Sol_140L0619Q0041.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040443777

BLM OC-NOC CONST A&E SEC(OC664)

DENVER FEDERAL CENTER

BLDG. 50

POB 25047

LNC

DENVER CO 80225

Jennifer Rodman-Snyder (303) 2366660

106/28/2019

140L0619Q0041

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

1) Statement of Work

2) Location Map

3) Wage Determination

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

1 14 calendar days and complete it within ________________ ________________ calendar days after receiving

52.211-10

07/29/2019

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

BLM OC NOC CONST A&E SEC(OC664)

DENVER FEDERAL CENTER

BUILDING 50

POB 25047

LNC

DENVER CO 80225

Jeane E. Steed

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 18

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140L0619Q0041

BLM-CA El Mirage Visitor Center Door Replacements

Legacy Doc #: BLM

Delivery: 14 Days After Notice to Proceed

Delivery Location Code: 0004276245

BLM-CA BARSTOW FIELD OFFICE

2601 BARSTOW ROAD

BARSTOW CA 92311 US

00010 Replace BLM-California El Mirage Visitor Center doors

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Request for Quote: 140L0619Q0041

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 4

Request for Quotation

Type of Contract: Construction, Firm Fixed Priced (FFP), Single Award Contract County: San Bernardino, CA Type of Construction: Other Building Equipment Contractors

Magnitude: $20,000 - $45,000 NAICS: 238290 SIZE STD: $15M SET-ASIDE: Small Business

Bureau of Land Management Technical Representative Contracting Officer (CO)

Name: Bessie Hayes Jeane Steed

Email: bhayes@blm.gov jsteed@blm.gov

Quote Submittal Due Date: July 29, 2019 5:00pm Mountain Time

Award Selection Process:

Lowest Price mailto:bhayes@blm.gov mailto:jsteed@blm.gov

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 5

GENERAL

(a) The Bureau of Land Management (BLM) is seeking quotations for construction services as attached in the accompanying statement of work. The BLM intends to conduct this acquisition by use of simplified acquisition procedures in accordance with FAR Part 13. A single contract award will be made to the Offeror that submits a quotation that has been determined to be the lowest price reasonable offeror.

(b) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quotation. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to adhere to quotation requirements, at the time of submission, may result in the quotation being unacceptable to the Government and eliminated from consideration for award.

(c) Offerors are cautioned to submit adequate information to enable the Government to fully ascertain each offeror’s capability to perform the requirements in accordance with the requirements of the request for quotation (RFQ).

(d) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the Contracting Officer in writing (email is the preferred method) with supporting rationale by the question deadline specified on the cover page of this document.

(e) This RFQ does not commit the Government to any costs incurred in the preparation and submission of a quote or for any other costs incurred by any firm submitting a quote in response to this solicitation. Note specifically that the Offeror will not be participating in a sealed bid procurement process under this acquisition method. Issuance of this RFQ does not constitute an award commitment on the part of the Government.

(f) Quotation must be valid for a minimum of 60 days.

(g) Respondents must complete the System for Award Management (SAM) at https://www.sam.gov/portal/public/SAM/ (previously ORCA and CCR). The Government will obtain respondent representations and certifications through this system.

(h) Award is subject to and based on the availability of funds. This project is currently funded based upon an independent cost estimate.

(i) Including all other factors, to qualify for award, a respondent must be determined responsible in accordance with Federal Acquisition Regulation Part 9.

(j) Respondents shall not contact any government personnel related to this requirement other than the Contracting Officer.

(k) All questions should be emailed directly to the Contracting Officer. Only written RFI’s will be considered and responded to by the Government. BLM responses to RFIs will be posted as an amendment to the solicitation.

SPECIAL CONTRACT REQUIRMENTS

WORK HOURS

The performance period established for this contract is based upon all work being conducted during regular working hours between 7:00am and 4:00pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection. The following Federal Legal Holidays are observed:

New Year’s Day Martin Luther King, Jr. Day President’s Day Memorial Day Independence Day Labor Day Columbus Day Veterans Day Thanksgiving Day Christmas

COMMUNICATIONS

“Time” for communications received after 3:00pm, after 12:00 pm locally on Fridays, or after 12:00 pm locally prior to a holiday will not start until the next business day. All times are local Mountain Standard Time.

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 6

FIRE DANGER SEASON

If the Contracting Officer Representative (COR) allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

DRAWINGS

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full size drawings may contact the Contracting Officer identified in the solicitation.

PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA

(a) The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the affected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

LIMITATIONS ON SUBCONTRACTING REPORTING

In accordance with 52.219-14 Limitations on Subcontracting, the prime contractor must perform at least 15% of the cost of the contract, excluding the cost of materials with its own employees and employees of a similarly situated subcontractor. A similarly situated subcontractor is a small business concern subcontractor that is a participant of the same SBA program that qualified the prime contractor as an eligible offeror and awardee of the contract. The contractor is responsible for ensuring compliance with the Limitation on Subcontracting.

At the conclusion of the period of performance and prior to final payment, the contractor shall submit a Limitation on Subcontracting Report directly to the Contracting Officer. The following information is required as part of the report: 1) the total amount paid to the prime contractor during the performance period broken out by labor and materials 2) list of similarly situated subcontractors and the amounts paid to each during the performance period broken out by labor and materials 3) list of any other subcontractors and the amounts paid to each during the performance period broken out by labor and materials.

If the Contracting Officer review of the report finds that the contractor is not in compliance for the period of performance, the contractor will be notified in writing. Penalties for failure to comply are described in 13 CFR 125.6(h) which states:

Whoever violates the requirements set forth in paragraph (a) of this section shall be subject to the penalties prescribed in 15 U.S.C.

645(d), except that the fine shall be treated as the greater of $500,000 or the dollar amount spent, in excess of permitted levels, by the entity on subcontractors. A party's failure to comply with the spirit and intent of a subcontract with a similarly situated entity may be considered a basis for debarment on the grounds, including but not limited to, that the parties have violated the terms of a Government contract or subcontract pursuant to FAR 9.406-2(b)(1)(i) (48 CFR 9.406-2(b)(1)(i)).

QUOTATION SUBMITTAL

Quotes must be in accordance with and in the order detailed in this section. Failure to submit quotes according to the instructions provided within the solicitation may result in an offeror’s quote being deemed “non-responsive.” Quotes are due by the date and time specified on the cover page of this document to the Contracting Officer’s email address.

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 7

REQUIRED DOCUMENTATION

Respondent shall submit the following information in response to this RFQ:

(1) Short Cover Letter:

(i) Offeror’s (company) name, address, and phone number

(ii) Point of contact for individuals within the company

(iii) A statement that the quote is valid for the time period set in block 13, Additional Solicitation Requirements.

(iv) A response to the following questions:

o Judgments, Claims, and Lawsuits: Are there any judgments, claims, and/or lawsuits pending or outstanding against or involving entity or partners comprising your entity?

o No ___, Yes ___. If “Yes,” submit details of all judgments or claims against either parent office or division/branch that will be responsible for the accomplishment of this project on a separate sheet.

o Is your entity or partners comprising your entity under suspension or debarment by any Federal, state or local agency, or been terminated on any past projects (Federal or others)?

o No ___, Yes ___. If “Yes,” submit details on a separate sheet.

(2) Sign Standard Form (SF) 1442, Solicitation, Offer, and Award, [Construction, Alteration, or Repair]. Please insert total price quoted within block 17. An official having the authority to contractually bind the Offeror's company must sign the SF 1442 in accordance with the procedures prescribed in the Federal Acquisition Regulation Subpart 4.102. (i.e. Blocks 14, 17, 19, 20a-20c)

(3) Acknowledgement of Amendments: Acknowledge all solicitation amendments (if applicable) using one of the methods set forth in Block 11 of Standard Form 30, the form on which any amendment will be issued. This will included completing blocks 8, and 15A-15C and the SF 1442, block 19, Acknowledgement of Amendments.

BASIS FOR CONTRACT AWARD

(a) This acquisition is a Small Business set-aside under the North American Industry Classification System (NAICS) Code 238290 with a small business size standard of $15M. An offeror determined to be other than a Small Business will be deemed ineligible for award.

(b) The Government will select the quote that meets all requirements of the statement of work at the lowest price.

(c) The Government intends to make ONE award based upon evaluation of quotes received. Award will be made to the responsible contractor whose quote conforms to all solicitation requirements, such as terms and conditions, representations and certifications, technical requirements, and also provides the lowest price responsible offeror.

CONTRACT PROVISIONS

PROVISIONS INCORPORATED BY REFERENCE

Clause Title Date

52.204-7 System for Award Management October 2018

52.204-16 Commercial and Government Entity Code Reporting July 2016

52.204-19 Incorporation by Reference of Representations and Certifications December 2014

52.204-22 Alternative Line Item Proposal January 2017

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 8

PROVISIONS INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS October 2018

(a)

(1) The North American Industry classification System (NAICS) code for this acquisition is 238290.

(2) The small business size standard is $15M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror has an active registration in the System for Award Management (SAM), the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certification in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[X] (i) Paragraph (d) applies.

[_] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation. (ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements— Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law.

