1.1) Cover Page

Solicitation

For Participation in

Circuit 680 UG Cable Replacement Construction Services for

JEA

Jacksonville, FL

Solicitation Number 1412223678

Mandatory Pre-Response Meeting via Microsoft Teams or Teleconference on October 05, 2026, at 1:00PM EST

Microsoft Teams meeting

Join: https://teams.microsoft.com/meet/228549820404641?p=xGKbpzIjunqlqrwqZo

Meeting ID: 228 549 820 404 641

Passcode: dw7vR7c5

Need help? | System reference

Dial in by phone

+1 469-208-1810,,655100162# United States, Carrollton

Find a local number

Phone conference ID: 655 100 162#

Join on a video conferencing device

Tenant key: jea@m.webex.com

Video ID: 118 681 107 4

More info

Responses are due on October 27, 2026, by 12:00 PM EST

All Responses shall be submitted through JEA’s E-Procurement and Contract Management Portal which is provided by Zycus Supplier Network which can be accessed at https://zsn.zycus.com/guest. Instructions on how to login to

Zycus is provided below in this Solicitation. LATE RESPONSES MAY BE REJECTED.

JEA will publicly open all Responses received from qualified Respondents on the Due Date, via Microsoft Teams.

For more information please contact the JEA Buyer at:

Jason Behr, behrjv@jea.com https://teams.microsoft.com/meet/228549820404641?p=xGKbpzIjunqlqrwqZo https://aka.ms/JoinTeamsMeeting?omkt=en-US https://teams.microsoft.com/l/meetup-join/19%3ameeting_Y2Y4Nzg4YjktMjQ3Yy00MDU1LWFmNTUtNTZlYWQ0ODg1YTY0%40thread.v2/0?context=%7b%22Tid%22%3a%22c0d91960-576d-4631-bc37-56584b7dc8db%22%2c%22Oid%22%3a%22d486d8f3-a679-44da-ae62-3c81a61b1dde%22%7d tel:+14692081810,,655100162 https://dialin.teams.cloud.microsoft/7f16dcab-d946-4f6a-8038-ba775494cd86?id=655100162 https://www.webex.com/msteams?confid=1186811074&tenantkey=jea&domain=m.webex.com https://zsn.zycus.com/guest mailto:behrjv@jea.com

1.2) Scope of Work (Imeson substation)

The purpose of this solicitation is to select a contractor to provide construction services for the replacement of approximately 1,200 feet of a 69 kV underground getaway originating from the Dillion Substation. Work will occur within the substation and generation facility, as well as within the City of Jacksonville right‑of‑way along Talleyrand

Avenue and Wigmore Street. The scope includes installation of an open‑cut, concrete‑encased duct bank; installation of a HDD duct bank; pulling and installation of 69 kV EPR cable; modifications to an overhead transmission riser pole and substation termination structures; removal of existing direct‑buried 69 kV cable; site restoration; maintenance of traffic; permitting; and all other related activities.

1.3) Background

JEA owns, operates and manages the electric system established by the City of Jacksonville, Florida since 1895. In June

1997, JEA also assumed operation of the water and sewer system previously managed by the City. JEA is located in

Jacksonville, Florida, where we proudly serve an estimated 541,076 electric, 407,161, water and 30,460 reuse water customers. JEA is Florida's largest community owned utility and the eighth largest municipal in the United States.

1.4) Invitation - Submitting a Response

Respondents that meet the Minimum Qualification stated herein are invited to submit a Response to this Solicitation to perform the Work. A complete copy of this Solicitation, the Technical Specifications, forms and all other documents referenced in this Solicitation are on JEA’s E-Procurement and Contract Management Portal which is provided by

Zycus Supplier Network which can be accessed at https://zsn.zycus.com/guest/genericRegister/JEA074. Instructions on how to login to Zycus is provided below in this Solicitation.

All Responses are due at the time indicated on the title page of this Solicitation. Section 1 of this Solicitation are the instructions for submitting a Response for this Solicitation. Section 2 of this Solicitation contain the definitions and commercial contract terms associated with this procurement.

A Contract will be presented to the Respondent awarded this Work and the Contract will incorporate by reference this entire Solicitation and all associated Addenda. A sample of the JEA Contract can be found on jea.com.

All documentation submitted with a Response must reference the Solicitation Title and Number stated herein. All

Responses must be made on the appropriate forms and formats as specified by this Solicitation and uploaded to JEA’s procurement platform.

All Responses should be delivered electronically to JEA via the Zycus platform. An automated, detailed auditing system provides sealed Response integrity. Responses remain sealed on the platform until the Close Date & Time

(Due Date & Time).

A Respondent shall be solely responsible for timely delivery of its Response to the Zycus Supplier

Network. Respondents are strongly encouraged to acquire log in credentials early as possible. Additionally

Respondents are encouraged to submit Responses early to ensure uploading process goes smoothly. If Respondent is not able to submit its Response via Zycus, then please email the Response to the JEA Buyer identified in the

Section below titled "Questions".

Responses are due by the time and on the date stated on the cover page of this Solicitation. LATE RESPONSES

MAY BE REJECTED.

1.5) Zycus Instructions

I. How to Log Into Zycus

A. New Users – Zycus

1. New Users will need to register to login. Registration will require Company name, address, phone, contact, title, phone and email address. Also, it is recommended users use Google Chrome to access Zycus.

