N00024-19-R-4404-0004.docx

N0002419R4404

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0004

The purpose of this Amendment is to:

-Update clauses and provisions to current dated versions as indicated herein.

-Revise Clause 52.217-7 as indicated in red text.

-Update Section B Notes B, C, D, and E in their entirety.

-Revise Exhibit A, B, and C Rev 1 Contract Data Requirements List as indicated herein.

SECTION B - SUPPLIES OR SERVICES AND PRICES

The following have been modified:

GROWTH RESERVATION

NOTE D: GROWTH RESERVATION

The growth reservation hours and material dollar requirements listed in Section B, NOTE A, are a part of this contract under the original solicitation and award. The hour reservation shall include prime contractor hours. The balance of hours and material remaining in the reservation CLINs after negotiations have concluded, and when it is evident that no additional growth will be directed in accordance with NOTE A, is subject to a decrease change order. Only actual production hours expended will be considered towards the contractor’s obligation to provide the defined reservation hour effort. While supervision, quality assurance, and other nonproduction labor should be included in the pricing for reservation items in the original bid, they shall not count towards satisfying the contractor’s obligation to provide reserved hours. The labor hour reservation shall not include any allowance for technical representatives or for any other Government directed source unless specifically addressed. Material dollars shall be based on actual costs to the prime Contractor of acquiring the materials provided and total cost of subcontractor efforts proposed. Material dollars may include freight or duties which would be reflected on the invoice for the material. The Contractor shall not be allowed to add material handling charges, overhead (including G&A), or profit into the actual cost of materials expended toward the reservation. The information received in the consolidated final report required by Section C Paragraph 6 will be used by the Contracting Officer in the issuance of one contract modification, which will be a final settlement for all reservation Work. This reservation is Level of Effort to Completion. Once the scope of work for a task has been listed and a mutually agreeable number of hours or material has been agreed to, neither party will be entitled to an adjustment based on actual hours or material dollars required. Each task shall receive approval by the Navy Project Manager and the Administrative Contracting Officer (ACO).

LABOR & MATERIAL BURDEN RATES

NOTE B: FIXED SHIP REPAIR LABOR AND MATERIAL BURDEN RATES FOR GROWTH AND NEW WORK

SCHEDULE OF PRICES / RATES: SHIP REPAIR LABOR RATE (FULLY BURDENED)

1. The Contractor’s fully burdened ship repair labor rate will be used for negotiating growth and new work to be performed under this contract. The contractor agrees that the number of hours included in its price proposal for contract modifications shall include only direct production hours. For these purposes, direct production hours are for skilled labor at the journeyman level expended in direct production including but not limited to the following functions:

Abrasive cleaning/blasting Fire Watch Welding Burning Brazing Carpentry Machinists (inside and outside) Electrical Work Electronic Work Engineering Design Support Lagging Ship-fitting Boiler-making Painting Sheet-metal Work Pipefitting Rigging General Labor Staging/Scaffolding Diesel Mechanics

1. The fully burdened ship repair labor rate proposed by the contractor listed in paragraph 7 below shall include all costs associated with support functions (whether charged directly or indirectly by the offeror’s accounting systems) provided in support of the direct production functions listed in paragraph 1 above. Support functions shall be considered to be included in the offeror’s fully burdened ship repair labor rate for direct production hours. Labor hours for the below support functions shall not be separately proposed, including in support of subcontractors. Support functions include, and are not limited to, those types listed below:

Testing Quality Assurance Execution Planning Cleaning (except tank cleaning) Supervision Security Surveying Administration Transportation Purchasing Staff Lofting Other indirect support Handling & Warehousing Safety/Environmental Program Management

1. The fully burdened ship repair labor rate is a fixed hourly rate that includes all wages, overhead, all other indirect costs, general and administrative expenses, Facilities Capital Cost of Money (FCCOM) and profit. The fully burdened ship repair labor rate represents a blended rate including labor transferred between divisions, subsidiaries, or affiliates of the contractor under a common control.

1. Consumable materials are goods used in the ordinary course of work performance such as office supplies, paper, rags, vehicle or equipment fuel costs, cleaning chemicals, disposable tools, welding rods, paint buckets, paint brushes, protective clothing, etc. that are consumed/used in the process of repair and do not become an integral part of the repaired vessel. Consumable material shall be included in the contractor’s fully burdened ship repair labor rate and not separately priced.

