11 - Amendment 00002.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

Previous edition unusable

00002

Amendment 00002 is hereby issued to incorporate the following items into Invitation for Bids 15B10621B00000002:

1) Contractor Requests for Information and Government Responses.

Federal Bureau of Prisons Field Acquisition Office 346 Marine Forces Drive Grand Prairie, TX 75051

Federal Bureau of Prisons FCC Butner Old NC Highway 75 Butner, NC 27509

RP# 0240-21

15B10621B00000002

1D2B05/04/2021

04/12/2021

1 18

Invitation for Bids 15B10621B00000002 Linear Accelerator Building Addition FCC Butner, NC Requests for Information #1 – 5/4/2021 Question 1:

Will the cafeteria be accessible to workers since they are prohibited from leaving the worksite?

BOP Response: Clarification No contractors will not be allowed use of the cafeteria. On previous jobs, contractors bring their food with them.

Question 2:

Is the water utility able to supply water for the office trailer?

BOP Response: Clarification Section 015000: 1.3.B address this. Attached to this document is the approximate location of where domestic cold water can be connected to in the Federal Medical Center Powerhouse.

The water line is within 20’ of the rear wall of the powerhouse as shown on the attached image. See Attachment 1.

Question 3:

Contractors will need at least 4 weeks after receipt of the jobsite photos in order to properly inform subcontractors of the work required. This is especially true due to the delays imposed by COVID. Can the bid date be extended until June 8th?

BOP Response: Clarification At this time, the Government does not intend to extend the deadline for receipt of bids. Should that decision change, the extension will be publicized by way of a solicitation amendment posted to https://beta.sam.gov.

Question 4:

Can you provide the company that currently services/supports the fire alarm system?

BOP Response: Clarification Schneider Electric is the contractor that services our fire alarm system.

Question 5:

We have a millwork subcontractor that follows the AWI guidelines and standards for all of their work, but does not participate in the certification program. Is the AWI certification requirement required for casework fabricators?

BOP Response: Clarification Per section 064116, contractors shall comply with the Architectural Woodwork Standards, which includes providing labels and certificates from the AWI certification program.

Invitation for Bids 15B10621B00000002 Linear Accelerator Building Addition FCC Butner, NC Requests for Information #1 – 5/4/2021 Question 6:

Attached is a substitution request from Metal Roofing System for specifications 07 41 13.16 and 07 71 00. Please review and advise is this product is acceptable.

BOP Response: Clarification For this RFI, the request for a substitution does not apply as the manufacturers listed are for reference only and are noted as not being limited to. That being said and as long as the supplied product meets the requirements of the specification the answer is the product can be used. However, the product presented, does not meet all requirements of the specification, specifically with regards to the material and gauge. The document provided has .032 Aluminum highlighted, which does not meet the .034 (22 gauge) galvanized steel as specified. Based on the proposed product, it appears that .034 Galvalume is available and this material should be used if this product is to be considered acceptable. See attachment 2.

Question 7:

Per the specs, all contractors and crew members will need to have a background check to work on the premises. Will these checks be performed by the Prison Officials and if so, is there a charge or is this to be done by the General Contractor.

BOP Response: Clarification The background checks will be performed by the Bureau of Prisons. There is no charge to the General Contractor to complete these background investigations. The General Contractor is required to have all paperwork completed for each applicant and submitted to the badging program manager for the project which is the COR Justin Burroughs.

LO

C

A

TI

O N

O F

D O

M E

S

TI

C W

A

TE

R L

IN

E

IN

F

M C

P O

W E

R H

O U

S E

Attachment 1

7687 Mikron Drive Stanley, NC 28164 P: 704.820.3110 F: 704.820.0113

370-C Allied Drive Conway, SC 29526 P: 843.347.6673 F: 843.347.6693

3214 Hanover Drive Johnson City, TN 37604 P: 423.434.0535 F: 423.434.0537

8131 Virginia Pine Court Richmond, VA 23237 P: 804.912.1851 F: 804.918.4988

345 Maple St.

Gallatin, TN P: 615.989.7600 F: 615.989.1927

Project

We know that the Project needs a permanent roof solution with a competitive price to keep the project within the owner’s budget. Metal Roofing Systems (MRS) has been requested by some of the better roofers to provide them with a quote for our quality roofing products for this project. As a manufacturer of top quality metal panels and edge metal products, our competitive pricing will help keep the project within your owner’s budget.

