12467019R0060.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

956600

USDA FOREST SERVICE

NATIONAL FORESTS IN MISSISSIPPI

200 S LAMAR ST STE 500N BOX 44

JACKSON MS 39201

447U

GEMAA PELCH 601-965-1671

1x 06/04/2019

12467019R0060

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

ERFO Road Repairs 2019, Francis Marion National Forest

The Francis Marion National Forest soliciting for road contractors to install culverts, recondition roadbeds & ditch lines, and place aggregate on Forest Service roads in Berkeley and Charleston County, South Carolina.

- ERFO #1 Western Roads 2019 Repairs: Magnitude of this construction project is between $250,000 and $500,000.

- ERFO #2 Central Roads 2019 Repairs: Magnitude of this construction project is between $250,000 and $500,000.

- ERFO #3 Eastern Roads. Magnitude of this construction project is between

$500,000 and $1,000,000.

OFFERS MAY BE SUBMITTED ON ONE AREA, ALL AREAS OR ANY COMBINATION. Work on all areas shall be completed concurrently.

An offer guarantee is required. A Site Visit is not scheduled.

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 120 calendar days and complete it within ________________ ________________ calendar days after receiving

07/05/2019

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

USDA FOREST SERVICE

NATIONAL FORESTS IN MISSISSIPPI

200 S LAMAR ST STE 500N BOX 44

JACKSON MS 39201

447U

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

X gpelch02 Highlight

Francis Marion National Forest 12467019R0060 ERFO Road Repairs – 2019 Page 3 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall not be in addition to the contract price. Include bond payments under 151.01 Mobilization.

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

TABLE OF CONTENTS

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS .................................................................. Page 4-21

B.1 ERFO #1 Western Roads 2019 Repairs ........................................................................... Page 4-10

B.2 ERFO #2 Central Roads 2019 Repairs ........................................................................... Page 11-15

B.3 ERFO #3 Eastern Roads 2019 Repairs ........................................................................... Page 16-21

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK ............................................... Page 22-23

SECTION D--PACKAGING AND MARKING ............................................................................................ Page 23

SECTION E--INSPECTION AND ACCEPTANCE ........................................................................................ Page 24

SECTION F--DELIVERIES OR PERFORMANCE ........................................................................................ Page 24

SECTION G--CONTRACT ADMINISTRATION DATA ............................................................................... Page 25

SECTION H--SPECIAL CONTRACT REQUIREMENTS ............................................................................... Page 25

SECTION I--CONTRACT CLAUSES .................................................................................................... Page 25-30

SECTION J--LIST OF ATTACHMENTS ................................................................................................... Page 31

SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF OFFERORS OR

RESPONDENTS .............................................................................................................................. Page 31-34

SECTION L--INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS OR RESPONDENTS ........... Page 35-38

SECTION M - EVALUATION FACTORS FOR AWARD .............................................................................. Page 39

WAGE DETERMINATION .............................................................................................................. Page 40-44

CONTRACTOR’S FINANCIAL INFORMATION SHEET ............................................................................. Page 45

ERFO Road Repairs – 2019 Page 4 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

PART I-THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

Schedule of Items

B.1 ERFO #1 Western Roads 2019 Repairs, Francis Marion District, Berkeley County

FR 103A

ITEM

NO. DESCRIPTION PAY

UNIT

EST.

QTY.

UNIT

PRICE

TOTAL

PRICE

15101 Mobilization Lump Sum 1

30116 Aggregate surface course, grading FLBC, compaction method A

Ton 550

30301

Ditch reconditioning

Mile 2.73

30307

Roadbed reconditioning, compaction method A

Mile 2.73

62503

Turf establishment Lump Sum 1

FR 103A TOTAL:

FR 108

ITEM

NO. DESCRIPTION PAY

UNIT

EST.

QTY.

