BARRACKS_SPECS_VOL1_16May2016.pdf

28-APR

AIT Complex Phase III

-BARRACKS

VOLUME 1 OF 3

E4TSERCN

Text Box

Ft. Lee AIT Barracks Phase III FY15 041449FTLEE

PROJECT TABLE OF CONTENTS

VOLUME 1 OF 3

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 30 00.10 50 PROJECT WORK REQUIREMENTS AND RESTRICTIONS

01 30 00.20 50 ADMINISTRATIVE REQUIREMENTS

01 31 19.00 50 PROJECT MEETINGS

01 32 01.00 50 PROJECT S2CHEDULE

01 33 00.00 50 SUBMITTAL PROCEDURES

01 33 29 SUSTAINABILITY REPORTING

01 35 26.00 50 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 02.00 50 QUALITY CONTROL SYSTEM (QCS)

01 45 04.00 50 CONTRACTOR QUALITY CONTROL

01 50 02.00 50 TEMPORARY CONSTRUCTION FACILITIES

01 57 19.00 20 TEMPORARY ENVIRONMENTAL CONTROLS

01 57 19.01 20 SUPPLEMENTAL TEMPORARY ENVIRONMENTAL CONTROLS

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 62 35.00 50 RECYCLED / RECOVERED MATERIALS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 02.00 50 CLOSEOUT SUBMITTALS

01 78 23.00 50 OPERATION AND MAINTENANCE DATA

01 91 00.80 COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

02 61 13 EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL

02 65 00 UNDERGROUND STORAGE TANK REMOVAL

02 81 00 TRANSPORTATION AND DISPOSAL OF HAZARDOUS MATERIALS

02 82 14.00 10 ASBESTOS HAZARD CONTROL ACTIVITIES

02 82 16.00 20 ENGINEERING CONTROL OF ASBESTOS CONTAINING MATERIALS

02 82 33.13 20 REMOVAL/CONTROL AND DISPOSAL OF PAINT WITH LEAD

02 83 13.00 20 LEAD IN CONSTRUCTION

02 84 16 HANDLING OF LIGHTING BALLASTS AND LAMPS CONTAINING PCBs

AND MERCURY

VOLUME 2 OF 3

DIVISION 03 - CONCRETE

03 11 13.00 10 STRUCTURAL CAST-IN-PLACE CONCRETE FORMING

03 15 00.00 10 CONCRETE ACCESSORIES

03 20 00.00 10 CONCRETE REINFORCING

03 30 00.00 10 CAST-IN-PLACE CONCRETE

03 35 00.00 10 CONCRETE FINISHING

03 39 00.00 10 CONCRETE CURING

DIVISION 04 - MASONRY

04 20 00 MASONRY

DIVISION 05 - METALS

05 05 23 WELDING, STRUCTURAL

05 12 00 STRUCTURAL STEEL

05 21 19 OPEN WEB STEEL JOIST FRAMING

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 50 13 MISCELLANEOUS METAL FABRICATIONS

PROJECT TABLE OF CONTENTS Page 1

05 51 00 METAL STAIRS

05 51 33 METAL LADDERS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 20 00 FINISH CARPENTRY

06 41 16.00 10 LAMINATE CLAD ARCHITECTURAL CASEWORK

06 61 16 SOLID POLYMER (SOLID SURFACING) FABRICATIONS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 05 23 PRESSURE TESTING AN AIR BARRIER SYSTEM FOR AIR TIGHTNESS

07 13 53 ELASTOMERIC SHEET WATERPROOFING

07 17 00 BENTONITE WATERPROOFING

07 21 16 MINERAL FIBER BLANKET INSULATION

07 22 00 ROOF AND DECK INSULATION

07 26 30 SPRAY POLYURETHANE FOAM INSULATING AIR BARRIER SYSTEM

(ABR)

07 27 10.00 10 BUILDING AIR BARRIER SYSTEM

07 42 63 FABRICATED WALL PANEL ASSEMBLIES

07 52 00 MODIFIED BITUMINOUS MEMBRANE ROOFING

07 60 00 FLASHING AND SHEET METAL

07 61 14.00 20 STEEL STANDING SEAM ROOFING

07 84 00 FIRESTOPPING

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 11 16 ALUMINUM DOORS AND FRAMES

08 14 00 WOOD DOORS

08 33 13 METAL ROLLING COUNTER DOORS

08 33 23 OVERHEAD COILING DOORS

08 34 59 VAULT DOORS AND DAY GATES

08 41 13 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

08 44 00 CURTAIN WALL AND GLAZED ASSEMBLIES

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

08 91 00 METAL WALL AND DOOR LOUVERS

DIVISION 09 - FINISHES

09 22 00 SUPPORTS FOR PLASTER AND GYPSUM BOARD

09 29 00 GYPSUM BOARD

09 30 13 CERAMIC TILING

09 51 00 ACOUSTICAL CEILINGS

09 65 00 RESILIENT FLOORING

09 65 36 STATIC-CONTROL RESILIENT FLOORING

09 65 66 RESILIENT ATHLETIC FLOORING

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 10 00 VISUAL COMMUNICATIONS SPECIALTIES

