140L3621Q0015.pdf

140L3621Q0015

1. REQUEST NO.

5a. ISSUED BY

NAME

a. NAME

c. STREET ADDRESS

d. CITY

10. PLEASE FURNISH QUOTATIONS TO

THE ISSUING OFFICE IN BLOCK 5a ON

OR BEFORE CLOSE OF BUSINESS (Date)

2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG.1

RATING

6. DELIVERY BY (Date)

7. DELIVERY

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

PAGE OF PAGES

5b. FOR INFORMATION CALL: (No collect calls)

TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANY

e. STATE f. ZIP CODE

c. CITY

d. STATE e. ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

THIS RFQ

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

IS IS NOT A SMALL BUSINESS SET ASIDEX

06/24/2021

1 45

5001 SOUTHGATE DR.

BILLINGS MT 59101

BLM MT-STATE OFC(MT935)

03/30/2022

BLM-MT MONTANA STATE OFFICE*

5001 SOUTHGATE DR.

BILLINGS

MT 59101-4669

406 896-5148Velvett Cummins

07/26/2021 1700 ES

FOB DESTINATION

OTHER

(See Schedule)X

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

2021 First Peoples Catalog and Curation Legacy Doc #: BLM Period of Performance: 10/01/2021 to 03/30/2022

00010 PHOTO ARCHIVIST FY2020

Product/Service Code: B525 Product/Service Description: SPECIAL

STUDIES/ANALYSIS- NATURAL RESOURCE

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations

13. NAME AND ADDRESS OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

a. NAME OF QUOTER

AREA CODE

NUMBER

15. DATE OF QUOTATION

b. TELEPHONE are are not attached

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA - FAR (48 CFR) 53.215-1(a)

2021 First Peoples Catalog and Curation

Contents

SECTION C: DESCRIPTION/SPECIFICATIONS/SCOPE OF WORK

SECTION D: PACKAGING AND MARKING

SECTION E: INSPECTION AND ACCEPTANCE

SECTION F: DELIVERIES OR PERFORMANCE

SECTION G: CONTRACT ADMINISTRATION DATA

SECTION H: SPECIAL CONTRACT REQUIREMENTS

SECTION I: CONTRACT CLAUSES

SECTION J: LIST OF ATTACHMENTS

SECTION K: REPRESENTATIONS AND CERTIFICATIONS

SECTION L: INSTRUCTIONS, CONDITIONS AND NOTICE TO OFFERORS

SECTION M: EVALUATION FACTORS FOR AWARD

52.212-2 -- Evaluation -- Commercial Items (Jan 1999)

SECTION C: DESCRIPTION/SPECIFICATIONS/SCOPE OF WORK

SECTION C

DESCRIPTION/SPECIFICATIONS/SCOPE OF WORK

FY 2021 Bureau of Land Management, Billings Curation Center, Archaeological Curation and Library Re-inventory Project

I. General Background.

A. The Bureau of Land Management's (BLM) Billings Curation Center (BCC) is the primary repository for archaeological collections originating from BLM lands in Montana, North Dakota and South Dakota. The BLM is required to identify, evaluate, and protect prehistoric and historic cultural resources originating from public lands under its jurisdiction; and to ensure that Bureau initiated or Bureau authorized actions do not inadvertently harm or destroy cultural resources. These requirements are mandated by the National Historic Preservation Act and related regulations found at 36 CFR 800.

II. Specific Background.

The Bureau of Land Management (BLM) Billings Curation Center (BCC) proposes to complete two curation and library reorganization projects under this proposed contract; a.) Processing and cataloging the First People’s Bison Jump to BCC’s b.) Conducting an inventory and reorganization of the BCC’s 12,000 volume library.

A. The Bureau of Land Management (BLM), Montana State Office (MTSO) Billings Curation Center proposes to create a digital archive of all documents associated with BCC accessioned archaeological/Cultural projects representing the cultural history of the northern great plains.