UNIT

PRICE

TOTAL

PRICE

15101 Mobilization Lump Sum 1

20302 Removal of culverts, disposal method Off Forest Land Each 2

20701 Earthwork geosynthetics, type non-woven geotextile Square Yard 200

30104 Aggregate base, grading Commercial #4 slag, compaction method A Ton 40

30106 Subbase, grading Borrow Cubic Yard 30

30116 Aggregate surface course, grading FLBC, compaction method A Ton 40

30301 Ditch reconditioning Mile 2.56

30307 Roadbed reconditioning, compaction method A Mile 2.56

60201 48 inch pipe culvert, Corrugated Metal Pipe, Type 2 Aluminized Foot 60

62503 Turf establishment Lump Sum 1

63352 Sign (including post) Each 4

FR 108 TOTAL:

ERFO Road Repairs – 2019 Page 5 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 109

ITEM

NO. DESCRIPTION PAY

UNIT

EST.

QTY.

UNIT

PRICE

TOTAL

PRICE

15101

Mobilization

Lump Sum 1

20302

Removal of culverts, disposal method Off Forest Land

Each 3

20701

Earthwork geosynthetics, type non-woven geotextile

Square Yard 140

30104

Aggregate base, grading Commercial #4 slag, compaction method A Ton 50

30106

Subbase, grading Borrow

Cubic Yard 60

30116

Aggregate surface course, grading FLBC, compaction method A

Ton 50

Mile 3.09

Mile 3.09

60201A

18 inch pipe culvert, Corrugated Metal Pipe, Type 2 Aluminized

Foot 30

60201B

24 inch pipe culvert, Corrugated Metal Pipe, Foot 60

Turf establishment

63352

Sign (including post)

Each 6

FR 109 TOTAL:

ERFO Road Repairs – 2019 Page 6 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 110

UNIT

EST.

QTY.

UNIT

PRICE

Lump Sum 1

Removal of culvert, disposal method Off Forest

Each 1

Ton 120

Mile 5.08

Mile 5.08

60201

Foot 32

Each 2

FR 110 TOTAL:

FR 110A

UNIT

EST.

QTY.

UNIT

PRICE

Ton 180

Mile 1.7

Mile 1.7

FR 110A TOTAL:

ERFO Road Repairs – 2019 Page 7 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 124

UNIT

EST.

QTY.

UNIT

PRICE

geotextile

Yard 450

Ton 160

Cubic Yard 195

Ton 1010

Mile 1.78

24 inch pipe culvert, Reinforced Concrete Culvert (RCP)

Foot 160

Each 4

FR 124 TOTAL:

ERFO Road Repairs – 2019 Page 8 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 128A

UNIT

EST.

QTY.

UNIT

PRICE

geotextile

Yard 4154

Ton 700

Cubic Yard 800

Mile 0.63

Mile 0.63

FR 128A TOTAL:

FR 136

UNIT

EST.

QTY.

UNIT

PRICE

Ton 1000

Mile 2.31

Mile 2.31

FR 136 TOTAL:

ERFO Road Repairs – 2019 Page 9 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 198

UNIT

EST.

QTY.

UNIT

PRICE

geotextile

Yard 1880

Ton 760

Cubic Yard 510

Ton 780

Mile 3.25

Mile 3.25

FR 198 TOTAL:

FR 199

UNIT

EST.

QTY.

UNIT

PRICE

Ton 45

Mile 0.95

Mile 0.95

FR 199 TOTAL:

ERFO Road Repairs – 2019 Page 10 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

B.1 ERFO #1 Western Roads 2019 Repairs Totals

FR 103A TOTAL:

FR 108 TOTAL:

FR 109 TOTAL:

FR 110 TOTAL:

FR 110A TOTAL:

FR 124 TOTAL:

FR 128A TOTAL:

FR 136 TOTAL:

FR 198 TOTAL:

FR 199 TOTAL:

ERFO #1 Western Roads 2019 Repairs Grand Total:

ERFO Road Repairs – 2019 Page 11 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

B.2 ERFO #2 Central Roads 2019 Repairs, Francis Marion District, Berkley County

FR 174

UNIT

EST.

QTY.

UNIT

PRICE

Ton 270

Mile 4.06

Mile 4.06

FR 174 TOTAL:

FR 265

UNIT

EST.

QTY.

UNIT

PRICE

Ton 400

Mile 3.42

Mile 3.42

Foot 60

Each 4

FR 265 TOTAL:

ERFO Road Repairs – 2019 Page 12 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 265A

UNIT

EST.