10 14 00.20 INTERIOR SIGNAGE

10 14 01 EXTERIOR SIGNAGE

10 21 13 TOILET COMPARTMENTS

10 22 39 FOLDING PANEL PARTITIONS

PROJECT TABLE OF CONTENTS Page 2

10 26 13 WALL AND CORNER GUARDS

10 28 13 TOILET ACCESSORIES

10 44 16 FIRE EXTINGUISHERS

DIVISION 12 - FURNISHINGS

12 21 00 WINDOW BLINDS

12 31 00 MANUFACTURED METAL CASEWORK

12 48 13.13 FOOT GRID ENTRANCE SYSTEMS

DIVISION 14 - CONVEYING EQUIPMENT

14 21 23 ELECTRIC TRACTION PASSENGER ELEVATORS

DIVISION 21 - FIRE SUPPRESSION

21 12 00 STANDPIPE SYSTEMS

21 13 13.00 10 WET PIPE SPRINKLER SYSTEM, FIRE PROTECTION

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 11 25 FACILITY GAS PIPING

VOLUME 3 OF 3

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

23 05 48.00 40 VIBRATION, SEISMIC AND ATFP CONTROLS FOR HVAC PIPING AND

EQUIPMENT

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 09 23 LONWORKS DIRECT DIGITAL CONTROL FOR HVAC AND OTHER

BUILDING CONTROL SYSTEMS

23 25 00 CHEMICAL TREATMENT OF WATER FOR MECHANICAL SYSTEMS

23 52 00 HEATING BOILERS

23 64 26 CHILLED, CHILLED-HOT, AND CONDENSER WATER PIPING SYSTEMS

23 65 00 CLOSED CIRCUIT COOLERS

23 73 13.00 40 MODULAR INDOOR CENTRAL-STATION AIR-HANDLING UNITS

23 81 47 WATER-LOOP HEAT PUMP SYSTEMS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 08 01 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 23 00 SWITCHBOARDS

26 28 01.00 10 COORDINATED POWER SYSTEM PROTECTION

26 29 23 VARIABLE FREQUENCY DRIVE SYSTEMS UNDER 600 VOLTS

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

27 54 00.00 20 COMMUNITY ANTENNA TELEVISION (CATV) SYSTEMS

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

PROJECT TABLE OF CONTENTS Page 3

28 20 00.00 20 ELECTRONIC SECURITY SYSTEMS (ESS) FOR ARMS VAULT,

COMMERCIAL

28 31 76 INTERIOR FIRE ALARM AND MASS NOTIFICATION SYSTEM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

31 11 00 CLEARING AND GRUBBING

31 31 16.19 TERMITE CONTROL BARRIER SYSTEM

31 31 16 SOIL TREATMENT FOR SUBTERRANEAN TERMITE CONTROL

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 05 33 LANDSCAPE ESTABLISHMENT

32 11 16 BASE COURSE FOR RIGID PAVING

32 11 24 GRADED CRUSHED AGGREGATE BASE COURSE FOR PERVIOUS PAVEMENT

32 13 13.06 PORTLAND CEMENT CONCRETE PAVEMENT FOR ROADS AND SITE

FACILITIES

32 13 43 PERVIOUS CONCRETE PAVING

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 17 23.00 20 PAVEMENT MARKINGS

32 92 19 SEEDING

32 92 23 SODDING

32 93 00 EXTERIOR PLANTS

DIVISION 33 - UTILITIES

33 40 00 STORM DRAINAGE UTILITIES

33 51 15 NATURAL-GAS / LIQUID PETROLEUM GAS DISTRIBUTION

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 4

SECTION 01 11 00

SUMMARY OF WORK

08/11

PART 1 GENERAL

1.1 WORK COVERED BY CONTRACT DOCUMENTS

1.1.1 Project Description

The work includes abatement of asbestos and lead paint, demolition of four

(4) buildings and their associated infrastructure, construction of a 300 Person Barracks, a 600 Person Barracks, two (2) Lawn Equipment Storage Buildings, a Physical Trainning Pit, underground utilities, site grading, sidewalks, parking lots, fire lanes, and incidental related work.

1.1.2 Location

The work shall be located at Fort Lee, Virginia on the site bounded by A and B Avenues and 11th and 16th Streets, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.2 OCCUPANCY OF PREMISES

All buildings to be demolished will be abandoned prior to award of this Contract.

Before work is started, the Contractor shall arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, corridors, and stairways.

1.3 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work shall be in a condition equal to or better than that which existed before new work started.

1.4 LOCATION OF UNDERGROUND FACILITIES

Obtain digging permits prior to start of excavation. Scan the construction site with electromagnetic or sonic equipment, and mark the surface of the ground or paved surface where existing underground utilities are discovered. Verify the elevations of existing piping, utilities,and any type of underground or encased obstruction not indicated to be specified or removed but indicated or discovered during scanning in locations to be traversed by piping, ducts, and other work to be conducted or installed. Verify elevations before installing new work closer than

SECTION 01 11 00 Page 1 nearest manhole or other structure at which an adjustment in grade can be made.

1.4.1 NOTIFICATION

Notify the Contracting Officer at least 48 hours prior to starting excavation work.

1.5 SALVAGE MATERIAL AND EQUIPMENT

Items designated by the Contracting Officer to be salvaged shall remain the property of the Government.

