635-20-102 Specifications.pdf

05-01-20

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 00 - SPECIAL SECTIONS

00 01 15 List of Drawing Sheets 05-20

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 03-20

01 32 16.15 Project Schedules (Small Projects – Design/Bid/Build 03-20

01 33 23 Shop Drawings, Product Data, and Samples 05-17

01 35 26 Safety Requirements 05-20

01 42 19 Reference Standards 09-19

01 45 00 Quality Control 03-19

01 45 29 Testing Laboratory Services 11-18

01 45 35 Special Inspections 03-19

01 57 19 Temporary Environmental Controls 01-11

01 81 13 Sustainable Construction Requirements 10-17

01 91 00 General Commissioning Requirements 10-15

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

DIVISION 03 – CONCRETE (NOT USED)

DIVISION 04 – MASONRY (NOT USED)

DIVISION 05 – METALS

05 50 00 Metal Fabrications 08-18

DIVISION 06 – WOOD, PLASTICS AND COMPOSITES (NOT USED)

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 00 Firestopping 02-16

07 92 00 Joint Sealants 10-17

DIVISION 08 – OPENINGS

08 90 00 Louvers and Vents 05-15

DIVISION 09 – FINISHES

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

00 01 10-2

SECTION NO. DIVISION AND SECTION TITLES DATE

09 22 16 Non-Structural Metal Framing 06-18

09 29 00 Gypsum Board 04-20

09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES (NOT USED)

DIVISION 11 – EQUIPMENT (NOT USED)

DIVISION 12 – FURNISHINGS (NOT USED)

DIVISION 13 - SPECIAL CONSTRUCTION

13 05 41 Seismic Restraint Requirements for Non-Structural

Components

01-14

DIVISION 14– CONVEYING EQUIPEMENT (NOT USED)

DIVISION 21- FIRE SUPPRESSION

21 13 13 Wet-Pipe Sprinkler Systems 06-15

DIVISION 22 – PLUMBING (NOT USED)

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

23 05 11 Common Work Results for HVAC 02-20

23 05 12 General Motor Requirements for HVAC and Steam

Generation Equipment

02-20

23 05 41 Noise and Vibration Control for HVAC Piping and

Equipment

02-20

23 05 93 Testing, Adjusting, and Balancing for HVAC 02-20

23 07 11 HVAC and Boiler Plant Insulation 02-20

23 08 00 Commissioning of HVAC Systems 02-20

23 09 23 Direct-Digital Control System for HVAC 09-11

23 21 13 Hydronic Piping 02-20

23 21 23 Hydronic Pumps 02-20

23 22 13 Steam and Condensate Heating Piping 02-20

23 25 00 HVAC Water Treatment 02-20

23 31 00 HVAC Ducts and Casings 02-20

23 34 00 HVAC Fans 02-20

23 36 00 Air Terminal Units 02-20

23 37 00 Air Outlets and Inlets 02-20

23 40 00 HVAC Air Cleaning Devices 03-20

23 72 00 Air-to-Air Energy Recovery Equipment 03-20

23 73 00 Indoor Central-Station Air-Handling Units 03-20

23 82 00 Convection Heating and Cooling Units 03-20

23 82 16 Air Coils 03-20

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

Mechanical Engineer Rectangle

Mechanical Engineer Text Box

NOT IN SCOPE

Mechanical Engineer Rectangle

00 01 10-3

SECTION NO. DIVISION AND SECTION TITLES DATE

DIVISION 25 – INTEGRATED AUTOMATION (NOT USED)

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16

26 05 19 Low-Voltage Electrical Power Conductors and Cables 01-17

26 05 26 Grounding and Bonding for Electrical Systems 01-17

26 05 33 Raceway and Boxes for Electrical Systems 01-18

26 24 16 Panelboards 01-18

26 24 19 Motor Control Center 01-18

26 27 26 Wiring Devices 01-18

26 29 11 Motor Controllers 01-18

26 29 21 Enclosed Switches and Circuit Breakers 01-17

DIVISION 27 – COMMUNICATIONS (NOT USED)

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 31 00 Fire Detection and Alarm 10-11

DIVISION 31 – EARTHWORK (NOT USED)

DIVISION 32 – EXTERIOR IMPROVEMENTS (NOT USED)

DIVISION 33 – UTILITIES (NOT USED)

DIVISION 34 – TRANSPORTATION (NOT USED)

DIVISION 48 – Electrical Power Generation (NOT USED)

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

07-01-15

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

SHEET

NO.

