127EAX25R0014 External Documents.pdf

Solicitation No: 127EAX25R0014 Project Name: Tallac and Meeks Bay Barracks Reconstruction

Table of Contents

PART I—THE SCHEDULE

SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS

B.1 SCHEDULE OF ITEMS

B.2 SCHEDULE NOTES

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C.1 SCOPE OF CONTRACT

C.2 PROJECT LOCATION

C.3 MAGNITUDE OF CONSTRUCTION PROJECT

C.4 TECHNICAL SPECIFICATIONS

SECTION D--PACKAGING AND MARKING

D.1 PACKING AND MARKING

D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE

SECTION E--INSPECTION AND ACCEPTANCE

E.1 CLAUSES

SECTION F--DELIVERIES OR PERFORMANCE

F.1 CLAUSES

SECTION G--CONTRACT ADMINISTRATION DATA

G.1 CLAUSES

PART II--CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

I.1 CLAUSES

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

J.1 ATTACHMENTS

PART IV--REPRESENTATIONS AND INSTRUCTIONS

SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF

OFFERORS OR RESPONDENTS

K.1 PROVISIONS

K.2 OTHER STATEMENTS OF OFFERORS OR RESPONDENTS

SECTION L--INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR

RESPONDENTS

L.1 PROVISIONS

L.2 INSTRUCTIONS

SECTION M--EVALUATION FACTORS FOR AWARD

M.1 PROPOSAL EVALUATION

M.2 TECHNICAL EVALUATION FACTORS

PART I—THE SCHEDULE

SECTION B--SUPPLIES OR SERVICES AND PRICES/COSTS

B.1 SCHEDULE OF ITEMS

Item Supplies/Services Qty Unit of

Issue Unit Price Total Price

0001 Tallac and Meeks Bay Barracks Reconstruction

a. Windows and Blinds 1 LS

b. Doors 1 LS

c. Pope Barracks Roofing and Siding 1 LS

d. Meeks Electrical Service and Finishes 1 LS

e. Supply and Waste Plumbing 1 LS

f. 3-Zone Mini-Split Heating and Cooling

System

1 LS

g. Meeks Bay Barracks Interior Renovations

1 LS

h. Meeks Bay Barracks Exterior Paint 1 LS

i. Pope Decking Reconstruction 1 LS

Total Value

B.2 SCHEDULE NOTES

***Note to Contractors: All line items listed above must be priced. If all line items are not priced, your proposal will not be accepted and will be considered non-responsive. ****

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

C.1 SCOPE OF CONTRACT

The Lake Tahoe Basin Barracks project includes the construction of various building systems at two buildings located within the Lake Tahoe Basin, California. The locations of the buildings are described below. This work generally includes exterior work at the Pope Barracks, and interior work at the Meeks Bay Barracks, more specifically includes updates to the deck, doors, windows, roofing and siding at the Pope Barracks, and interior renovations at the Meeks Barracks including insulation, gypsum wall board, paint, flooring, plumbing, electrical, cabinetry, heating, water heater, and all finishes necessary to fully occupy the building. In addition, work will include a new 200 amp electrical service to the Meeks Barracks. All materials, equipment and workmanship shall be ADA compliant and completed in a manner that meets all provisions of the Architectural Barriers Act. A more detailed description of work is included below following the itemized bid schedule.

C.2 PROJECT LOCATION

Meeks Bay Barracks:

From the Lake Tahoe Basin Management Unit’s Supervisor’s Office: Travel northeast on College Ave toward Al Tahoe Blvd for 305 feet, turn left onto Al Tahoe Blvd for 0.4 miles, turn left onto Lake Tahoe Blvd for 2.0 miles. Turn right onto CA-89 N/Emerald Bay RD for 16.4 miles, turn right into 7941 Emerald Bay Rd. Meeks Bay Resort and arrive at Meeks Barracks building located on the right side of the road. (39.03826, -120.12418).