The salvaged property shall be segregated, itemized, delivered, and off-loaded at the Government designated storage area located within 5 miles of the construction site.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

All work must meet LEED 2009 Silver certification requirements.

-- End of Section --

SECTION 01 11 00 Page 2

SECTION 01 30 00.10 50

PROJECT WORK REQUIREMENTS AND RESTRICTIONS

07/07

PART 1 GENERAL

1.1 DEFINITIONS

a. Facility: The facility is:

Fort Lee.

b. Abbreviations:

CO: Contracting Officer or his authorized representative.

1.2 SPECIAL CONTRACTOR REQUIREMENTS

1.2.1 Project Phasing and Performance period

The Contractor shall complete the work within the duration specified in Section 00 73 00 "Contract Requirements". The parking lot supporting the clinic shall be constructed prior to the demolition of the Building 3127 parking lot.

1.2.2 STRUCTURAL DRAWING DIMENSIONS

The building layout, including both horizontal and vertical dimensions, is shown on the Architectural sheets contained in the contract drawings.

The Contractor shall use the dimensions from the Architectural sheets to obtain dimensions for foundation layout and structural members as necessary to prepare all shop drawings and fabricate structural members.

There may be some instances where the Contractor shall have to adjust actual dimensions to the submitted items that he will use, to finalize the location of a structural member. Any such adjustments shall be clearly identified on the submitted shop drawings for Government review.

1.3 COOPERATION WITH USING AGENCY AND OTHER CONTRACTORS

During the period of this contract, other contracts may be in force for the construction of other features of work on or adjacent to the site of work being accomplished under this contract. It shall be the responsibility of the Contractor on this contract to be fully informed of the extent of the limits of work to be performed by other Contractors.

Should there be any conflict between these limits, it shall be brought to the attention of the Contracting Officer(CO)and the CO's decision shall be final. Also, prior to completion of work under this contract, members of the Using Agency may be performing work or occupying facilities on or adjacent to the area. The Contractor shall arrange his plant and shall schedule and perform this work so as to effectively cooperate with all other Contractors and Government agencies.

1.4 PERSONNEL RESTRICTIONS

Personnel are limited to the immediate site areas and shall not enter buildings or facilities not involved in the work. All employees of the Contractor will be subject to all rules and regulations of the Facility

SECTION 01 30 00.10 50 Page 1 which pertain to personnel. The Contractor shall erect fences and signs as specified and be responsible for the restrictions of all personnel. The Contractor's plans for restricting personnel access to the project site shall be submitted for approval as a part of the Safety Plan (Accident Prevention Plan). Facility access shall be restricted. Contractor shall comply with current security requirements. All vehicles shall be registered with the military police.

1.4.1 Fort Lee Visitor Control Policy and Access Policy

Contractor shall comply with attached Visitor Control Policy and items 1, 3, 4, and 15 of Section VIII of attached ENG FORM 6055.

1.5 TRANSPORTATION FACILITIES

The Facility is served by an all weather surfaced road network. Road(s) within the Facility proposed to be used by the Contractor shall be subject to prior approval of the Facility authorities and such roads, if used, shall be maintained throughout construction and shall be restored to as good condition as existed prior to their use. The Contractor shall also construct, subject to approval, such temporary haul roads and bridges as may be necessary for conducting his work. Any such temporary construction shall be removed and the affected area restored to its original condition. All costs for the use of existing transportation facilities, for the construction of temporary facilities, and for maintenance, repair, removal and restoration shall be borne by the Contractor. All custruction vehicles and deliveries must enter Ft. lee through the Shop Rd gate between the hours of 6:00AM and 2:00PM. Construction vehicles entering Ft. Lee at other times must enter through the Sisisky Gate.

1.5.1 Use of Roads

Hard-surfaced roads from major and primary municipal roads serve the Facility. The movement of all vehicles within the Facility shall be confined to the roads designated and shall comply with traffic regulations within the Facility. The Contractor shall keep all roads clear of all obstructions and free of mud and other foreign materials resulting from operations. The Contractor's vehicles shall at no time follow a vehicle closer than 50 feet, and all vehicles shall pull off the road and come to a complete stop when meeting emergency vehicles, or vehicles with flashing lights. Facility speed limits and traffic controls shall be observed.

1.5.2 Road Restrictions

The movement of all vehicles within the Facility shall be confined to the roads designated and shall comply with traffic regulations within the Facility. Other roads may be used only with the approval of the CO.

1.5.3 Cleated Vehicles

Cleated vehicles shall not be moved over surfaced roads except at the immediate site of the area where they are to be used.

1.6 COORDINATION IN WORK AREAS

1.6.1 Unoccupied Work Area

The area where the Contractor is scheduled to perform the work will not be

SECTION 01 30 00.10 50 Page 2 occupied during the work, however, the Contractors work activities may affect other area(s) that are occupied. All work shall be in accordance with the Contractor's work plan.

1.6.2 Maintenance of Utilities

Any active utilities, including but not limited to electricity, gas, water, sewer, heating, air conditioning, or any like service, that will require interruption or replacement in any occupied area affected as a result of the Contractors scheduled work activities, shall be temporarily provided by the Contractor at his own expense until the affected service is fully and permanently restored. All temporary method(s) of service replacement the Contractor proposes for use on this contract shall be approved by the CO prior to commencing the work.