2. Note if the company is already doing business with JEA, you may find the company is already registered in Zycus.

To find out if you are registered, try entering your email address in the New User Registration screen. If you receive a https://zsn.zycus.com/guest/genericRegister/JEA074 message stating “Email ID already registered”, log in as an Existing User Log-in”. If you don’t know your password, enter your email address and click on “Forgot Password”.

B. Existing Users or New Users with Previously Registered Emails

1. Once the user has a login on the sourcing platform select “Existing User Log-in”, the user may navigate to the solicitation by selecting the icon for the applicable solicitation.

II. How to Submit a Response Using Zycus

1. Once logged in, users will see all JEA Sourcing Events, then select the applicable event.

2. Once in the Sourcing Event. The Sourcing Event has prompts for actions required to respond to the solicitation.

3. For the user to proceed to submit a Response to JEA using Zycus, the user will be required to provide its acceptance of the of the Zycus iSource Terms & Conditions associated with the work. Such Terms and Conditions may cover non-disclosure, safety, cyber security, Invitation for Bid contract terms, etc.

4. Once all terms are accepted, additional Solicitation information will be available for viewing and submitting a

Response by selecting “Confirm Participation”. JEA will then have a record indicating the company intends to submit a Response.

5. A user then can respond to each section of the Solicitation, once completed with each section, select “Save”. Note each section has a red, yellow, green light code. Items will turn green once completed. Yellow and red lights mean there is additional action required. Users may also note under each tab, there are multiple questions to respond to, scroll down the list to ensure all questions are answered.

6. In most Solicitations, JEA will provide Technical Specifications, pricing tables in Excel which the user will need to download. Additionally, Excel pricing tables may need to be uploaded once completed to as part of the Response.

Users can download the required attachments by selecting the “Buyers Attachments” icon.

7. Once the required forms are uploaded and saved, the section light will turn green. Once all sections are completed and green lighted, the User may select “Submit Response”.

8. Once the user selects “Submit Response”, the user will receive a “Success” pop-up when submitted.

9. Once submitted users may recall and modify submitted documentation and submit information until the Response

Due Date and Time.

10. Zycus does not automatically transfer a pricing submission from the qualifying round into live auction setting for award consideration. Each user shall manually re-submit its qualifying Response into the live auction environment for consideration of award.

1.6) Questions

All Questions must be submitted in writing to the JEA Buyer listed herein at least five business days prior to the opening date. Questions received within five business days prior to the opening date may not be answered.

1.7) Pre-Response Meeting

There may be a mandatory Pre-Response meeting associated with this Solicitation at the date and time listed on the cover page of this Solicitation. All interested Respondents are invited to attend the Pre-Response meeting. Those planning to attend the Microsoft Teams teleconference may email their name and contact information to the JEA

Buyer listed herein at least 48 hours prior to the Pre-Response meeting to facilitate roll call. A Respondent must only sign in representing one company, unless otherwise agreed to by JEA in writing.

1.8) Opening of Responses

All Responses received shall be publicly announced and recorded via Microsoft Teams at the date and time indicated on the cover page of this Solicitation.

The details for the Microsoft Teams will be on jea.com at the following website: https://www.jea.com approximately

48 hours before the Response opening.

At the opening of Responses, a JEA representative will publicly open each Response that was received prior to the

Date and Time, except for those Responses that have been properly withdrawn. JEA has the right to waive irregularities or informalities in the Responses to the extent allowable under applicable laws.

1.9) Alternate Provisions and Conditions (RFP&ITN)

Terms and conditions found in Responses that are contrary to requirements found in this Solicitation, including, but not limited to, the Contract terms and conditions contained in Section 2 of this Solicitation and any requirements found in the Technical Specifications attached as an exhibit or attachment to this Solicitation, will be rejected and are of no force and effect. However, JEA reserves the right to negotiate different terms and conditions and requirements if JEA determines that such terms and conditions and requirements are in the best interest of JEA.

1.10) Minimum Qualifications

Respondent must meet the following Minimum Qualifications to be considered eligible to have its Response evaluated by JEA. Respondents must complete and submit the Minimum Qualification Form provided in this Solicitation.

Respondents that are working or have worked for JEA in the past 2 years involving similar work must submit JEA as a reference. JEA reserves the right to ask for additional back up documentation or additional reference projects to confirm the Respondent meets the requirements stated above.

JEA may reject Responses from Respondents not meeting all of the following Minimum Qualifications:

I. Respondent must not be on the State of Florida Convicted Vendor List, State of Florida’s Suspended

Vendor List, the City of Jacksonville’s Disqualified Vendor List, have their bidding privileges actively suspended by JEA, been debarred by JEA, or have had a contract with JEA was terminated for default within the last two (2) years.

II. The respondent must be on the Responsible Bidder’s List (RBL) for Category EG7 Underground

Transmission Construction 69kV and Above - Solid Dielectric Cables

III. The Respondent shall comply with the technical and commercial specifications for this solicitation.

1.11) Number of Contracts to be Awarded

JEA intends to Award one (1) Contract for the Work. JEA reserves the right to Award more than one Contract based on certain groupings of the Work items, or JEA may exclude certain Work items, if JEA determines that it is in its best interest.