This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 9

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specifY the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals—Representation. This provision applies to solicitations that include the clause at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $79,507 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran— Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

__X_ (i) 52.204-17, Ownership or Control of Offeror.

__X_ (ii) 52.204-20, Predecessor of Offeror.

___ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

___ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

___ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

___ (vii) 52.227-6, Royalty Information.

___ (A) Basic.

___ (B) Alternate I.

___ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR CLAUSE TITLE DATE CHANGE

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

https://www.sam.gov/

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 10

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK May 2014 a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION February 1999

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade Goals for Female Participation for Each Trade

19%

6.9%

These goals are applicable to all of the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S.

Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is the El Mirage Visitor Center.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS May 2014

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American— Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

http://acquisition.gov/far/current/html/52_222.html#wp1147505 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 11

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.252-1 SOLICITATIONS PROVISIONS INCORPORATED BY REFERENCE – FEBRUARY 1998

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this address: http://acquisition.gov/far/index.html

CONTRACT CLAUSES

CLAUSES INCORPORATED BY REFERENCE

Clause Title Date

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements Jan 2017 52.204-9 Personal Identity Verification of Contractor Personnel Jan 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards Oct 2018 52.204-13 System for Award Management Maintenance Oct 2018 52.209-6 Protecting the Government’s Interest when Subcontracting with Contractors

Debarred, Suspended, or Proposed for Debarment Oct 2015

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations Nov 2015 52.213-4 Terms and Conditions – Simplified Acquisitions (Other than Commercial Items) Nov 2017 52.216-7 Allowable Cost and Payment Alternate I Aug 2018

Feb 1997 52.219-6 Notice of Total Small Business Set Aside (Deviation 2019-O0003) Dec 2018 52.219-28 Post-Award Small Business Program Representation Jul 2013 52.222-3 Convict Labor Jun 2003 52.222-6 Construction Wage Requirements Aug 2018 52.222-7 Withholding of Funds May 2014 52.222-8 Payrolls and Basic Records Aug 2018 52.222-9 Apprentices and Trainees Jul 2005 52.222-10 Compliance with Copeland Act Requirements Feb 1988 52.222-11 Subcontracts (Labor Standards) May 2014 52.222-12 Contract Termination-Debarment May 2014 52.222-13 Compliance with Construction Wage Rate Requirements and Related Act Regulations May 2014

52.222-14 Disputes Concerning Labor Standards Feb 1988 52.222-15 Certification of Eligibility May 2014 52.222-21 Prohibition of Segregated Facilities Apr 2015 52.222-26 Equal Opportunity Sep 2016 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/FormsStandard62.html#wp1177057

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 12

52.222-27 Affirmative Action Compliance Requirements for Construction

Apr 2015

52.222-36 Equal Opportunity for Workers with Disabilities Jul 2014 52.222-50 Combating Trafficking in Persons Jan 2019 52.222-54 Employment Eligibility Verification Oct 2015 52.222-55 Minimum Wages Under Executive Order 13658 Dec 2015 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction

Contracts Sep 2013

52.223-3 Hazardous Material Identification and Material Safety Data Jan 1997 52.223-5 Pollution Prevention and Right-to-Know Information May 2011 52.223-15 Energy Efficiency in Energy-Consuming Products Dec 2007 52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction

Contracts

Aug 2018

52.223-18 Encouraging Contractor Policy to Ban Text Messaging While Driving Aug 2011 52.223-21 Foams Jun 2016 52.225-13 Restrictions on Certain Foreign Purchases Jun 2008 52.228-2 Additional Bond Security Oct 1997 52.228-5 Insurance – Work on a Government Installation Jan 1997 52.228-11 Pledge of Assets Aug 2018 52.228-12 Prospective Subcontractor Requests for Bonds May 2014 52.228-14 Irrevocable Letter of Credit Nov 2014 52.228-15 Performance and Payment Bonds – Construction Oct 2010 52.232-1, Alt 1 Disputes May 2014

Dec 1991 52.232-5 Payments under Fixed-P rice Construction Contracts May 2014 52.232-23 Assignment Of Claims May 2014 52.232-27 Prompt Payment for Construction Contracts May 2014 52.232-33 Payment by Electronic Funds Transfer – System for Award Management Oct 2018 52.232-39 Unenforceability of Unauthorized Obligations Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors Dec 2013 52.233-3 Protest After Award Aug 1996 52.233-4 Applicable Law for Breach of Contract Claims Oct 2004 52.236-2 Differing Site Conditions Apr 1984 52.236-3 Site Investigation and Conditions Affecting the Work Apr 1984 52.236-5 Material and Workmanship Apr 1984 52.236-6 Superintendence by the Contractor Apr 1984 52.236-7 Permits and Responsibilities Nov 1991 52.236-8 Other Contracts Apr 1994 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

