0526 Amendment 0007.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE J

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

August 24, 2010

4. REQUISITION/PURCHASE REQ. NO.

5. PROJECT NO. (If applicable)

Camp Pendleton, CA

6. ISSUED BY CODE

SP0600 7. ADMINISTERED BY (If other than Item 6) CODE

DLA ENERGY

8725 JOHN J. KINGMAN RD., SUITE 4950

FT. BELVOIR, VA 22060-6222

BUYER/SYMBOL – PATRICIA PETERSON/DESC-BXB

PHONE - (703) 767-9339 FAX - (703) 767- 9338 6.2

E-MAIL: Patricia.Peterson@dla.mil

8. NAME AND ADDRESS OF CONTRACTOR (NO., street,city,county,State,and ZIP Code)

X

9a. AMENDMENT OF SOLICITATION NO.

SP0600-09-R-0526

9b. DATED (SEE ITEM 11)

September 8, 2009

10a. MODIFICATION OF CONTRACT/ORDER

NO.

10b. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

[ X ] The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers [ ] is extended, [ x ] is not extended Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning ____1___ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or(c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

X

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b)

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF: MUTUAL AGREEMENT OF THE PARTIES

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor [] is not, [ X ] is required to sign this document and return ___1____ copy to the issuing office.

4. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

a. Additional clauses have been incorporated into the solicitation and can be found on pages 2-9.

b. All references to Defense Energy Support Center (DESC) are hereby changed to reflect DLA Energy effective August 1, 2010.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remain unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

16A. NAME OF CONTRACTING OFFICER

15B. NAME OF CONTRACTOR/OFFEROR

BY

(Signature of person authorized to sign)

15C.DATE

SIGNED

16B. UNITED STATES OF AMERICA

BY

(Signature of Contracting Officer)

16C.DATE

SIGNED

NSN: 7540-01-152-8070 30-105 STANDARD FORM 30(REV 10-83)

Amendment 0007

C19.07 SAMPLING AND TESTING OF PETROLEUM PRODUCTS (STORAGE) (DESC OCT 2001)

(a) SAMPLING. The samples identified in the solicitation attachment entitled MINIMUM REQUIREMENTS FOR STORAGE SAMPLING AND TESTING are a required part of the services to be provided. The Contractor must provide these samples using qualified personnel, facilities, and equipment on-site and shall include all associated costs in the monthly service charge. These on-site resources may be provided by Contractor personnel or by a commercial source acting on behalf of the Contractor. The Quality Representative will not be responsible for taking any samples for the Contractor. All samples must be taken in accordance with ASTM D 4057, Standard Practice for Manual Sampling of Petroleum and Petroleum Products (API Manual of Petroleum Measurement Standards (MPMS), Chapter 8.1).

(b) TESTING. The tests identified in this solicitation attachment entitled MINIMUM REQUIREMENTS FOR STORAGE SAMPLING AND TESTING are a required part of the services to be provided. Those tests identified in the attachment which are part of a higher order analysis (defined as follows: Composite Samples, Storage Tanks After Receipt, Interface Mixture, Dormant Stocks, and Individual Tests, including particulate contamination) shall be provided by the Contractor using one of the following options (the Contractor shall check the appropriate box below):

[ ] The Contractor will perform the tests using its own qualified personnel, facilities, and equipment. (All costs for this service are to be included in the monthly service charge.)

[ ] The Contractor will not perform the tests using its own personnel, but will provide on a seven days per week, 24 hours a day basis, it’s own facilities and equipment for testing of product by Government personnel. (All costs for this service are to be included in the monthly service charge.)

[ ] The Contractor will not provide its own personnel, facilities, or equipment. Instead, the Contractor will, within 24 hours after sampling, transport any sample(s) to a commercial laboratory approved by the Government and arrange for that commercial laboratory to perform all the required tests. The Government, at its own option, may direct that samples be tested at a Government laboratory under contract to the Government. In this case, transport of such samples is still the responsibility of the Contractor. (The Government will reimburse the Contractor for the actual costs of the tests performed by their commercial laboratory. All other associated costs must be included in the monthly service charge.)

All other tests found in the above referenced attachment, which are not part of a higher order analysis, shall be provided in accordance with the CONTRACTOR INSPECTION RESPONSIBILITIES (STORAGE) clause.

