6973GH-24-R-00121.pdf

Section A - Solicitation/Contract Form

Section B - Supplies or Services/Prices

Section B - Schedule

See Section J, Attachment 1.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications

Scope of Work

See Section J, Attachments 2-7.

C.1 Description The contractor shall furnish all labor, tools, materials, equipment, and supplies, necessary to accomplish the construction project, in accordance with the specifications and drawings, and the other terms, conditions, and provisions as set forth herein. All work performed and any materials and equipment used will be subject to approval by the Contracting Officer Representative (COR) and Contracting Officer (CO). This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

C.2 Bid vs. Offer References to the terms "bid", "bidder", et. throughout the specification are intended to mean "offer", "offeror", etc.

C.3 Specifications and/or Drawings The following specifications and/or drawings are applicable to this acquisition.

(a) Drawings, Attachment 3 100% Type B FAA-MMAC 19-035903 VTD Upgrades Drawings, February 8, 2024, 63 pages

(b) Specifications, "Attachment 4 100% Type B FAA-MMAC 19-035903 VTD Upgrades Specifications, February 8, 2024, 461 pages

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking

Clause List

Section E - Inspection and Acceptance

Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

Section F - Deliveries or Performance

Clause List

F.1 Working Hours Work at the site shall be accomplished between the hours of Normal work hours are between 7:30 a.m. and 4:00 p.m., Monday through Friday. The contractor must coordinate work activities outside these hours with the COR.., Monday through Friday, excluding federally established holidays, except when prior approval has been obtained from the Contracting Officer seven (7) days in advance. Approval for overtime work shall not be construed as an agreement for payment of overtime work.

F.2 Utility Outages and Shutdown Utility outages and shutdown shall be coordinated with the Contracting Officer and Project Manager. Outages affecting FAA operations are required to be accomplished at night, on weekends, or designated government holidays. Prior to any outage or shutdown, twenty-one (21) working days notification must be made to coordinate scheduling of any work to be performed during any hours.

F.3 Contractor Use of Premises

(a) General: Limit use of site and premises to allow:

(1) Owner Occupancy

(2) Work by others

(b) Access to Site: Limited to area required for construction.

F.4 Contractor's Construction Schedule and Material Submittal The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fifteen (15) days of the date established for "Commencement of Work" in accordance with Clause 3.2.2.3-56 which is incorporated by reference.

Section G - Contract Administration Data

Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within 10 calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements

Clause List

H.1 Permits and Responsibilities

The contractor shall secure and pay for all permits, licenses, special inspections, certificates, etc...required by Federal, State, and City/Town officials as necessary to perform the work, prior to starting construction, and in a timely manner to avoid delays in starting the job. The Contractor shall abide by all requirements dictated by the municipality for such permits without any additional cost H.2 Submission of Contract Performance and Payment Bonds

(a) Pursuant to AMS Clauses 3.4.1-4, Performance Bond Requirements, and 3.4.1-5, Payment Bond Requirements, incorporated herein by reference, the contractor shall within 15 calendar days after the award of the contract deliver to the Contracting Officer -

(1) A Performance Bond on Standard Form 25 in a penal sum equal to 100 percent of the contract price;

and

(2) A Payment Bond on Standard Form 25-A in a penal sum equal to 100 percent of the contract price.

(b) Copies of Standard Form 25 and Standard Form 25-A are attached and listed at Section J.

(c) Each bond shall be accompanied by a Power of Attorney whereby the surety company authorized the execution of the bond by its agent or employee.

(d) Each bond shall remain in full force and effect through the entire term of the contract, including extensions and warranty/guarantee periods, if any.

H.3 Accident and Fire Reporting

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state by private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.4 Construction Safety Program

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities. Chapter 33 Construction Safety (Section J) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

Any subcontractors and outside associates or consultants required by the Contractor in connection with the services covered by the contract will be limited to individuals or firms that were specifically identified and agreed to during Screening Information Request (SIR) communications. The contractor shall obtain the Contracting Officer's written consent before making any substitution for these subcontractors, associates, or consultants.

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (JAN 2022)

(a) Definitions.

(1) "The Act," as used in this clause, means section 1352, title 31, United States Code.

(2) "Agency," as used in this clause, means executive agency, within the meaning of 5 U.S.C. 101, 102, and 104(I), and any wholly owned Government corporation within the meaning of 31 U.S.C. 9101.

(3) "Covered Federal action," as used in this clause, means any of the following Federal actions:

(i) The awarding of any Federal contract.

(ii) The making of any Federal grant.

(iii) The making of any Federal loan.