1.12) Insurance Requirements

Prior to JEA issuing a Purchase Order to the Company to begin the Work, the Company shall submit a certificate of insurance (COI) that is in compliance with amounts and requirements as indicated in this Solicitation. Note that the

COI shall specifically indicate JEA as additional insured on all required insurance except Worker's Compensation and

Professional Liability (if applicable). Furthermore, waiver of subrogation must be provided for all required insurance in favor of JEA, including its board members, officers, employees, agents, successors, and assigns.

1.13) Liquidated Damages In Contract

The Contract issued pursuant to this Solicitation contains liquidated damages tied to project completion deadlines. The

Respondent should review the specific time frames and liquidated damage amounts prior to submitting its Response.

1.14) Liquidated Damages

If the Company fails to obtain Substantial Completion of the Work within [40] days after the negotiated substantial completion date, the Company shall pay JEA the sum of [$1,000] per day for each and every calendar day, including

Sundays and Holidays, starting on this day until the date the Work obtains Substantial Completion.

Liquidated Damages are capped at a maximum of ten percent (10%) of the Contract Price.

The Company understands and agrees that said daily sum is to be paid not as a penalty, but as compensation to JEA as a fixed and reasonable amount for damages and losses that JEA will suffer because of such default, whether through increased administrative and engineering costs, interference with JEA's normal operations, other tangible and intangible costs, or otherwise, which costs will be impossible or impractical to measure or ascertain with any reasonable specificity.

Liquidated Damages may, at JEA's sole discretion, be deducted from any monies held by JEA that are otherwise payable to Company. The Company's responsibility for Liquidated Damages shall in no way relieve the Company of any other obligations under the Contract.

1.15) Jacksonville Small and Emerging Business (JSEB) Participation Goal - Optional

All questions and correspondence concerning the JSEB program should be addressed to the following contact:

Bill Hickey

Manager, Supplier Diversity Programs and Procurement Services

JEA

hickwj@jea.com or jsebprogram@jea.com

1.16) Basis of Award - Highest Evaluated

JEA will use the Selection Criteria listed below to evaluate the Responses. JEA may make its Award decision based solely upon the information submitted in the Responses. JEA may also choose to have one or more Respondent make presentations to representatives of JEA. It is always in the best interest of the Respondent to provide informative, concise, well-organized technical and business information relative to the Work, in both the initial submittal of its

Response and in any subsequent submittals.

Please note, JEA may reject Responses that request material changes or take exceptions to JEA commercial terms and conditions.

Responses will be scored and ranked by a committee of evaluators. Each evaluator will individually score the

Responses using the evaluation matrix attached to this Solicitation. Using these scores, each evaluator will rank the

Responses using "1" for the Response receiving the highest number of points from the matrix. Responses with an equal number of points will receive the same numerical ranking. JEA will total the numerical rankings for each

Response and consider the Response with the lowest total to be the most highly qualified Response. Any tie will be broken using the total of the matrix scores of all evaluators. If a tie persists, the tie will be broken in accordance with the JEA Procurement Operational Procedures.

1.17) Bid Bond

All Reponses shall be accompanied by a bid security in the amount stated on the Response Form. The bid security must be furnished by the Respondent at or before the opening of the Responses. The bid security shall either be issued by a surety company authorized to do business in the State of Florida, or Respondent shall furnish a certified check or cashier's check in the amount of five percent of the total amount shown on the Response Form. The JEA Bid Bond form can be found at jea.com. Failure to furnish the required bid security will disqualify the Response. If the

Respondent is awarded the Work and fails to execute the Contract within ten (10) days of postmarked date on the

Contract Documents, JEA shall retain the Bid Bond or check as liquidated damages.

1.18) Selection Criteria

The following criteria will be used by JEA to evaluate and rank Responses from Respondents who meet the Minimum

Qualifications specified in this Solicitation.

1.19) Quotation of Rates (RFP) (30 Points)

Respondent shall provide a completed Response form for scope of services in this solicitation. Additionally, if requested, the provider shall provide a completed the Response Workbook in Appendix B. The total Response price should be entered on the Proposal Form. The total Response price shall firm fixed prices, not estimates, and include all profit, taxes, benefits, and all other items. ANY MODIFICATIONS, EXCEPTION, OR OBJECTIONS CONTAINED

WITHIN THE RESPONSE FORM MAY SUBJECT THE RESPONSE TO DISQUALIFICATION.

1.20) Project Narrative (5 Points)

The Respondent shall provide a summary of the project to illustrate an understanding of what will be needed to successfully complete the project along with needed materials/permits. Additional points will be awarded to

Respondents who provide three potential critical paths with proposed solutions.

This deliverable shall be submitted as a separate PDF and labeled *CompanyName*_ProjectNarrative.pdf.

Evaluate:

• Narrative of Project

• Understanding of Project Critical Path

• Risk Management plan with proposed solutions to Critical Path Items

1.21) Work Plan & Resource Availability (15 Points)

The Respondent shall describe the work plan to complete the project successfully and meet JEA's milestones. The

Respondent shall include a demonstration of resource availability to complete the work in accordance with the schedule.

