Statement_of_Work_and_Clauses_revised_0002.pdf

CLAUSES AND PROVISIONS

STATEMENT OF WORK/TECHNICAL SPECIFICATIONS FOR REMOVAL AND INSTALLATION

OF OUTDOOR/EXTERIOR SIGNAGE

52.252-2 Clauses Incorporated by Reference. (FEB 1998)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS-COMMERCIAL ITEMS (MAY 2024)

GS0919 Legal Holidays (JAN 2002) 12 GS0925 Unscheduled Closures – Fixed Price (MAR 2003) GS1330 Key Personnel (JUL 2001) GS1332 Contractor's Representative (JUL 2001) GS1338 Notice to the Government of Delays (JUL 2001) GS1346 bCompliance with Occupational Safety and Health Act -- Government-Owned (APR 2003) GS1348 Accident Reporting (APR 2003) 15 GS1350 Supervision of Contractor's Employees (JUL 2007) GS1363 Nonpersonal Services - Independent Contractor (JUL 2007) Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013) GS1131 Deobligation of Unexpended Funds GS1440 Wage Determination Applicable (JUL 2001)

PROVISONS

52.252-2 Clauses Incorporated by Reference. (FEB 1998) 52.204-20 Predecessor of Offeror (AUG 2020) 52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (NOV 2021) 52.204-26 Covered Telecommunications Equipment or Services-Representation (OCT 2020) 52.212-3 Offeror Representations and Certifications – Commercial Items (MAY 2024) 52.216-1 Type of Contract (APR 1984) 52.219-1 Small Business Program Representations (FEB 2024) 52.222-22 Previous Contracts and Compliance Reports (Feb 1999) 52.222-25 Affirmative Action Compliance (Apr 1984) 52.212-2 Evaluation - Commercial Items. (NOV 2021)

QUOTATION SUBMISSION

STATEMENT OF WORK/TECHNICAL SPECIFICATIONS FOR REMOVAL AND

INSTALLATION OF OUTDOOR/EXTERIOR SIGNAGE

A. Introduction:

The U.S. Geological Survey (USGS), Upper Midwest Environmental Science Center (UMESC), La Crosse, WI has a requirement for the removal of outdoor/exterior signage, design, and installation of a new entrance sign.

B. Background:

The current UMESC main building entrance sign was installed in the late 1990s. The newest segment D and conference facility entrance has a newer modern sign that was installed in 2012 after the wing was constructed. Visitors often mistake the adjacent segment D entrance for the main entrance because of the newer sign. The main entrance sign is the oldest signage for the facility and needs replacement to represent the high-quality research image that USGS maintains and to match the newer signage from 2012 for a consistent front image.

C. USGS Mandatory Requirements:

• Trademarked USGS Identifier: The USGS identifier is protected and only available for use for this particular project.

• The Contractor is not allowed to alter the USGS Trademarked Identifier. The USGS is providing the Contractor with a one-time use of the USGS trademarked identifier for the purpose identified in this Statement of Work.

• The identifier consists of three elements: a monogram of the letters “USGS,” a symbolic mark, and the motto “science for a changing world”.

• PDF – (for reference see Attachment A- Attachment A - UMESC front bldg entrance sign_mockup2024)

• Fonts - Times New Roman and Univers Condensed are the current USGS Visual Identity System (VIS) fonts.

• Color Green - The identifier appears in the key color green (PMS 349) when placed against white or light-colored backgrounds.

• Final Design of the signage must be submitted to USGS for review and approval.

D. Scope:

The Contractor shall design, deliver, remove old sign entrance, and install new entrance sign, that matches the current adjacent sign over the conference facility. There shall not be any alterations to the identifier and the job must be done with an official identifier.

E. Technical Requirements: The Contractor shall include the following features in the design:

• Current older sign that will be replaced is a fabricated aluminum backer panel 44” x 92” mounted on aluminum channel behind backer panel. See Attachment A - UMESC front bldg entrance sign_mockup2024. New sign shall match existing sign #2 (backer and logo/colors/block letters and add the center name under the logo as example shows.