Pope Barracks:

From the Lake Tahoe Basin Management Unit’s Supervisor’s Office: Travel northeast on College Ave toward Al Tahoe Blvd for 305 feet, turn left onto Al Tahoe Blvd for 0.4 miles, turn left onto Lake Tahoe Blvd for 2.0 miles. Turn right onto CA-89 N/Emerald Bay RD for 2.7 miles, turn right onto Valhalla RD for 0.2 miles, then turn left on Museum RD for 285 and arrive at Pope Barracks building located on the right side of the road. (38.93723, -120.04460).

C.3 MAGNITUDE OF CONSTRUCTION PROJECT

The Construction Magnitude is Between $250,000.00 and $500,000.00

C.4 TECHNICAL SPECIFICATIONS

1) Forest Service Supplemental Specifications to the FP-14

SECTION D--PACKAGING AND MARKING

D.1 PACKING AND MARKING

All shipments of materials, equipment and/or supplies shall be addressed to the Contractor and not to the Government.

D.2 PROJECT LABELING FOR OFFICIAL CORRESPONDENCE

The Government singularly identifies each project with a contract number at time of award. The contract number is a unique identifier to purposely and permanently represent an awarded project. The Government issued contract number is to be referenced on all official communication starting upon notice of award.

SECTION E--INSPECTION AND ACCEPTANCE

E.1 CLAUSES

FAR 52.246-12 Inspection of Construction (AUG 1996) FAR 52.246-13 Inspection-Dismantling, Demolition, or Removal of Improvements (AUG

1996)

SECTION F--DELIVERIES OR PERFORMANCE

F.1 CLAUSES

FAR 52.211-13 Time Extensions (SEP 2000) FAR 52.236-15 Schedules for Construction Contracts (APR 1984) FAR 52.242-14 Suspension of Work (APR 1984)

FAR 52.211.10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 calendar days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

SECTION G--CONTRACT ADMINISTRATION DATA

G.1 CLAUSES

AGAR 452.204-70 Modification for Contract Closeout

PART II--CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

I.1 CLAUSES

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR): https://www.acquisition.gov/browse/index/far (Clauses are located at FAR part 52 and begin with 52)

Department of Agriculture Acquisition Regulation (AGAR):https://www.acquisition.gov/agar (Clauses are located at AGAR part 452 and begin with 452)

Deviations to clauses may be viewed at: USDA FAR Class Deviations

FAR 52.202-1 Definitions (JUN 2020) FAR 52.203-3 Gratuities (APR 1984) FAR 52.203-5 Covenant against Contingent Fees (MAY 2014) FAR 52.203-6 Restrictions on Subcontractor Sales to the Government (JUN 2020) FAR 52.203-7 Anti-Kickback Procedures (JUN 2020) FAR 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper

Activity (MAY 2014) FAR 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014) FAR 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (JUN

2020) FAR 52.203-17 Contractor Employee Whistleblower Rights (NOV 2023) (Whistleblower

Guidance to contractor employees) FAR 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (JAN 2017) FAR 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

(JUN 2020)

FAR 52.204-13 System for Award Management Maintenance (OCT 2018) FAR 52.204-14 Service Contract Reporting Requirements (OCT 2016) FAR 52.204-19 Incorporation by Reference of Representations and Certifications (DEC

2014) FAR 52.204-23 Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab Covered Entities (DEC 2023) FAR 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video

Surveillance Services or Equipment (NOV 2021) FAR 52.204-27 Prohibition on a ByteDance Covered Application (JUN 2023)

FAR 52.209-6 Protecting the Government's Interest when Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment, or Voluntarily Excluded (JAN 2025)

FAR 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (OCT 2018)

FAR 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015)

FAR 52.215-2 Audit and Records -- Negotiation (JUN 2020) FAR 52.215-8 Order of Precedence—Uniform Contract Format (OCT 1997) FAR 52.219-6 Notice of Total Small Business Set-Aside (NOV 2020) FAR 52.222-3 Convict Labor (JUN 2003) FAR 52.222-4 Contract Work Hours and Safety Standards -- Overtime Compensation

(MAY 2018)