This can include presentation of prior work that demonstrates appropriate staffing and equipment levels to meet the project schedule. The work plan shall provide a detailed and logical sequence of work and describe a detailed breakdown of the following:

1. Procurement & Logistics Execution Plan

• Long-Lead Items (LLIs): Identify all critical path equipment and materials, including early engineering release and ordering strategies for LLIs.

• Supply Chain & Quality: Detail vendor pre-qualification, expediting procedures, and inspection plan for quality control. Note: All vendors need to be from JEA's approved manufacturers.

• Logistics & Material Control: Outline the strategy for shipping, site receipt, inventory tracking, and material preservation.

2. Construction Execution Plan

• Construction Methodology: Describe the physical build strategy, sequencing of trades, and any modularization or pre-fabrication strategies.

• Resource & Labor Management: Include a manpower chart with number of crews and equipment necessary for the project and details on subcontractor management.

This deliverable shall be submitted as a separate PDF and labeled

*CompanyName*_WorkPlan&ResourceAvailability.pdf.

• Overall procurement and construction plan

• Material lead times to successfully complete the project on or before the ISD

• Anticipated staff to successfully complete the project on or before the ISD

• Anticipated equipment to successfully complete the project on or before the ISD

1.22) Company Experience (30 Points)

The Respondent shall provide a summary of three (3) projects of similar scope, scale, and complexity. The examples should be able to demonstrate that the Team's experience and knowledge qualify them to complete the necessary work in a successful manner. The respondent shall have successfully completed three (3) similar projects in or along a City and FDOT ROW (underground electrical installation) in Florida within the past five (5) years ending on 8/31/2026.

Respondents that are working or have worked for JEA in the past 2 years involving similar work must submit JEA as a reference; should the supplier have more than one JEA projects within the defined period, supplier’s response shall only be composed of one (1) JEA projects and the remainer in other non-JEA projects unless only JEA projects can meet the requirements.

Provide the project reference company name, contact, phone, and email on the Minimum Qualification Form provided in Appendix B – Response Forms. Please also provide:

• a general summary of the project,

• a general summary of the results of the project related to work provided,

• if the project completed on the original agreed upon schedule and if not, a detailed reason for deviations,

• if the project completed on the original agreed upon contracted amount and if not, a not a detailed reason for deviations

• a project schedule of the completed project outlining all major milestones that were acheived on time to meet the

ISD

• project location

This deliverable shall be submitted as three separate PDF and labeled *CompanyName*_Reference1.pdf, *CompanyName*_Reference2.pdf, and *CompanyName*_Reference3.pdf.

1.23) Schedule (15 Points)

The Respondent shall provide a detailed preliminary project schedule that includes a comprehensive and realistic task breakdown, including clear durations, dependencies, and resource allocation. Clearly identifies key project milestones, aligns with critical path, and ensures adherence to JEA milestone and outage dates.

This deliverable shall be submitted as a separate PDF and labeled *CompanyName*_Schedule.pdf.

• Schedule provided by the bidder.

• Includes bulk material procurement timeline and aligns with construction milestones

• Includes subtasks for open cut and HDD sections

• Start Date is 12/14/2027

• Outages anticipated in Spring from 02/01 - 04/12. 2028

• Desired ISD date is 04/12/2028

1.24) Jacksonville Small Emerging Business (JSEB) (5 Points)

JEA will award points for utilizing a Jacksonville Small Emerging Business (JSEB) in the performance of the initial design scope of work. This can include surveying, SUE, geotechnical engineering, permitting, and design tasks. Future JSEB participation may be required for construction services, to be determined by JEA and the bidder during design. At this time, do not include JSEB participation for construction. Points will be assessed based on the percentage of work to be subcontracted to a JSEB firm for the initial design scope of work only. The bidder is to indicate the percentage of work that they will subcontract to a JSEB firm in their proposals.

Submissions missing required information will be scored lower.

• Overall JSEB commitment

• Bidder = JSEB, award 5 Points

• Subcontractor is JSEB at ≥ 5%, award 4 points

• Subcontractor is JSEB at ≥ 4%, award 3 points

• Subcontractor is JSEB at ≥ 3%, award 2 points

• Subcontractor is JSEB at ≥ 2%, award 1 point

• Subcontractor is JSEB at ≥ 1%, award 0 points

1.25) Safety Qualification Requirement

Respondent shall be in compliance with JEA's Contractor Safety Management Process policy. If the Respondent fails to obtain JEA approval as a JEA Safety Qualified company, JEA may terminate the Respondent’s contract.

JEA Safety information is available online at http://www.jea.com/About/Procurement/Contractor_Safety/. Please note that it may take up to ten (10) business days for a company to be approved as JEA Safety Qualified. It is the

Respondent’s responsibility to ensure it is following the JEA Safety policy. A list of the JEA's Safety Qualified vendors can be found on https://www.jea.com/About/Procurement/Contractor_Safety/.

To finalize Company JEA safety prequalified and work on JEA property companies will need to complete or have already completed the following training:

1. Contractor Supervisors working on site need to take or have taken the Supervisor Leadership Develop class (SLD)

– 1 day (8 hour) class offered the North Florida Safety Council on a monthly basis.

