RFQ_15A00018Q00000118_Amendment_0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NUMBER

3. EFFECTIVE DATE

09/28/2018

4. REQUISITION/PURCHASE REQUISITION NUMBER

DJA-18-ASOD-PR-0295

5. PROJECT NUMBER (If applicable)

15A000CODE

ATF - ACQUISITIONS BRANCH

Brian Wilkins 99 New York Ave. NE Washington, DC 20226

(O) 2026489120

(F) 2026489654 Brian.Wilkins@ATF.gov

6. ISSUED BY CODE7. ADMINISTERED BY (If other than Item 6)

9A. AMENDMENT OF SOLICITATION NUMBER

15A00018Q00000118

CODE FACILITY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, country, state and ZIP Code) (X)

X 9B. DATED (SEE ITEM 11)

09/12/2018

10A. MODIFICATION OF CONTRACT/ORDER

NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X XThe above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning ____copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

ORDER NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of this amendment 0001 is hereby issued to extend the closing date for quotes to 09/28/2018 at 5:00pm EST.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Brian K. Wilkins

(Signature of person authorized to sign)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED

By (Signature of Contracting Officer)

16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

15A00018Q00000118/0001 Page 1 of 10

Table of Contents

Section Description Page Number

1 Solicitation/Contract Form 2 Commodity or Services Schedule 3 Contract Clauses

ATF-14 ELECTRONIC INVOICING

ATF-17 NOTICE TO THE GOVERNMENT OF DELAYS

ATF-19 AUTHORITY TO OBLIGATE THE GOVERNMENT

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders--Commercial Items (Nov 2017)

4 List of Attachments 5 Solicitation Provisions

ATF-43 Corporate Representation Regarding Felony Conviction Under Any Federal Law or Unpaid Delinquent Tax Liability - Solicitation (DEVIATION 2015-02) (March 2015) Section L Instructions, Conditions and Notices to Offerors or Respondents Section M Evaluation Factors for Award

15A00018Q00000118/0001 Page 2 of 10

Section 2 - Commodity or Services Schedule

Night Vision Devices

SCHEDULE OF SUPPLIES/SERVICES

CONTINUATION SHEET

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 TNV/PVS-14 L3 Gen3 In-Filmed White Phosphor

Line Period of Performance: 09/28/2018 - 10/27/2018

Previous :

6.000000

Change: 0.000000

Current : 6.000000

EA $____________ $___________________

0002 Wilcox L4 G37 Mount System - ACH/MICH

Line Period of Performance: 09/28/2018 - 10/27/2018

Previous :

6.000000

Change: 0.000000

Current : 6.000000

EA $____________ $___________________

Section 3 - Contract Clauses

A.1 ADDENDUM TO FAR 52.212-4, Contract Terms and Conditions--Commercial Items (Jan 2017)

The terms and conditions for the following clauses are hereby incorporated into this solicitation and resulting contract as an addendum to FAR clause 52.212-4.

Clauses By Reference

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov

Clause Title Fill-ins (if applicable)

52.212-4 Contract Terms and Conditions--Commercial Items (Jan 2017)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

(Dec 2013)

52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013)

52.204-7 System for Award Management (Oct 2016)

15A00018Q00000118/0001 Page 3 of 10

Clauses By Full Text

ATF-14 ELECTRONIC INVOICING

ELECTRONIC INVOICING (Revised October 27,2008)

The Bureau of Alcohol, Tobacco, Firearms and Explosives (ATF) encourages contractors to invoice electronically. Invoicing electron-ically saves time, money, and physical storage space for both the Government and the contractor.

Each invoice must be a proper invoice in accordance with Federal Acquisition Regulations (FAR) 32.905(b). The contractor may sub-mit a combined invoice with each ATF contract/order number. The invoice must clearly identify the specific Contract Line Item (CLIN) or item number for which the contractor is seeking payment under the contract/order. If the invoice covers multiple CLINs or item numbers, the invoice must clearly identify specific amounts and activity applicable to each.

Electronic invoices must be submitted to the ATF Contracting Officer's Representative (COR)/POC named in Section G/Section

3.3 of this contract and Financial Management Division (FMD), Finance.Branch@ATF.gov. Electronic invoices will serve as the offi-cial original copy. The e-mail subject line must contain the name of the ATF COR/POC named in Section G/Section 3.3 of the oblig-ation document, the Order/Award number, the Invoice number and Vendor name (i.e.: John Doe_DJAxxxxxxxxx_Invoice #xxx_ABC, Inc.). ATF will return to the vendor any invoices that do not contain the correct subject line information.