FAR 52.222-6 Construction Wage Rate Requirement (AUG 2018) FAR 52.222-7 Withholding of Funds (MAY 2014) FAR 52.222-8 Payrolls and Basic Records (JUL 2021) FAR 52.222-9 Apprentices and Trainees (JUL 2005) (DEVIATION FEB 2025) FAR 52.222-10 Compliance with Copeland Act Requirements (FEB 1988) FAR 52.222-11 Subcontracts (Labor Standards) (MAY 2014) FAR 52.222-12 Contract Termination - Debarment (MAY 2014) FAR 52.222-13 Compliance with Construction Wage Rate Requirements and Related

Regulations (MAY 2014) FAR 52.222-14 Disputes Concerning Labor Standards (FEB 1988) FAR 52.222-15 Certification of Eligibility (MAY 2014) FAR 52.222-35 Equal Opportunity for Veterans (JUN 2020) FAR 52.222-36 Equal Opportunity for Workers with Disabilities (JUN 2020) FAR 52.222-37 Employment Reports on Veterans (JUN 2020) FAR 52.222-40 Notification of Employee Rights Under National Labor Relations Act

(DEC 2010)

FAR 52.222-50 Combating Trafficking in Persons (NOV 2021) FAR 52.222-54 Employment Eligibility Verification (JAN 2025) FAR 52.222-55 Minimum Wages for Contractor Workers under Executive Order 14026

(JAN 2022)

FAR 52.222-62 Paid Sick Leave under Executive Order 13706 (JAN 2022) FAR 52.223-2 Reporting of Biobased Products Under Service and Construction Contracts

(MAY 2024) (DEVIATION FEB 2025)

FAR 52.223-3 Hazardous Material Identification and Material Safety Data (FEB 2021)- FAR 52.223-23 Sustainable Products & Services (MAY 2024) (DEVIATION FEB 2025) FAR 52.225-13 Restrictions on Certain Foreign Purchases (FEB 2021) FAR 52.226-7 Drug-Free Workplace (MAY 2024) FAR 52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving

(MAY 2024)

FAR 52.227-1 Authorization and Consent (JUN 2020) FAR 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (JUN

2020)

FAR 52.227-4 Patent Indemnity -- Construction Contracts (DEC 2007) FAR 52.228-2 Additional Bond Security (OCT 1997) FAR 52.228-11 Individual Surety - Pledge of Assets (FEB 2021) (DEVIATION MAY

2023) FAR 52.228-12 Prospective Subcontractor Requests for Bonds (DEC 2022) FAR 52.228-14 Irrevocable Letter of Credit (NOV 2014) FAR 52.228-15 Performance and Payment Bonds -- Construction (JUN 2020)

(DEVIATION MAY 2023)

FAR 52.229-3 Federal, State, and Local Taxes (FEB 2013) FAR 52.232-5 Payments under Fixed-Price Construction Contracts (MAY 2014) FAR 52.232-17 Interest (MAY 2014) FAR 52.232-23 Assignment of Claims (MAY 2014) FAR 52.232-27 Prompt Payment for Construction Contracts (JAN 2017) FAR 52.232-33 Payment by Electronic Funds Transfer – System for Award Management

(OCT 2018)

FAR 52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013) FAR 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (MAR

2023) FAR 52.233-1 Disputes (MAY 2014) Alt 1 (DEC 1991) FAR 52.233-3 Protest after Award (AUG 1996) FAR 52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004) FAR 52.236-2 Differing Site Conditions (APR 1984) FAR 52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984) FAR 52.236-5 Material and Workmanship (APR 1984) FAR 52.236-6 Superintendence by the Contractor (APR 1984) FAR 52.236-7 Permits and Responsibilities (NOV 1991) FAR 52.236-8 Other Contracts (APR 1984) FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements (APR 1984) FAR 52.236-10 Operations and Storage Areas (APR 1984) FAR 52.236-11 Use and Possession Prior to Completion (APR 1984) FAR 52.236-12 Cleaning Up (APR 1984) FAR 52.236-13 Accident Prevention (NOV 1991) Alternate I (NOV 1991) FAR 52.236-17 Layout of Work (APR 1984) FAR 52.236-21 Specifications and Drawings for Construction (FEB 1997) Alternate I (APR 1984) FAR 52.236-26 Preconstruction Conference (FEB 1995) FAR 52.240-1 Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by