SHEET NAME

GI001 COVER SHEET

GI002 GENERAL INFORMATION & ABBREVIATIONS

A-141 FOURTH FLOOR PLAN

M-001 MECHANICAL ABBREVIATIONS AND GENERAL NOTES

M-002 MECHANICAL SYMBOLS

M-501 MECHANICAL DETAILS

M-502 MECHANICAL DETAILS

M-503 MECHANICAL DETAILS

M-504 MECHANICAL DETAILS

M-505 MECHANICAL DETAILS

M-506 MECHANICAL DETAILS

M-507 MECHANICAL DETAILS

M-601 MECHANICAL SCHEDULES

M-602 MECHANICAL SCHEDULES

M-603 MECHANICAL SCHEDULES

M-701 MECHANICAL CONTROLS

M-702 MECHANICAL CONTROLS

M-703 MECHANICAL RISER DIAGRAM

M-704 MECHANICAL RISER DIAGRAM

MD101 GROUND FLOOR HVAC DEMO PLAN 1 (AHU 4)

MD102 GROUND FLOOR HVAC DEMO PLAN 2 (AHU 4)

MD103 GROUND FLOOR HVAC DEMO PLAN 3 (AHU 4)

MD111 FIRST FLOOR HVAC DEMO PLAN 1 (AHU 4)

MD112 FIRST FLOOR HVAC DEMO PLAN 2 (AHU 4)

MD113 FIRST FLOOR HVAC DEMO PLAN 3 (AHU 4)

MD121 SECOND FLOOR HVAC DEMO PLAN 1 (AHU 4)

MD122 SECOND FLOOR HVAC DEMO PLAN 2 (AHU 4)

MD123 SECOND FLOOR HVAC DEMO PLAN C (AHU 7)

MD131 THIRD FLOOR HVAC DEMOLITION PLAN (AHU 7 AND 14)

MD181 EIGHTTH FLOOR HVAC DEMOLITION PLAN (AHU 4)

M-100 GROUND FLOOR AHU 4 ZONES

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

Mechanical Engineer Rectangle

Mechanical Engineer Text Box

NOT IN SCOPE

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

00 01 15 - 2

M-110 FIRST FLOOR AHU 4 ZONES

M-120 SECOND FLOOR AHU 4 AND 7 ZONES

M-140 FOURTH FLOOR AHU 14 ZONES

MH101 GROUND FLOOR HVAC PLAN 1 (AHU 4)

MH102 GROUND FLOOR HVAC PLAN 2 (AHU 4)

MH103 GROUND FLOOR HVAC PLAN 3 (AHU 4)

MH111 FIRST FLOOR HVAC PLAN 1 (AHU 4)

MH112 FIRST FLOOR HVAC PLAN 2 (AHU 4)

MH113 FIRST FLOOR HVAC PLAN 3 (AHU 4)

MH121 SECOND FLOOR HVAC PLAN 1 (AHU 4)

MH122 SECOND FLOOR HVAC PLAN 2 (AHU 4)

MH123 SECOND FLOOR HVAC PLAN 3 (AHU 7)

MH131 THIRD FLOOR HVAC PLAN (AHU 7 AND 14)

MH141 FOURTH FLOOR HVAC PLAN 1 (AHU 14)

MH142 FOURTH FLOOR HVAC PLAN 2 (AHU 14)

MP101 GROUND FLOOR HVAC PLAN 1 (AHU 4)

MP102 GROUND FLOOR HVAC PLAN 2 (AHU 4)

MP103 GROUND FLOOR HVAC PLAN 3 (AHU 4)

MP111 FIRST FLOOR MECHANICAL PIPING PLAN 1 (AHU 4)

MP112 FIRST FLOOR MECHANICAL PIPING PLAN 2 (AHU 4)

MP113 FIRST FLOOR MECHANICAL PIPING PLAN 3 (AHU 4)