Contractors who are unable to submit electronic invoices may mail their invoices to the COR/POC named in Section G/Section 3.3 of this contract and FMD address provided below:

Bureau of Alcohol, Tobacco, Firearms & Explosives Attn: Finance Branch EXPEDITE CONTRACT INVOICE 99 New York Avenue, NE Mail Drop 4S-288 Washington, DC 20226

(End of Clause)

ATF-17 NOTICE TO THE GOVERNMENT OF DELAYS

NOTICE TO THE GOVERNMENT OF DELAYS (Revised July 19, 2007)

In the event the Contractor encounters difficulty in meeting performance requirements, or when he anticipates difficulty in complying with the contract delivery schedule or completion date, or whenever the Contractor has knowledge that any actual or potential situ-ation is delaying or threatens to delay the timely performance of the contract, the Contractor shall immediately notify the Contracting Officer and the Contracting Officer's Representative COR(s), in writing, giving pertinent details; provided, however, that this date shall be information only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date, or any rights or remedies provided by law or under this contract.

(End of Clause)

ATF-19 AUTHORITY TO OBLIGATE THE GOVERNMENT

AUTHORITY TO OBLIGATE THE GOVERNMENT (Revised July 19, 2007)

The Contracting Officer is the only individual who can legally commit or obligate the Government to the expenditure of public funds.

No cost chargeable to the proposed contract can be incurred before receipt of a fully executed contract or specific authorization from the Contracting Officer.

(End of Clause)

[END OF ADDENDUM TO FAR 52.212-4]

15A00018Q00000118/0001 Page 4 of 10

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders--Commercial Items (Nov 2017)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this con-tract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Divi-sion E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(3) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incor-porated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C.

6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3.

__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (Jan 2011) of 52.219-4.

__ (13) [Reserved]

X (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644).

__ (ii) Alternate I (Nov 2011).

__ (iii) Alternate II (Nov 2011).

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

15A00018Q00000118/0001 Page 5 of 10

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

X (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)).

__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Nov 2016) of 52.219-9.

__ (v) Alternate IV (Nov 2016) of 52.219-9.

X (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

__ (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages--Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f).

__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

X (26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

X (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

X (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).

X (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

X (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

__ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

__ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C.

6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O.

13693).

15A00018Q00000118/0001 Page 6 of 10

__ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

__ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

X (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513).

__ (43) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

__ (44) 52.223-21, Foams (Jun 2016) (E.O. 13693).

__ (45)(i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

__ (46) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

__ (47)(i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (48) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

__ (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Of-fice of Foreign Assets Control of the Department of the Treasury).

__ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

__ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

__ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X (55) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (56) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (59) 52.242-5, Payments to Small Business Subcontractors (Jan 2017)(15 U.S.C. 637(d)(12)).

__ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

15A00018Q00000118/0001 Page 7 of 10

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495).

__ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

__ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Con-tracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services- -Requirements (May 2014) (41 U.S.C. chapter 67).

__ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

__ (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

__ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

__ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Con-tractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relat-ing to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to ap-peals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made avail-able until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indic-ated below, the extent of the flow down shall be as required by the clause--

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Divi-sion E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for

15A00018Q00000118/0001 Page 8 of 10 construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting oppor-tunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph

(l) of FAR clause 52.222-17.

(v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)

(vi) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212)

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down re-quired in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

(xii) __(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627).

__(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

(xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989).

(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xvii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2017) (E.O. 13706).

(xviii)(A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xix) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xx) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in ac-cordance with paragraph (e) of FAR clause 52.226-6.

(xxi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C.

2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

Section 4 - List of Attachments

No Clauses

No Attachments

Section 5 - Solicitation Provisions

15A00018Q00000118/0001 Page 9 of 10

Provisions By Full Text

ATF-43 Corporate Representation Regarding Felony Conviction Under Any Federal Law or Unpaid Delinquent Tax Liability - Solicitation (DEVIATION 2015-02) (March 2015)

Corporate Representation Regarding Felony Conviction Under Any Federal Law or Unpaid Delinquent Tax Liability – Soli-citation (DEVIATION 2015-02) (March 2015)

(a) None of the funds made available by the Department’s current Appropriations Act may be used to enter into a contract, memor-andum of understanding, or cooperative agreement with a corporation –

(1) convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government; or

(2) that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, un-less an agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government.

(b) By submitting a response to this solicitation, the offeror represents that, as of the date of this offer –

(1) the offeror is not a corporation convicted of a felony criminal violation under any Federal or State law within the preceding 24 months; and,

(2) the offeror is not a corporation that has any unpaid Federal or State tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely man-ner pursuant to an agreement with the authority responsible for collecting the tax liability.

(End of Provision)

Section L Instructions, Conditions and Notices to Offerors or Respondents

SECTION L - QUOTE INSTRUCTIONS

Provide a "Firm-Fixed-Price" OPEN MARKET Quote

(a) The Offeror shall submit an electronically signed and dated offer no later than September 28, 2018, 5:00 PM Eastern Standard Time (EST) to Brian.Wilkins@atf.gov.

(b) Quote must include a cost for each item see attached Pricing Table.

(c) The electronic submission shall be in Microsoft Word or Adobe Acrobat Portable Data Format (PDF).

Section M Evaluation Factors for Award

Evaluation Factors:

Award will be made on an "All on None Basis and Lowest Cost." No Substitutions".

15A00018Q00000118/0001 Page 10 of 10