American Security Drone Act-Covered Foreign Entities (NOV 2024) FAR 52.242-13 Bankruptcy (JUL 1995) FAR 52.243-4 Changes (JUN 2007) FAR 52.244-6 Subcontracts for Commercial Products and Commercial Services (JAN

2025) (DEVIATION FEB 2025)

FAR 52.246-21 Warranty of Construction (MAR 1994) FAR 52.248-3 Value Engineering – Construction (OCT 2020) FAR 52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR

2012)-Alternate I (SEP 1996) FAR 52.249-10 Default (Fixed-Price Construction) (APR 1984) FAR 52.253-1 Computer Generated Forms (JAN 1991)

FAR 52.225-9 Buy American Act-Construction Materials (OCT 2022)

(a) Definitions. As used in this clause—

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies.

However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if–

(A) The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029.

Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all component used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners.

Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States.

Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. Chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows:

____None____________________________________________

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable.

(A) For domestic construction material that is not a critical item or does not contain critical components.

(1) The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(2) For construction material that is not a COTS item and does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that is manufactured in the United States and does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest offer of foreign construction material that exceeds 55 percent domestic content as a domestic offer and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(A)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(A)(2) of this clause will no longer apply as of January 1, 2030.

(B) For domestic construction material that is a critical item or contains critical components.

(1) The cost of a particular domestic construction material that is a critical item or contains critical components, subject to the requirements of the Buy American statute, is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent plus the additional preference factor identified for the critical item or construction material containing critical components listed at FAR 25.105.

(2) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest foreign offer of construction material that is manufactured in the United States and exceeds 55 percent domestic content as a domestic offer, and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(B)(1) of this clause.

(3) The procedures in paragraph (b)(3)(i)(B)(2) of this clause will no longer apply as of January 1, 2030.

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1) (i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction Material Description Unit of Measure Quantity Price (Dollars)* Item1

Foreign construction material _______ _______ _______ Domestic construction material _______ _______ _______ Item 2

Foreign construction material _______ _______ _______ Domestic construction material _______ _______ _______

[*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued)].

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.]

FAR 52.252-6 Authorized Deviations in Clauses (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Agriculture Acquisition Regulation (48 CFR 4) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

J.1 ATTACHMENTS

Attachment 1 – Statement of Work Attachment 2 – Specifications Attachment 3 – Fire Plan Attachment 4 – Barracks Drawings Attachment 5 – Wage Determination

PART IV--REPRESENTATIONS AND INSTRUCTIONS

SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER

STATEMENTS OF OFFERORS OR RESPONDENTS

K.1 PROVISIONS

FAR 52.204-29 Federal Acquisition Supply Chain Security Act Orders—Representation and Disclosures (Dec 2023)

FAR 52.236-28 Preparation of Proposals – Construction (OCT 1997)

FAR 52.204-8 Annual Representations and Certifications (JAN 2025) (DEVIATION FEB 2025)

(a) (1) The North American Industry Classification System (NAICS) code for this acquisition is 237310.

(2) The small business size standard is $45M.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519 if the acquisition—

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b) (1) If the provision at FAR 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at FAR 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) ☐ Paragraph (d) applies.

(ii) ☐ Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) FAR 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless–

(A) The acquisition is to be made under the simplified acquisition procedures in FAR part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) FAR 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) FAR 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) FAR 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at FAR 52.204-7, System for Award Management.

(v) FAR 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) FAR 52.204-26, Covered Telecommunications Equipment or Services- Representation. This provision applies to all solicitations.

(vii) FAR 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations- Representation.

(viii) FAR 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) FAR 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) FAR 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) FAR 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) FAR 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied FAR part 19 in accordance with FAR 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) FAR 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied FAR part 19 in accordance with FAR 19.000(b)(1)(ii).