2. All company employees working on JEA sites will be required to take or have taken:

I. 10 Hour OSHA safety class, and

II. 2 hour JEA site specific or

I. CSSO that class covers both the OSHA – 10 and the JEA 2 hour site specific training.

II. Substation Electrical Safety

1.26) Payment and Performance Bond Amount and Requirements

After receipt of the Contract, the Company awarded the Work shall furnish a Payment and Performance Bond in the amount indicated on the Response Form, made out to JEA in forms and formats approved and provided by JEA, as security for the faithful performance of the Work of Contract. JEA will send the approved bond forms to the Company for execution along with the Contract, however, in no case shall the date on the bond forms be prior to that of the executed Contract. The surety must be authorized and licensed to transact business in Florida. A fully executed

Payment Bond and Performance Bond must be recorded with the Clerk of Duval County Court and delivered to JEA before JEA will issue a Purchase Order to begin the Work. No Purchase Order shall be issued until the Payment and

Performance Bonds are recorded and delivered to the JEA Procurement Department. If the Company fails or refuses to furnish or record the required bonds, JEA will retain the Company's Bid Bond as liquidated damages.

The Payment and Performance Bond requirements may be less than the full Contract amount. The Company should be aware that their bond premiums may be adjusted by their bonding company, if actual Work exceeds the amount of the bond, however, any increase in total premiums required will not be approved by JEA for any change in Contract price as either a change order or as an adjustment through the use of a Supplemental Work Authorization. Unless otherwise specified on the Bid Form, the Company shall be solely responsible for obtaining and maintaining the required

Payment and Performance Bonds throughout the term of the Contract. To be acceptable to JEA as Surety for

Performance and Payment Bonds, a Surety Company shall comply with the following provisions:

I. The Surety Company shall have a current and valid Certificate of Authority, issued by the State of

Florida, Department of Insurance, authorizing it to write surety bonds in the State of Florida.

II. The Surety Company shall have a current and valid Certificate of Authority issued by the United

States Department of Treasury under Sections 9304 to 9308 of Title 31 of the United States Codes.

III. The Surety Company shall be in full compliance with the provisions of the Florida Insurance Code.

IV. The Surety Company shall have at least twice the minimum surplus and capital required by the Florida

Insurance Code during the life of this agreement.

V. If the Contract Award Amount exceeds $500,000, the Surety Company shall also comply with the following provisions:

The Surety Company shall have at least the following minimum ratings in the latest issue of A.M. Best's Key Rating

Guide.

POLICY HOLDER'S CONTRACT AMOUNT AND REQUIRED FINANCIAL RATING:

$500,000 TO 1,000,000: A-CLASS IV

$1,000,000 TO 2,500,000: A-CLASS V

$2,500,000 TO 5,000,000: A-CLASS VI

$5,000,000 TO 10,000,000: A-CLASS VII

$10,000,000 TO 25,000,000: A- CLASS VIII

$25,000,000 TO 50,000,000: A- CLASS IX

$50,000,000 TO 75,000,000: A- CLASS X

http://www.jea.com/About/Procurement/Contractor_Safety https://www.jea.com/About/Procurement/Contractor_Safety/

The Surety Company shall not expose itself to any loss on any one risk in an amount exceeding ten (10) percent of its surplus to policyholders, provided: Any risk or portion of any risk being reinsured shall be deducted in determining the limitation of the risk as prescribed in this section. These minimum requirements shall apply to the reinsuring carrier providing authorization or approval by the State of Florida, Department of Insurance, to conduct business in this state has been met.

In the case of the surety insurance company, in addition to the deduction for reinsurance, the amount assumed by any co-surety, the value of any security deposited, pledged or held subject to the consent of the surety and for the protection of the surety shall be deducted.

1.27) Subcontractors Use for the Performance of the Work

The Respondent must list the names of the major Subcontractors that it intends to use for this Work, unless the Work will be self-performed by the Respondent. The Subcontractors must be listed on the Subcontractors Form which is available at jea.com. Failure to submit this form with the Response may result in rejection of Respondent's Response.

The Respondent shall not use Subcontractors other than those shown on the Subcontractor Form unless it shows good cause and obtains the JEA Representative's prior written consent.

If the Respondent plans to use Subcontractors to perform over 50% of the Work, the Respondent shall obtain JEA's approval at least five days prior to the Response Due Date. Failure to obtain JEA approval may result in rejection of the Respondent's Response.

1.28) Shipping, Freight, And Travel--F.O.B. Destination

The Respondent shall include the price for travel, shipment of materials and equipment in its pricing shown on its

Response unless otherwise stated herein. The shipment of all materials shall be F.O.B. Destination.

If the Solicitation allows for travel expenses to be billed separately, then all the Respondent’s travel expenses will be reimbursed in accordance with JEA's Contractor Travel Policy.

1.29) Required Forms to be Submitted

The following forms must be completed and submitted to JEA at the timeframes stated below. The Respondent can obtain the required forms, other than the Minimum Qualification Form, Response Form and Response Workbook, by downloading them from JEA.com.

A. The following forms are required to be submitted with the Response:

I. Minimum Qualifications Form- This form can be found in Appendix B of this Solicitation

II. Response Form- This can be found in Appendix B of this Solicitation

III. Response Workbook - This can be found in Appendix B of this Solicitation

IV. List of JSEB Certified Firms (if any)

V. Subcontractor Form (if any). However, if the following Subcontractors are utilized to perform this

Work, they shall be listed on the referenced Subcontractor Form: a. Electrical, b. Plumbing, c.