Your design for this project reflects your interest in looking after the owner’s best interest. MRS likewise tries to look after the owner’s best interest by offering the best quality products on the market today at competitive pricing and these products are installed by our network of trained, certified roofing contractors.

Having performed a detailed review of the contact documents, we want to assure you that we have the same products as you have specified and that they meet or exceed your relevant performance requirements.

Since a number of roofing contractors have asked for our pricing on this project, we ask for you to please review and approve the attached CSI Substitution Request Form and let us know if you have any questions. Also, please let us know if you need for us to make the substitution request with some other form.

Please feel free to call me on my cell phone (804) 385-5798 if you should have any additional questions on the MRS product’s compliance to the specified requirements.

Sincerely, Peter Ryan Metal Roofing Systems, Inc.

Attachment 2

SUBSTITUTION

REQUEST

Project:

To:

Re:

Substitution Request Number:

From: Peter Ryan, Metal Roofing System Date:

A/E project Number:

Contract For:

Specification Title: Division 7 Section: 07 Page:

Description: Standing Seam Metal Roof Article/Paragraph: Part 2 -

Specification Title: Division 7 Section: 07 Page:

Description:

Article/Paragraph: Part 2 -

Proposed Substitution: MRS System 00 & MRS Manufacturer: 7670 Mikron Drive, Stanley, NC 28164 Phone: 704-820-3110 Fax: 704-820-0113

Trade Name: Metal Roofing Systems Inc.

Attached data includes product description, specifications, drawings, photographs, and performance and test data adequate for evaluation of the request; applicable portions of the data are clearly identified Attached data also includes a description of changes to the Contract Documents that the proposed substitution will require for its proper installation.

The Undersigned certifies:

• Proposed substitution has been fully investigated and determined to be equal or superior in all respects to specified product.

• Same warranty will be furnished for proposed substitution as for specified product

• Same maintenance service and source of replacement parts, as applicable, is available

• Proposed substitution will have no adverse effect on other trades and wilt not affect or delay progress schedule

• Proposed substitution docs not affect dimensions and functional clearances.

• Payment will be made for changes to building design, including A/E design, detailing, and construction costs caused by the substitution.

Submitted by: Peter Ryan

Firm: Metal Roofing Systems Inc.

Address: 7670 Mikron Drive, Stanley, NC 28164

Telephone: 704-820-3110

A/E's REVIEW AND ACTION

Substitution approved - Make submittals in accordance with Specification Section.

Substitution approved as noted - Make submittals in accordance with Specification Section

Substitution rejected - Use specified materials.

Substitution Request received too late - Use specified materials.

Signed by

Supporting Data Attached: Drawings Product Data Samples Tests Reports _

©Copyright 2013, CSI. Form Version: January 2013 110 South Union St., Suite 100, Alexandria, VA 22314 CSIForm 1.5C

SUBSTITUTION REQUEST FORM

To:

Project:

We hereby submit for your consideration the following product instead of the specified item for the above project:

DRAWING: SPEC. SECT. NO: 07 41 13.16 – STANDING-SEAM METAL ROOF PANELS

PARAGRAPH: 2.2., .

Proposed Substitution: MRS SYSTEM 00

DRAWING: SPEC. SECT. NO: 07 71 00 – ROOF SPECIALTIES

PARAGRAPH: 2. ., . –

Proposed Substitution: MRS -LOCK

Attach complete information on changes to Drawings and/or Specifications which proposed substitution will require for its proper installation.

Submit with request all necessary samples and substantiating data to prove equal quality and performance to that which is specified. Clearly mark manufacturer's literature to indicate equality in performance.

Fill in blanks below:

A. Does the substitution affect dimensions shown on the Drawings? No If yes, clearly indicate the changes:

B. Will the undersigned pay for changes to the building design, including engineering and detailing costs caused by the requested substitution? No If no, fully explain: MRS product is exact same as the specified product and thus will not affect the building design.