(c) All facilities and equipment to be provided, whether that of a Contractor or a commercial laboratory, must conform to the standards for such facilities and equipment established by the Occupational Safety and Health Act and the National Fire Protection Association or local regulations, whichever is more stringent.

(DESC 52.211-9FL5)

E1.11 QUALITY CONTROL PLAN (DESC MAR 2000)

(a) Upon award, the Contractor shall prepare, in triplicate and in English, a Quality Control Plan (QCP). Prior to the first receipt of Government-owned product into the facility, two copies of the QCP shall be forwarded to the Contracting Officer and one copy to the assigned Quality Assurance Representative for approval.

(b) The QCP shall include the following quality control procedures employed by the Contractor.

(1) Receiving (both product and additives);

(2) Blending;

(3) Sampling;

(4) Testing;

(5) Storage and handling;

(6) Loading and shipping;

(7) Calibration program for testing and measuring equipment in accordance with ISO 10012-1, "Quality Assurance Requirements for Measuring Equipment, Part I." Equivalent local regulation, as appropriate, may be used as well. Whichever program used must include a section addressing meter proving (used to determine quantity) and must comply with the American Petroleum Institute Manual of Petroleum Measurement Standards, Chapters 4, 5, and 6, or equivalent foreign standard. For any item that requires calibration but is not covered by ASTM, API, or IP publications, the applicable manufacturer's recommended calibration method(s) outlined in the applicable industry publication shall be used if acceptable to the Government;

(8) Quantity measurement;

(9) Records and reports; and

(10) Corrective action procedures (to include, but not be limited to, procedures for notification of Quality Representative, actions to be taken on discovery of off-spec product during receipts/shipments, upgrading procedures for Contractor-caused contamination, leaks, etc.). The

QCP shall also include an organizational chart of key personnel and their responsibilities and a schematic diagram of the facility with key inspection/activity points marked for each product handled.

(c) The QCP shall require that each Contractor employee be familiar with its content and shall state that it must be reviewed semiannually and revised as needed. Revision should occur when any change is made to the inspection system, when any corrective action needs to be incorporated due to quality problems, and as otherwise necessary. The Contractor shall sign and date each revision of the QCP.

(DESC 52.246-9F32)

E28 CONTRACTOR INSPECTION RESPONSIBILITIES (STORAGE) (DESC OCT 2002)

(a) Inspection and tests by the Government of services, facilities, and equipment specified within this contract does not relieve the Contractor from responsibility to meet all requirements of the contract.

(b) The Contractor shall furnish personnel, facilities, and equipment on-site to accomplish the following routine tests and procedures.

These on-site resources may be provided by Contractor personnel or by a commercial source action on behalf of the Contractor. The Quality Representative will not be responsible for performing any of these services for the Contractor.

(1) Sampling of storage tanks, shipments and receipts in accordance with ASTM D 4057, Standard Practice for Manual Sampling of Petroleum and Petroleum Products (API Manual of Petroleum Measurement Standards (MPMS), Chapter 8.1);

(2) Retaining of product composite samples from shipments and receipts as follows:

MINIMUM

METHOD OF SHIPMENT MINIMUM QUANTITY RETENTION PERIOD

Pipeline 20 liters 60 days

Tanker/Barge Parcel Composite 20 liters 90 days Each compartment 0.5 liters 90 days

Navy Fleet Oilers/Vessels 10 liters 60 days

Tank Truck/Car 1 liter 15 days

NOTE: After the minimum retention period, samples shall be tested for Appearance, Color (Visual), API Gravity/Density and Flash Point and, if found to be on-specification, shall be returned to like Government stock on-site. Sample containers may be reused if properly cleaned.

(3) Determining the presence of water in storage tanks, shipments and receipts. Ensure that accurate water cuts are obtained by means of a water indicating paste conforming to MIL-W-83779B. Two suggested sources are Stewart Hall Chemical Testmaster Water Indicating Paste or Sartomer Sar Gel Water Indicating Paste (see Note 2 below);

(4) Determining Density at 15 degrees Celsius or API gravity of products by ASTM D 1298 or ASTM D 4052 (see Note 2 below);

(5) Determining the temperature of products by the API MPMS, Chapter 7 (see Note 2 below);

(6) Determining the Appearance of applicable products using ASTM D 4176, Procedure 1 (see Note 2 below);

(7) Determining the visual color of products.

