EXHIBIT 15 - PERFOMANCE AND PAYMENT BOND.pdf

PERFORMANCE BOND

LOS ANGELES COUNTY

METROPOLITAN TRANSPORTATION AUTHORITY

CONTRACT NO. ____________________

WHEREAS the Los Angeles County Metropolitan Transportation Authority ("LACMTA") has awarded to ____________________________________________________ ("Principal"), Contract No __________________, ____________________________________________ and

WHEREAS Principal is required under the terms of the Contract to furnish a Bond for the faithful performance of the Contract;

NOW, THEREFORE, we __________________ __________________, as Principal, and _____________________________________, ("Surety"), as Surety, are held and firmly bound unto LACMTA in the sum of ______________________________________________ Dollars ($__________________________), this amount being not less than the Total Contract Price in lawful money of the United States of America, for payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severably, firmly by these presents. In case suit is brought upon this Bond, Surety shall pay reasonable attorneys' fees to LACMTA in an amount to be fixed by the court.

The condition of this obligation is such that, if the hereby-bonded Principal or its heirs, executors, administrators, successors, assigns, or Subcontractors shall in all things stand to and abide by and well and truly keep and perform all the undertakings, terms, covenants, conditions, and agreements in the Contract and any alteration thereof, made as therein provided, all within the time and in the manner therein designated and in all respects according to their true intent and meaning, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect.

Further, Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or modification of the contract documents, or of the Work to be performed thereunder, shall in any way affect its obligations under this Bond, and it does hereby waive notice of any such change, extension of time, alteration, or modification of the contract documents or of the Work to be performed thereunder.

EXHIBIT 15 -

IN WITNESS WHEREOF, three identical counterparts of this instrument, each of which shall for all purposes be deemed an original hereof, have been duly executed by Principal and Surety named herein, on the _____________ day of _________________________ 20_______, the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative pursuant to authority of its governing body.

By:

(Principal)

By:

(Surety)

PAYMENT (MATERIAL AND LABOR) BOND

LOS ANGELES COUNTY

METROPOLITAN TRANSPORTATION AUTHORITY

CONTRACT NO. ____________________

WHEREAS the Los Angeles County Metropolitan Transportation Authority ("LACMTA") has awarded to ____________________________________________________ ("Principal"), Contract No __________________, ____________________________________________ and

WHEREAS Principal is required under the terms of the Contract to furnish a Bond to secure the payment of claims of laborers, mechanics, material men, and other persons as provided by law;

NOW, THEREFORE, we _____________________________________, as Principal, and _____________________________________, ("Surety"), as Surety, are held and firmly bound unto LACMTA in the sum of ______________________________________________ Dollars ($__________________________), this amount being not less than the Total Contract Price in lawful money of the United States of America, for payment of which sum well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors, and assigns, jointly and severably, firmly by these presents. In case suit is brought upon this Bond, Surety will pay reasonable attorneys' fees to LACMTA and the plaintiff(s) in an amount to be fixed by the court.

The condition of this obligation is such that, if the hereby-bonded Principal, or its heirs, executors, administrators, successors, or assigns, or Subcontractors shall fail to pay any of the persons named in Civil Code § 3181 or to pay amounts due under the Unemployment Insurance Code with respect to work or labor performed under the Contract, or amounts due under the Contract, or any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of Principal or its Subcontractors pursuant to § 13020 of the Unemployment Insurance Code with respect to Work or labor performed under the Contract, then the Surety herein named shall pay for the same in an amount not exceeding the sum specified in this Bond; otherwise the above obligation shall be void.

This Bond shall inure to the benefit of any of the persons named in Civil Code § 3181 as to give a right of action to such persons or their heirs, executor's, administrators, successors, or assigns in any suit brought upon this Bond.

Further, Surety, for value received, hereby stipulates and agrees that no change, extension of time, alteration, or modification of the contract documents, or of the Work to be performed thereunder, shall in any way affect its obligations on this Bond, and it does hereby waive notice of such change, extension of time, alteration, or modification of the contract documents, or of the Work to be performed thereunder.

IN WITNESS WHEREOF, three identical counterparts of this instrument, each of which shall for all purposes be deemed an original hereof, have been duly executed by Principal and Surety named herein, on the _____________ day of _________________________ 20_______, the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative pursuant to authority of its governing body.

By:

(Principal)

By:

(Surety)