Apr 1984

52.236-10 Operations and Storage Areas Apr 1984 52.236-11 Use and Possession Prior to Completion Apr 1984

52.236-12 Cleaning up Apr 1984

52.236-13 Accident Prevention Nov 1991

52.236-14 Availability and Use of Utility Services Apr 1984

52.236-17 Layout of Work Apr 1984 52.236-21 Alt 1 Specifications and Drawings for Construction Feb 1997

Apr 1984 52.236-26 Preconstruction Conference Feb 1995 52.242-14 Suspension of Work Apr 1984

52.244-6 Subcontracts for Commercial Items Jan 2019

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 13

52.245-1 Government Property Apr 2012

52.245-9 Use and Charges Apr 2012

52.246-21 Warranty of Construction Mar 1994 52.249-10, Alt I Default (Fixed-Price Construction) Apr 1984 DIAR 1452.201-70 Authorities and Delegations Sep 2011

DIAR 1452.203-70 Restrictions on Endorsements – Department of the Interior Jul 1996

DIAR 1452.204-70 Release of Claims – Department of the Interior Jul 1996

DIAR 1452.236-70 Prohibition Against Use of Lead-Based Paint – Department of the Interior Jul 1996 DIAR 1452.237-70 Information Collection – Department of the Interior Jul 1996

CLAUSES INCORPORATED BY FULL TEXT

CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (December 2015)

1) FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2) The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3) We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4) When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5) Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a) Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b) Your comments should focus on objective facts in the AO's narrative and should a)provide your views on the causes and ramifications of the assessed performance.

c) All information provided should be reviewed for accuracy prior to submission.

d) If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e) Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS- RC marked as “Pending” with or without comments and whether or not it has been closed.

f) If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated:

"The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

The following guidelines apply concerning your use of the past performance evaluation:

Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(END OF CLAUSE)

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 14

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS- INVOICE PROCESSING PLATFORM (IPP) April 2013 Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System

(IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

Format and Content:

Each invoice shall be submitted on the Contractor’s letterhead or invoice form with the following:

1. Invoice date and Government Contract Number

2. Billing period specified with beginning and ending dates. The beginning date must not be later than the completion date or within any previous billing dates.

3. The accounting must follow the approved schedule of values as described in the specification attachment.

4. Total amount due for the billing period

5. Certification of Progress Payment

6. Payrolls (Mail weekly)

7. Substantiation of Subcontractor Payment

8. 52.223-9 Certification with final payment request.

9. A Release of Claims (See 1452.204-70) with a request for final payment.

A Progress Report (may be included in Progress Meeting Notes) shall be submitted to support each invoice and shall include a summary of work performed during the period of performance identified on the invoice, which at a minimum must include:

1. ACTIVITY: Description of the previous month’s project activities and the planned activities for the next month. Also, Describe activities performed on contingency task(s), percent complete, task or deliverable schedule and identify any issues or concerns that may affect the performance and/or completion of the task(s);

2. PERCENTAGE COMPLETE: In accordance with the accepted Schedule of Values, for each task/deliverable: identify the percentage completed during the month and the cumulative percentage completed;

3. SCHEDULE: Reconcile progress of each task/deliverable with the schedule identified for each; submit a revised schedule as required.

4. ISSUES OR CONCERNS: Identify issues and/or concerns that may affect the project Statement of Work (SOW) or schedule.

5. OTHER INFORMATION: Any other information required in the Contract to be included in the Progress Report.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its quotation.

LOCAL INTERNET PAYMENT PLATFORM (IPP) HOTLINE

To check payment status, contact the Payment Hotline at 877-480-9724 or 303-236-2850. You will need to leave a message with the following information:

1. Company Name

2. Contract Number

3. Invoice Number

4. Invoice Amount

5. A brief description of why you are calling

6. Your contact information

If you do not receive a callback from the Payment Hotline within 72 hours, please contact the Contract Officer with the day and time you contacted the Payment Hotline.

https://www.ipp.gov/

PROJECT DESCRIPTION: El Mirage Visitor Center Door Replacements PAGE 15

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK April 1984 ALTERNATE 1 April 1984

The Contractor shall be required to

(a) commence work under this contract within 1 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 14 calendar days after receipt of the notice to proceed. The time stated for completion shall include final cleanup of the premises.

52.225-09 BUY AMERICAN ACT - CONSTRUCTION MATERIALS May 2014

(a) Definitions. As used in this clause-- “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101); (ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies.