PROPERTY: Firearms, ammunition, knives, other weapons, drugs, narcotics, and alcoholic beverages are not permitted inside/outside the secure perimeter or anywhere else on Federal property at any time. This includes the private vehicles of contract workers. Violators will be subject to criminal prosecution. All persons, vehicles, and equipment are subject to search by institution authorities at any time.

NO CONTACT WITH INMATES: Contract workers are not to have any contact with inmates at any time. No photographs may be taken of inmates.

CONTRACTOR EMPLOYEE WORK DRESS: Green or khaki-colored clothing is not allowed, as inmates wear these colors.

PHOTOGRAPHS: The institution’s Facilities Department maintains a digital camera that will be utilized by FBOP staff to document the project work. The Contractor may request copies of these photos, and may request that photos be taken for specific conditions. Cellular telephones equipped with photographic capabilities are prohibited on the project construction site.

USP MARION- PROJECT 4D4A

6 | P a g e

VIII. ADDITIONAL DISCUSSION:

Meeting minutes recorded by:

Chelsea Walker, Contract Specialist USP Marion

NOTICE:

MEETING MINUTES ARE PROVIDED FOR INFORMATIONAL PURPOSES ONLY. THEY ARE NOT

INTENDED TO CHANGE ANY SPECIFICATIONS, TERMS OR CONDITIONS OF THE

SOLICITATION. ANY AND ALL CHANGES TO THE SOLICITATION SHALL BE ISSUED IN

SUBSEQUENT AMENDMENTS ISSUED BY THE CONTRACTING OFFICER ON A STANDARD

FORM 30 (SF-30).

CHELSEA

WALKER

Digitally signed by CHELSEA

WALKER

Date: 2021.05.27 10:43:54 -05'00'