MP121 SECOND FLOOR MECHANICAL PIPING PLAN 1 (AHU 4)

MP122 SECOND FLOOR MECHANICAL PIPING PLAN 2 (AHU 4)

MP181 EIGHTH FLOOR MECHANICAL PIPING PLAN (AHU 4)

MP131 THIRD FLOOR MECHANICAL PIPING PLAN (AHU 7 AND 14)

MP132 MECHANICAL PIPING ENLARGEMENT PLAN (AHU 7 AND 14)

MP181 EIGHTH FLOOR MECHANICAL PIPING PLAN (AHU 4)

MP701 MECHANICAL PIPING RISER DIAGRAM

E-001 ELECTRICAL SYMBOLS & ABBREVIATIONS

E-501 ELECTRICAL DETAIL SHEET

EP101 GROUND FLOOR POWER PLAN 1 (AHU 4)

EP102 GROUND FLOOR POWER PLAN 2 (AHU 4)

EP103 GROUND FLOOR POWER PLAN 3 (AHU 4)

EP111 FIRST FLOOR POWER PLAN 1 (AHU 4)

EP112 FIRST FLOOR POWER PLAN 2 (AHU 4)

EP113 FIRST FLOOR POWER PLAN 3 (AHU 4)

EP121 SECOND FLOOR POWER PLAN 1 (AHU 4)

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Text Box

NOT IN SCOPE

00 01 15 - 3

EP122 SECOND FLOOR POWER PLAN 2 (AHU 4)

EP131 THIRD FLOOR POWER PLAN (AHU 7 AND 14)

EP141 FOURTH FLOOR POWER PLAN 1 (AHU 14)

EP181 EIGHTH FLOOR POWER PLAN (AHU 4)

- - - E N D - - -

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Rectangle

Mechanical Engineer Text Box

NOT IN SCOPE

12-01-18 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.11 PHYSICAL DATA

1.12 PROFESSIONAL SURVEYING SERVICES

1.13 LAYOUT OF WORK

1.14 AS-BUILT DRAWINGS

1.15 WARRANTY MANAGEMENT

1.16 USE OF ROADWAYS

1.17 RESIDENT ENGINEER'S FIELD OFFICE

1.18 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.19 TEMPORARY USE OF EXISTING ELEVATORS

1.20 TEMPORARY USE OF NEW ELEVATORS

1.21 TEMPORARY TOILETS

1.22 AVAILABILITY AND USE OF UTILITY SERVICES

1.23 NEW TELEPHONE EQUIPMENT

1.24 TESTS

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents ii

1.25 INSTRUCTIONS

1.26 GOVERNMENT-FURNISHED PROPERTY

1.27 RELOCATED EQUIPMENT / ITEMS

1.28 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

1.29 CONSTRUCTION SIGN

1.30 SAFETY SIGN

1.31 PHOTOGRAPHIC DOCUMENTATION

1.32 FINAL ELEVATION Digital Images

1.33 HISTORIC PRESERVATION

1.34 VA TRIRIGA CPMS

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

Contractor shall completely prepare site for building operations, including demolition and removal of existing structures, and furnish labor and materials and perform work for Oklahoma City VAMC as required by drawings and specifications.

A. Visits to the site by Bidders may be made only by appointment with the

Contracting Officers Representative.

B. Offices of Valhalla Engineering as Architect-Engineers, will render certain technical services during construction. Such services shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Government without affirmations by Contracting Officer or his duly authorized representative.

C. Before placement and installation of work subject to tests by testing laboratory retained by Department of Veterans Affairs, the Contractor shall notify the COR in sufficient time to enable testing laboratory personnel to be present at the site in time for proper taking and testing of specimens and field inspection. Such prior notice shall be not less than three workdays unless otherwise designated by the COR.

D. All employees of general contractor and subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, GENERAL CONSTRUCTION: Work includes general construction, alterations, site prep and necessary removal of existing equipment and construction and certain other items.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -2

ITEM II, Electrical Work: Work includes all labor, material, equipment, and supervision to perform the required electrical construction work on this project including providing power to equipment.

