Lubbock screening station & video courtroom upgrades designs at the US federal courthouse in lubbock, TX

Ended Awarded Last action

Contract number
47PH0920F0014
Awardee
Awarding agency
Obligated
$25,870

Award facts

Opportunity
Contract value 100% obligated
$25,870.22 Current and potential, with all options
Completion date 100% complete
Current and potential, with all options
Funding agency
Administrative Office of the U.S. Courts
NAICS code
541310 Architectural Services
PSC
C211 Architect And Engineering- General: Landscaping, Interior Layout, And Designing
Set-aside
No set-aside
Competition
Full and Open Competition Architect-Engineer FAR 6.102
Pricing
Firm Fixed Price
Place of performance
Lubbock, TX 79401, USA

Award details come from SAM.gov/FPDS.

Transactions

Action Obligated Date
Supplemental Agreement for work within scope PS0011 · To extend the completion date due to the customer (courts) have not made a decision as to what flooring they are wanting for the design specifications for the… $0
Supplemental Agreement for work within scope PS0010 · To extend the completion date due to the customer delays to add additional work to the design specifications for the mahon federal courthouse, lubbock TX. $0
Supplemental Agreement for work within scope PS0009 · To extend the completion date due to the customer (courts) wanting to add additional work to the design specifications for the lubbock courts projects,… $0
Supplemental Agreement for work within scope PS0007 · To extend the completion due to delays from the courts reviewing project designs for the lubbock projects, mahon usch, lubbock TX. $0
Supplemental Agreement for work within scope PS0006 · To administratively correct the completion end date from 06/01/2021 to 06/20/2021 for the projects located in lubbock, TX $0
Supplemental Agreement for work within scope PS0005 · To extend the completion date from 03/22/2021 to 06/01/2021 for the projects in lubbock, TX for excusable delays caused by agency review. $0
Supplemental Agreement for work within scope PS0004 · Extend the completion date due to delays by the customer to review the project submittals, lubbock courtroom video infrastructure upgrades GH mahon federal… $0
Supplemental Agreement for work within scope PS0003 · Extend the period of performance because of agency delay with reviewing drawings for lubbock courtroom video infrastructure upgrades 1205 texas AVE. Lubbock… $0
Other Administrative Action PS0001 · Extension of lubbock courtroom design projects GH mahon federal courthouse 1205 texas AVE. Lubbock, TX 79424 $0
Original award $25,870

Quick answers

Who was awarded contract 47PH0920F0014?

47PH0920F0014 was awarded to Richter Associates Architects Inc. by Region 7 (Public Buildings Service) on January 29, 2020.

How much is contract 47PH0920F0014 worth?

The government has obligated $25,870 on 47PH0920F0014.

Which agency awarded contract 47PH0920F0014?

Region 7 (Public Buildings Service) awarded 47PH0920F0014, with funding from Administrative Office of the U.S. Courts.

Is contract 47PH0920F0014 an order under another contract?

Yes. 47PH0920F0014 is a delivery order under 47PH0817D0017, an indefinite delivery contract.

Was contract 47PH0920F0014 competed?

The extent of competition for 47PH0920F0014 was full and open competition.

On GovTribe

See this award's full record

  • Every transaction and funding action
  • The awardee's other awards and teaming partners
  • Similar awards and recompete opportunities
  • Ask GovTribe AI about this award
Try for free Login