B. All of the work shall be conducted on premises, during posted business hours.

C. All cataloging work (b) shall be completed in accordance with BCC Packaging standards (attached)

D. All supplies needed in performance of these objectives will be supplied by the MTSO/BLM.

III. Statement of Work.

A. The Contractor shall:

1. Have appropriate educational requirements.

2. Be eligible for DOI security clearance.

3 Process and catalog, in accordance with the Billings Curation Center’s packaging requirements, a 56 cubic ft. collection of archaeological material from the First

People’s Bison Jump project held at the BCC. Collections will need to be inventoried, labeled, repackaged, and added to the BCC’s Unix/Informix database. Also, an accession file will need to be created and digitized. (est. time, 3 months at a 40hr/wk schedule)

4. Conduct a re-inventory of the Billings Curation Center’s 12,000 volume library. This will include possibly relocation of material, removal of duplicates. Cull materials that do not reflect the collection guidelines of the BCC, along with excess copies of relevant material. Conduct inventory of digital records to reflect accurate record of library materials. Rewrite labels in physical materials to reflect library locations. (est.

time, 3 months at a 40hr.wk schedule)

5. Contractor shall begin work October 1, 2021

6. Personnel performing the work must meet the following criteria for qualification:

1) Bachelor degree in History, Library Science, Museum Studies and/or Anthropology with an archeology emphasis; 2) Graduate Level coursework in Museum Studies, Archaeology, Archival Science; 3) one year of full-time professional experience in the processing of archival/museum collections. 4.) Background in Northern Plains Archaeology.

E. Methodologies.

The Contractor shall adhere to the BCC's Packaging Requirements - 2009 (attachment 1).

F. Specifications and Standards.

SECTION D

INSPECTION AND ACCEPTANCE

I. Inspection.

A. Inspection, in the form of a review at each stage of the process, (sorting, digitizing, labeling) will be performed by the Project Inspector (PI). Accordingly, all reports, data, and documentation required by the contract will be submitted to the PI who will recommend approval/disapproval for acceptance purposes to the Contracting Officer.

II. Acceptance.

B. Final acceptance of all items/services to be delivered under this contract shall be the responsibility of the Contracting Officer. Final payment may be withheld pending completion of any necessary rework by the Contractor.

SECTION E

DELIVERIES OR PERFORMANCE

I. Deliverables.

Submitted to the following:

A.

B.

C.

II. Period of Performance

A. Contractor must start October 1, 2021.

B. Contractor must conduct work within posted BLM business hours.

C. Contractor must be complete within 12 months of start date.

III Address for Deliverables:

David K. Wade, Project Inspector Bureau of Land Management Montana State Office 5001 Southgate Drive Billings, MT 59101

IV Contractor Invoicing and Payment:

Invoicing and payments are to be submitted monthly.

SECTION F

SECTION G

SPECIAL CONTRACT REQUIREMENTS

I. Pre-Work Conference and Notice to Proceed.

A. Immediately after award, a pre-work conference shall be held between the Contractor and the PI and CO. The date and time of the meeting shall be determined by the PI and the Contractor in consultation.

Discussions pertaining to contract requirements and the specific responsibilities of each party will be conducted at this time.

II. Key Personnel.

A. The Contractor agrees that key personnel; i.e, those in direct charge of the work identified in the Contractor's proposal shall be those utilized in the performance of this contract. Any changes must be approved by the Contracting Officer prior to initiation of field work.

III. Confidentiality of Information.

A. Specific site locational data, which would allow location of cultural resource sites identified during performance of this contract, shall not be released by the Contractor to anyone except the BLM, without the written consent of BLM.

IV. Copyright.

A. The Contractor agrees to indemnify the government against any claim of copyright infringement which may result by reason or publication by the government of material in any report pertaining to the contract work submitted by the Contractor. The Contractor agrees that no copyright by statute shall be established by the Contractor in any materials produced in this contract, and that all materials and deliverables become government property.

V. Fire Danger Season

If the COR allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

VI. Electronic Invoicing and Payment Requirements – Internet Payment Platform (IPP)(AUG 2009) All payment requests must be submitted by Suppliers electronically through the U.S. Department of the Treasury Financial Management Service (FMS), in partnership with the Federal Reserve Bank of Boston (FRBB), a fiscal agent of the U.S. Treasury, is offering the IPP service for use by Federal Government agencies and their suppliers at no charge. The IPP facilitates the conversion of paper-based processes to electronic interactions by providing a Web-based portal for easy data access at no charge to Agencies and their Suppliers. NOTE: The Internet Payment Platform (IPP) is the Department of the Interior (DOI) preferred method of submitting invoices for payment.

“Payment request” means any request for contract financing payment or invoice payment by the Supplier.

To constitute a proper invoice, the payment request must comply with the requirements identified in FAR 32.905(b), “Payment Documentation and Process” and FAR 52.232-25.

Suppliers can enroll to access and use IPP for submitting requests for payment by going to the website http://www.ipp.gov/. Supplier assistance with enrollment can be obtained by contacting the FBMS Customer Support Desk at 703-793-5575 or email FBMS_IPP@FBMS.doi.gov.