ITEM III, Mechanical Work: Work includes all labor, material, equipment, and supervision to perform the required Mechanical construction work on this project including replacement of air handlers, fan coils, select terminal boxes and supporting piping and duct work.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -3

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the premises in the event of a national emergency. The General Contractor may return to the site only with the written approval of the Contracting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate keys and lock combinations to the Contracting Officers Representative for the purpose of security inspections of every area of project including toolboxes and parked machines and take any emergency action.

2. The General Contractor shall turn over all permanent lock cylinders to the VA locksmith for permanent installation. See Section 08 71 00, DOOR

HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The General Contractor is responsible for safekeeping of all drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”. Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the

Contracting Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting Officer.

5. All paper waste or electronic media such as CD’s shall be shredded and destroyed in a manner acceptable to the VA.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -4

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access, and maintenance of all project drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of (2 to 5) permits shall be issued for General

Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the

Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the approval of the Contracting

Officer and shall be built with labor and materials furnished by the

Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the Contractor and shall be removed by the Contractor at its expense upon completion of the work. With the written consent of the Contracting Officer, the buildings and utilities may be abandoned and need not be removed.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -5

C. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting

Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the

Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

D. Working space and space available for storing materials shall be as determined by the COR.

E. Workers are subject to rules of Oklahoma City Medical Center applicable to their conduct.

F. Execute work so as to interfere as little as possible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during construction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of Veterans Affairs in quantities sufficient for not more than two workdays. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vacated portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and safety requirements.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -6

G. Phasing:

1. The Medical Center must maintain its operation 24 hours a day 7 days a week. Therefore, any interruption in service must be scheduled and coordinated with the COR to ensure that no lapses in operation occur.

It is the CONTRACTOR'S responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the interim life safety measure to be used during the work, and a schedule defining the duration of the work with milestone subtasks. The work to be outlined shall include, but not be limited to:

2. To ensure such executions, Contractor shall furnish the COR with a schedule of approximate phasing dates on which the Contractor intends to accomplish work in each specific area of site, building or portion thereof. In addition, Contractor shall notify the COR two weeks in advance of the proposed date of starting work in each specific area of site, building or portion thereof. Arrange such phasing dates to ensure accomplishment of this work in successive phases mutually agreeable to

Medical Center Director, COR and Contractor, as follows:

Phase I: AHU-7

Phase II: AHU-4

Phase III: AHU-14

THE FOLLOWING PHASING REQUIREMENTS ARE INTENDED TO DEFINE PERFORMANCE-

BASED PARAMETERS TO ENSURE COMPLETION OF THE PROJECT WITH MINIMAL

DISRUPTION TO THE FACILITY. THE CONTRACTOR SHALL PLAN ITS MEANS AND

METHODS AND ALLOCATE TIME AND RESOURCES AS NECESSARY TO MEET THE

MINIMUM REQUIREMENTS HEREIN. THE CONTRACTOR IS REQUIRED TO DEVELOP A

SCHEDULE PER SPECIFICATION REQUIREMENTS THAT COVERS ALL ASPECTS OF THE

SCOPE OF WORK REQUIRED BY THE CONTRACT DOCUMENTS. GC SHALL COORDINATE

WORK WITH VHA COR FOR ACCESS TO SPACES SERVED.

EACH AHU IN THE PROJECT SHALL BE CONSIDERED A SEPARATE PHASE WITH

SEPARATE SUBSTANTIAL COMPLETION, TAB, CX, PUNCH-LIST, AND CLOSEOUT

REQUIREMENTS PER SPECIFICATIONS. SCOPE IN EACH PHASE MUST BE COMPLETED

AND CLOSED OUT BEFORE MOVING TO THE NEXT PHASE.”

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

Mechanical Engineer Rectangle

Mechanical Engineer Text Box

NOT IN SCOPE

01 00 00 -7

SEQUENCE OF WORK SHALL BE:

1. AHU-7

2. AHU-4

3. AHU-14

UNLESS OTHERWISE NOTED, ALL WORK SHALL BE CONDUCTED DURING NIGHT OR

WEEKEND SHIFTS AND SPACES SHALL BE RETURNED TO THE VHA COR OR

REPRESENTATIVE EACH MORNING. MECHANICAL EQUIPMENT ROOMS ARE EXEMPT FROM

THIS REQUIREMENT. PROVIDE TEMPORARY AHUs AS REQUIRED TO KEEP ALL SPACES

SERVED CONDITIONED THROUGHOUT THE COURSE OF WORK. SEE TEMP AHU

SCHEDULES FOR MINIMUM REQUIREMENTS.