• Refer to Attachment A- Attachment A - UMESC front bldg entrance sign_mockup2024) sign specs for existing sign as a guide to match (colors, block letters, backer panel).

• Non-lit sign - shall not include backlight with halo like current sign.

• Center name included under the Identifier (logo and motto) – “Upper Midwest Environmental Sciences Center”.

• Backer Panel:

• Material: Shall be fabricated aluminum

• Shall be mounted by hidden aluminum channel concealed behind

• Must be custom match Sherwin Williams SW 6170 Techno Gray

• Raised Block Letters/logo:

• Fabricated aluminum or acrylic letters

• Shall have reverse channel letters

• Must be green color (PMS 349)

• Must be 1“thickness + 1/2” standoff from backer panel

The final design of outdoor exterior signage is to be reviewed by the Office of Communications and Publishing to ensure that visual identity standards are being followed and for consistency across the USGS.

F. Deliverables

• The Contractor shall deliver and install the new entrance sign at USGS, UMESC, 2630 Fanta Reed Road, La Crosse, WI, 54603.

• Work shall be performed during regularly schedule facility hours (7:30 am - 4:00 pm;

Mon - Fri).

• The Contractor shall provide equipment as necessary to minimize debris in and around work areas.

• The Contractor shall clean surfaces impacted by installation work and remove any debris created by the installation from this project.

• The Contractor shall notify the Technical Liaison (TL) prior to any issues affecting project completion or delivery date as soon as practical.

Period of Performance: 09/23/2024 through 01/22/2025

52.252-2 Clauses Incorporated by Reference. (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/ http://www.doi.gov/pam/aindex.html http://farsite.hill.af.mil/reghtml/Regs/far2afmcfars/fardfars/Far/52_000.htm?zoom_highlight=52 %2E212-4

52.202-1 Definitions (JUN 2020) 52.203-19 Prohibition on Reporting Certain Internal Confidentiality Agreements or Statements (JAN 2017) 52.204-13 System for Award Management Maintenance (OCT 2018) 52.204-18 Commercial and Government Entity Code Maintenance (AUG 2020) 52.204-19 Incorporation by Reference of Representations and Certifications (DEC 2014) 52.209-10 Prohibition on Contracting with Inverted Domestic Corporation (NOV 2015) 52.212-4 Contract Terms and Conditions – Commercial Items (NOV 2023) 52.226-7 Drug-Free Workplace (MAY 2024) 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) 52.233-1 Disputes (MAY 2014) 52.246-4 Inspection of Services-Fixed-Price (Aug 1996)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT

STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS (MAY 2024)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

http://www.acquisition.gov/far/ http://www.doi.gov/pam/aindex.html https://www.acquisition.gov/far/52.203-19#FAR_52_203_19 https://www.acquisition.gov/far/52.204-23#FAR_52_204_23 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25 https://www.acquisition.gov/far/52.209-10#FAR_52_209_10 https://www.acquisition.gov/far/52.232-40#FAR_52_232_40 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/10/3801 https://www.acquisition.gov/far/52.233-3#FAR_52_233_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.233-4#FAR_52_233_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-6#FAR_52_203_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/4655

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

X_ (4) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) (41 U.S.C. 4712); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

(5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (6) [Reserved].

__ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

X (9) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

__ (10) 52.204-28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts. (Dec 2023) (Pub. L. 115–390, title II).

X (11) (i) 52.204-30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) (Pub. L. 115–390, title II).

__ (ii) Alternate I (Dec 2023) of 52.204–30.

(12) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Nov 2021) (31 U.S.C. 6101 note).

__ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

__ (14) [Reserved].

__ (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) (15 U.S.C. 657a).

__ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (17) [Reserved]

(18) (i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-6.

__ (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C. 644).

__ (ii) Alternate I (Mar 2020) of 52.219-7.

__ (20) 52.219-8, Utilization of Small Business Concerns (Feb 2024) (15 U.S.C. 637(d)(2) and (3)).

__ (21) (i) 52.219-9, Small Business Subcontracting Plan (Sep 2023) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Jun 2020) of 52.219-9.