If your firm is unable to comply with using IPP for submitting invoices for payment due to lack of an account with a financial institution; a physical or mental disability; a geographic, language, or literacy barrier; or a financial hardship, then you must inform the contracting officer orally or in writing

VIII. H.4 9.1510.018 Preservation of Historical and Archeological Data APRIL 1998

(a) Public Law 93-291, May 24, 1974, provides for the preservation of scientific, pre-historical, and archeological data (including relics and specimens) which might otherwise be lost due to alteration of the terrain as a result of any Federal construction project.

(b) The Contractor agrees that should he or any of his employees in the performance of this contract discover evidence of possible scientific, pre-historical, or archeological data he will notify the Contracting Officer immediately in writing giving the location and nature of the findings.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the applicable clauses in the Contract Clauses Section of this contract.

(d) The Contractor agrees to insert this paragraph in all subcontracts which involve the performance of work on the terrain of the site.

I. DOI ELECTRONIC INVOICING-- Electronic Invoicing and Payment Requirements – Invoice Processing Platform (IPP) (May 2013)

Payment requests must be submitted electronically through the U.S. Department of the Treasury Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the clause 52.212-4 Contract Terms and Conditions – Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov

Under this contract, an itemized invoice is required to be submitted as an attachment to the IPP invoice. Deliverables are to be received and accepted prior to payment. Invoices submitted prior to acceptance may be rejected. The following document is required to be included as an attachment to the electronic invoice: A detailed description of the progress to date.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instruction via email from the Federal Reserve Bank of Boston (FRBB) prior to the contract award date, but no more than 3 -5 business days of the contract award date.

Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via emailippgroup@bos.frb.org or phone (866) 973-3131.

https://www.ipp.gov/ mailto:ippgroup@bos.frb.org

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Office with its proposal or quotation.

Section 2—Contract Clauses

52.252-2 – Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses incorporated by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address: http://farsite.hill.af.mil/vffara.htm

(End of Clause)

52.204-9 -- Personal Identity Verification of Contractor Personnel (Jan 2011) 52.204-13 -- System for Award Management Maintenance (Oct 2018) 52.204-18--Commercial and Government Entity Code Maintenance (Jul 2016) 52.211-17 -- Delivery of Excess Quantities (Sep 1989) 52.212-4 -- Contract Terms and Conditions -- Commercial Items (Oct 2018) 52.223-2 -- Affirmative Procurement of Biobased Products Under Service and Construction Contracts (Sep 2013) 52.224-1 -- Privacy Act Notification (Apr 1984) 52.224-2 -- Privacy Act (Apr 1984) http://farsite.hill.af.mil/vffara.htm

52.232-18 -- Availability of Funds (Apr 1984) 52.232-39 – Unenforceability of Unauthorized Obligations (Jun 2013) 52.232-40 – Providing Accelerated Payments to Small Business Subcontractors (Dec 2013) 52.233-4 -- Applicable Law For Breach Of Contract Claim (OCT 2004) 52.237-3 -- Continuity of Services (Jan 1991) 52.247-34 -- F.o.b. – Destination (Nov 1991)

52.211-18 -- Variation in Estimated Quantity (Apr 1984) 1510.11.703-70 (June 2000) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of thecontract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified. (End of Clause) 52.249-1 -- Termination for Convenience of the Government (Fixed-Price) (Short Form) (Apr 1984)

The Contracting Officer, by written notice, may terminate this contract, in whole or in part, when it is in the Government’s interest. If this contract is terminated, the rights, duties, and obligations of the parties, including compensation to the Contractor, shall be in accordance with Part 49 of the Federal Acquisition Regulation in effect on the date of this contract.

52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (Jan 2021)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108- 77, 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.]

(c) _X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with

Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

(d) (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C.

3509).

(e) (3) 52.203-15, Whistleblower Protections under the American Recovery and

Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

(f)

(4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note).

(5) [Reserved]

(6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

(7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

(8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note).

(9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

(10) [Reserved]

(11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

(ii) Alternate I (Nov 2011) of 52.219-3.

(12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

(ii) Alternate I (Jan 2011) of 52.219-4.

(13) [Reserved]

_X (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644).

(ii) Alternate I (Nov 2011).

(iii) Alternate II (Nov 2011).

(15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15U.S.C.

644).

(ii) Alternate I (Oct 1995) of 52.219-7.

(iii) Alternate II (Mar 2004) of 52.219-7.

(16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C.

637(d)(2) and (3)).

(17) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637 (d)(4)).

(ii) Alternate I (Nov 2016) of 52.219-9.