HVAC, d. Instrument and controls (I&C), e. Equipment Suppliers (i.e., pumps, fans, etc..), f. Material

Suppliers, g. Roofing, h. Fuel, I. Mechanical Engineer, j. Fire Protection, h. etc.

If the above listed forms are not submitted with the Response by the Response Due Time and Date, JEA may reject the

Response.

B. JEA also requests the following documents to be submitted prior to Contract execution. A Response will not be rejected if these forms are not submitted at the Response Due Date and Time. However, failure to submit these documents prior to Contract execution could result in Response rejection.

I. Conflict of Interest Certificate Form - This form can be found at JEA.com

II. Insurance certificate

III. W-9

IV. Evidence of active registration with the State of Florida Division of Corporations (www.sunbiz.org)

V. Any technical submittals as requires by the Technical Specifications

1.30) Addenda Issuance

JEA may issue Addenda prior to the opening of Responses to change or clarify the intent of this Solicitation. The

Respondent is responsible for ensuring it has received all Addenda prior to submitting its Response and must acknowledge receipt of all Addenda by completing the Confirmation of Receipt of Addenda. JEA will post Addenda when issued online at JEA.com. Companies must obtain Addenda from the JEA.com website. It is the responsibility of each Respondent to ensure it has received and incorporated all Addenda into its Response. Failure to acknowledge receipt of Addenda may be grounds for rejection of a Response.

1.31) Contract Execution and Start of Work

Within 30 days from the date of Award, JEA will present the successful Respondent with the Contract. Unless expressly waived by JEA, the successful Respondent must execute a Contract for the Work within 10 days after receiving the Contract from JEA. If the Respondent fails to execute the Contract or associated documents as required, JEA may cancel the Award with no further liability to the Respondent and retain any bid security or bond.

Upon JEA's receipt of the executed Contract, certificate of insurance, and recorded Payment and Performance bonds

(if applicable), JEA will issue a PO, in writing and signed by an authorized JEA representative as acceptance of the

Response and authorization for the company to proceed with the Work, unless otherwise stated in the Contract or PO.

For Construction Services: In the event that JEA intends to authorize the successful Respondent to proceed with administrative work only, or with only a portion of the Work, then the PO shall state the specific limitations of such authorization and JEA will issue a separate written Notice to Proceed to authorize the Respondent to begin Field Work, when applicable, or to perform the remainder of the Work, or any portion thereof. The Respondent shall ensure that it is prepared to begin Field Work upon receipt of Notice to Proceed. Any Work performed outside of this partial authorization shall be at the Respondent's risk and JEA shall have no obligation to pay for such Work.

1.32) Ex Parte Communication

Ex Parte Communication is defined as any inappropriate communication concerning a Solicitation between any officers, employees or other representatives of Respondent and a JEA representative during the time in which the

Solicitation is being advertised through the time of Award. Examples of inappropriate communications include:

private communications concerning the details of the Solicitation in which a company becomes privy to information not available to the other Respondents. Social contact between companies and JEA Representatives should be kept to an absolute minimum during the Solicitation process.

Ex Parte Communication is strictly prohibited. Failure to adhere to this policy will disqualify the noncompliant

Respondent. Any questions or clarifications concerning this Solicitation must be sent in writing via email to the JEA

Buyer at least five business days prior to the opening date. If JEA determines that a question should be answered or a requirement should be clarified, JEA will issue an Addendum to the Solicitation.

1.33) Conflict of Interest

This conflict of interest policy applies to all JEA construction projects ("Project"). Any company bidding the construction phase of a Project cannot at the time of Response/bid submittal, be affiliated with or have any direct or indirect ownership interest in the architect/engineer ("Designer") of record. The company will also be prohibited from bidding if the Designer has any direct or indirect ownership interest in the Contractor. Should JEA erroneously award a contract in violation of this policy, JEA may terminate the contract at any time with no liability to company, and company shall be liable to JEA for all damages, including but not limited to the costs to rebid the Project. The purpose of this policy is to encourage bidding and eliminate any actual or perceived advantage that one Respondent may have over another.

1.34) Certifications and Representations of the Company

By signing and submitting its Response, the Respondent certifies and represents as follows:

A. That the individual signing the Response is duly authorized to contractually bind the Respondent to the terms and conditions of this Solicitation and the Contract. Respondent shall provide satisfactory evidence of such authority within three days of JEA’s request.

B. That every aspect of the Response and the detailed schedule for the execution of the Work, are based on its own knowledge and judgment of the conditions and hazards involved, and not upon any representation of JEA. JEA assumes no responsibility for any understanding or representation made by any of its representatives during or prior to execution of the Contract unless such understandings or representations are expressly stated in the Contract and the

Contract expressly provides that JEA assumes the responsibility.

C. That, if successful, the Respondent will be registered to conduct business in the State of Florida and in active status with the Florida Division of Corporations at the time of execution of a Contract.

D. That the Respondent maintains in active status any and all licenses, permits, certifications, insurance, bonds and other credentials including, but not limited to, all licenses necessary to perform the Work. The Respondent also certifies that, upon the prospect of any change in the status of applicable licenses, permits, certifications, insurances, bonds or other credentials, the Respondent shall immediately notify JEA of status change.