QTY.

UNIT

PRICE

Ton 360

Mile 1.57

Mile 1.57

FR 265A TOTAL:

FR 167

UNIT

EST.

QTY.

UNIT

PRICE

20302 Removal of culverts, disposal method Off Forest Land

20701 Earthwork geosynthetics, type non-woven geotextile

Yard 270

Ton 60

Cubic Yard 90

Ton 60

Mile 3.30

Mile 3.30

24 inch pipe culvert, Reinforced Concrete Culvert

(RCP)

FR 167 TOTAL:

ERFO Road Repairs – 2019 Page 13 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 262

UNIT

EST.

QTY.

UNIT

PRICE

Ton 160

Mile 1.33

Mile 1.33

FR 262 TOTAL:

FR 179B

UNIT

EST.

QTY.

UNIT

PRICE

Ton 1300

Mile 1.24

Mile 1.24

FR 179B TOTAL:

ERFO Road Repairs – 2019 Page 14 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 176

UNIT

EST.

QTY.

UNIT

PRICE

geotextile

Yard 1350

Ton 500

Mile 2.08

Mile 2.08

FR 176 TOTAL:

FR 161

UNIT

EST.

QTY.

UNIT

PRICE

Ton 1460

Mile 14.16

Mile 14.16

FR 161 TOTAL:

ERFO Road Repairs – 2019 Page 15 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

B.2 ERFO #2 Central Roads 2019 Repairs Totals

FR 174 TOTAL:

FR 265 TOTAL:

FR 265A TOTAL:

FR 167 TOTAL:

FR 262 TOTAL:

FR 179B TOTAL:

FR 176 TOTAL:

FR 161 TOTAL:

ERFO #2 Central Roads 2019 Repairs Grand Total:

ERFO Road Repairs – 2019 Page 16 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

B.3 ERFO #3 Eastern Roads 2019 Repairs, Francis Marion District, Berkeley & Charleston Counties

FR 223

UNIT

EST.

QTY.

UNIT

PRICE

Mobilization Lump Sum 1 compaction method A Ton 400

Ditch reconditioning Mile 3.99

Mile 3.99

FR 223 TOTAL:

FR 228

UNIT

EST.

QTY.

UNIT

PRICE

Ton 1200

Mile 3.73

Mile 3.73

FR 228 TOTAL:

ERFO Road Repairs – 2019 Page 17 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

FR 238

UNIT

EST.

QTY.

UNIT

PRICE

geotextile

Yard 210

Ton 75

Cubic Yard 90

Ton 425

Mile 2.01

Mile 2.01

FR 238 TOTAL:

FR 239

NO. DESCRIPTION PAY UNIT EST.

QTY.

UNIT

PRICE

Mile 1.10

Mile 1.10

FR 239 TOTAL:

ERFO Road Repairs – 2019 Page 18 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

FR 220C

ITEM

NO. DESCRIPTION PAY UNIT EST.

QTY.

UNIT

PRICE

geotextile

Yard 250

Cubic Yard 250

Ton 1000

FR 220C TOTAL:

FR 224

ITEM

NO. DESCRIPTION PAY UNIT EST.

QTY.

UNIT

PRICE

TOTAL

PRICE

15101 Mobilization Lump Sum 1

20701 Earthwork geosynthetics, type non-woven geotextile

Square Yard 230

30104 Aggregate base, grading Commercial #4 slag, compaction method A Ton 95

30106 Subbase, grading Borrow Cubic Yard 75

30116 Aggregate surface course, grading FLBC, compaction method A Ton 95

30301 Ditch reconditioning Mile 3.54

30307 Roadbed reconditioning, compaction method A

Mile 3.54

62503 Turf establishment

FR 224 TOTAL:

ERFO Road Repairs – 2019 Page 19 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

FR 204

ITEM

NO. DESCRIPTION PAY UNIT EST.

QTY.

UNIT

PRICE

geotextile

Yard 100

Ton 30

Cubic Yard 60

Ton 4080

Mile 9.00

Mile 9.00

36 inch pipe culvert, Reinforced Concrete

Foot 80

FR 204 TOTAL:

ERFO Road Repairs – 2019 Page 20 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

FR 204A

ITEM

NO. DESCRIPTION PAY UNIT EST.