(8) Determining the Flash Point of applicable products using test methods cited in the appropriate product specification (see Note 2 below);

(9) Conversion of gross to net gallonage (liters);

(10) Determining the percentage (volume) of fuel system icing inhibitor (FSII) by means of a portable refractometer in accordance with ASTM D 5006. One suggested source is H.B. Industries, Inc., Glenview, IL 60025 (B/2 Anti-Icing Additive test kit) (see Note 2 below); and

(11) Determining the range of fuel electrical conductivity using ASTM D 2624. One suggested source for a conductivity meter is Emcee Electronics, Inc., Sarasota, FL 33581 (Model 1152) (see Note 2 below).

Note 1: All costs for providing the above tests and procedures shall be included in the monthly service charge. The only exception to the Contractor’s obligation to provide these services as part of the monthly service charge is when the tests described above are part of the higher order analysis (defined as the following categories: Composite Samples, Storage Tanks After Receipt, Interface Mixtures, Dormant Stocks and Individual Tests (including particulate contamination) found in the attachment to the solicitations entitled MINIMUM REQUIREMENTS FOR STORAGE SAMPLING AND TESTING. Provisions for providing higher order analyses are covered in the SAMPLING AND TESTING OF PETROLEUM PRODUCTS (STORAGE) clause.

Note 2: Upon request, the Contractor shall permit the Quality Representative unrestricted use of the equipment and ancillary supplies needed to perform this test/procedure on behalf of the Government.

(c) During the contract, the Contractor shall furnish representative samples of the product in each storage tank, shipment or receipt at the request of, and in the manner and to the place designated by, the Quality Representative. Sample size will be 2 gallons for gasoline-type fuels and one gallon or 10 gallons for jet diesel-type fuels. The number of samples to be furnished during any 12-month period shall not exceed eight times the number of tanks specified in the contract. Such samples shall be packed, marked, and shipped by the Contractor, shipping expense prepaid, in containers and shipping boxes furnished by the Contractor. Sample containers shall be epoxy coated on the interior. This requirement is in addition to sampling required elsewhere in this clause and the contract. All reasonable direct shipping costs associated with samples required by this paragraph shall be reimbursed upon request from the Contractor and such costs shall not be included in the monthly service charge. However, all other costs related to this requirement shall be included as part of the monthly service charge.

(DESC 52.246-9FE1)

F1.05 GENERAL SHIPPING CONDITIONS (DESC OCT 1997)

(a) The Contractor will prepare the inspection and shipment documents covering deliveries made from the terminal in accordance with instructions contained in the Documentation and Product Property Control Plan. Normally, the document will consist of DD Form 250 for tank car, tank truck, pipeline, and packaged shipments, and DD Form 250-1 and ullage/innage reports in the case of barge and tanker shipments.

The Contractor will distribute the DD Forms 250 and the Quality Representative (QR) will distribute the DD Forms 250-1. When the QR is not present for release or shipment of product inspected at these facilities, and the Contractor's quality control program has been approved by the responsible Government Quality Office in accordance with paragraph 246.471 of the DOD FAR Supplement, the Contractor will insert the following certification on the inspector's copy of the shipping documents:

"I certify that the above supplies were (a) in the quantity indicated, (b) taken from Government-owned and approved stocks, and (c) loaded into inspected and approved containers. This shipment was released in accordance with paragraph 246.471-2 of the DoD FAR Supplement under authorization of (NAME and TITLE OF THE

AUTHORIZED REPRESENTATIVE OF THE CONTRACT ADMINISTRATION OFFICE)

in a letter dated (DATE OF AUTHORIZING LETTER). (SIGNATURE AND TITLE OF

CONTRACTOR'S DESIGNATED REPRESENTATIVE)."

(b) Shipment of products hereunder will be made only pursuant to a "release" furnished by the Product Property Administrator or his designated representative. The "release" will indicate the consignees who are authorized to issue "calls" or "orders" for shipment of product.

Such "release" will be periodically furnished to the Contractor by the cognizant Product Property Administrator.