__ (v) Alternate IV (Sep 2023) of 52.219-9.

__ (22) (i) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

__ (ii) Alternate I (Mar 2020) of 52.219-13.

__ (23) 52.219-14, Limitations on Subcontracting (Oct 2022) (15 U.S.C. 637s).

__ (24) 52.219-16, Liquidated Damages—Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)).

https://www.acquisition.gov/far/52.203-13#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-15#FAR_52_203_15 https://www.acquisition.gov/far/52.203-17#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/3.900#FAR_3_900 https://www.acquisition.gov/far/52.204-10#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/52.204-14#FAR_52_204_14 https://www.acquisition.gov/far/52.204-15#FAR_52_204_15 https://www.acquisition.gov/far/52.204-27#FAR_52_204_27 https://www.acquisition.gov/far/52.204-28#FAR_52_204_28 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/52.204-30#FAR_52_204_30 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/52.209-6#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/52.209-9#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/52.219-3#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/52.219-4#FAR_52_219_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-6#FAR_52_219_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-6#FAR_52_219_6 https://www.acquisition.gov/far/52.219-7#FAR_52_219_7 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-7#FAR_52_219_7 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-9#FAR_52_219_9 https://www.acquisition.gov/far/52.219-13#FAR_52_219_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-13#FAR_52_219_13 https://www.acquisition.gov/far/52.219-14#FAR_52_219_14 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-16#FAR_52_219_16

__ (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran- Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (Feb 2024) (15 U.S.C. 657f).

X (26) (i) 52.219-28, Post Award Small Business Program Representation (Feb 2024) (15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (Mar 2020) of 52.219-28.

__ (27) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022) (15 U.S.C. 637(m)).

__ (28) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C. 637(m)).

__ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C. 644(r)).

__ (30) 52.219-33, Nonmanufacturer Rule (Sep 2021) (15U.S.C. 637(a)(17)).

X (31) 52.222-3, Convict Labor (Jun 2003) (E.O.11755).

X (32) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Feb 2024).

X (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

X (34) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246).

__ (ii) Alternate I (Feb 1999) of 52.222-26.

__ (35) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

__ (ii) Alternate I (Jul 2014) of 52.222-35.

__ (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

__ (ii) Alternate I (Jul 2014) of 52.222-36.

__ (37) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

_X_ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

X (39) (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (40) 52.222-54, Employment Eligibility Verification (May 2022) (Executive Order 12989).

(Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__ (41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (MAY 2024) ( 42 U.S.C. 7671, et seq.

__ (43) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (MAY 2024) (MAY 2024) ( 42 U.S.C. 7671, et seq.).

__ (44) 52.223-20, Aerosols (MAY 2024) ( 42 U.S.C. 7671, et seq.).

__ (45) 52.223-21, Foams, (MAY 2024) ( 42 U.S.C. 7671, et seq.).

__ (46) 52.223-23, Sustainable Products and Services (MAY 2024) ( E.O. 14057, 7 U.S.C.

8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

(47) (i) 52.224-3 Privacy Training (Jan 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (Jan 2017) of 52.224-3.

X (48) (i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83).

__ (ii) Alternate I (Oct 2022) of 52.225-1.

https://www.acquisition.gov/far/52.219-27#FAR_52_219_27 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-28#FAR_52_219_28 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-28#FAR_52_219_28 https://www.acquisition.gov/far/52.219-29#FAR_52_219_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-30#FAR_52_219_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.219-32#FAR_52_219_32 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec644.htm https://www.acquisition.gov/far/52.219-33#FAR_52_219_33 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec637.htm https://www.acquisition.gov/far/52.222-3#FAR_52_222_3 https://www.acquisition.gov/far/52.222-19#FAR_52_222_19 https://www.acquisition.gov/far/52.222-21#FAR_52_222_21 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title29-section793&num=0&edition=prelim https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 https://www.acquisition.gov/far/52.222-37#FAR_52_222_37 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-54#FAR_52_222_54 https://www.acquisition.gov/far/22.1803#FAR_22_1803 https://www.acquisition.gov/far/52.223-9#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-9#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.223-11#FAR_52_223_11 https://www.govinfo.gov/link/uscode/42/7671 https://www.acquisition.gov/far/52.223-12#FAR_52_223_12 https://www.govinfo.gov/link/uscode/42/7671 https://www.govinfo.gov/link/uscode/42/7671 https://www.govinfo.gov/link/uscode/42/7671 https://www.federalregister.gov/executive-order/14057 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/7/8102 https://www.govinfo.gov/link/uscode/42/6962 https://www.govinfo.gov/link/uscode/42/8259b https://www.govinfo.gov/link/uscode/42/7671l https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 https://www.acquisition.gov/far/52.225-1#FAR_52_225_1 https://www.acquisition.gov/far/52.225-1#FAR_52_225_1