AHU-14 AND AHU-7 MAY BE SERVED BY THE SAME TEMPORARY UNIT. CONTRACTOR'S

OPTION: IR SUITE SERVED BY AHU-7 CAN BE SHUT DOWN FOR ONE CONTINUOUS

WEEK. IF CONTRACTOR CAN COMPLETE WORK PER THE DOCUMENTS WITHIN 1 WEEK

INCLUDING WEEKENDS (9 CALENDAR DAYS) AND RETURN SPACE TO VHA, TEMPORARY

UNIT FOR AHU-7 WILL NOT BE REQUIRED. REFER TO SPECIFICATIONS FOR

POTENTIAL VHA ACTIONS IF THERE ARE DELAYS IN RETURNING TO SPACE TO

OPERATION.

SEQUENCE FOR AHU-4: FAN COILS AND VAVS REPLACED PER THE DOCUMENTS MUST BE

COMPLETED PRIOR TO START OF AHU-4 WORK AND MAY BE COMPLETED CONCURRENT

WITH WORK SHOWN FOR AHU-14 AND AHU-7. MODIFY EXISTING AHU-4 OUTPUT AS

REQUIRED TO MAINTAIN OA CFM TO SPACES SERVED. COORDINATE FOR ACCESS TO

PHARMACY THROUGH VHA COR. SPACES SHALL BE RETURNED TO THE VHA COR EACH

MORNING. VHA WILL PROVIDE TEMPORARY SPOT COOLING FOR FCU AND VAV

REPLACEMENT AREAS. COORDINATE WITH THE VHA COR IN ADVANCE FOR SCHEDULED

WORK AREAS IN ORDER TO ALLOW PRIOR SPOT COOLER MOVEMENT AND SETUP.

H. Buildings No. 1 will be occupied during performance of work.

Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical Centers operations will not be hindered. Contractor shall permit access to Department of Veterans

Affairs personnel and patients through other construction areas which serve as routes of access to such affected areas and equipment. These

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents June, 4, 2021

Project Number 635-20-102

Mechanical Engineer Rectangle

Mechanical Engineer Text Box

NOT IN SCOPE

Mechanical Engineer Rectangle

01 00 00 -8 routes whether access or egress shall be isolated from the construction area by temporary partitions and have walking surfaces, lighting etc.

to facilitate patient and staff access. Coordinate alteration work in areas occupied by Department of Veterans Affairs so that Medical Center operations will continue during the construction period.

1. Immediate areas of alterations not mentioned in preceding Subparagraph

1 will be temporarily vacated while alterations are performed.

B. When a building and/or construction site is turned over to Contractor, Contractor shall accept entire responsibility including upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specified.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for pre-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

C. Utilities Services: Maintain existing utility services for Medical Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -9

Refer to specification Sections 26 05 11, REQUIREMENTS FOR ELECTRICAL

INSTALLATIONS, for additional requirements.

2. Contractor shall submit a request to interrupt any such services to

COR, in writing, 7 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a contract construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the construction project, for such items as water, sewer, electricity, gas or steam, payment of such fee shall be the responsibility of the Government and not the

Contractor.

D. Abandoned Lines: All service lines such as wires, cables, conduits, ducts, pipes and the like, and their hangers or supports, which are to be abandoned but are not required to be entirely removed, shall be sealed, capped or plugged at the main, branch or panel they originate from. The lines shall not be capped in finished areas, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or partitions; so that they are completely behind the finished surfaces.

E. To minimize interference of construction activities with flow of Medical

Center traffic, comply with the following:

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -10

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

2. Method and scheduling of required cutting, altering and removal of existing roads, walks and entrances must be approved by the Resident

Engineer COR.