QTY.

UNIT

PRICE

Mile 1.19

Mile 1.19

24 inch pipe culvert, Reinforced Concrete

FR 204A TOTAL:

FR 217A

ITEM

NO. DESCRIPTION PAY UNIT EST.

QTY.

UNIT

PRICE

geotextile

Square Yard 505

Ton 305

Cubic Yard 235

Ton 505

Mile 1.04

Mile 1.04

FR 217A TOTAL:

ERFO Road Repairs – 2019 Page 21 of 45

NOTE: Payment for bond premiums in accordance with Clause 52.232-5, Payments under Fixed-Price Construction Contracts, shall

Payment will be made on actual work performed as described in FP-14 109.01 unless otherwise noted.

B.3 ERFO #3 Eastern Roads 2019 Repairs Totals

FR 223 TOTAL:

FR 228 TOTAL:

FR 238 TOTAL:

FR 239 TOTAL:

FR 220C TOTAL:

FR 224 TOTAL:

FR 204 TOTAL:

FR 204A TOTAL:

FR 217A TOTAL:

ERFO #3 Eastern Roads 2019 Repairs Grand Total:

ERFO Road Repairs – 2019 Page 22 of 45

SECTION C--DESCRIPTION/SPECIFICATIONS/STATEMENT OF WORK

1.1 SCOPE: The contractor shall provide all materials, labor, equipment, tools, transportation, permits, licenses, supervision, expertise, and other incidentals necessary to successfully complete removing and installing culverts, reconditioning roadbed and ditch lines, and aggregate placement on the Francis Marion National Forest in accordance with attached plans, Standard Specifications for Construction of Roads and Bridges on Federal Highway Project, FP-14, and supplemental specifications (See Section J).

The project is divided into three areas:

• ERFO #1 Western Roads 2019 Repairs: Magnitude of this construction project is between $250,000 and $500,000.

• ERFO #2 Central Roads 2019 Repairs: Magnitude of this construction project is between $250,000 and $500,000.

• ERFO #3 Eastern Roads. Magnitude of this construction project is between $500,000 and $1,000,000.

OFFERS MAY BE SUBMITTED ON ONE AREA, ALL AREAS OR ANY COMBINATION.

The Government reserves the right to make multiple awards as a result of this solicitation.

Offerors are required to be registered in SAM at the time an offer or quotation is submitted in order to comply with the annual representations and certifications requirements (FAR 4.1102).

1.2 LOCATION:

• ERFO #1 Western Roads 2019 Repairs, Francis Marion District, Berkeley County, South Carolina

• ERFO #2 Central Roads 2019 Repairs, Francis Marion District, Berkley County, South Carolina

• ERFO #3 Eastern Roads 2019 Repairs, Francis Marion District, Berkeley & Charleston Counties, South Carolina

1.3 SAFETY: During the life of this contract, the contractor is required to maintain a site-specify Safety Plan. The Contractor is responsible for ensuring that proper techniques and procedures are followed and precautions taken to prevent injury to any person or property as a result of work performed under this contract. The Contractor and the Contractor’s employees shall adhere to all safety regulations and guidelines applicable to this type of work. These include, but are not limited to safety requirements provided by the Occupational Safety and Health Administration (29 CFR 1910-1926, www.osha.gov). It is the contractor’s responsibility to know what safety regulations and guidelines are applicable to this type of work.

1.4 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS.

The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place.

The Contractor shall protect from damage all existing improvements and utilities (1) at or near the work site, and (2) on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

Fuel and Machine Fluids. The contractor shall instruct employees in environmental protection practices. The contractor is responsible for operating under conditions which preclude the waste of fuel or spoiling the environment. Machine fluids (fuel, oils, coolants, etc.)

shall not be drained on the ground or allowed to enter any watercourse. Inadvertent spills shall be contained immediately and the Contracting Officer’s Representative shall be notified immediately. Promptly remediate the spill unless otherwise directed by authorities.