1. Physical materials are goods that become an integral part of the repaired vessel in the course of the repair, such as equipment, replacement steel, pipes, paint, and fasteners. The material burden rates apply to physical materials but not to consumable materials. The material burden rate will be applied to the actual cost of the physical material. Actual cost does not include handling charges, general and administrative cost, overhead, profit, or any other indirect cost.

1. For contract changes involving subcontractors, subcontractor quotes will be treated as Other Direct Costs (ODCs) and will be subject to the contract material burden rate shown in paragraph (7) below. Subcontractor quotes must be competitively acquired and submitted with the contractor’s Change Order Price Analysis (COPA) in response to Request for Contract Changes (RCCs) and Reservation Task Requests (RTRs) issued by the Contracting Officer. At no time will the proposed total to be performed by the prime contractor combined with subcontractor quote, material quote, and applicable burdens be allowed to cost more than it would have, had the prime contractor directly provided all material and labor. The proposed total pricing restriction addressed in the preceding sentence does not apply in any case where the work is required to be performed by Original Equipment Manufacturers (OEMs), Government directed subcontractors, Government authorized vendors, or any other work at the sole discretion of the Administrative Contracting Officer. RCCs and RTRs that are subcontracted for material only (no associated labor required within the RCC) shall not be subject to the Material Burden Rate.

1. The contract fixed fully burdened ship repair labor rate and material burden rate are shown below. These fixed rates shall be used for negotiating growth and new work during the availability:

USS MICHAEL MURPHY (DDG112) FY20 SRA

1. The Contractor’s fully burdened ship repair labor rate shall be escalated by TBD (Provided by Government) % quarterly commencing 3 months through 24 months after the Attachment J-3 availability completion date and shall be used to negotiate growth and new work when the changes must be performed during a Government responsible extension. The escalated cost shall reflect when the work is to be performed. The material burden rate shall not change.

OPTION ITEM FAR 52.217-7

NOTE C: Option item to which the option clause FAR 52.217-7 applies and which is to be supplied only if and to the extent said option is exercised.

SCHEDULE OF PRICES / RATES

NOTE E: SCHEDULE OF PRICES / RATES FOR THE PURPOSES OF A GOVERNMENT REQUIRED EXTENSION DAILY RATES FOR PIERSIDE AND DRY DOCKING (FULLY BURDENED)

· CLINS 0021 for the USS MICHAEL MURPHY (DDG112) FY20 SRA

1. In the event of a Government required extension, the Contractor’s fully burdened daily rates for pierside and dry-docking will be used for negotiating additional dry-dock and/or pierside performance days under this contract.

1. The contractor agrees that the daily rates shall include all costs that run with time associated with additional performance days in accordance with the work package specification requirements of this availability. The daily rates shall include all costs associated with additional performance days (whether charged directly or indirectly by the offeror’s accounting systems) including but not limited to:

· Temporary Services

· Internet Connectivity

· Air Conditioning

· Support Services for the Navy, its agents and contractors

· Facilities, including but not limited to:

· Piers

· Office spaces

· Trailers

· Parking

· Flammable Liquid Storage and Hazardous Material Storage

· Material Warehousing and Lay-down space

· Project Management and other labor costs that run with time including but not limited to:

· Program Management

· Supervision

· Integration & Scheduling

· Cleaning (except tank cleaning)

· Quality Assurance

· Execution Planning

· Security

· Administration

· Contracts

· Purchasing

· Other indirect support

· Safety/Environmental

· Transportation

1. The fully burdened daily rates are fixed daily rates that include all wages, overhead, all other indirect costs, general and administrative expenses, Facilities Capital Cost of Money (FCCOM) and profit.

1. The contract’s fixed fully burdened daily rates for pierside and dry-docking are shown below. These rates are to be used during the availability’s extension period, up to 24 months after the attachment J-X availability completion date. These fixed rates shall be used for additional docking and pierside days:

SECTION G - CONTRACT ADMINISTRATION DATA

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

“Payment request” and “receiving report” are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order:

(1) Document type. The Contractor shall submit payment requests using the following document type(s):

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items—

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either “Invoice 2in1” or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

[Note: The Contractor may use a WAWF “combo” document type to create some combinations of invoice and receiving report in one step.]