1.35) Ethics

By submitting a Response, the Respondent certifies that its Response is made without any previous understanding, agreement or connection with any other person, firm, or corporation submitting a Response for the same Work other than as a Subcontractor or supplier, and that the Response is made without outside control, collusion, fraud, or other illegal or unethical actions. The Respondent shall comply with all JEA and City of Jacksonville ordinances, policies and procedures regarding ethics.

The Respondent shall submit only one Response to this Solicitation. If JEA has reasonable cause to believe the

Respondent has submitted more than one Response for the same Work, other than as a Subcontractor or sub-supplier, JEA shall disqualify the Response and may pursue debarment actions.

The Respondent shall disclose the name(s) of any public officials who have any financial position, directly or indirectly, in Respondent or its Response by completing and submitting the Conflict of Interest Certificate Form available at jea.com. Failure to fully complete and submit the Conflict of Interest Certificate will disqualify the

Response. If JEA has reason to believe that collusion exists among the Respondents, JEA shall reject any and all

Responses from such Respondents and will proceed to debar the Respondents from future JEA Awards in accordance with the JEA Procurement Code.

JEA is prohibited by its Charter from awarding contracts to JEA board members, officers or employees, and is prohibited from awarding contracts in which a JEA officer or employee has a financial interest. JEA shall reject all

Responses from JEA board members, officers or employees, as well as, all Responses in which a JEA officer or employee has a financial interest.

In accordance with Florida Statutes Sec. 287.133, JEA shall reject Responses from any persons or affiliates convicted of a public entity crime as listed on the Convicted Vendor list maintained by the Florida Department of Management

Services. JEA shall not make an Award to any officer, director, executive, partner, shareholder, employee, member, or agent active in management of the Respondent listed on the Convicted Vendor list for any transaction exceeding

$35,000 for a period of 36 months from the date of being placed on the Convicted Vendor list.

JEA shall also reject any Responses from any persons or affiliates that are listed on State of Florida’s Suspended

Vendor List, the City of Jacksonville’s Disqualified Vendor List, JEA’s Suspended Vendors list, or have had a contract with JEA terminated for default within the last two (2) years.

1.36) JEA Publications

Applicable JEA publications are available at jea.com.

1.37) Mathematical Errors

In the event of a mathematical error in calculation of the prices entered on the Response, the Unit Prices will prevail.

The corrected price utilizing the Unit Prices quoted by Respondent will be used to determine if the Company is awarded a Contract for the Work and the corrected pricing will be used throughout the Term.

1.38) Modification or Withdrawal of Responses

The Respondent may modify or withdraw its Response at any time prior to the Response Due Date and Time by giving written notice to JEA's Chief Procurement Officer by submitting an updated Response. JEA will not accept modifications submitted by telephone, telegraph, email, or facsimile, or those submitted after the Response Due Date and Time. The Respondent may not modify or withdraw its Response for a period of 90 days following the opening of

Responses.

1.39) Notice of Prohibition Against Considering Social, Political, or Ideological Interests

Pursuant to Section 287.0501, Florida Statutes, JEA may not:

(i) Request documentation of or consider a vendor’s social, political, or ideological interests when determining whether a vendor is a responsible vendor; or

(ii) Give preference to a vendor based on the vendor’s social, political, or ideological interests.

1.40) Prohibition Against Contingent Fees

The Respondent warrants that it has not employed or retained any company or person, other than a bona fide employee working for the Respondent, or an independent sales representative under contract with the Respondent, to solicit or secure a contract with JEA, and that it has not paid or agreed to pay any person, company, corporation, or other individual, other than a bona fide employee working solely for the Respondent, or an independent sale representative under contract with the Respondent, any fee, commission, percentage, gift, or any other consideration, contingent upon or resulting from the Award or the Contract. If a breach or violation of the provisions occurs, JEA shall have the right to terminate the Contract without liability, and at its discretion, to deduct from the Contract Price, or otherwise recover, the full amount of such fee, commission, percentage, gift or consideration.

1.41) Protest of Solicitation and Award Process

Any protests regarding this Solicitation must be filed in writing and in accordance with the JEA Procurement Code, as amended from time to time. The JEA Procurement Code is available online at www.jea.com.

1.42) Availability Of Response After Opening

In accordance with the Florida Public Records Law, Florida Statutes, Chapter 119, copies of all Responses are available for public inspection thirty (30) days after the opening of Responses or on the date of Award announcement, whichever is earlier. Respondents may review opened Responses once they are available for public inspection by contacting the designated JEA Buyer or JEA's Public Records custodian whose contact information can be found at jea.com. JEA will post a summary of the Response results immediately after the Response opening.

1.43) Reservation of Rights of JEA

This Solicitation provides potential Respondents with information to enable the submission of written offers. This

Solicitation is not a contractual offer or commitment by JEA to purchase products or services.

JEA reserves the right to reject all Responses, and to waive informalities if JEA deems such action to be in its best interest. JEA may reject any Responses that it deems incomplete or irregular including, but not limited to, Responses that omit a price on any one or more items for which prices are required, Responses that omit Unit Prices if Unit Prices are required, Responses that offer equal items when the option to do so has not been stated, and Responses that fail to include a Bid Bond, where one is required.