C. What effect does substitution have on other Contracts or other Trades? None

D. What effect does substitution have on construction schedule?

None. Possible shorter lead time because MRS is a local Manufacturer.

E. Manufacturer's warranties of the proposed and specified items are: Superior. Proposed substitution includes 35-yr Finish Warranty (vs. 20-yr specified).

F. Reason for request: MRS product is the exact same as the specified profile but with better warranties (see above) and MRS is a local manufacturer.

G. Itemized comparison of specified item(s) with the proposed substitution; list significant variations: See attached document

H. Accurate cost data comparing proposed substitution with product specified:

I. Designation of maintenance services and sources:

(Attach additional sheets if required.)

Certification of Equal Performance And Assumption Of Liability For Equal

Performance For Use By Architect:

The undersigned states that the function, appearance and quality are equivalent or superior to the specified item. Submitted By:

Accepted Not

Accepted

Accepted as Noted Received

Too Late

Signature: Peter Ryan Title: Architectural Manager By:

Firm: Metal Roofing Systems, Inc. Date:

Remarks:

Address: 7687 Mikron Drive, Stanley, NC 28164

Telephone:704-820-3110 Date: 10/17/2017

Signature shall be by person having authority to legally bind his firm to the above terms. Failure to provide legally binding signature will result in rejection of proposed substitution

WITH STRESS RIBS

WITH STRIATIONS

FLAT

5/16”

7/16”5/16”

1 1/2”

5/16”

7/16”5/16”

1 1/2”

5/16”

7/16”5/16”

1 1/2”

12”-20”

12”-20”

12”-20”

12" - 20" o.c.

1-1/2" or 1" high mechanical seam single or double lock

.032,.040, & .050 aluminum 22 or 24 ga galvalume 16 oz. copper

ASTM E1592 Tested Ideal for low slope conditions in commercial or residential applications

Material: .032, .040, & .050 Aluminum 24 & 22 Ga. Galvalume 16 & 20 Oz. Copper

Features: Striations (Recommended) Flat Stress Ribs

RequireMents: Solid Substrate Ice & Water Shield or Synthetic Underlayment Minimum Roof Pitch: 1/2” on 12”

Finish: Hylar 5000 or Kynar 500

Comparison sheet for equal

MRS System 1500

Feature Specified Metal Roofing Systems

MRS

MRS System 1500 Mechanically Single/Double

1 1/2” Smooth/Striations/Ribs Blind, Self Drilling Factory

As Selected 20 yrs

Manufacturer Model Seamed Panel Lock Panel Width Seam Height Panel Finish Fastener Type Created Location Test Procedure Material Material Finish Name Material Finish Material Gauge

Material Color Finish Warranty Watertight Warranty 20 yrs

Fluoropolymer Kynar 500/Hylar 5000

As Selected 35 yrs 20 yrs

LEED Credit SS7.2 Comply w/ Solar Reflectivity Yes LEED Credit MR4.1 (> 25% total) Post-Consumer 23% Pre-Consumer 8%

12”-20”

WITH STRESS RIBS

5/16”

7/16”5/16”

1 1/2”

370-C Allied Drive Conway, SC 29526 Tel: 843-365-6673 Fax: 843-365-6683

3214 Hanover Road Johnson City, TN 37604 Tel: 423-239-0013 Fax: 423-447-7150

7687 Mikron Drive Stanley, NC 28164 Tel: 704-820-3110 Fax: 704-820-0113

Locations:

Website: www.metalroofingsystems.biz

Secure-Lock Gravel Stop .050, .040, .032 Aluminum 24 ga Galvalume

Material: .050, .040, 032 Aluminum, 24 ga Galvalume

Finish: Hylar 5000 or Kynar 500 Aluminum

RR

X"

ANSI/SPRI ES-1 Tested and Approved

#10 X 1" FASTENER

@ 12" O.C.

#10 X 1" FASTENER

@ 12" O.C.