(c) Conveyances required for shipments shall be furnished or designated by the Government. The Contractor shall inspect all shipping conveyances prior to loading to insure that product loaded will not be lost or contaminated by the condition of the equipment. Tank truck inspection must be performed by qualified Contractor personnel. Delegation of this responsibility shall not be passed to the tank truck operator/driver. The tank truck operator/driver may be permitted to physically load the tank truck; however, the loading operation must be under the surveillance and direction of Contractor personnel. Equipment found to be unsatisfactory shall be reported as follows: (1) TANKERS AND BARGES. Report immediately by telephone to the QR; if not present, the master of the tanker or barge or to the carrier's agent or general office;

(2) TANK CARS. Report to the QR and by wire (Government Rate, Collect) to Commander, Eastern Area, Military Traffic Management Command, ATTN: MTE-INR-O, Brooklyn, NY 11250. Any shortage or overage of tank cars shall be similarly reported; (3) TRANSPORT TRUCKS. Contractor shall expeditiously report to the Traffic Manager of the appropriate Defense Fuel Region, Government QR, and to the carrier's terminal where equipment is domiciled.

(d) Except when loading barges or tankers, or making pipeline deliveries, strainers of 100 mesh or finer shall be utilized in loading aviation fuels and jet lubricating oil and 60 mesh or finer in the case of reciprocating engine oil. Strainers shall be located as near the loading point as practicable. Contractor shall furnish and periodically inspect and clean such strainers and repair same, if necessary, keeping a written record thereof.

(e) Contractor shall affix serially numbered seals to the dome covers of tank cars and all openings in the case of tank trucks in such a manner that entry could only be gained by breaking a seal. Such seals will be furnished by the Contractor. Seal numbers will be indicated on shipping documents.

(f) Placards, as required by 49 CFR 172.506 and 49 CFR 172.508, shall be furnished and affixed to all tank cars and tank trucks by Contractors unless placards are already affixed.

(g) FOR TANK CARS ONLY.

(1) If Government-owned or leased tank cars are furnished, the Contractor will maintain records showing each day a car is received or forwarded by car number and will furnish the information to the Defense Fuel Regional Office upon request.

(2) Bottom outlet gaskets and manway cover gaskets, when required due to deterioration or loss, shall be furnished and applied to tank cars by the Contractor.

(3) The Contractor shall (i) inspect empty Government-owned tank cars located on the Contractor's premises and (ii) ship tank cars located on the Contractor's premises to repair facilities as directed by the Government.

(h) Unless otherwise directed, the Contractor shall prepare and distribute Government bills of lading utilized in shipments. Such bills of lading, routing instructions, and transportation assistance will be furnished by the Defense Fuel Region placing orders.

(i) The Contractor shall comply with routing instructions furnished by the Government. Such instruction will include names, routes, route order numbers, and other pertinent information. The Contractor shall be responsible for scheduling of commercial transport trucks, trucks and trailer, and tank wagons to its plant in accordance with such routing instructions and consonant with the applicable order. The Contractor shall provide sufficient advance notice to carriers and schedule the carrier's equipment for loading. The Contractor shall reimburse the Government for any demurrage incurred as a result of improper scheduling.

(j) Custody of product shipped by pipeline, and risk of loss thereof, shall pass from the Contractor to the carrier when the product passes the flange connecting the Contractor's pipeline and the carrier's pipeline.

(k) Custody of product shipped by transport truck, and risk of loss thereof, shall pass from the Contractor to the carrier when the loaded transport truck is released for shipment by the Contractor.

(l) Custody of product shipped by tank car, and risk of loss thereof, shall pass from the Contractor to the carrier when the loaded tank car is picked up by the carrier.

(m) Custody of product delivered to tanker or barge, and risk f loss thereof, shall pass from the Contractor to the carrier when the fuel passes the vessel’s permanent hose connection.

(n) The Contractor shall be held accountable for demurrage charges arising from delay(s)in shipment by tank cars and transport trucks except when those delays are caused by reasons beyond the control and without the fault or negligence of the Contractor and its subcontractors.

(o) The following subparagraphs only apply to barges and tankers.

(1) SCHEDULED ARRIVAL DATE AND BASIC ALLOWED LAYTIME.