1.6.3 Hours of Work

The normal work hours for construction shall be from 7:30 a.m. to 4:00 p.m.

Monday through Friday of each week. Any request to change these hours shall be made in writing to the Contracting Officer at least two calendar days prior to the desired day on which the change is to go into effect.

The changed hours shall not go into effect until written permission has been received from the Contracting Officer.

1.6.4 Gate Times

Shop Road Gate 6:00a.m. to 2:00p.m. Monday through Friday

1.6.5 Existing Utility Location

Existing utilities must be located before doing any digging work on Facility. The Contractor shall be responsible to contact Miss Utility, obtain all necessary existing utility locations, which may be necessary to accomplish his work, and mark any utility lines in the immediate vicinity of his work. It shall be the responsibility of the Contractor to contact Miss Utilities at 1-800-552-7110 for locating commercial utilities 48 hours prior to digging operations.

1.6.6 Digging Permits

Contractor is responsible for obtaining all digging permits, including associated locating and marking services, in accordance with installation and local requirements, at no additional cost to the Government.

"Clearance Permits for Digging', must be obtained before doing any work on Facility. The Contractor shall be responsible to obtain all necessary digging permits and pay costs associated with the permit,which may be necessary to accomplish his work. The Contractor must coordinate with the Installation Environmental Management Office to obtain written permission to dig. Ground disturbance outside those limitations are prohibited.

Chamges must be coordinated with the EMO.

SECTION 01 30 00.10 50 Page 3

1.7 INTERRUPTIONS OF UTILITIES

1.7.1 Approval

Utility services shall not be interrupted by the Contractor to relocate, make connections, or interrupt for any purpose, without written approval of the CO.

1.7.2 Request

Request for permission to shut down services shall be submitted in writing to the CO not less than 10 calendar days prior to date of proposed interruption. or as required by DPW, except for electrical services.

Request for electrical service outage/energize shall require a 14-calendar day notice or as required by DPW. The request shall give the following information:

a. Nature of Utility (Gas, L.P. or H.P., Water, Elec.)

b. Size of line and location of shutoff.

c. Buildings and services affected.

d. Hours and date of shutoff.

e. Estimated length of time service will be interrupted.

1.7.3 Service Interruptions

Services shall not be shut off until receipt of approval of the proposed hours and date from the Contracting Officer.

1.7.4 Timely Disconnections

Shutoffs which will cause interruption of Government work operations as determined by the Contracting Officer shall be accomplished during regular non-work hours or non-work days of the Using Agency without any additional cost to the Government.

1.7.5 Utilities Operation

Operation of valves on water mains will be by Virginia American Water (VAW) personnel. Where shutoff of water lines interrupts service to fire hydrants or fire sprinkler systems, the Facility Fire Department shall be notified by the Contractor in writing 72 hours prior to the proposed interruption or as required by Department of Public Works (DPW). The Contractor shall arrange his operations and have sufficient material and personnel available to complete the work without undue delay and shall restore service without delay in event of emergency.

1.7.6 Gas

Flow in gas mains which have been shut off shall not be restored until the Government inspector has determined that all items serviced by the gas line have been shut off.

1.8 PHYSICAL DATA

The physical conditions indicated on the drawings and in the

SECTION 01 30 00.10 50 Page 4 specifications are the result of site visits, surveys and borings. See Section 31 00 00 EARTHWORK for boring logs and data.

1.9 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Contract Clause entitled "Default: (Fixed Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

1.9.1 Schedule

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS

BASED ON (5) DAY WORK WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

Ft. Lee 6 6 6 8 6 6 7 5 3 5 5 5

1.9.2 Records

Upon acknowledgement of the Notice to Proceed and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

1.9.3 Impacted Days

The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day in each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in the schedule of monthly anticipated adverse weather delays, above, the contracting officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a

SECTION 01 30 00.10 50 Page 5 modification in accordance with the Contract Clauses entitled "Default (Fixed Price Construction)".

1.10 SITE CONTAMINATION

This site is designated a Category I site and is defined as a site that is located in a traditional non-hazardous location, such as in an administrative, recreation, or housing area and that the Government has no reason to suspect soil contamination.

The buildings to be demolished do contain hazardous materials such as lead paint and asbestos. Please refer to the appropriate specification sections adressing these hazardous materials.

1.10.1 Contamination Removal

In the event that contamination beyond that shown or specified is encountered, the Contracting Officer shall be advised immediately. The contamination shall be removed as directed and replaced with satisfactory material. Payment therefore will be made in conformance with the CHANGES clause of the CONTRACT CLAUSES.

1.10.2 Compliance Requirements

The Contractor shall comply with applicable Federal, state and local laws, codes, ordinances and regulations (including the obtaining of licenses and permits) in connection with any hazardous material, substance or waste.

1.10.3 Requirements

The requirements of this clause and any act or failure to act by the Government shall not relieve the Contractor of any responsibility or liability for the safety of Government, Contractor or subcontractor personnel or property.