Comparison sheet for equal

MBED MRS

Feature Specified Metal Roofing Systems Manufacturer MRS Model Nominal Fascia Height Created Location Test Procedure Material Material Finish Material Color

W.P. Hickman

MBED

Factory

ANSI/SPRI ES-1

Aluminum/Galvalume Kynar 500 As Selected

MRS

Factory

ANSI/SPRI ES-1

Aluminum/Galvalume Kynar 500 As Selected

Material Thickness .063, .050, .040, .032 Alum .063, .050, .040, .032 Alum.

24 Ga. 24 Ga.

Finish Warranty 35 yrs Wind Warranty 20 yrs – 110 mph Test Pull-Out Value 150 psf

MEETS ANSI/SPRI ES-1 YES YES

Material Waranty 25 yrs

X"

#10 x 1" FASTENER @ 12" O.C.

5-Year Watertightness Limited Warranty

T

SAMPLE

WARRANTY RESPONSIBILITY:

35 -Year Limited COOLR “Paint ” Warranty AZ50 Galvalume®, G90 Galvanized, or Aluminum

EXCLUSIVE WARRANTY

This Warranty (collectively, the “Warranty”) is issued by Metal Roofing Systems Inc. (hereinafter referred to as “MRS”), to the customer identified in this Certificate (hereinafter referred to as “Customer”) and applies to the finish on AZ50 Galvalume®, G90 Galvanized, or Aluminum flat sheet and coil products (hereinafter referred to as the “Product”) with PVDF based coating consisting of KYNAR 500® or Hylar 5000® resin (hereinafter referred to as the “Coating”) if erected anywhere within the Continental United States includingAlaska, Hawaii and Canada.

1. Subject to the provisions contained herein, MRS warrants that during the Thirty-Five (35) Year Warranty Period, MRS' COOLR stock Coatings will not chip, crack, peel, flake or check (except for such slight crazing or cracking as may occur on tightly roll-formed edges or break bends at the time of roll forming or other fabrication of pre-painted sheet or coil and which is accepted in the industry as standard). Subject to the provisions contained herein, MRS warrants that for Thirty (30) years from the date of installation of panels, the Coating will not chalk in excess of ASTM D-4214-89 method D659 number eight (8) rating, or change color more than Five (5.0) Hunter �E units as determined by ASTM method D-2244-2. Color change will be measured on an exposed painted surface that has been cleaned of surface soils and chalk, and the corresponding values measured on the original or unexposed surface. It is understood that fading or color change may not be uniform, if the surfaces are not equally exposed to the sun and elements.

2. This Warranty does not apply to circumstances beyond MRS' control, including:

a. Fire or other casualty or physical damage;

b. Unusual harmful fumes, foreign substances in the atmosphere or standing water. No warranty is provided for the coating on any substrate that is subjected to sea spray or installed on a property located 1500 or fewer feet from a coastline, salt or brackish water, or any salt water environment;

c. Improper treatment of or defects in the metal or in the fabrication or areas where items such as snow guards or solar panels are attached / adhered to the product.

d. Intermittent or continual submersion in water or any other liquid or solid material;

e. Damage from wind, deliberate damage, improper handling by erectors, from abrasive or chemical cleaners.

f. Mishandled Products, e.g., ANY PRODUCT WHICH

HAS BEEN ABUSED, ALTERED, MODIFIED, USED

IN A MANNER NOT ORIGINALLY INTENDED, OR

STORED CONTRARY TO OUR INSTRUCTIONS.

g. Stored or installed in a way that allows for poor air circulation, contact with animals or animal waste.

h. Embossing that fractures or severely stretches the film (i.e. film is diminished at the point of emboss by greater than 0.2 mils.

3. This Warranty does not cover damage or deterioration resulting from moisture contamination or entrapment or any other contamination detrimental to the coating, which occurs prior to installation of the Products, including, without limitation, contamination occurring during shipment of the Product to the jobsite or during storage at the jobsite. This Warranty does not cover failure due to corrosion of substrate.

4. EXCLUDED ATMOSPHERIC CONDITIONS

This Warranty does not apply to sheet exposed at any time to corrosive, aggressive, harmful or other abnormal atmospheric conditions, including but not limited to:

A. Areas subject to fallout exposure to corrosive chemicals, ash, fumes, cement dust, animal waste, or it’s decomposition by-products, fallout from copper, lead, nickel or silver mining or refining operations and carbon black;

B. Conditions/circumstances where corrosive fumes or condensation are generated or released inside the building;

C. Areas subject to water run-off from lead or copper flashing or piping or areas in contact with lead or copper or lumber containing same;

5. All Warranty work will be performed by MRS, or any company, dealer, contractor, applicator, or distributor selected by MRS. Since there may be a color variance between the replacement or repainted Product and the originally installed Product due to normal weathering (i.e. exposure to sunlight and extremes of temperature and weather) of the originally installed Products, this condition shall not be indicative of a defect.

6. NOT WITHSTANDING ANYTHING TO THE CONTRARY

CONTAINED HEREIN, MRS' LIABILITY SHALL NOT EXCEED

THE LESSER OF THE FOLLOWING: (I) THE CUSTOMER’S

LIABILITY DIRECTLY ATTRIBUTABLE TO A BREACH OF THIS

WARRANTY, OR (II) THE REFINISHING OR REPLACEMENT OF

THE FAILED COATED MATERIAL, OR AT MRS' OPTION,

REFUND OF THE PURCHASE PRICE WHICH SHALL NOT

EXCEED AN AMOUNT EQUAL TO ONE HUNDRED PERCENT

(100%) OF THE AMOUNTS PAID TO MRS BY THE CUSTOMER

FOR THE PURCHASE OF THE DEFECTIVE PRODUCT. MRS

SHALL NOT BE LIABLE FOR INJURY TO PROPERTY OTHER

THAN THE FLAT SHEET AND/OR COIL PRODUCTS COATED

WITH FLUOROCARBON PAINT SYSTEMS, IN THE CONDITION

AND AS PURCHASED BY CUSTOMER FROM MRS. MRS, IN ALL

INSTANCES, SHALL HAVE THE SOLE AND EXCLUSIVE RIGHT

TO DETERMINE WHETHER OR NOT REFINISHING OR

REPLACEMENT OF THE FAILED AREAS IS REQUIRED, AND TO

FULFILL ITS OBLIGATION UNDER THE WARRANTY, MRS

RESERVES THE RIGHT TO NEGOTIATE AND APPROVE ANY

FINAL CONTRACT LET FOR REFINISHING AND REPLACEMENT

AS THE CASE MAY BE.

7. This Warranty applies only to products manufactured by the customer within six (6) months from shipment thereof by Metal Roofing Systems Inc.

8. Claims under this Warranty must be presented by the customer to MRS in writing during the warranty period and within thirty (30) days after Customer becomes aware that any warranted condition has occurred. Time is of the essence and failure to give notice within the specified time shall discharge MRS from any obligations under this Warranty. MRS must be given a reasonable opportunity to do an on-site inspection to determine if there is a coating failure.

9. The laws of the State of Ohio shall exclusively govern the rights and duties of the parties to this Warranty. Any controversy or claim arising out of or related to this Warranty, or the breach thereof shall be brought before a court of competent jurisdiction in Cleveland, Ohio under the substantive and procedural laws of the State of Ohio.

10. Customer acknowledges that MRS is not the manufacturer or applicator of the coating warranted herein and agrees that all issues arising from or related to the exceptions set forth herein shall be determined finally and conclusively as to Customer, by the original manufacturer.

11. Due to pigment limitations, Regal Red, Matte Black and L/S Antique Black are covered by a number eight (8) rating for chalk, and five (5) � E units for fade for a period of ten (10) years from installation. Copper and other metallic colors have no rating available for color change.

12. This Warranty applies solely to MRS “inventoried stock” colors. Custom matched colors and non-inventoried items may have different Warranty terms, or not be warranted.

13. For this Warranty to apply, the Customer must retain certain records. In order for MRS to process a claim, we will need to be told the original coil or skid tag number.

14. THIS WARRANTY IS GIVEN AS THE SOLE AND

EXCLUSIVE WARRANTY AND EXCLUSIVE REMEDY

BY OR AGAINST MRS, AND NO OTHER

WARRANTIES, EITHER EXPRESS OR IMPLIED,

INCLUDING BUT NOT LIMITED TO WARRANTIES OF

MERCHANTABILITY OR FITNESS FOR A PARTICULAR

PURPOSE OR PURPOSES, ARE MADE, AND ANY SUCH

OTHER WARRANTIES ARE EXPRESSLY DISCLAIMED.