(iv) The entering into of any cooperative agreement.

(v) The extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.

(4) "Indian tribe" and "tribal organization," as used in this clause, have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C. 5304) and include Alaskan Natives.

(5) "Influencing or attempting to influence," as used in this clause, means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.

(6) "Local government," as used in this clause, means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.

(7) "Officer or employee of an agency," as used in this clause, includes the following individuals who are employed by an agency:

(i) An individual who is appointed to a position in the Government under title 5, United States Code, including a position under a temporary appointment.

(ii) A member of the uniformed services, as defined in subsection 101(3), title 37, United States Code.

(iii) A special Government employee, as defined in section 202, title 18, United States Code.

(iv) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, title 5, United States Code, appendix 2.

(8) 'Person,' as used in this clause, means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(9) 'Reasonable compensation,' as used in this clause, means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.

(10) 'Reasonable payment,' as used in this clause, means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.

(11) 'Recipient,' as used in this clause, includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(12) 'Regularly employed,' as used in this clause, means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person must be considered to be regularly employed as soon as he or she is employed by such person for 130 working days.

(13) 'State,' as used in this clause, means a State of the United States, the District of Columbia, the Commonwealth of Puerto Rico, a territory or possession of the United States, an agency or instrumentality of a State, and multi- State, regional, or interstate entity having governmental duties and powers.

(b) Prohibitions. The offeror, by signing its offer, hereby certifies to the best of his or her knowledge and belief that:

(1) No Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment or modification of any Federal contract, grant, loan, or cooperative agreement;

(2) If any funds other than Federal appropriated funds (including profit or fee received under a covered Federal action) have been paid, or will be paid, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the screening information request (SIR), the offeror must complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to the Contracting Officer; and

(3) He or she will include the language of this clause in all subcontract awards at any tier and require that all recipients of subcontract awards in excess of $150,000 must disclose accordingly.

(4) This certification and disclosure is a prerequisite for making or entering into this contract imposed by the Act.

Any person who makes a prohibited expenditure or fails to file or amend a disclosure form, must be subject to a civil penalty of not less than $10,000 and not more than $100,000, for each such failure.

(c) The prohibitions of the Act do not apply under the following conditions:

(1) Agency and legislative liaison by its own employees.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of a payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action if the payment is for agency and legislative liaison activities not directly related to a covered Federal action.

(ii) For purposes of subdivision (c)(1)(i) of this clause, providing any information specifically requested by an agency or Congress is permitted at any time.

(iii) The following agency and legislative liaison activities are permitted at any time where they are not related to a specific solicitation for any covered Federal action:

(A) Discussing with an agency the qualities and characteristics (including individual demonstrations) of the person's products or services, conditions or terms of sale, and service capabilities.

(B) Technical discussions and other activities regarding the application or adaptation of the person's products or services for an agency's use.

(iv) The following agency and legislative liaison activities are permitted where they are prior to Screening Information Request (SIR) of any covered Federal action:

(A) Providing any information not specifically requested but necessary for an agency to make an informed decision about initiation of a covered Federal action;

(B) Technical discussions regarding the preparation of an unsolicited proposal prior to its official submission; and

(C) Capability presentations by persons seeking awards from an agency pursuant to the provisions of a law authorizing such actions;

(v) Only those services expressly authorized by subdivision (c)(1)(i) of this clause are permitted under this clause.

(2) Professional and technical services.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of:

(A) A payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action, if payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action.

(B) Any reasonable payment to a person, other than an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action if the payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action. Persons other than officers or employees of a person requesting or receiving a covered Federal action include consultants and trade associations.

(ii) For purposes of subdivision (c)(2)(i) of this clause, 'professional and technical services' must be limited to advice and analysis directly applying any professional or technical discipline. For example, drafting of a legal document accompanying a submittal/offer by a lawyer is allowable. Similarly, technical advice provided by an engineer on the performance or operational capability of a piece of equipment rendered directly in the negotiation of a contract is allowable. However, communications with the intent to influence made by a professional (such as a licensed lawyer) or a technical person (such as a licensed accountant) are not allowable under this section unless they provide advice and analysis directly applying their professional or technical expertise and unless the advice or analysis is rendered directly and solely in the preparation, submission or negotiation of a covered Federal action. Thus, for example, communications with the intent to influence made by a lawyer that do not provide legal advice or analysis directly and solely related to the legal aspects of his or her client's submittal/offer, but generally advocate one proposal over another are not allowable under this section because the lawyer is not providing professional legal services.

