Amendment1.pdf

(x)

1202NV20Q0033

x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

02NV

IDAHO FALLS ID 83401

1405 HOLLIPARK DRIVE

IDAWY ACQUISTITION SERVICE CENTER

USDA FS

06/13/20200001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

05/28/2020

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Telehandler purchase for the Bridget-Teton National Forest

Bridger Teton Nation Forest Telehandler

The purpose of this amendment is to change the delivery date and answer questions.

This amendment will change the deliver date to and the answer to the questions are as follows:

Q:Please confirm if the telehandler is a rental or a purchase.

A:The purpose of the solicitation is to purchase a telehandler.

Continued ...

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

AMELIA R. VELASCO

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

TEL: EMAIL: 208-529-1020 ext: 5848 amelia.velasco@usda.gov

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 2

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

1202NV20Q0033/0001

Q:Would a later period of performance date be considered?

A:Considering delays with ordering due to COVID 19, the delivery date will be extended to November 1, 2020. See Section II-2 Delivery changes stated below.

Q:Please confirm email submission with e-sig is acceptable.

A:Responses with an electronic signatures via email will be accepted. Please consider the size of your response prior to submitting via email.

If you plan to mail, please let Amelia Velasco, Contracting Officer, know what date to expect your response through the mail at amelia.velasco@usda.gov.

Section II- 2 - Delivery shall be replaced in it's entirety as follows:

Delivery of the telehandler is to the following addresses:

Greys River RD

671 North Washington Street

Afton, WY 83110

The Telehandler shall be delivered no later than November 1, 2020. All delivery dates shall be coordinated with the Contracting Officers Representative for the contract.

Delivery shall take place Monday through Friday 8 a.m. to 4:30 p.m. MST excluding federal holidays, unless otherwise approved in writing by the Contracting Officer.

Vendor shall provide notice of delivery to the designated Government official at least 48 hours in advance of delivery to allow sufficient time for the government to coordinate offloading.

Government officials contact information will be provided at the time of award.

It is the Contractor's responsibility to coordinate delivery and off-loading with the transportation company.

All other terms and conditions remain the same.

Period of Performance: 07/01/2020 to 11/01/2020

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110