_ (49) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) (19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C.

chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109- 53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (Dec 2022) of 52.225-3.

__ (iv) Alternate III (NOV 2023) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (50) 52.225-5, Trade Agreements (NOV 2023) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X_ (51) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

__ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov2007) (42 U.S.C. 5150).

_X_ (55) 52.226-8, Encouraging Contractor to Ban Text Messaging While Driving (MAY 2024) ( E.O. 13513).

__ (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

__ (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

__ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 3805).

X (59) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct2018) (31 U.S.C. 3332).

__ (60) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (61) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (62) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (63) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)).

__ (64) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

__ (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

_X_ (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter67).

_X_ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

(4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) ( 29U.S.C.206 and 41 U.S.C. chapter 67).

__ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.govinfo.gov/link/uscode/19/3301 https://www.govinfo.gov/link/uscode/19/3301 https://www.govinfo.gov/link/uscode/19/2112 https://www.govinfo.gov/link/uscode/19/3805 https://www.govinfo.gov/link/uscode/19/4001 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-3#FAR_52_225_3 https://www.acquisition.gov/far/52.225-5#FAR_52_225_5 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section2501&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title19-section3301&num=0&edition=prelim https://www.acquisition.gov/far/52.225-13#FAR_52_225_13 https://www.acquisition.gov/far/52.225-26#FAR_52_225_26 https://www.acquisition.gov/far/52.226-4#FAR_52_226_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-5#FAR_52_226_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-5#FAR_52_226_5 https://www.federalregister.gov/executive-order/13513 https://www.acquisition.gov/far/52.229-12#FAR_52_229_12 https://www.acquisition.gov/far/52.232-29#FAR_52_232_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/3805 https://www.acquisition.gov/far/52.232-30#FAR_52_232_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/3805 https://www.acquisition.gov/far/52.232-33#FAR_52_232_33 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/far/52.232-34#FAR_52_232_34 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.232-36#FAR_52_232_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.239-1#FAR_52_239_1 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title5-section552a&num=0&edition=prelim https://www.acquisition.gov/far/52.242-5#FAR_52_242_5 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-42#FAR_52_222_42 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-43#FAR_52_222_43 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-44#FAR_52_222_44 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-51#FAR_52_222_51

__ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

_X_ (7) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

X (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C. 1792).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1), in a subcontract for commercial products or commercial services. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) (41 U.S.C. 4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii) (A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition. (Dec 2023) (Pub. L. 115–390, title II).

(B) Alternate I (Dec 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (Feb 2024) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

https://www.acquisition.gov/far/52.222-53#FAR_52_222_53 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-55#FAR_52_222_55 https://www.acquisition.gov/far/52.222-62#FAR_52_222_62 https://www.acquisition.gov/far/52.226-6#FAR_52_226_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/2.101#FAR_2_101 https://www.acquisition.gov/far/52.215-2#FAR_52_215_2 https://www.acquisition.gov/far/subpart-4.7#FAR_Subpart_4_7 https://www.acquisition.gov/far/52.203-13#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.203-17#FAR_52_203_17 https://www.govinfo.gov/link/uscode/41/4712 https://www.acquisition.gov/far/52.203-19#FAR_52_203_19 https://www.acquisition.gov/far/52.204-23#FAR_52_204_23 https://www.acquisition.gov/far/52.204-25#FAR_52_204_25 https://www.acquisition.gov/far/52.204-27#FAR_52_204_27 https://www.govinfo.gov/link/plaw/115/public/390 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637&num=0&edition=prelim https://www.acquisition.gov/far/19.702#FAR_19_702 https://www.acquisition.gov/far/52.219-8#FAR_52_219_8 https://www.acquisition.gov/far/52.222-21#FAR_52_222_21

(x) 52.222-26, Equal Opportunity (Sep 2015) (E.O.11246).

