Design build sanostee day school.

Ended Awarded Last action

Contract number
INA10PC75111
Awardee
Awarding agency
Obligated
$13,263,197

Award facts

Contract value 100% obligated
$13,263,196.75 Current and potential, with all options
Completion date 100% complete
Current and potential, with all options
NAICS code
236210 Industrial Building Construction
PSC
Not on record
Set-aside
No set-aside
Competition
Full and Open Competition · 1 offer Multiple Award, Fair Opportunity
Pricing
Firm Fixed Price
Place of performance
Sanostee, NM 87461, USA
Legislative mandates

Award details come from SAM.gov/FPDS.

Transactions

Action Obligated Date
Change Order 15 · New sanostee school $10,319
Change PIID 14A $0
Change Order 14 · Performance period extension for additional work to the electrical HVAC. $66,007
Change Order 12 · Contract to provide additional work on IT configuration work includes mobilization for the new sanostee school. $3,397
Change Order 11 · Modification to extend the contract performance period to april 16, 2012 at no additional cost. $0
Change Order 10 · Modification for telephone setup and handset configuration and training. $10,438
Change Order 9 · Modification is issued to provide payment for fuel and materials escaluation cost. Contractor accumulated extra cost due to the government's delay in design… $70,705
Change Order 8 · Modification to pay C3, LLC for the government delay in design review on the 99% submittal for sanostee new school replacement project. $135,962
Change Order 7 · Contractor to perform additional work not in the original scope of work. $6,623
Change Order 6 · Change order to perform additional work to comply with project requirements for the new school construction of sanostee day school, sanostee, NM. $102,541
Change Order 5 · Modified to include PCO additional work not include in planning and design build phase. $671,591
Change Order 4 · Modified to include three items not part oforiginal scope of work to complete the new BIA sanostee school. $172,081
Change Order 3 · Modified to included additional work to complete this project. $247,147
Change Order 2 · Contract perfomance period is extended by 30 calendar days at no additional cost to the government. $0
Other Administrative Action 1 · The purpose of this modification is to transfer contracting officer authority to dianne gutierrez and to transfer the contract administration to the navajo… $0
Original award $11,766,386
Show all 16

Quick answers

Who was awarded contract INA10PC75111?

INA10PC75111 was awarded to C3 LIMITED Liability Company by Navajo Region (Bureau of Indian Affairs and Indian Education) on September 3, 2010.

How much is contract INA10PC75111 worth?

The government has obligated $13,263,197 on INA10PC75111.

Is contract INA10PC75111 an order under another contract?

Yes. INA10PC75111 is a delivery order under INF98210AD001, an indefinite delivery contract.

Was contract INA10PC75111 competed?

The extent of competition for INA10PC75111 was full and open competition. The government received 1 offer.

On GovTribe

See this award's full record

  • Every transaction and funding action
  • The awardee's other awards and teaming partners
  • Similar awards and recompete opportunities
  • Ask GovTribe AI about this award
Try for free Login