(iii) Alternate II (Nov 2016) of 52.219-9.

(iv) Alternate III (Nov 2016) of 52.219-9.

(v) Alternate IV (Nov 2016) of 52.219-9.

_X (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

(19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)).

(20) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

(21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657f).

_X (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

(23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

(24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

_X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

(31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

_X (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

(ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627).

(34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

(35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016).

(Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017).

Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(36) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016).

(37) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA- Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

(ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicableto the acquisition of commercially available off-the-shelf items.)

(38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693).

(39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693).

(40) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514

(ii) Alternate I (Oct 2015) of 52.223-13.

(41) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014)(E.O.s 13423 and 13514).

(ii) Alternate I (Jun 2014) of 52.223-14.

(42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

(43) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal ComputerProducts (Oct 2015) (E.O.s 13423 and 13514).

(ii) Alternate I (Jun 2014) of 52.223-16.

_X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513).

(45) 52.223-20, Aerosols (Jun 2016) (E.O. 13693).

(46) 52.223-21, Foams (Jun 2016) (E.O. 13696).

(47) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(ii) Alternate I (Jan 2017) of 52.224-3.

_X (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

(49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43).

(ii) Alternate I (May 2014) of 52.225-3.

(iii) Alternate II (May 2014) of 52.225-3.

(iv) Alternate III (May 2014) of 52.225-3.

(50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X (51) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42U.S.C.

5150).

(54) 52.226-5, Restrictions on Subcontracting Outside Disaster or EmergencyArea (Nov 2007) (42 U.S.C. 5150).

(55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002)(41 U.S.C. 4505), 10 U.S.C. 2307(f)).

(56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C.

4505, 10 U.S.C. 2307(f)).

_X (57) 52.232-33, Payment by Electronic Funds Transfer— System for Award Management (Jul 2013) (31 U.S.C. 3332).

(58) 52.232-34, Payment by Electronic Funds Transfer—Other Than Systemfor Award Management (Jul 2013) (31 U.S.C. 3332).

(59) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

(60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

(61) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C.

637(d)(12)).

(62) (i) 52.247-64, Preference for Privately Owned U.S.-Flag CommercialVessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

(ii) Alternate I (Apr 2003) of 52.247-64.

(g) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

(1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495)

_X (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.).

_X (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

30021 Archeological Technician $16.19

(4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67).

(5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

(6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

(7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67).

(8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O.

13658).

(9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O.

13706).

(10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792).

(11) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C.

5112(p)(1)).

(h) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records --

Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arisingunder or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(i)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) ofthis clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C.

637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities.

If the subcontract (except subcontracts to small business concerns) exceeds

$700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495).

Flow down required in accordance with paragraph (1) of FAR clause 52.222-17.

(v)

_X (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126).

_X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X (28) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C.

793).

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(vi) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(ix) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

(x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xi) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67).

(xii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C.

chapter 78 and E.O. 13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).

(xiii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xiv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41U.S.C.

chapter 67)

(xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989).

(xvi) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xvii) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016) (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017).

Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the FederalRegister advising the public of the termination of the injunction.

(xviii) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016).

(xix) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O.

13706).

(xx) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xxi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxiii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercialitems a minimal number of additional clauses necessary to satisfy its contractualobligations.

SECTION J: LIST OF ATTACHMENTS

Attachment 1-- Billings Curation Center Packaging Attachment 2-- Relevant Experience and Past Performance Attachment 3-- Service Contract Wage Rates

SECTION K: REPRESENTATIONS AND CERTIFICATIONS

Section 4—Contract Provisions

52.252-1 -- Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address: http://farsite.hill.af.mil/vffara.htm

52.204-7 -- System for Award Management (Oct 2018) 52.204-16 --Commercial and Government Entity Code Reporting (Jul 2016) 52.212-1 -- Instructions to Offerors -- Commercial Items (June 2020) 52.225-2 -- Buy American Certificate (May 2014) 52.246-4 -- Inspection of Services -- Fixed-Price (Aug. 1996) http://farsite.hill.af.mil/vffara.htm

52.212-3 -- Offeror Representations and Certifications -- Commercial Items (Feb 2021)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through

(u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by anycourt of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoinedor restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’ “. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

http://www.sam.gov/portal http://www.dol.gov/fairpayandsafeworkplaces

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(vi) The Family and Medical Leave Act; and

(vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP)for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 andthe Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror.

Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the VietnamEra Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000- 9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to http://www.osha.gov/dcsp/osp/approved_state_plans.html the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174).

Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technologythat is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently ownedand operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding

$750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women;

and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”,…