1.11 WORK IN QUARANTINED AREA

The work called for by this contract involves activities in counties quarantined by the Department of Agriculture to prevent the spread of certain plant pests which may be present in the soil. The Contractor agrees that all construction equipment and tools to be moved from such counties shall be thoroughly cleaned of all soil residues at the construction site with water under pressure and that hand tools shall be thoroughly cleaned by brushing or other means to remove all soil. In addition, if this contract involves the identification, shipping, storage, testing, or disposal of soils from such a quarantined area, the Contractor agrees to comply with the provisions of ER 1110-1-5 and attachments, a copy of which will be made available by the Contracting Officer upon request. The Contractor agrees to assure compliance with this obligation by all subcontractors.

1.12 HISTORICAL AND ARCHAEOLOGICAL FINDS

Federal legislation provides for the protection, preservation, and collection of scientific, prehistoric, historical, and archaeological data, including relics and specimens which might otherwise be lost due to

SECTION 01 30 00.10 50 Page 6 alteration of the terrain or building features as a result of any Federal construction project. Should the Contractor, or any of the Contractor's employees, or parties operating or associated with the Contractor, in the performance of this contract discover evidence of possible scientific, prehistoric, historical, or archaeological data, the Contractor shall immediately cease work at that location, avoid further disturbance, and notify the Contracting Officer, giving the location and nature of the findings. The Contractor shall forward written confirmation to the Contracting Officer as directed. The Contractor shall exercise care so as not to disturb or damage artifacts or fossils uncovered during excavation operations, and shall provide such cooperation and assistance as may be necessary to preserve the findings for removal or other disposition. Any person who, without permission, injures, destroys, excavates, appropriates, or removes any historical or prehistoric artifact, object of antiquity, or archaeological resource on the public lands of the United States is subject to arrest and penalty of law. Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance or changes in the work, or both. If such delays or changes are ordered, an equitable adjustment will be made in the contract in accordance with the applicable clauses of the contract.

1.12.1 Inadvertent Discovery or Damage

If during excavation or other construction activities any unidentified or unanticipated historical, archaeological, and cultural resources are discovered or found, all activities that may damage or alter such resources shall be temporarily suspended. Resources covered by this paragraph include but are not limited to: any human skeletal remains or burial; artifacts; shell, midden, bone, charcoal, or other deposits; rock or coral alignments, paving, wall, or other constructed features; and any indication of agricultural or other human activities. Upon such discovery or find, the Contractor shall immediately call the Fort Lee Cultural Resources Manager (CRM) or staff archaeologist, 804-734-4434. The Contractor shall cease all activities that may impact or damage the discovery, secure the area and prevent employees or other persons from trespassing on, removing or otherwise disturbing such resources until the CRM makes a determination on their significance. Any person, who without permission, injures, destroys, excavates, appropriates, or removes any historical or prehistoric artifact, object of antiquity, or archaeological resource on the public lands of the United States is subject to arrest and penalty of law. WHERE APPROPRIATE BY REASON OF DISCOVERY, THE CONTRACTING

OFFICER MAY ORDER DELAYS IN THE TIME OF PERFORMANCE OR CHANGES IN THE

WORK, OR BOTH. IF SUCH DELAYS OR CHANGES ARE ORDERED, AN EQUITABLE

ADJUSTMENT WILL BE MADE IN THE CONTRACT IN ACCORDANCE WITH THE APPLICABLE

CLAUSES OF THE CONTRACT.

1.13 EQUIPMENT-IN-PLACE LIST:

The Contractor shall maintain a list of equipment installed under the terms of the contract. In the event that the contract includes more than one building or facility, a list must be maintained for each and delivered to the Contracting Officer upon acceptance of each building or facility.

Forms to be used for this purpose shall be obtained from the Area Engineer's Office. The list shall include the following:

a. Contract number

b. Description of item

c. Model number

SECTION 01 30 00.10 50 Page 7

d. Serial number

e. Capacity

f. Name of manufacturer

g. Address of manufacturer

h. Condition of item

i. Replacement cost

j. Name of person who checked item

1.14 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

1.14.1 Allowable Costs

Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a Contractor or subcontractor at any tier shall be based on actual cost data when the Government can determine both ownership and operating costs for each piece of equipment or equipment groups of similar serial and series from the Contractor's accounting records. When both ownership and operating costs cannot be determined from the Contractor's accounting records, equipment costs shall be based upon the applicable provisions of EP 1110-1-8, "Construction Equipment Ownership and Operating Expense Schedule," Region II. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retrospective pricing, the schedule in effect at the time the work was performed shall apply.

1.14.2 Rental Costs

Equipment rental costs are allowable, subject to the applicable provisions of the Federal Acquisition Regulations, and shall be substantiated by certified copies of paid invoices. Rates for equipment rented from an organization under common control, lease-purchase or sale-leaseback arrangements will be determined using the schedule except that rental costs leased form an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees are allowable. Costs for major repairs and overhaul are unallowable.

1.14.3 Equipment Costs

When actual equipment costs are proposed and the total amount of the pricing action is over $25,000, cost or pricing data shall be submitted on the Standard Form 1411, "Contract Pricing Proposal Cover Sheet". By submitting cost or pricing data, the Contractor grants to the Contracting Officer or an authorizing representative the right to examine those books, records, documents and other supporting data that will permit evaluation of the proposed equipment costs. After price agreement the Contractor shall certify that the equipment costs or pricing data submitted are accurate, complete and current.