F. Coordinate the work for this contract with other construction operations as directed by Resident Engineer COR. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contractor shall make a thorough survey with the COR and a representative of VA Supply Service, of buildings in which alterations occur and areas which are anticipated routes of access, and furnish a report, signed by both, to the Contracting

Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient flooring, doors, windows, walls, and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbing fixtures and accessories, electrical fixtures, equipment, venetian blinds, shades, etc., required by drawings to be either reused or relocated, or both.

3. Shall note any discrepancies between drawings and existing conditions at site.

4. Shall designate areas for working space, materials storage, and routes of access to areas within buildings where alterations occur, and which have been agreed upon by Contractor and COR.

B. Any items required by drawings to be either reused or relocated or both, found during this survey to be nonexistent, or in opinion of COR ad/or

Supply Representative to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with specifications which will be furnished by

Government. Provided the contract work is changed by reason of this

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -11 subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR 52.243-4).

C. Re-Survey: Thirty days before expected partial or final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furnish a report on conditions then existing, of resilient flooring, doors, windows, walls, and other surfaces as compared with conditions of same as noted in first condition survey report:

1. Re-survey report shall also list any damage caused by Contractor to such flooring and other surfaces, despite protection measures; and will form basis for determining extent of repair work required of Contractor to restore damage caused by Contractor's workers in executing work of this contract.

D. Protection: Provide the following protective measures:

1. Wherever existing roof surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled, and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust, and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -12

1. Reserved items which are to remain property of the Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings located in rooms and spaces in which work is to be done under this contract shall remain the property of the Government. When rooms and spaces are vacated by the

Department of Veterans Affairs during the alteration period, such items which are NOT required by drawings and specifications to be either relocated or reused will be removed by the Government in advance of work to avoid interfering with Contractor's operation.

4. PCB Transformers and Capacitors: The Contractor shall be responsible for disposal of the Polychlorinated Biphenyl (PCB) transformers and capacitors . The transformers and capacitors shall be taken out of service and handled in accordance with the procedures of the

Environmental Protection Agency (EPA) and the Department of

Transportation (DOT) as outlined in Code of Federal Regulation (CFR), Titled 40 and 49, respectively. The EPA's Toxic Substance Control Act

(TSCA) Compliance Program Policy Nos. 6-PCB-6 and 6-PCB-7 also apply.

Upon removal of PCB transformers and capacitors for disposal, the

"originator" copy of the Uniform Hazardous Waste Manifest (EPA Form

8700-22), along with the Uniform Hazardous Waste Manifest Continuation

Sheet (EPA Form 8700-22A) shall be returned to the Contracting Officer who will annotate the contract file and transmit the Manifest to the

Medical Center's Chief.

a. Copies of the following listed CFR titles may be obtained from the

Government Printing Office:

40 CFR 261 .......Identification and Listing of Hazardous Waste

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -13

40 CFR 262 .......Standards Applicable to Generators of Hazardous

Waste

40 CFR 263 .......Standards Applicable to Transporters of

Hazardous Waste

40 CFR 761 .......PCB Manufacturing, Processing, Distribution in

Commerce, and use Prohibitions

49 CFR 172 .......Hazardous Material tables and Hazardous

Material Communications Regulations

49 CFR 173 .......Shippers - General Requirements for Shipments and Packaging

49 CRR 173 .......Subpart A General

49 CFR 173 .......Subpart B Preparation of Hazardous Material for

Transportation

49 CFR 173 .......Subpart J Other Regulated Material; Definitions and Preparation

TSCA .............Compliance Program Policy Nos. 6-PCB-6 and 6-

PCB-7

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which are not to be removed and which do not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees when specifically authorized to do so and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workers, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -14 party, the locations of which are made known to or should be known by the

Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer may have the necessary work performed and charge the cost to the Contractor.

(FAR 52.236-9)

C. Refer to Section 01 57 19, TEMPORARY ENVIRONMENTAL CONTROLS, for additional requirements on protecting vegetation, soils, and the environment. Refer to Articles, "Alterations", "Restoration", and

"Operations and Storage Areas" for additional instructions concerning repair of damage to structures and site improvements.

