Attachment_5 _F-1.pdf

SECTION F

DELIVERIES OR PERFORMANCE

F-1

National Park Service Solicitation Number

1. CLAUSES INCORPORATED BY REFERENCE

(FAR 52.252-2) (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

Also, the full text of a clause may be accessed electronically at this/these addresses:

http:/www.arnet.gov

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

CLAUSE

NUMBER DATE TITLE

52.242-15 AUG 1989 STOP-WORK ORDER

52.242-17 APR 1984 GOVERNMENT DELAY OF

WORK

2. TIME EXTENSIONS

(FAR 52.211-13) (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

3. SUSPENSION OF WORK

(FAR 52.242-14) (APR 1984)

A. The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the

Contracting Officer determines appropriate for the convenience of the Government.

B. If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

SECTION F

DELIVERIES OR PERFORMANCE

F-2

National Park Service Solicitation Number

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

C. A claim under this clause shall not be allowed--

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved

(but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

4. REVIEW AND APPROVAL

The COTR will notify the Contractor, in writing, of approval or rejection of the submittals within 3 calendar days. Any additions or corrections shall be completed and returned to the Government within 4 calendar days. In the event the Government delays beyond the period specified, the Contractor shall be entitled to a day-to-day extension in the completion date.