1.15 SUBCONTRACTS AND WORK COORDINATION

Contract Clauses "SUBCONTRACTS", "PERMITS AND RESPONSIBILITIES", and "MATERIAL AND WORKMANSHIP" are supplemented as follows:

SECTION 01 30 00.10 50 Page 8

a. Divisions or sections of specifications are not intended to control the Contractor in dividing the work among subcontractor, or to limit work performed by any trade.

b. Contractor shall be responsible for coordination of the work of the trades, subcontractors, and materials.

c. The Government or its representative will not undertake to settle any difference between the Contractor and Contractor's subcontractors, or between subcontractors.

d. The Government reserves the right to refuse to permit employment on the work or require dismissal from the work of any subcontractor who, by reason of previous unsatisfactory work on Corps of Engineers projects, or for any other reason is considered by the Contracting Officer to be incompetent or otherwise objectionable.

1.16 CONSTRUCTION MANPOWER AND EQUIPMENT REPORT

The Contractor shall submit executed CENAO Form 987, Construction Manpower and Equipment Report daily. The report shall include manpower and equipment for the general and subcontractors. Forms are available from the Contracting Officer.

1.17 PURCHASE ORDERS

To ensure proper expediting of orders the Contractor and his subcontractors shall furnish to the Contracting Officer, one copy of each purchase order covering supplies or services required for performance of the work. Each purchase order shall clearly indicate the date of placement, the date delivery is required in order to avoid delay in the scheduled progress of the work, and the date delivery is promised by the supplier or producer. Copies of purchase orders shall be forwarded on the date issued.

1.18 PROFIT

1.18.1 Weighted Guidelines

Weighted guidelines method of determining profit shall be used on any equitable adjustment change order or modification issued under this contract. The profit factors shall be as follows:

Factor Rate Weight Value

Degree of Risk 20 Relative difficulty of work 15 Size of Job 15 Period of performance 15 Contractor's investment 05 Assistance by Government 05 Subcontracting 25

1.18.2 Value

Based on the circumstances of each procurement action, each of the above factors shall be weighted from .03 to .12 as indicated below. The value

SECTION 01 30 00.10 50 Page 9 shall be obtained by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

1.18.2.1 Degree of Risk

Where the work involves no risk or the degree of risk is very small, the weighting should be .03; as the degree of risk increases, the weighting should be increased up to a maximum of .12. Lump sum items will have, generally, a higher weighted value than the unit price items for which quantities are provided. Other things to consider: the portion of the work to be done by subcontractors, nature of work, where work is to be performed, reasonableness of negotiated costs, amount of labor included in costs, and whether the negotiation is before or after performance of work.

1.18.2.2 Relative Difficulty of Work

If the work is most difficult and complex, the weighting should be .12 and should be proportionately reduced to .03 on the simplest of jobs. This factor is tied in to some extent with the degree of risk. Some things to consider: the nature of the work, by whom it is to be done, where, and what is the time schedule.

1.18.2.3 Size of Job

All work not in excess of $100,000 shall be weighted at .12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from .12 to .05.

1.18.2.4 Periods of Performance

Jobs in excess of 24 months are to be weighted at .12. Jobs of lesser duration are to be proportionately weighted to a minimum of .03 for jobs not to exceed 30 days. No weight where additional time not required.

1.18.2.5 Contractor's Investment

To be weighted from .03 to .12 on the basis of below average, average, and above average. Things to consider: amount of subcontracting, mobilization payment item, Government furnished property, equipment and facilities, and expediting assistance.

1.18.2.6 Assistance by Government

To be weighted from .12 to .03 on the basis of average to above average.

Things to consider: use of Government owned property, equipment and facilities, and expediting assistance.

1.18.2.7 Subcontracting

To be weighted inversely proportional to the amount of subcontracting.

Where 80 percent or more of the work is to be subcontracted, the weighting is to be .03 and such weighting proportionately increased to .12 where all the work is performed by the Contractor's own forces.

1.19 Real Property Items

The Contractor shall coordinate with the Fort Lee Real Property Officer and prepare a list of real property items constructed under the subject

SECTION 01 30 00.10 50 Page 10 contract. The list shall include the following: category code, real property item description, # of units, units of measure, and total quantity. Near the end of construction, the Contractor shall use the list to assign the construction cost for the items and submit to the Government.

1.20 BLASTING

Blasting will not be permitted.

PART 2 PRODUCTS (THIS PART NOT USED)

PART 3 EXECUTION (THIS PART NOT USED)

SECTION 01 30 00.10 50 Page 11

1388464913CIV

Typewritten Text

1388464913CIV

Typewritten Text 02-15

Page 1 of 4ENG FORM 6055, APR 2014 PREVIOUS EDITIONS ARE OBSOLETE.

US Army Corps of Engineers

CONTRACT REQUIREMENTS PACKAGE

ANTITERRORISM/OPERATIONS SECURITY REVIEW COVER SHEET

For use of this form, see AR 525-13, ALARACT 05/2012; and USACE OPORD 2013-74; the proponent agency is CECO-P.