(i) Notice shall be furnished to the Contractor in advance of the date on which loading is to be made, which date is hereinafter referred to as the "Scheduled Arrival Date." Each notice will specify the quantity to be loaded, the cargo number, and name of the vessel and the scheduled loading date. For tankers, notice will also include the size of the vessel and the expected time of arrival. Notice of delivery will be furnished at least 72 hours in advance of the scheduled arrival date for tankers, and at least 48 hours in advance of the scheduled arrival date for barges. When anticipated vessel transit time to the loading point is less than 72/48 hours, the Government will provide the maximum notice practicable. Any change in the scheduled arrival date of less than 48 hours notice for barges and 72 hours notice for tankers will require verbal approval of the Contractor, confirmed in writing..

(ii) The Contractor shall provide as soon as possible, but within 3 hours after issue of notice of readiness to load from a barge and within 6 hours after the Contractor receives notice of readiness to load from a tanker, a reachable berth, free of cost to the Government, where the vessel can be safely moored and afloat with necessary access thereto PROVIDED, however --

(A) If the vessel is tendered for loading on a date earlier than the last agreed scheduled arrival date, the Government’s vessel shall be loaded as soon as possible in its proper turn with other vessels, and laytime shall not commence until the vessel moors alongside or, for barges, 3:00 A.M. local time; for tankers, 6:00 A.M. local time, on the last agreed scheduled arrival date, whichever occurs first.

(B) If the vessel is tendered for loading later than 12:00 noon of the day following the last scheduled arrival date, the vessel shall be loaded in its proper turn with other vessels. Laytime shall commence when the vessel moors alongside, provided a good faith effort is made by the Contractor to moor the vessel in its turn with other vessels as loading berths become available. If the vessel is not moored in its proper turn with other vessels, laytime will commence at 6:00 A.M. on the date the Government vessel’s turn occurred.

(iii) Laytime shall commence either (A) at the expiration of the notice period prescribed in subparagraph (ii) above, berth or no berth, or (B) immediately when the vessel moors alongside, with or without notice of readiness, whichever occurs first.

(iv) Laytime, once started, shall continue 24 hours per day, 7 days per week, without interruption, from its commencement until loading of the barge or tanker is completed and hoses have been removed.

(v) Unless otherwise provided in the Schedule, the Contractor shall be allowed and will complete unloading within laytime determined as follows:

(A) FOR BARGES: One hour for each 2,000 barrels of product to be loaded.

(B) FOR TANKERS: Thirty-six hours for load of full vessel cargo. When partial vessel cargoes are to be loaded, the 36 hours will be prorated based on quantities loaded by each supplier. The 36 hours includes allowances for routine events that occur in the loading process, such as cushioning and topping off of vessel tanks.

(vi) Hoses and loading arms for loading shall be furnished, connected, and disconnected by the Contractor.

(2) INCREASES TO BASIC ALLOWED LAYTIME.

(i) If, after laytime commences, the conditions or facilities of the barge or tanker to be loaded do not permit loading, basic allowed laytime shall be increased by the duration of the delay.

(ii) If the vessel is delayed in reaching its berth and the delay is caused by the fault of the vessel, basic allowed laytime shall be increased by the duration of the delay.

(iii) After laytime commences, when vessels are required to dock at anchorage due to vessel delays such as vessel inspection and inerting, laytime credit will be allowed for transit time from anchors away at anchorage until first line ashore berthing, not to exceed 2 hours.

(iv) If regulations of the owner or operator of the vessel prohibit loading at any time after laytime has commenced, time so lost shall be added to basic allowed laytime.

(v) If, for any reason, the Contractor is delayed in loading the barge or tanker because of actions of a Government representative, acting under the contract, that arise through no fault or negligence on the part of the Contractor or its subcontractors, basic allowed laytime shall be increased by the duration of the delay.

(vi) There will be no increase to basic allowed laytime (nor other reductions to any resulting demurrage time) for saved laytime arising out of other loadings/discharges.

(vii) Delays, after commencement of laytime, attributed to causes beyond the control and without the fault or negligence of the Contractor or the U.S. Government will result in increasing the basic allowed laytime by one half of the delay time.

(3) PAYMENT OF DEMURRAGE. For all hours of laytime which elapse in excess of the basic allowed laytime for loading provided for by paragraph (1) above, or as otherwise provided in the Schedule, the Contractor shall pay demurrage to the Government as follows:

(i) USS, USNS, OR TIME CHARTERED VESSELS. At the demurrage rate for the vessel loaded computed to the nearest whole hour as published by the Military Sealift Command and in effect on the date the loading of the vessel is completed.