THERE ARE NO WARRANTIES THAT EXTEND BEYOND

THE DESCRIPTION CONTAINED IN THIS INSTRUMENT.

CUSTOMER WAIVES THE BENEFIT OF ANY RULE

THAT THE DISCLAIMERS OF WARRANTY SHALL BE

CONSTRUED AGAINST THE SELLER, AND AGREES

THAT THE DISCLAIMERS IN THIS INSTRUMENT

SHALL BE CONSTRUED LIBERALLY IN FAVOR OF

MRS. MRS SHALL NOT BE LIABLE FOR ANY SPECIAL,

INCIDENTAL OR CONSEQUENTIAL DAMAGES. MRS

HEREBY DISCLAIMS ALL LIABILITIES FOR DAMAGES

BASED ON THEORIES OF NEGLIGENCE AND STRICT

PRODUCT LIABILITY. THIS WARRANTY IS EXTENDED

TO CUSTOMER ALONE

AND NO OTHERS, IS NON-TRANSFERABLE AND NON-

ASSIGNABLE, AND MAY NOT BE ENLARGED IN ITS

SCOPE BY ANY REPRESENTATIVE, SALES PERSON,

AGENT OR OTHER EMPLOYEE OF

MRS. THE CUSTOMER SHALL NOT PERMIT ANYONE

TO CLAIM OR IMPLY THAT THIS WARRANTY

EXTENDS OR CAN BE “PASSED THROUGH” TO

ANYONE OTHER THAN THE CUSTOMER. THIS

PROVISION IS A MATERIAL TERM OF THIS

WARRANTY AND ITS VIOLATION OR BREACH BY

CUSTOMER OR ANY OF CUSTOMER’S AGENTS OR

REPRESENTATIVES, SHALL VOID AND CANCEL THIS

WARRANTY FOR ALL PURPOSES.

THE LIABILITY OF SELLER MRS SHALL NOT

EXTEND TO PERSONAL INJURY, PROPERTY

DAMAGE, LOSS OF PROFIT, DELAY OR ANY

INCIDENTAL OR CONSEQUENTIAL DAMAGES

RESULTING FROM THE FAILURE OF ANY PRODUCT

OR COATING TO CONFORM WITH THE PROVISIONS

OF THIS LIMITED WARRANTY.

MRS SHALL NOT IN ANY EVENT BE LIABLE TO THE

CUSTOMER OR ANY OTHER PERSON OR ENTITY

FOR ANY ACTIONS, CLAIMS, CAUSES OF ACTION,

DAMAGES, EXPENSES AND/OR LIABILITIES ARISING

FROM OR RELATED TO THE DESIGN, USE OR

FAILURE OF THE PRODUCT OR COATING, FOR THE

INTERUPTION OF THE CUSTOMER’S OPERATIONS

OR BUSINESS, FOR THE COST OF LABOR EXPENDED

BY OTHERS ON ANY DEFECTIVE PRODUCT OR

COATING OR FOR ANY SPECIAL, INDIRECT OR

CONSEQUENTIAL DAMAGES WHATSOEVER OR LOSS

OF PROFIT OR OTHER FINANCIAL LOSS ARISING

OUT OF THE USE OR FAILURE OF THE PRODUCT OR

COATING, EVEN IF MRS HAS BEEN ADVISED OF THE

POSSIBILITY OF SUCH ACTIONS, CLAIMS, CAUSES

OF ACTION, DAMAGES, EXPENSE, LOSS AND/OR

LIABILITIES, WHETHER ARISING FROM BREACH OF

CONTRACT, BREACH OF WARRANTY, TORT,

INCLUDING NEGLIGENCE, STRICT LIABILITY OR

OTHERWISE TO ANYONE BY REASON OF THE FACT

THAT SUCH PRODUCT OR COATING SHALL HAVE

BEEN DEFECTIVE.