(xiv) [Reserved]

(xv) [Reserved]

(xvi) FAR 52.222-38, Compliance with Veterans’ Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) FAR 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at FAR 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) FAR 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) [Reserved]

(xx) FAR 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at FAR 52.225-1.

(xxi) FAR 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at FAR 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) FAR 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at FAR 52.225-5.

(xxiii) FAR 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xxiv) FAR 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) FAR 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

☐ (i) FAR 52.204-17, Ownership or Control of Offeror.

☐ (ii) FAR 52.204-20, Predecessor of Offeror.

☒ (iii) FAR 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

☐ (iv) FAR 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

☐ (v) FAR 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

☐ (vi) FAR 52.227-6, Royalty Information.

☐ (A) Basic.

☐ (B) Alternate I.

☐ (vii) FAR 52.227-15, Representation of Limited Rights Data and Restricted

Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in any updates to the representations and certifications posted on SAM.

(End of provision)

FAR 52.209-7 Information Regarding Responsibility Matters (OCT 2018)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options;

and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager;

plant manager; head of a division or business segment; and similar positions).

(b) The offeror ☐ has ☐ does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see FAR 52.204-7).

(End of provision)

K.2 OTHER STATEMENTS OF OFFERORS OR RESPONDENTS

System updates may lag policy updates. The System for Award Management (SAM) may continue to require entities to complete representations based on provisions that are not included in agency solicitations, including:

FAR 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals— Representation

FAR 52.222-25, Affirmative Action Compliance Contracting officers will not consider these representations when making award decisions or enforce requirements. Entities are not required to, nor are they able to, update their entity registration to remove these representations in SAM.

SECTION L--INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR

RESPONDENTS

L.1 PROVISIONS

FAR 52.252-1 Solicitation Provisions Incorporated by Reference (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

Federal Acquisition Regulation (FAR): https://www.acquisition.gov/browse/index/far (Provisions are located at FAR part 52 and begin with 52)

Department of Agriculture Acquisition Regulation (AGAR):https://www.acquisition.gov/agar (Provisions are located at AGAR part 452 and begin with 452)

Deviations to provisions may be viewed at: USDA FAR Class Deviations

FAR 52.201-1 Acquisition 360: Voluntary Survey (SEP 2023) FAR 52.204-7 System for Award Management (NOV 2024) FAR 52.204-16 Commercial and Government Entity Code Reporting (AUG 2020) FAR 52.204-22 Alternative Line-Item Proposal (JAN 2017) FAR 52.207-6 Solicitations and Offers from Small Business Concerns and Small Business

Teaming Arrangements or Joint Ventures (Multiple Award Contracts)

(AUG 2024)

FAR 52.215-1 Instructions to Offerors--Competitive Acquisition (NOV 2021) FAR 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work

(MAY 2014)

FAR 52.222-33 Notice of Requirement for Project Labor Agreement (JAN 2024) FAR 52.225-10 Notice of Buy American Act Requirement—Construction Materials (MAY

2014) FAR 52.225-12 Notice of Buy American Requirement—Construction Materials Under

Trade Agreements (MAY 2014) FAR 52.228-17 Individual Surety – Pledge of Assets (Bid Guarantee) (FEB 2021) FAR 52.236-27 Site Visit (Construction) (FEB 1995)

FAR 52.216-1 Type of Contract (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

FAR 52.228-1 Bid Guarantee (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds –

(1) To unsuccessful bidders as soon as practicable after the opening of bids, and (2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $190,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

FAR 52.233-2 Service of Protest (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer Troy McCullough at troy.mccullough@usda.gov.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

FAR 52.252-5 Authorized Deviations in Provisions (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Agriculture Acquisition Regulation (48 CFR Chapter 4) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

L.2 INSTRUCTIONS

(a) General Instructions. Proposals submitted in response to this solicitation shall be furnished as specified below.

(1) The proposal must include a technical proposal and business/price proposal. Each of the parts shall be separate and complete so that evaluation of one may be accomplished independently from evaluation of the other. All documents shall be Microsoft Word, Microsoft Excel, or Adobe PDF.