D. Refer to FAR clause 52.236-7, "Permits and Responsibilities," which is included in General Conditions. A National Pollutant Discharge Elimination

System (NPDES) permit is required for this project. The Contractor is considered an "operator" under the permit and has extensive responsibility for compliance with permit requirements. VA will make the permit application available at the (appropriate medical center) office. The apparent low bidder, contractor and affected subcontractors shall furnish all information and certifications that are required to comply with the permit process and permit requirements. Many of the permit requirements will be satisfied by completing construction as shown and specified. Some requirements involve the Contractor's method of operations and operations planning and the Contractor is responsible for employing best management practices. The affected activities often include, but are not limited to the following:

- Designating areas for equipment maintenance and repair;

- Providing waste receptacles at convenient locations and provide regular collection of wastes;

- Locating equipment wash down areas on site, and provide appropriate control of wash-waters;

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -15

- Providing protected storage areas for chemicals, paints, solvents, fertilizers, and other potentially toxic materials; and

- Providing adequately maintained sanitary facilities.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the COR.

Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restoring work, shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged. Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4) and "DIFFERING SITE CONDITIONS" (FAR 52.236-2).

1.11 PHYSICAL DATA

A. Data and information furnished or referred to below is for the

Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the

Contractor.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -16

1. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by

(FAR 52.236-4)

B. Government does not guarantee that other materials will not be encountered, nor that proportions, conditions or character of several materials will not vary from those indicated by explorations. Bidders are expected to examine site of work and logs of borings; and, after investigation, decide for themselves character of materials and make their bids accordingly. Upon proper application to Department of Veterans

Affairs, bidders will be permitted to make subsurface explorations of their own at site.

1.12 PROFESSIONAL SURVEYING SERVICES (NOT USED)

1.13 LAYOUT OF WORK

A. The Contractor shall lay out the work from Government established base lines and benchmarks, indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at Contractor's own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting

Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting

Officer until authorized to remove them. If such marks are destroyed by the Contractor or through Contractor's negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the

Contractor.

(FAR 52.236-17)

1.14 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -17

B. All variations shall be shown in the same general detail as used in the contract drawings. To ensure compliance, as-built drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings in electronic format (scanned to PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the

COR.

D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.15 WARRANTY MANAGEMENT

A. Warranty Management Plan: Develop a warranty management plan which contains information relevant to FAR 52.246-21 Warranty of Construction in at least 30 days before the planned pre-warranty conference, submit one set of the warranty management plan. Include within the warranty management plan all required actions and documents to assure that the

Government receives all warranties to which it is entitled. The plan must be in narrative form and contain sufficient detail to render it suitable for use by future maintenance and repair personnel, whether tradesman, or of engineering background, not necessarily familiar with this contract.

The term “status” as indicated below must include due date and whether item has been submitted or was approved. Warranty information made available during the construction phase must be submitted to the

Contracting Officer for approval prior to each monthly invoice for payment. Assemble approved information in a binder and turn over to the

Government upon acceptance of the work. The construction warranty period will begin on the date of the project acceptance and continue for the product warranty period. A joint 4 month and 9-month warranty inspection will be conducted, measured from time of acceptance, by the Contactor and the Contracting Officer. Include in the warranty management plan, but not limited to, the following:

1. Roles and responsibilities of all personnel associated with the warranty process, including points of contact and telephone numbers within the company of the Contractor, subcontractors, manufacturers or suppliers involved.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -18

2. Furnish with each warranty the name, address, and telephone number of each of the guarantor’s representatives nearest project location.

3. Listing and status of delivery of all Certificates of Warranty for extended warranty items, to include roofs, HVAC balancing, pumps, motors, transformers and for all commissioned systems such as fire protection and alarm systems, sprinkler systems and lightning protection systems, etc.

4. A list for each warranted equipment item, feature of construction or system indicating:

a. Name of item.

b. Model and serial numbers.

c. Location where installed.

d. Name and phone numbers of manufacturers and suppliers.

e. Name and phone numbers of manufacturers or suppliers.

f. Names, addresses and phone numbers of sources of spare parts.

g. Warranties and terms of warranty. Include one-year overall warranty of construction, including the starting date of warranty of construction. Items which have extended warranties must be indicated with separate warranty expiration dates.

h. Starting point and duration of warranty period.

i. Summary of maintenance procedures required to continue the warranty in force.

j. Cross-reference to specific pertinent Operation and Maintenance manuals.

k. Organizations, names and phone numbers of persons to call for warranty service.

l. Typical response time and repair time expected for various warranted equipment.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -19

5. The plans for attendance at the 4 and 9-month post construction warranty inspections conducted by the government.

6. Procedure and status of tagging of all equipment covered by extended warranties.

7. Copies of instructions to be posted near selected pieces of equipment where operation is critical for warranty and/or safety reasons.