(xi) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222- 40.

(xv) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

(xvi) (A) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O 13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

(xix) 52.222-54, Employment Eligibility Verification (May 2022) (E.O. 12989).

(xx) 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 (Jan 2022).

(xxi) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O. 13706).

(xxii) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. Subtitle A, Part V, Subpart G Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (Jun 2020) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) (31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxvi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph

(d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial products and commercial services a minimal number of additional clauses necessary to satisfy its contractual obligations.

52.242-17 Government Delay of Work (Apr 1984)

(a)If the performance of all or any part of the work of this contract is delayed or interrupted (1)by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2)by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly.

Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or https://www.acquisition.gov/far/52.222-26#FAR_52_222_26 https://www.acquisition.gov/far/52.222-35#FAR_52_222_35 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-36#FAR_52_222_36 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-37#FAR_52_222_37 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-40#FAR_52_222_40 https://www.acquisition.gov/far/52.222-41#FAR_52_222_41 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-chapter67-front&num=0&edition=prelim https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-50#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-51#FAR_52_222_51 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-53#FAR_52_222_53 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.222-54#FAR_52_222_54 https://www.acquisition.gov/far/52.222-55#FAR_52_222_55 https://www.acquisition.gov/far/52.222-62#FAR_52_222_62 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.224-3#FAR_52_224_3 https://www.acquisition.gov/far/52.225-26#FAR_52_225_26 https://www.acquisition.gov/far/52.226-6#FAR_52_226_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/52.226-6#FAR_52_226_6 https://www.acquisition.gov/far/52.232-40#FAR_52_232_40 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/10/3801 https://www.acquisition.gov/far/52.232-40#FAR_52_232_40 https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 https://www.govinfo.gov/content/pkg/USCODE-2019-title46/html/USCODE-2019-title46-subtitleV-partD-chap553-subchapI-sec55305.htm https://www.acquisition.gov/far/52.247-64#FAR_52_247_64 for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved; and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

GS0231 Technical Liaison-Technical Direction (JUL 2018)

a) The performance required herein shall be subject to the technical direction of the Technical Liaison (TL) as identified below. As used herein, "technical direction" is defined as direction to the contractor that fills in details, suggests possible lines of approach, or otherwise supplements the scope of the work set forth herein and shall not constitute a new assignment, and does not supersede or modify any article or clause of this contract.

(b) The Technical Liaison is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government. Only a warranted

Contracting Officer is authorized to obligate funds on this or any other contract action.

(c) The contractor shall immediately notify the Contracting Officer in writing if the Technical Liaison has taken an action (or fails to take action) or issues direction (written or oral) that the contractor considers to exceed the above limitations.

(d) The Technical Liaison assigned for this contract is:

Name: TBD Phone:

Email:

(e) Only the Contracting Officer may designate a new Technical Liaison.

GS0919 Legal Holidays (JAN 2002)

The following legal holidays are observed by this Government agency:

New Year's Day January 01 Martin Luther King's Birthday 3rd Monday in January

Presidents Day 3rd Monday in February Memorial Day Last Monday in May Juneteenth June 19 Independence Day July 04 Labor Day 1st Monday in September Columbus Day 2nd Monday in October Veterans Day November 11 Thanksgiving Day 4th Thursday in November Christmas Day December 25

When a holiday falls on Saturday or Sunday, it is observed on the adjacent Friday or Monday, respectively.

In addition to the holidays listed above, the contractor agrees to observe leave days or closures designated by Federal Statute, Executive Order, or Presidential Proclamation.