SECTION I - CONTRACT INFORMATION

1. CONTRACT TITLE

Fort Lee AIT Barracks Complex Phase III

2. LOCATION

Fort Lee, VA

3. SOLICITATION/CONTRACT NO.

Project Number: 246

4. CLASS APPROVAL REQUEST NUMBER

5. CONTRACT TYPE

Construction IDIQ MATOC SATOC Service Supply Task Order

Other (specify)

SECTION II - PURPOSE

Part A. Purpose of cover sheet is to document the review of the requirements package performance work statement (PWS)/statement of work (SOW)/ statement of requirements (SOR) for antiterrorism (AT) and other related protection matters to include, but not limited to: operation security (OPSEC), information assurance (IA), physical security, law enforcement, intelligence and foreign disclosure. Army policy requirement: A Signed AT/OPSEC cover sheet is required to be included in all requirements packages except for supply contracts under the simplified acquisition level threshold ($150K), field ordering officer actions and Government purchase card purchases. Local policy may require this form for supply contracts under the simplified acquisition level threshold based on risk and threat. Mandatory review and signatures: The organizational Antiterrorism Officer (ATO) and OPSEC Officer must review each requirements package, unless a signed class approval request form is completed, prior to submission to the supporting contracting activity to include coordination with other staff review as appropriate. If the requiring activity (RA) does not have an ATO or OPSEC Officer, the first ATO and OPSEC Officer in the chain of command will review the contract for AT/OPSEC considerations.

SECTION III - STANDARD CONTRACT LANGUAGE

Part B. Standard Contract Language and/or Additional PWS/SOW/SOR Language. The applicability of each requirement must be considered and each block must be checked "Yes" or "N/A". If the standard PWS/SOW/SOR language text found in Section VIII. of this form is sufficient to meet specific contract request requirements, check "Yes" in block below and include this language in the PWS/SOW/SOR. If the standard PWS/SOW/SOR language applies, but is not in of itself sufficient, check "Yes" and include both the standard language and additional contract specific language in the PWS/SOW/SOR. If standard PWS/SOW/SOR language text does not apply, check "N/A".

SECTION IV - REQUIRED CLAUSES

Required Clause(s) (see Section VII. for sample language) YES N/A

1. AT Level I training (general).

2. AT awareness training for US based contractor personnel traveling overseas.

3. Access and general protection policy and procedures.

4. iWATCH and/or CorpsWatch training.

5. Access to government information systems.

6. OPSEC SOP/Plan requirements.

7. Requirement for OPSEC training.

8. Information assurance/information technology training.

9. Information assurance/information technology training certification.

10. Contractors Authorized to Accompany the Force (OCONUS).

11. Contract requiring performance or delivery in a foreign country (OCONUS).

12. Handling/Access to Classified Information.

13. Will be escorted in areas where they may be exposed to classified and/or sensitive materials.

14. Contractor Company to obtain a Facility Clearance and individual clearances at the appropriate level.

15. Pre‐screen candidates using E‐Verify Program.

16. For contracts requiring armed security guards.

Page 2 of 4ENG FORM 6055, APR 2014

SECTION V - REMARKS

1. CONTRACT TITLE

Fort Lee AIT Barracks Complex Phase III

2. LOCATION

Fort Lee, VA

3. SOLICITATION/CONTRACT NO.

Project Number: 246

4. CLASS APPROVAL REQUEST NUMBER

5. CONTRACT TYPE

Construction IDIQ MATOC SATOC Service Supply Task Order

Other (specify)

The Corps is in the process of awarding an AE task order for support on the Fort Lee AIT Barracks Complex Phase III. In order to finalize the award, the AT/OPSEC Form 6056 must filled out and signed for the Corps Contracting Division. Contractor will not have access to Fort Lee enterprise networks.

SECTION VI - ANTITERRORISM REVIEWER'S SIGNATURE

I am ATO Level II certified and I have reviewed the requirements package and understand my responsibilities IAW Army Regulation 525‐13, Antiterrorism.

1. TYPED OR PRINTED NAME 2. RANK/CIVILIAN GRADE 3. PHONE NUMBER

5. DATE

2015-06-17

4. SIGNATURE

SECTION VII - OPERATIONS SECURITY REVIEWER'S SIGNATURE

I am OPSEC Level II certified and have reviewed the requirements package to ensure that there are no OPSEC concerns regarding the release and/or publication of attached documentation to public forums as well as to determine OPSEC requirements for the Contractor, and understand my responsibilities IAW Army Regulation 530‐1, Operations Security.

3. PHONE NUMBER

804-734-5145

2. RANK/CIVILIAN GRADE

GS-11

1. TYPED OR PRINTED NAME

Jeffrey L. Crisco

4. SIGNATURE 5. DATE

2015-06-17

DONOVAN.ROBERT.ANTHONY.102072

Digitally signed by DONOVAN.ROBERT.ANTHONY.1020720758 DN: c=US, o=U.S. Government, ou=DoD, ou=PKI, ou=USA, cn=DONOVAN.ROBERT.ANTHONY.1020720758 Date: 2015.06.17 13:48:01 -04'00'

CRISCO.JEFFREY.LYNN.1054863612

Digitally signed by CRISCO.JEFFREY.LYNN.1054863612 DN: c=US, o=U.S. Government, ou=DoD, ou=PKI, ou=USA, cn=CRISCO.JEFFREY.LYNN.1054863612 Date: 2015.06.17 16:19:51 -04'00'

Page 3 of 4ENG FORM 6055, APR 2014

SECTION VIII - STANDARD CONTRACT PROVISION AND CLAUSE TEXT APPLICABILITY AND/OR ADDITIONAL PWS/SOW/SOR LANGUAGE

1. AT Level I Training. This provision/contract text is for contractor employees with an area of performance within an Army controlled installation, facility or area. Proposed language: "All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities, controlled access areas, or require network access, shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. Upon request, the contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at the following website: https://atlevel1.dtic.mil/at/; or it can be provided by the RA ATO in presentation form which will be documented via memorandum."