SIGNATURE:

This Warranty is not valid unless signed by an authorized employee or agent of Metal Roofing Systems Inc.

METAL ROOFING SYSTEMS INC.

By: _________________________________

Name Printed:

Title: President

Date:

"Metal Roofing Systems"

Issued To:

For:

Job:

Color:

Completion Date:

7687 Mikron Drive Stanley, NC 28164 P: 704.820.3110 F: 704.820.0113

370-C Allied Drive Conway, SC 29526 P: 843.347.6673 F: 843.347.6693

3214 Hanover Drive Johnson City, TN 37604 P: 423.434.0535 F: 423.434.0537

LOCATIONS

www.metalroofingsystems.biz

YEAR

WARRANTY

.063

YEAR

PAINT WARRANTY

Galvalume® is a registered trademark of BIEC. Hylar 5000 ® is a registered trademark of Solvay Solexis, Inc. Kynar 500 ®is a registered trademark of Atofina, Inc.

Oil canning is an aesthetic issue and is an inherent part of light gauge cold formed metal products. By using coil that

,tnemevom lamreht rof gningised ,ylreporp dessecorp neeb sah following stringent specifications for installation and proper handling most oil canning can be eliminated. Oil canning is not grounds for coil/panel rejection.

STOCK AVAILABILITY MATRIX

GALVALUME ALUMINUM

24 ga. .032 .040 .050ISR EMI 3yr. SRI

Aged Copper 0.47 0.85 0.46 53

Ash Gray 0.39 0.84 0.39 41

Burgundy 0.25 0.85 0.23 23

Champagne Metallic 0.37 0.80 0.35 37

Charcoal Gray 0.29 0.84 0.28 28

Colonial Red 0.30 0.85 0.29 30

Copper Metallic 0.49 0.86 0.47 56

Dark Bronze 0.26 0.84 0.25 24

Dove Gray 0.49 0.86 N/A 56

Evergreen 0.27 0.86 0.26 26

Hartford Green 0.26 0.85 0.25 24

Hemlock Green 0.29 0.86 0.29 29

Mansard Brown 0.27 0.86 0.25 26

Matte Black 0.29 0.83 0.27 27

Medium Bronze 0.30 0.87 0.28 31

Patina Green 0.28 0.87 0.28 28

Pre-weathered Galvalume ® 0.30 0.79 0.28 27

Regal Blue 0.26 0.85 0.25 24

Regal Red 0.42 0.83 0.41 45

Regal White 0.67 0.86 0.67 81

Sandstone 0.54 0.86 0.53 63

Sierra Tan 0.35 0.86 0.34 37

Silver Metallic 0.59 0.79 0.60 67

Slate Blue 0.29 0.85 0.28 28

Slate Gray 0.33 0.84 0.33 33

Bone White 0.47 0.83 N/A 58

Stone White 0.60 0.86 0.56 71

Surrey Beige 0.42 0.85 0.41 46

Terra Cotta 0.35 0.86 0.35 37

Acrylic Coated Galvalume ® 0.67 0.14 0.55 56

Stocked Item

Energy Star Compliant

LEED 2009 Compliant

ISR Initial Solar Reflectance

EMI Emissivity

SRI Solar Reflectance Index

KEYNOTES

All metal is painted with a .20 mil primer and .70 -.90 mil Top Coat of 70% Kynar 500 or Hylar 5000. The reverse side has a .20 primer and .30 - .40 backer coating.

22 gauge steel available upon request.

For low slope roofing to meet Energy Star requirements the ISR must be ≥ 0.65. After 3 years, the solar reflectance must be ≥0.50.

For steep slope roofing to meet Energy Star requirements the ISR must be ≥ 0.25. After 3 years, the solar reflectance must be ≥0.15.

For low slope roofing to meet LEED 2009 requirements the SRI must be ≥ 78.

For steep slope roofing to meet LEED 2009 requirements the SRI for 100% of the roof must be ≥ 29.

Low slope is defined as ≤2:12.

Steep slope is defined as >2:12.

* IF DESIRED COLOR IS NOT LISTED ON MATRIX PLEASE CONTACT METAL ROOFING SYSTEMS FOR AVAILABILITY

22 ga.