GS0925 Unscheduled Closures – Fixed Price (MAR 2003)

(a) The USGS facility where contractor employees are working may occasionally be closed temporarily and federal employees dismissed, such as for inclement weather, holiday early closings, power outages, or other emergencies. In these cases, the Contracting Officer or COR will advise the contractor whether any of the contractor's activities on Government facilities are considered critical and require continued performance. In most cases, the Contractor will be required to dismiss employees at Government facilities who are performing noncritical tasks after federal employees are dismissed.

(b) If the unscheduled closure causes an increase in the cost of contract performance or if any contract term or condition is affected by the closure, the Contractor may request an adjustment pursuant to clause GS1338 Notice to the Government of Delays.

(c) Contractor performance at locations that are not affected by the unscheduled closure will not be subject to this clause.

GS1330 Key Personnel (JUL 2001)

(a) The Contractor shall assign to this contract the following key personnel to the identified positions/functions:

Position/Function Name

Contractor’s Representative ___________________________

Alternate Contractor’s Representative ___________________________

(Offeror must fill in names of proposed key personnel, as presented in the technical proposal.)

(b) During the first 90 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment.

The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 90-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes must possess qualifications comparable to the original key person, as well as satisfying any minimum standards set forth elsewhere in the solicitation/contract. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions.

This clause will be modified to reflect any approved changes of key personnel.

GS1332 Contractor's Representative (JUL 2001)

(a) Upon contract award, the contractor shall furnish to the contracting officer the name of the person he has designated and assigned exclusively to this contract as his agent or representative.

The contractor's representative shall exercise overall management responsibility for the contract effort, receive technical direction, and handle problems arising under the contract, such as dismissals, disciplinary matters, etc. The contractor's representative is further responsible for coordinating matters of mutual concern with the Government representatives. In the event questions of responsibility arise, they shall be resolved by the contracting officer or his authorized representative.

(b) The contractor's representative may not be diverted to other projects for 14 consecutive days or more without giving prior written notification to the contracting officer or his representative.

Such notification shall include a justification for the diversion, together with information on the proposed substitute in sufficient detail to permit analysis of any potential negative effects on contract performance. No substitution shall be made without the written consent of the contracting officer; provided, however, that the contracting officer may grant such consent retroactively. Any such substitution of a permanent nature will be made a part of this contract through the issuance of a modification.

(c) When the Contractor's Representative is temporarily unavailable to manage the contract effort for a period longer than 72 hours, including absences due to vacation or illness, the contractor will provide to the COR a written designation of an alternate representative, itemizing any limitations in the alternate's authority. The procedures of paragraph (b) above do not apply to such temporary designations unless they are expected to exceed the time period indicated in that paragraph.

GS1338 Notice to the Government of Delays (JUL 2001)

In the event the contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract delivery schedule or date, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the contractor shall immediately notify the contracting officer and the COR (if one has been designated), in writing, giving pertinent details. This data shall be informational only in character. Notice under this provision shall not be construed as a waiver by the Government of any delivery schedule or date or of any rights or remedies provided by law or under this contract.

GS1346 Compliance with Occupational Safety and Health Act -- Government- Owned (APR 2003)

Performance of work shall comply with the provisions of the Occupational Health and Safety Act of 1970, as amended (OSHA). If, at any time during the performance of this contract, the Government-furnished facilities and/or equipment do not conform to OSHA standards, the contractor must so notify the Contracting Officer, in writing, including a recommendation of the corrective action needed."

GS1348 Accident Reporting (APR 2003)

If an accident occurs on Government-controlled facilities, an instant notice report must be provided to the Contracting Officer's Representative and the Contracting Officer, and a written detailed report must be provided within 2 work days. An accident is defined as an event which causes injury, illness, or loss or damage to Government-owned or private property. The contractor will cooperate with any ensuing Government accident investigation.

GS1350 Supervision of Contractor's Employees (JUL 2007)

(a) Personnel assigned to render services under this contract shall at all times be employees of the Contractor (or a subcontractor) and under the direction and control of the Contractor.

Notwithstanding any other provisions of this contract, the Contractor shall at all times be responsible for the supervision of its employees in the performance of the services required hereunder.

(b) If the…