(ii) VOYAGE CHARTERED VESSELS. At the demurrage rate cited in the charter, except that the demurrage payable by the Contractor shall in no event exceed the demurrage expense incurred by the Government under the Charter.

(DESC 52.247-9FP1)

I1.07 CENTRAL CONTRACTOR REGISTRATION (ALTERNATE A) (APR 2008/SEP 2007)

(a) DEFINITIONS. As used in this clause-- Central Contractor Registration (CCR) database means the primary Government repository for Contractor information required for the conduct of business with the Government.

Commercial and Government Entity (CAGE) code means—

(1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an “NCAGE code.”

Data Universal Numbering Systems (DUNS) number means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

Data Universal Numbering System + 4 (DUNS+4) number means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional CCR records for identifying alternative Electronic Funds Transfer (EFT) accounts (see the FAR at Subpart 32.11) for the same parent concern.

Registered in the CCR database means that—

(1) The Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the CCR database;

(2) The Contractor’s CAGE code is in the CCR database; and

(3) The Government has validated all mandatory data fields to include validation of the Taxpayer Identification Number (TIN) within the Internal Revenue Service, and has marked the records “Active.” The Contractor will be required to provide consent for TIN validation to the Government as part of the CCR registration process.

(b) (1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the CCR database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS+4” followed by the DUNS or DUNS+4 number that identifies the offeror’s name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the CCR database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number—

(i) Via the Internet at http://fedgov.dnb.com/webform or, if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business name.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

http://fedgov.dnb.com/webform�

(iii) Company physical street address, city, state and Zip Code.

(iv) Company mailing address, city, state and Zip Code (if separate from physical).

(v) Company telephone number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the CCR database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the CCR database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the CCR database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the CCR database to ensure it is current, accurate and complete. Updating information in the CCR does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(g) (1) (i) If a Contractor has legally changed its business name, “doing business as” name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to—

(A) Change the name in the CCR database;

(B) Comply with the requirements of Subpart 42.12 of the FAR; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification and sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the CCR information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the CCR records to reflect an assignee for the purpose of assignment of claims (see FAR Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the CCR database. Information provided to the Contractor’s CCR record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the “Suspension of Payment” paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the Internet at http://www.ccr.gov or by calling 1-888-227-2423 or 269-961-5757.

(FAR 52.204-7/DFARS 252.204-7004)

SUP 5252.204-9400 Contractor Access to Federally Controlled Facilities and/or Unclassified Sensitive Information or Unclassified IT Systems (May

2010)

Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The Deputy Secretary of Defense Directive-Type Memorandum (DTM) 08-006 – “DoD Implementation of Homeland Security Presidential Directive – 12 (HSPD-12)” dated November 26, 2008 (or its subsequent DoD instruction) directs implementation of HSPD-12.

This clause is in accordance with HSPD-12 and its implementing directives. This clause applies to contractor employees requiring physical access to any area of a federally controlled base, facility or activity and/or requiring access to a DoD computer/network, to perform certain unclassified both non-sensitive and sensitive duties. It is the responsibility of the command/facility where the work is performed to ensure compliance.

The requirement to control access to sensitive information applies to all US government IT systems and/or areas where unclassified but sensitive information may be discussed, displayed or maintained. DON policy prescribes that all unclassified data that has not been approved for public release and is stored on mobile computing devises must be treated as sensitive data and encrypted using commercially available encryption technology.

Whenever granted access to sensitive information, contractor employees shall follow applicable DoD/DoN instructions, regulations, policies and procedures when reviewing, processing, producing, protecting, destroying and/or storing that information. Operational Security (OPSEC) procedures and practices must be implemented by both the contractor and contract employee to protect the product, information, services, operations and missions related to the contract. The contractor shall designate an employee to serve as the Contractor’s Security Representative. Within three work http://www.ccr.gov/� days after contract award, the contractor shall provide to the Navy Command’s Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the Contractor’s Security Representative. The Contractor’s Security Representative shall be the primary point of contact on any security matter. The Contractor’s Security Representative shall not be replaced or removed without prior notice to the Contracting Officer.