1.5 DOCUMENTATION AND RECORDS.

(a) The contractor shall maintain records of accomplishment. These reports shall be turned as requested for quality assurance/inspection purposes by the COR.

http://www.osha.gov/

ERFO Road Repairs – 2019 Page 23 of 45

(B) All documentation, records and schedules as described in the SOO that are the responsibility of the contractor, are the property of the Government and shall be turned over to the Government upon completion or termination of the contract. All records are subject to the Freedom of Information and/or Privacy Acts and any requests for release of any records shall be handled accordingly.

1.6 BIOPREFERRED STATEMENT

The Contractor must comply with Section 9002 of the Farm Security and Rural Investment Act of 2002 (FSRIA), Executive Order (EO) 13423, “Strengthening Federal Environmental, Energy, and Transportation Management,” and the Federal Acquisition Regulation to provide biobased products.

The Contractor shall utilize products and material made from biobased materials (e.g., insulating foam, composite panels, and concrete and asphalt release fluids) to the maximum extent possible without jeopardizing the intended end use or detracting from the overall quality delivered to the end user. All supplies and materials shall be of a type and quality that conform to applicable Federal specifications and standards. All supplies and materials to be used in the performance of work described herein are subject to the approval of the Contracting Officer Representative (COR).

The following is an example list of products that may be used in this contract for minor construction for which biobased products are available. The list is not all inclusive. It is desirable that vendors be able to supply the greatest number of biobased products listed meeting the health and environmental specifications.

Adhesive and Mastic Removers Graffiti and Grease Removers Building Insulation Hydraulic Fluid

Carpets Insulating Foam Cement and Concrete Roof Coatings

Composite Panels Water Tank Coatings Concrete and Asphalt Cleaners Wood and Concrete Sealers

Erosion Control Materials Wood and Concrete Stains Flowable Fill

Biobased products that are designated for preferred procurement under USDA’s BioPreferred program must meet the required minimum biobased content as stated in the USDA Final Rule available at www.biopreferred.gov. The Contractor should provide data for their biobased products such as biobased content and source of biobased material (i.e. particular crop or livestock). In addition to the biobased products designated by the U.S. Department of Agriculture in the BioPreferred Program, the Contractor is encouraged to use other commercially available biobased products.

The Contractor shall comply with the provision at FAR 52.223-1, Biobased Product Certification and the clause at FAR 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts and report in http://www.sam.gov, on the product types and dollar value of any USDA-designated biobased products purchased by the Contractor during contract performance.

AGAR 452.211-72 Statement of Work/Specifications (FEB 1988)

The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), to perform the Statement of Work/Specifications referenced in Section J.

AGAR 452.211-73 Attachments to Statements of Work/Specifications (FEB 1988)

The attachments to the Statement of Work/Specifications listed in Section J are hereby made part of this solicitation and any resultant contract.

SECTION D--PACKAGING AND MARKING

{There are NO clauses in this Section} http://www.sam.gov/

ERFO Road Repairs – 2019 Page 24 of 45

SECTION E--INSPECTION AND ACCEPTANCE

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/index.html http://www.usda.gov/procurement/policy/agar.html http://www.fs.fed.us/im/directives/fsh/6309.32/

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

FAR 52.246-12 Inspection of Construction (AUG 1996)

SECTION F--DELIVERIES OR PERFORMANCE

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/index.html

FAR 52.242-14 Suspension of Work (APR 1984)

FAR 52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than:

• B.1 ERFO #1 Western Roads 2019 Repairs 120 Days

• B.2 ERFO #2 Central Roads 2019 Repairs 120 Days

• B.3 ERFO #3 Eastern Roads 2019 Repairs 120 Days

The time stated for completion shall include final cleanup of the premises.

The Government anticipates the Notice to Proceed for all projects will be issued on or about August 12, 2019. Work on all areas shall be completed concurrently.

AGAR 452.236-75 Maximum Workweek--Construction Schedule (Nov 1996)

Within 10 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval:

(a) A schedule as required by FAR clause 52.236-15, Schedules for Construction Contracts, and

(b) The hours (including the daily starting and stopping times) and days of the week the Contractor proposes to carry out the work.