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert “See Schedule” or “Not applicable.”) (**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s WAWF point of contact.

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

The following included by reference have been revised:

SECTION I - CONTRACT CLAUSES

52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages, as described in the table below, per calendar day of delay.

The sum of liquidated damages, across all milestones in the table below, shall not exceed 10% of the awarded price of Availability, including all Base and Option Items.

END OF AVAIL - Mission Ready Vessel Redelivered to Fleet*

$133,640

Up to total maximum liquidated damage

(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and Service clause in this contract.

* In regard to the milestone “END OF AVAIL- Mission Ready Vessel Redelivered to Fleet”, if the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, such that their failure delays the completion of work that may be outside of the scope of the Contractor’s contract, such as AIT & 3rd Party Trade efforts and Government & 3rd Party test and trials, and this failure delays the Navy’s ability to return the vessel to the fleet at the milestone “END OF AVAIL - Mission Ready Vessel Redelivered to Fleet” the Contractor shall, in place of actual damages, pay to the Government liquidated damages, as described in the table below, per calendar day of delay.

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

NOTE C: Option item to which the option clause FAR 52.217-7 applies and which is to be supplied only if and to the extent said option is exercised.

(Applicable to all Option CLINs).

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor as outlined below. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

CLINs 0003-0010: No later than 20 days prior to the availability start date CLINs 0011-0021: At anytime prior to the delivery date under the contract (as modified)

The following included by full text have been revised:

252.203-7004 DISPLAY OF HOTLINE POSTERS (OCT 2016)

(a) Definition. “United States,” as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

(b) Display of hotline poster(s).

(1)(i) The Contractor shall display prominently the DoD fraud, waste, and abuse hotline poster prepared by the DoD Office of the Inspector General, in effect at time of contract award, in common work areas within business segments performing work under Department of Defense (DoD) contracts.

(ii) For contracts performed outside the United States, when security concerns can be appropriately demonstrated, the contracting officer may provide the contractor the option to publicize the program to contractor personnel in a manner other than public display of the poster, such as private employee written instructions and briefings.

(2) If the contract is funded, in whole or in part, by Department of Homeland Security (DHS) disaster relief funds and the work is to be performed in the United States, the DHS fraud hotline poster shall be displayed in addition to the DoD hotline poster. If a display of a DHS fraud hotline poster is required, the Contractor may obtain such poster from—

(i) DHS Office of Inspector General/MAIL STOP 0305, Attn: Office of Investigations – Hotline, 245 Murray Lane SW, Washington, DC 20528-0305; or

(ii) Via the internet at https://www.oig.dhs.gov/assets/Hotline/DHS_OIG_Hotline-optimized.jpg.

(c)(1) The DoD hotline poster may be obtained from: Defense Hotline, The Pentagon, Washington, D.C. 20301-1900, or is also available via the internet at http://www.dodig.mil/hotline/hotline_posters.htm.

(2) If a significant portion of the employee workforce does not speak English, then the poster is to be displayed in the foreign languages that a significant portion of the employees speak.

(3) Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the required poster at the website.

(d) Subcontracts. The Contractor shall include this clause, including this paragraph (d), in all subcontracts that exceed $5.5 million except when the subcontract is for the acquisition of a commercial item.

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

DOCUMENTS/EXHIBITS/ATTACHMENTS

The following document(s), exhibit(s), and other attachment(s) form a part of this solicitation:

The following document(s), exhibit(s), and other attachment(s) also form a part of this solicitation and will form a part of the contract resulting from this solicitation:

Exhibit A Rev 1 Contract Data Requirements List (CDRL) (DD Form 1423) A001-A003; A005-A009; A011; A012; A014 (Does not include A004, A0010, or A0013) Exhibit B Rev 1 Contract Data Requirements List (CDRL) (DD Form 1423) B001-B009 Exhibit C Rev 1 Contract Data Requirements List (CDRL) (DD Form 1423) C001-C002

SECTION K - REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 336611.

(2) The small business size standard is 1,250.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.] x (i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

x (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEC 2018)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.] x (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

x (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

x (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

x (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

(End of provision)

SECTION L - INSTRUCTIONS, CONDITIONS AND NOTICES TO BIDDERS

(End of Summary of Changes) image1.wmf