Similarly, communications with the intent to influence made by an engineer providing an engineering analysis prior to the preparation or submission of a submittal/offer are not allowable under this section since the engineer is providing technical services but not directly in the preparation, submission or negotiation of a covered Federal action.

(iii) Requirements imposed by or pursuant to law as a condition for receiving a covered Federal award include those required by law or regulation and any other requirements in the actual award documents.

(iv) Only those services expressly authorized by subdivisions (c)(2)(i) and (ii) of this clause are permitted under this clause.

(v) The reporting requirements herein must not apply with respect to payments of reasonable compensation made to regularly employed officers or employees of a person.

(d) Disclosure.

(1) If the Contractor, who requests or receives from an agency a Federal contract, has made or has agreed to make any payment using non-appropriated funds (to include profits from any Covered Federal action), to any person for the purpose of influencing or attempting to influence an officer or employee of any Agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with a Covered Federal action, the Contractor must file with that agency a disclosure form, OMB Standard Form LLL, Disclosure of Lobbying Activities..

(2) The Contractor must file a disclosure form at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the information contained in any disclosure form previously filed by such person under subparagraph (d)(1) of this clause. An event that materially affects the accuracy of the information reported includes:

(i) A cumulative increase of $25,000 or more in the amount paid or expected to be paid for influencing or attempting to influence a covered Federal action; or

(ii) A change in the person(s) or individual(s) influencing or attempting to influence a covered Federal action; or

(iii) A change in the officer(s), employee(s), or Member(s) contacted to influence or attempt to influence a covered Federal action.

(3) The Contractor must require the certification, and if required, a disclosure form by any person who requests or receives any subcontractor exceeding $150,000 under the Federal contract.

(4) All subcontractor disclosure forms must be forwarded from tier to tier until received by the prime Contractor.

The prime Contractor must submit all disclosures to the Contracting Officer at the end of the calendar quarter in which the disclosure form is submitted by the subcontractor.

(e) Agreement. The Contractor agrees not to make any payment prohibited by this clause.

(f) Penalties.

(1) Any person who makes an expenditure prohibited under paragraph (b) of this clause or fails to file or amend the disclosure form to be filed or amended by paragraph (b) must be subject to civil penalties as provided for by 31 U.S.C. 1352. An imposition of a civil penalty does not prevent the Government from seeking any other remedy that may be applicable.

(2) Contractors may rely without liability on the representations made by their subcontractors in the certification and in the disclosure form.

(g) Cost allowability. Nothing in this clause makes allowable or reasonable any costs which would otherwise be unallowable or unreasonable. Conversely, costs made specifically unallowable by the requirements in this clause will not be made allowable under any other provision.

(End of clause)

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses

Clause List

Incorporate by Full Text

AMS Guidance T3.6.4-26 Prohibition on Using ByteDance Covered Applications Including TikTok (INTERIM- June 2023)

(a) Definitions. As used in this clause— “Covered Application” means the social networking service TikTok or any successor application or service developed or provided by ByteDance Limited or an entity owned by ByteDance Limited.

“Information technology” means any equipment, or interconnected system(s) or subsystem(s) of equipment that is used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the agency.

(1) For purposes of this definition, equipment is used by the FAA if the equipment is used by the FAA directly or is used by a contractor under an FAA contract that requires-

(i) Its use; or

(ii) To a significant extent, its use in the performance of a service or the furnishing of a product.

(2) The term "information technology" includes computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources.

(3) The term "information technology" does not include any equipment that-

(i) Is acquired by a contractor incidental to a contract; or

(ii) Contains imbedded information technology that is used as an integral part of the product, but the principal function of which is not the acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information. For example, HVAC (heating, ventilation, and air conditioning) equipment, such as thermostats or temperature control devices, and medical equipment where information technology is integral to its operation, are not information technology.

(b) Prohibition. Section 102 of Division R of the Consolidated Appropriations Act, 2023 (Pub. L. 117-328), and its implementing guidance under Office of Management and Budget (OMB) Memorandum M-23-13, dated February 27, 2023, “No TikTok on Government Devices” Implementation Guidance, prohibit use of a covered application in the performance of a Federal contract. The Contractor is prohibited from using a covered application on any information technology owned or managed by the Government, or on any information technology used or provided under this contract, if this contract requires the use of that information technology, whether expressly or to a significant extent in the performance of a service or the furnishing of a product under this contract.

(c) Subcontracts. The Contractor must insert the substance of this clause, including this paragraph (c), in all subcontracts including subcontracts for the acquisition of commercial products or commercial services.