The maximum workweek that will be approved is 40 hours per week.

https://www.acquisition.gov/far/index.html http://www.usda.gov/procurement/policy/agar.html http://www.fs.fed.us/im/directives/fsh/6309.32/ https://www.acquisition.gov/far/index.html

ERFO Road Repairs – 2019 Page 25 of 45

SECTION G--CONTRACT ADMINISTRATION DATA

INVOICE PROCESSING PLATFORM (IPP): The "Submit Invoice-to" address for USDA orders is the Department of Treasury's Invoice Processing Platform (IPP). This platform is managed by the U.S. Department of Treasury and additional information is available at this website https://www.ipp.gov/index.htm.

Please have the following information available when submitting your invoices through IPP: (1) date of invoice; (2) date services were performed; (3) a unique invoice number; (4) description of the services performed; (5) the award number.

Invoices submitted without all the elements of a proper invoice will be returned and will result in delayed payments. Also, your SAM registration must stay active in order for you to continue receiving payments.

SECTION H--SPECIAL CONTRACT REQUIREMENTS

{There are NO clauses in this Section}

PART II-CONTRACT CLAUSES

SECTION I--CONTRACT CLAUSES

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/index.html

52.202-1 Definitions (NOV 2013) 52.203-3 Gratuities (APR 1984) 52.203-5 Covenant Against Contingent Fees (APR 1984) 52.203-6 Restrictions on Subcontractor Sales to the Government (SEP 2006) 52.203-7 Anti-Kickback Procedures (MAY 2014) 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (MAY 2014) 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014) 52.203-12 Limitation on Payments to Influence Certain Federal Transactions (OCT 2010) 52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (APR 2014) 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011) 52.204-7 System for Award Management (OCT 2018) 52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for

Debarment. (OCT 2015) 52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. (OCT 2018) 52.211-18 Variation in Estimated Quantity (APR 1984) 52.215-2 Audit and Records—Negotiation (OCT 2010) 52.219-6 Notice of Total Small Business Set-Aside (NOV 2011) 52.219-8 Utilization of Small Business Concerns (Oct 2018) 52.219-14 Limitations on Subcontracting (JAN 2017) 52.219-28 Post-Award Small Business Program Rerepresentation (JUL 2013) 52.222-3 Convict Labor (JUN 2003) 52.222-4 Contract Work Hours and Safety Standards -- Overtime Compensation. (May 2018) 52.222-6 Construction Wage Rate Requirements (Aug 2018) https://www.acquisition.gov/far/index.html