2. AT Awareness Training for Contractor Personnel Traveling Overseas. This standard language text required US based contractor employees and associated sub-contractor employees to make available and to receive government provided area of responsibility (AOR) specific AT awareness training as directed by AR 525-13 (Antiterrorism). Specific AOR training content is directed by the combatant commander with the unit ATO being the local point of contact. Proposed language: "All US based contractor employees and associated sub-contractor employees traveling overseas will receive the government provided AOR specific AT awareness training. The documentation of training completion must be provided to the COR prior to departure.”

3. Access and General Protection/Security Policy and Procedures. This standard language text is for contractor employees with an area of performance within an Army controlled installation, facility or area. Per Homeland Security Presidential Directive-12 (HSPD-12), Common Access

Cards (CAC) are required for contractors working six months or more; background investigations are required prior to CAC credential issuance.

Uncleared contractors working less than six months must submit to a background check, via the appropriate Provost Marshal Office, Director of

Emergency Services or Security Office, and must abide by applicable identification and access control requirements. Proposed language: "All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks or background investigation and to meet installation/facility access requirements to be accomplished by installation Provost

Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes."

4. Suspicious Activity Reporting Training (e.g. iWATCH, CorpsWatch, or See Something, Say Something). This standard language is for contractor employees with an area of performance within an Army controlled installation, facility or area. Proposed language: "The contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training."

5. Contractor Employees Who Require Access to Government Information Systems. This standard language text is for contractor employees with access to government info system. Proposed language: "All contractor employees with access to a government info system must be registered in the Army Training Certification Tracking System (ATCTS) at commencement of services, and must successfully complete the DOD Information

Assurance Awareness prior to access to the information systems and then annually thereafter in accordance with personnel security standards listed in

AR 25-2 (Information Assurance), an appropriate background investigation will be conducted prior to accessing the government information systems."

6. For Contracts that Require an OPSEC Standing Operating Procedure/Plan. This standard language text is for contractor employees with an area of performance for classified contracts or if the contract employee has access or responsibility to protect critical information. The Contractor, in collaboration with RA OPSEC Officer, shall develop an OPSEC Standard Operating Procedure (SOP)/Plan within 90 calendar days of contract award per AR 530-1 (Operations Security). Proposed language: "The Contractor shall develop an OPSEC SOP/Plan within 90 days of contract award. The

OPSEC SOP/Plan must be reviewed and approved by the RA OPSEC Officer. The SOP/Plan will include the government's critical information, why it needs to be protected, where it is located, who is responsible for it and how to protect it. In addition, the contractor shall identify an individual who will be an OPSEC Coordinator."

7. For Contracts that Require OPSEC Training. Per AR 530-1, (Operations Security) contractor employees must complete Level I OPSEC Training within 30 calendar days of contract award. Proposed language: "All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. OPSEC awareness training is available at the following websites: https://www.iad.gov/ ioss/ or http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum."

Page 4 of 4ENG FORM 6055, APR 2014

8. For Information assurance (IA)/information technology (IT) training. This standard language text is for contract employees who need network access and/or working IA/IT functions. Proposed language: "All contractor employees and associated sub-contractor employees must complete the

DoD IA awareness training before issuance of network access and annually thereafter. All contractor employees working IA/IT functions must comply with DoD and Army training requirements in DoDD 8570.01, DoD 8570.01-M and AR 25-2 within six months of employment."

9. For information assurance (IA)/information technology (IT) certification. Per DoD 8570.01-M , DFARS 252.239.7001 and AR 25-2, the contractor employees supporting IA/IT functions shall be appropriately certified upon contract award. The baseline certification as stipulated in DoD

8570.01-M must be completed upon contract award. Proposed language: "All contractor employees supporting IA/IT functions shall be appropriately certified upon contract IAW DoD 8570.01-M, DFARS 252.239-7001 and AR 25-2. The baseline certification as stipulated in DoD 8570.01-M must be completed upon contract award."

10. For Contractors Authorized to Accompany the Force. DFARS Clause 252.225-7040, Contractor Personnel Authorized to Accompany U.S.

Armed Forces Deployed Outside the United States. The clause shall be used in solicitations and contracts that authorize contractor personnel to accompany US Armed Forces deployed outside the US in contingency operations; humanitarian or peacekeeping operations; or other military operations or exercises, when designated by the combatant commander. Proposed language: "All contractor employees shall ensure the following

AT/OPSEC requirements are met prior to deploying personnel authorized to accompany U.S.