(2) The Government will evaluate proposals in accordance with the evaluation criteria set forth in Section M of this RFP. Offeror must have an active entity registration at https://www.sam.gov to submit an offer.

(3) All offers shall be submitted in the following format:

(a) 1 copy of the completed technical proposal. Maximum size: Twenty (20) 8 ½ x 11 pages single spaced.

(b) 1 copy of the completed business/price proposal.

(b) Technical Proposal Instructions

The technical proposal will be used to make an evaluation and arrive at a determination as to whether the proposal will meet the requirements of the Government. Therefore, the technical proposal must present sufficient information to reflect a thorough understanding of the requirements and a detailed description of techniques, procedures and program for achieving the objectives of the specifications/statement of work. At a minimum the technical proposal should clearly address the following:

i) Factor 1. Past Performance: submit a list of relevant past work the offeror has performed within the past 3 years along with contact information so the government may query prior customers. Information should include the project name, location, description of the work, dollar value and name/phone/email of project owner representative. Offerors may provide information on problems encountered on the identified contracts and the offeror’s corrective actions.

ii) Factor 2. Experience & Technical Approach to Performing the Work: When evaluating the Technical Approach to Performing the Work, the government will assess the reasonableness of the contractor’s proposed approach to performing the work including the use of biobased products in project implementation. The Government will assess the specialized experience and skill of the firm with a focus on experience that is similar to the specified project, within the past three years.

(c) Business/Price Proposal Instructions

The proposed price will be evaluated for reasonableness. The technical factors, when combined are equal to price. As the technical factors in offers become closer in evaluation process, price becomes more important.

The following information is required:

i) Signed Standard Form 1442, Solicitation/Offer/Award (Construction, Alteration, Repair), with blocks 14 – 20c completed by the offeror.

ii) Section B - Schedule of Items, all blocks must be completed by the offeror. All Items must be priced.

iii) Section K - Offeror Representations and Certifications – Complete the requested information in each applicable provision in Section K (FAR 52.204-8, FAR 52.209-13, FAR 52.204-24, FAR 52.209-7, FAR 52.219-4). Only return the applicable provisions, not the entire solicitation.

iv) Acknowledgement of solicitation amendments (if any). This can be accomplished by completing section 19 on the SF-1442 or by submitting the signed SF-30(s) from sam.gov with your price proposal.

v) Scanned copy of fully executed Bid Guarantee (Standard Form 24 and Power of Attorney).

(d) All documents shall be submitted as specified in block 13a of the SF-1442. It is the vendor’s responsibility to ensure delivery of all required documents by the date and time set for receipt of offers.

(e) Contact the Contracting Officer by telephone or by e-mail if you do not understand any part of these instructions.

Pursuant to FAR 36.211(b), information regarding USDA’s definitization of equitable adjustments for change orders under construction contracts may be found at Contracting with USDA | USDA. USDA’s procedures that apply to the definitization of equitable adjustment for change orders under construction contracts may be found in the USDA Contracting Desk Book, located at Policies & Regulations | USDA under Parts 436 and 443.

SECTION M--EVALUATION FACTORS FOR AWARD

M.1 PROPOSAL EVALUATION

Proposals will be evaluated using a best value approach. This process permits tradeoffs among price and non-price technical factors and allows the Government to accept other than the lowest priced quote. The government will evaluate quotes based on the technical evaluation factors specified in this solicitation. The technical factors, when combined are equal to price. As the technical factors in offers become closer in evaluation process, price becomes more important.

M.2 TECHNICAL EVALUATION FACTORS

Factors are of equal importance.

Factor 1. Past Performance Past performance is a measure of the degree to which the offeror (including major subcontractors) has satisfied previous customers and complied with Federal, State and Local laws and regulations. The Government may contact references to assess the quality of the contractor’s work, timely completion, project management, and compliance with regulatory requirements. The Government will consider the currency and relevance of the information, source of the information, context of the data and general trends in contractor performance.

The past performance evaluation will characterize the level of…