(End of clause)

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting

Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JAN 2023)

3.2.2.3-33 ORDER OF PRECEDENCE (APR 2024)

3.2.2.3-42 DIFFERING SITE CONDITIONS (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 2024) -

ALTERNATE I (APR 2024)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2004)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-58 LAYOUT OF WORK (MAR 2009)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2023)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 2021)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE FAA (OCT 2022)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 2024)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (JUL 2018)

3.3.1-9 INTEREST (APR 2023)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (JUL 2018)

3.4.1-6 ADDITIONAL BOND SECURITY (APR 1996)

3.4.1-7 NOTICE TO PROCEED (OCT 2019)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2020)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT

1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (JUL 2019)

3.5-1 AUTHORIZATION AND CONSENT (APR 2023)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JAN 2009)

3.6.1-1 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (OCT 2019)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED, WOMEN-OWNED, SERVICE-

DISABLED VETERAN OWNED, AND HUBZONE SMALL BUSINESS CONCERNS (JAN 2021)

3.6.1-4 SMALL BUSINESS SUBCONTRACTING PLAN (APR 2024)

3.6.1-5 PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (OCT 2022)

3.6.1-6 LIQUIDATED DAMAGES - SUBCONTRACTING PLAN (OCT 2022)

3.6.2-9 EQUAL OPPORTUNITY (JUL 2023)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (APR 2022)

3.6.2-13 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (APR 2022)

3.6.2-18 DAVIS BACON ACT (JUL 2023)

3.6.2-19 WITHHOLDING-LABOR VIOLATIONS (JUL 2023)

3.6.2-20 PAYROLLS AND BASIC RECORDS (JUL 2023)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (JUL 2023)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (JUL 2023)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (JUL 2023)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (JUL 2023)

3.6.2-39 TRAFFICKING IN PERSONS (JUL 2023)

3.6.2-46 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JUL 2023)

3.6.2-47 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE ORDER 14026

(JUL 2023)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (JAN 2020)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (JAN 2020)

3.6.3-16 RESERVED (APR 2023)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (JAN 2020)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.4-23 RESERVED (JUL 2023)

3.6.6-1 DRUG FREE WORKPLACE (APR 2023)

3.6.6-2 SEAT BELT USE BY CONTRACTOR EMPLOYEES (APR 2023)

3.6.6-3 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JUL 2023)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 2023)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 RESERVED (APR 2023)

3.13-13 RESERVED (APR 2023)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT

AWARDS (OCT 2023)

3.14-1 SECURITY REQUIREMENTS - CLASSIFIED CONTRACTS (JUL 2021) - ALTERNATE II

(JUL 2021)

3.2.2.3-41 PERFORMING WORK (APR 2024)

The Contractor must perform, using its own organization, work equivalent to at least 25 percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if the Contractor requests a reduction and the CO determines that it would be to the FAA's advantage to do so.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (OCT 2021)

The Contractor must (a) begin work under this contract within 10 calendar days after the date you receive the notice to proceed, (b) perform the work diligently, and (c) complete the entire work ready for use not later than 640 calendar days. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (OCT 2021) -

ALTERNATE I (OCT 2021)

The Contractor (you) must

(a) begin work under this contract within 10 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 640 calendar days. The time allowed for completion must include final cleanup of the premises.

(d) The completion date is based on the assumption that the successful offeror will receive the notice to proceed by September 30, 2024. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds to FAA within the time specified in the offer.

(End of clause)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

Funds are not presently available for this contract. The FAA's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the FAA for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JAN 2024)

(a) Definitions. As used in this clause

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the Unique Identity Identifier (UEI) or the Electronic Funds Transfer indicator, into the SAM database.

"System for Award Management (SAM) database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

"Unique Entity Identifier (UEI)" (also known as the Unique Entity ID) means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

"Electronic Funds Transfer indicator" means a 4-character suffix to the Unique Entity Identifier. This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the UEI or EFT indicator that identifies the offeror's name and address exactly as stated in the offer. The UEI will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a UEI, it should contact www.sam.gov directly to obtain one.

The offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company Physical Street Address, City, State, and ZIP Code.

(4) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(5) Company Telephone Number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran- Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are certified as an SDVOSB under the Small Business Administration's Veteran Small Business Certification Program (VetCert).

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) Change the name in the SAM database;

(B) Comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor must not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees must be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.3.1-40 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (APR 2022)

(a) Definitions. As used in this clause-

(1) "Contract financing" is a contractual authorization for payments to a contractor prior to acceptance of products or services by FAA.

(2) "Payment request" means a bill, voucher, invoice, or request for contract financing payment or invoice payment with associated supporting documentation.