ERFO Road Repairs – 2019 Page 26 of 45

52.222-7 Withholding of Funds (MAY 2014) 52.222-8 Payrolls and Basic Records (Aug 2018) 52.222-9 Apprentices and Trainees (JUL 2005) 52.222-10 Compliance with Copeland Act Requirements (FEB 1988) 52.222-11 Subcontracts (Labor Standards) (MAY 2014) 52.222-12 Contract Termination -- Debarment (May 2014) 52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014) 52.222-14 Disputes Concerning Labor Standards (FEB 1988) 52.222-15 Certification of Eligibility (MAY 2014) 52.222-21 Prohibition of Segregated Facilities (APR 2015) 52.222-26 Equal Opportunity (SEP 2016) 52.222-27 Affirmative Action Compliance Requirements for Construction (APR 2015) 52.222-35 Equal Opportunity for Veterans (OCT 2015) 52.222-36 Equal Opportunity for Workers with Disabilities (Jul 2014) 52.222-37 Employment Reports on Veterans (FEB 2016) 52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (DEC 2010) 52.222-50 Combating Trafficking in Persons (Jan 2019) 52.222-55 Minimum Wages Under Executive Order 13658 (DEC 2015) 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (SEP 2013) 52.223-3 Hazardous Material Identification and Material Safety Data. (JAN 1997) 52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2011) 52.223-6 Drug-Free Workplace (MAY 2001) 52.223-15 Energy Efficiency in Energy-Consuming Products. (DEC 2007) 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts (Aug 2018) 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011) 52.225-13 Restrictions on Certain Foreign Purchases (JUN 2008) 52.227-1 Authorization and Consent (DEC 2007) 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (DEC 2007) 52.227-4 Patent Indemnity -- Construction Contracts (DEC 2007) 52.228-1 Bid Guarantee (SEP 1996) 52.228-2 Additional Bond Security (OCT 1997) 52.228-5 Insurance—Work on a Government Installation (JAN 1997) 52.228-11 Pledges of Assets (Aug 2018) 52.228-12 Prospective Subcontractor Requests for Bonds (May 2014) 52.228-15 Performance and Payment Bonds – Construction (OCT 2010) 52.229-3 Federal, State, and Local Taxes (FEB 2013) 52.232-5 Payments under Fixed-Price Construction Contracts (MAY 2014) 52.232-17 Interest (MAY 2014) 52.232-23 Assignment of Claims (MAY 2014) 52.232-27 Prompt Payment for Construction Contracts (JAN 2017) 52.232-33 Payment by Electronic Funds Transfer-- System for Award Management (Oct 2018) 52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013) 52.233-1 Disputes (MAY 2014) 52.233-3 Protest After Award (AUG 1996) 52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004) 52.236-2 Differing Site Conditions (APR 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984) 52.236-5 Material and Workmanship (APR 1984) 52.236-6 Superintendence by the Contractor (APR 1984) 52.236-7 Permits and Responsibilities (NOV 1991) 52.236-8 Other Contracts (APR 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (APR 1984) 52.236-10 Operations and Storage Areas (APR 1984) 52.236-11 Use and Possession Prior to Completion (APR 1984) 52.236-12 Cleaning Up (APR 1984) 52.236-13 Accident Prevention (NOV 1991) Alternate I (NOV 1991) 52.236-14 Availability and Use of Utility Services (APR 1984 https://www.acquisition.gov/far/current/html/52_223_226.html#wp1188603

ERFO Road Repairs – 2019 Page 27 of 45

52.236-15 Schedules for Construction Contracts (APR 1984) 52.236-16 Quantity Surveys (APR 1984) Alternate I (APR 1984) 52.236-17 Layout of Work (APR 1984) 52.236-21 Specifications and Drawings for Construction (FEB 1997) Alternate I (APR 1984) Alternate II (APR 1984) 52.236-26 Preconstruction Conference (FEB 1995) 52.242-13 Bankruptcy (JUL 1995) 52.243-4 Changes (JUN 2007) 52.243-5 Changes and Changed Conditions (APR 1984) 52.244-6 Subcontracts for Commercial Items (Jan 2019) 52.245-1 Government Property (JAN 2017) 52.246-21 Warranty of Construction (MAR 1994) 52.248-3 Value Engineering – Construction (OCT 2015) 52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR 2012)--Alternate I (SEP 1996) 52.249-10 Default (Fixed-Price Construction) (APR 1984) 52.253-1 Computer Generated Forms (JAN 1991)

AGRICULTURE ACQUISITION REGULATION (48 CFR CHAPTER 4) CLAUSES

452.232-70 Reimbursement for Bond Premiums – Fixed-Price Construction Contracts (NOV 1996) 452.236-72 Use of Premises (NOV 1996) 452.236-73 Archeological or Historic Sites (FEB 1988) 452.236-74 Control of Erosion, Sedimentation and Pollution (NOV 1996) 452.236-76 Samples and Certificates (FEB 1988) 452.236-77 Emergency Response (NOV 1996)

FAR 52.223-9 Estimate of Percentage of Recovered Material Content for EPA-Designated Items. (MAY 2008)

(a) Definitions. As used in this clause—

“Postconsumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

“Recovered material” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall—

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to the Contracting Officer of the awarded task order.

FAR 52.223-11 Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (JUN 2016)

(a) Definition. “Ozone-depleting substance,” as used in this clause, means any substance the Environmental Protection Agency designates in 40 CFR Part 82 as—

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform; or

(2) Class II, including, but not limited to, hydrochlorofluorocarbons.

(b) The Contractor shall label products which contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j (b), (c), and (d) and 40 CFR Part 82, Subpart E, as follows:

WARNING

Contains (or manufactured with, if applicable) *_______, a substance(s) which harm(s) public health and environment by destroying ozone in the upper atmosphere.