JEA reserves the right to cancel, postpone, modify, reissue and amend this Solicitation at its discretion.

JEA reserves the right to cancel or change the date and time announced for opening of Responses at any time prior to the time announced for the opening of Responses. JEA may Award the Contract in whole or in part. JEA may award multiple or split Contracts if it is deemed to be in JEA's best interest.

1.44) Sunshine Law

Article I, Section 24, Florida Constitution, guarantees every person access to all public records and Chapter 119, Florida Statutes, provides a broad definition of public records. JEA is subject to these laws and related statutes

("Florida's Public Records Laws"). All Responses to this Solicitation or RFI are public record and available for public inspection unless specifically exempt by law.

If a Respondent believes that any portion of the documents, data or records submitted in response to this Solicitation or RFI are exempt from Florida's Public Records Law, Respondent must (1) clearly segregate and mark the specific sections of the document, data or records as "Confidential," (2) cite the specific Florida Statute or other legal authority for the asserted exemption, and (3) provide JEA with a separate redacted copy of its Response (the "Redacted Copy").

The cover of the Redacted Copy shall contain JEA's title and number for this Solicitation or RFI and Respondent's name, and shall be clearly labeled "Redacted Copy." Respondent should only redact those portions of records that

Respondent claims are specifically exempt from the Florida Public Records Laws. If Respondent fails to submit a redacted copy of information it claims is confidential, JEA is authorized to produce all documents, data and other records submitted to JEA in answer to a public records request for such information.

In the event of a request for public records to which documents that are marked as confidential are responsive, JEA will provide the Redacted Copy to the requestor. If a requestor asserts a right to any redacted information, JEA will notify Respondent that such an assertion has been made. It is Respondent's responsibility to respond to the requestor to assert that the information in question is exempt from disclosure under applicable law. If JEA becomes subject to a demand for discovery or disclosure of Respondent's redacted information under legal process. JEA shall give

Respondent prompt notice of the demand prior to releasing the information (unless otherwise prohibited by applicable law.) Respondent shall be responsible for defending its determination that the redacted portions of its Response are not subject to disclosure.

By submitting a Response to this Solicitation or RFI, Respondent agrees to protect, defend, and indemnify JEA from and against all claims, demands, actions, suits, damages, losses, settlements, costs and expenses (including but not limited to reasonable attorney fees and costs) arising from it relating to Respondent's determination that the redacted portions of its Response to this Solicitation or RFI are not subject to disclosure.

IF THE COMPANY HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA

STATUTES, TO THE COMPANY'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS

CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT:

JEA

Attn: Public Records

225 North Pearl Street

Jacksonville, FL 32202

Ph: 904-665-8606 publicrecords@jea.com

1.45) Scrutinized Companies

Pursuant to Section 287.135(2), Florida Statutes, a company is ineligible to, and may not, bid on, submit a proposal for, or enter into or renew a contract with an agency or local government entity for goods or services of:

(1) Any amount if, at the time of bidding on, submitting a proposal for, or entering into or renewing such contract, contractor is on the Scrutinized Companies that Boycott Israel List, created pursuant to Section 215.4725, Florida Statutes, or is engaged in a boycott of Israel; or

(2) One million dollars or more if, at the time of bidding on, submitting a proposal for, or entering into or renewing such contract, contractor:

i. Is on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List created pursuant to Section 215.473, Florida Statutes; or

ii. Is engaged in business operations in Cuba or Syria.

Pursuant to Section 287.135(3)(a)4, Florida Statutes, JEA may terminate this Contract at JEA’s option if this Contract is for goods or services in an amount of one million dollars or more and the Company:

(1) Is found to have submitted a false certification under Section 287.135(5), Florida Statutes;

(2) Has been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List created pursuant to Section 215.473, Florida Statutes;

(3) Is engaged in business operations in Cuba or Syria.

Pursuant to Section 287.135(3)(b), Florida Statutes, JEA may terminate this Contract at JEA’S option if this Contract is for goods and services of any amount and Company:

(1) Is found to have been placed on the Scrutinized Companies that Boycott Israel List; or

(2) Is engaged in a boycott of Israel.

1.46) Defined Terms

Words and terms defined in the section entitled "Definitions" of this document are hereby incorporated by reference into the entire document.

2) Contract Terms and Conditions 2.1) Contract Document Terms and Conditions

Section 2 of this Solicitation contains JEA’s general terms and conditions that will govern the Contract awarded under this Solicitation. The Contract Documents will incorporate by reference all of the terms and conditions of this

Solicitation, including all Technical Specifications, Appendices, Exhibits, Schedules and Forms included with this

Solicitation. An example of the Contract that the Company will be required to execute is available for review at jea.com.

2.2) Definitions

Capitalized words and terms used in this Solicitation shall have the meaning given to them in this Section 2. The

Technical Specifications to this Solicitation may define additional words and terms where necessary to clarify the

Work. Unless otherwise stated in this Solicitation or the Contract Documents, definitions set forth in Technical

Specifications shall apply only within the Technical Specifications.

2.3) Acceptance

JEA's written notice by the Project Manager to the Company that all Work as specified in the Contract, or a portion of the Work as specified in a Task or Work Order, has been completed to JEA's satisfaction.