Non-Sensitive Positions Contractor employee whose work is unclassified and non-sensitive (e.g., performing certain duties such as lawn maintenance, vendor services, etc ...)

and who require physical access to publicly accessible areas to perform those duties shall meet the following minimum requirements:

• Must be either a US citizen or a US permanent resident with a minimum of 3 years legal residency in the US (as required by The Deputy Secretary of Defense DTM 08-006 or its subsequent DoD instruction) and

• Must have a favorably completed National Agency Check with Written Inquiries (NACI) including a Federal Bureau of Investigation (FBI) fingerprint check prior to installation access.

To be considered for a favorable trustworthiness determination, the Contractor’s Security Representative must submit for all employees each of the following:

• SF-85 Questionnaire for Non-Sensitive Positions

• Two FD-258 Applicant Fingerprint Cards

• Original Signed Release Statements

The contractor shall ensure each individual employee has a current favorably completed NACI.

The Contractor’s Security Representative shall be responsible for initiating reinvestigations as required. Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date.

Sensitive Positions Contractor employee whose duties require accessing a DoD unclassified computer/network, working with sensitive unclassified information (either at a Government or contractor facility), or physical access to a DoD facility must be a US citizen and possess a favorable trustworthiness determination prior to installation access. To obtain a favorable trustworthiness determination, each contractor employee must have a favorably completed National Agency Check with Local Credit Checks (NACLC) which consists of a NACI including a FBI fingerprint check plus credit and law enforcement checks. Each contractor employee applying for a trustworthiness determination is required to complete:

• SF-85P Questionnaire for Public Trust Positions

• Two FD-258 Applicant Fingerprint Cards

• Original Signed Release Statements

Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date.

To maintain continuing authorization for an employee to access a DoD unclassified computer/network, and/or have access to sensitive unclassified information, the contractor shall ensure that the individual employee has a current requisite background investigation. The Contractor’s Security Representative shall be responsible for initiating reinvestigations as required and ensuring that background investigations remain current (not older than 10 years) throughout the contract performance period.

IT Systems Access When access to IT systems is required for performance of the contractor employee’s duties, such employees shall in-process with the Navy Command’s Security Manager and Information Assurance Manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual’s performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The SAAR-N shall be forwarded to the Navy Command’s Security Manager at least 30 days prior to the individual’s start date. Failure to provide the required documentation at least 30 days prior to the individual’s start date shall result in delaying the individual’s start date.

When required to maintain access to required IT systems or networks, the contractor shall ensure that all employees requiring access complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. The Contractor’s Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required.

Security Approval Process The Contractor’s Security Representative shall ensure that each individual employee pending assignment shall accurately complete the required forms for submission to the Navy Command’s Security Manager. The Contractor’s Security Representative shall screen the investigative questionnaires for completeness and accuracy and for potential suitability/security issues prior to submitting the request to the Navy Command’s Security Manager. Forms and fingerprint cards may be obtained from the Navy Command’s Security Manager. These required items, shall be forwarded to the Navy Command's Security Manager for processing at least 30 days prior to the individual employee’s anticipated date for reporting for duty. The Navy Command’s Security Manager will review the submitted documentation for completeness prior to submitting it to the Office of Personnel Management (OPM). Suitability/security issues identified by the Navy Command’s Security Manager may render the contract employee ineligible for the assignment. A favorable review of the questionnaire and advance fingerprint results are required as an interim measure prior to the contract employee start date. An unfavorable determination made by the Navy Command’s Security Manager is final and such a determination does not relieve the contractor from meeting any contractual obligation under the contract.

If contractor employees already possess a current favorably adjudicated investigation, the Navy Command’s Security Manager will use the Visit Authorization Request (VAR) via the Joint Personnel Adjudication System (JPAS). The contractor shall include the IT Position Category per SECNAV M-5510.30 for each employee designated on a VAR. The VAR requires annual renewal for the duration of the employee’s performance under the contract.

The Navy Command’s Security Manager will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DON Central Adjudication Facility (CAF) for a position of trust determination. When a favorable determination is not made, contractor employees shall not be permitted to work on this contract effort and if already working on the contract shall be removed immediately.

The potential consequences of any requirements under this clause including denial of access for a proposed contractor employee who fails to obtain a favorable trustworthiness determination in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees for working in non-sensitive positions, with sensitive information, and/or on Government IT systems. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have physical access to a federally controlled facility and/or access to a federally-controlled information system/network and/or access to government information.