B. Performance Bond: The Performance Bond must remain effective throughout the construction period.

1. In the event the Contractor fails to commence and diligently pursue any construction warranty work required, the Contracting Officer will have the work performed by others, and after completion of the work, will charge the remaining construction warranty funds of expenses incurred by the Government while performing the work, including, but not limited to administrative expenses.

2. In the event sufficient funds are not available to cover the construction warranty work performed by the Government at the contractor’s expenses, the Contracting Officer will have the right to recoup expenses from the bonding company.

3. Following oral or written notification of required construction warranty repair work, the Contractor shall respond in a timely manner.

Written verification will follow oral instructions. Failure to respond will be cause for the Contracting Officer to proceed against the

Contractor.

C. Pre-Warranty Conference: Prior to contract completion, and at a time designated by the Contracting Officer, the Contractor shall meet with the

Contracting Officer to develop a mutual understanding with respect to the requirements of this section. Communication procedures for Contractor notification of construction warranty defects, priorities with respect to the type of defect, reasonable time required for Contractor response, and other details deemed necessary by the Contracting Officer for the execution of the construction warranty will be established/ reviewed at this meeting. In connection with these requirements and at the time of the

Contractor’s quality control completion inspection, furnish the name, Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -20 telephone number and address of a licensed and bonded company which is authorized to initiate and pursue construction warranty work action on behalf of the Contractor. This point of contract will be located within the local service area of the warranted construction, be continuously available and be responsive to Government inquiry on warranty work action and status. This requirement does not relieve the Contractor of any of its responsibilities in conjunction with other portions of this provision.

D. Contractor’s Response to Construction Warranty Service Requirements:

Following oral or written notification by the Contracting Officer, the

Contractor shall respond to construction warranty service requirements in accordance with the “Construction Warranty Service Priority List” and the three categories of priorities listed below. Submit a report on any warranty item that has been repaired during the warranty period. Include within the report the cause of the problem, date reported, corrective action taken, and when the repair was completed. If the Contractor does not perform the construction warranty within the timeframe specified, the

Government will perform the work and back charge the construction warranty payment item established.

1. First Priority Code 1. Perform onsite inspection to evaluate situation, and determine course of action within 4 hours, initiate work within 6 hours and work continuously to completion or relief.

2. Second Priority Code 2. Perform onsite inspection to evaluate situation, and determine course of action within 8 hours, initiate work within 24 hours and work continuously to completion or relief.

3. Third Priority Code 3. All other work to be initiated within 3 workdays and work continuously to completion or relief.

4. The “Construction Warranty Service Priority List” is as follows:

Code 1-Life Safety Systems

a. Fire suppression systems.

b. Fire alarm system(s).

Code 1-Air Conditioning Systems

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00 -21

a. Air conditioning leak in part of the building, if causing damage.

b. Air conditioning system not cooling properly.

Code 1 Doors

a. Overhead doors not operational, causing a security, fire, or safety problem.

b. Interior, exterior personnel doors or hardware, not functioning properly, causing security, fire, or safety problem.

Code 3-Doors

a. Overhead doors not operational.

b. Interior/exterior personnel doors or hardware not functioning properly.

Code 1-Electrical

a. Power failure (entire area or any building operational after 1600 hours).

b. Security lights.

c. Smoke detectors.

Code 2-Electrical

a. Power failure (no power to a room or part of building).

b. Receptacles and lights not operational (in a room or part of building).

Code 3-Electrical

a. Exterior lights not operational.

Code 1-Gas

a. Leaks and pipeline breaks.

Code 1-Heat

a. Power failure affecting heat.

Oklahoma City VAMC Replace AHUS 4, 7, 14 and FCU Oklahoma City, Oklahoma

100% Construction Documents

01 00 00…