* The Contractor shall insert the name of the substance(s).

http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20

ERFO Road Repairs – 2019 Page 28 of 45

FAR 52.225-9 Buy American—Construction Materials (MAY 2014)

(a) Definitions. As used in this clause—

“Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means—

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: NONE.

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that—

ERFO Road Repairs – 2019 Page 29 of 45

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction Material Description

Unit of Measure

Quantity

Price (Dollars)*

Item 1: _______

Foreign construction material _______

Domestic construction material_______

Item 2: _______

ERFO Road Repairs – 2019 Page 30 of 45

Foreign construction material_______

Domestic construction material_______

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.]

[Include other applicable supporting information.]

[* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

AGAR 452.228-71 Insurance Coverage (Nov 1996)

Pursuant to FAR clause 52.228-5, Insurance-Work on a Government Installation, the Contractor will be required to present evidence to show, as a minimum, the amounts of insurance coverage indicated below:

(a) Workers Compensation and Employer's Liability. The Contractor is required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a Contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage of at least $100,000 shall be required, except in States with exclusive or monopolistic funds that do not permit worker's compensation to be written by private carriers.

(b) General Liability. The Contractor shall have bodily injury liability insurance coverage written on a comprehensive form of policy of at least $500,000 per occurrence.

(c) Automobile Liability. The Contractor shall have automobile liability insurance written on a comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage or loss.

(d) Aircraft Public and Passenger Liability. When aircraft are used in connection with performing the contract, the Contractor shall have aircraft public and passenger liability insurance. Coverage shall be at least $200,000 per person and $500,000 per occurrence for bodily injury, other than passenger injury. Coverage for passenger injury shall be at least $200,000 multiplied by the number of seats or passengers, whichever is greater.

FAR 52.236-1 Performance of Work by the Contractor (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 20 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

Order of Precedence--Construction

Any inconsistency in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The Schedule (excluding the specifications)

(2) Representations and Other Instructions

(3) Contract Clauses

(4) Other Documents, Exhibits, and Attachments

(5) The Specifications

(6) Drawings

ERFO Road Repairs – 2019 Page 31 of 45

PART III--LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J--LIST OF ATTACHMENTS

List of Attachments Number of Pages

Wage Determination: The following wage determination and any revisions issued apply to this project https://www.wdol.gov/wdol/scafiles/davisbacon/SC34.dvb?v=0 5

Standard Specifications for the Construction of Roads and Bridges on Federal Highway Projects (FP-14) https://flh.fhwa.dot.gov/resources/specs/ 762

ERFO #1 Western Roads 2019 Repairs Supplemental Specifications 53

ERFO #2 Central Roads 2019 Repairs Supplemental Specifications 49

ERFO #3 Eastern Roads 2019 Repairs 48

PART IV--REPRESENTATIONS AND INSTRUCTIONS

SECTION K--REPRESENTATIONS, CERTIFICATIONS, AND OTHER STATEMENTS OF OFFERORS OR

RESPONDENTS

Offerors are required to be registered in SAM at the time an offer or quotation is submitted in order to comply with the annual representations and certifications requirements (FAR 4.1102).

FAR 52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

https://www.acquisition.gov/far/index.html

52.204-19 Incorporation by Reference of Representations and Certifications.

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-

Representation and Certifications.

52.236-28 Preparation of Proposals-Construction.

AGAR 452.219-70 SIZE STANDARD AND NAICS CODE INFORMATION (NOV 1996)

The North American Industrial classification System Code(s) and business size standard(s) describing the products and/or services to be acquired under this solicitation are listed below:

--NAICS Code 237310 --Size Standard $36.5 million https://www.wdol.gov/wdol/scafiles/davisbacon/SC34.dvb?v=0 https://flh.fhwa.dot.gov/resources/specs/ https://www.acquisition.gov/far/index.html

ERFO Road Repairs – 2019 Page 32 of 45

FAR 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a) (1) The North American Industry Classification System (NAICS) code for this acquisition is 237310.

(2) The small business size standard is $36.5 million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b) (1) If the provision at 52.204-7, System for…