Design-Build Services at Grove Park Garage
Closed State & local contract opportunity Posted
- Solicitation number
- RFP26-0434
- State
- Florida
- Responses due
Opportunity facts
- Jurisdictions
- NIGP codes
- 15553 Parking Structures
- 28555 Lighting, Area, Pole Or Standard Mounted (Parking Lots, Etc.)
- 90610 Buildings - Architectural Design
- 90625 Design Build Services
- 90652 Interior Design, Space Planning, And Exhibits/Displays
- 90735 Designing Services
- 90924 Building Construction, Commercial And Institutional
- 91336 Construction, Parking Lot And Alley
- 92517 Civil Engineering
- 92532 Electronic Engineering
- UNSPSC codes
- 95121500 Commercial and entertainment buildings and structures
- 95121704 Prison building
- 95121503 Cafeteria
- 95121703 Court building
- 95121606 Railway station
- 95121701 Post office
- 81101500 Civil engineering
- 72141400 Detention facility construction and repair services
- 72121104 Restaurant construction service
- 95121712 Art gallery
Show all 44
- 95121608 Underground railway station
- 95121501 Shopping mall
- 95121715 Public toilet facility
- 95121506 Theater
- 95121705 Fire station
- 72153700 Parking facility construction and equipment installation and maintenance and repair services
- 95121645 Motorway service area
- 95121644 Parking lot
- 39111618 Sports lighting system
- 72121105 Shopping center and mall construction service
- 72141401 Detention facility construction service
- 95121604 Bus garage
- 95121607 Railway depot
- 95121605 Automotive repair or servicing building
- 95121711 Civic center
- 39111619 Large area lighting system
- 72153612 Interior design or decorating
- 82141602 Article display arrangement
- 72121100 Commercial and office building construction services
- 95121700 Public buildings and structures
- 72111104 New dormitory construction service
- 72111105 New hotel or motel construction service
- 72121101 Commercial and office building new construction service
- 72141128 Public square construction and or remodelling service
- 95121702 Police station
- 95121603 Bus station
- 95122106 Hostel
- 95121505 Shopping center
- 95121504 Shop building
- 95121714 Public changing room and shower facility
- 95121507 Market
- 95121706 Ambulance station
- 72152708 Parking lot construction service
- 95121646 Bicycle parking rack
- Point of contact
-
- William Resto william.resto@orlando.gov (407) 246-3635
Opportunity details come from procurement.opengov.com. Updated .
About this opportunity
The City of Orlando is requesting proposals for design-build services at Grove Park Garage under RFP26-0434, with sealed responses due September 4, 2026 at 2:00 p.m. local time via OpenGov. The project is a seven-level parking structure with a minimum of 800 parking spaces on a 6.75-acre site one block northwest of the Kia Center, with programming for Downtown Clean Team and Ambassadors' headquarters on Level 1 and dedicated parking for courthouse employees and sports venue overflow on remaining levels. MBE participation of 18% and WBE participation of 6% are weighted evaluation factors.
Respondents must be appropriately licensed Florida contractors and include either a Florida-licensed qualifying agent for architectural services or a qualified engineer registered in Florida. The scope encompasses design, permitting, construction, vehicle detection systems, dynamic signage, license plate recognition, electric vehicle charging infrastructure, and digital parking management systems. The design and construction schedule shall not exceed 670 days from Notice to Proceed, with liquidated damages of $4,000 per day for delays. The project is subject to Davis-Bacon wage rates for Orange County, Florida and a living wage floor of $15.00 per hour. Compliance with LEED certification goals under the City's Green Works 2030 initiative is required, with consideration for solar-ready equipment and net-zero energy design objectives.
The total project budget is $35.75 million, encompassing all design, permitting, construction, and fees for a complete facility ready for City occupancy. The Design-Build Fee comprises profit and general overhead costs applied to the Cost of Work and will be scored as a best-value component during final ranking. Respondents must demonstrate financial stability and ability to secure performance and payment bonds equal to the contract price through an approved surety with at least an "A-" rating, and maintain errors and omissions insurance of $3 million minimum.
A non-mandatory pre-proposal conference is scheduled for August 18, 2026 at 10:00 a.m. at the Fairview Conference Room, 9th Floor, 400 S. Orange Avenue, Orlando, Florida. Questions are due August 26, 2026 at 5:00 p.m. William Resto, Purchasing Agent II, is the primary point of contact at (407) 246-3635 or william.resto@orlando.gov. All solicitation documents are available for download at no cost from the City of Orlando's e-procurement portal at https://procurement.opengov.com/portal/orlando. The City reserves the right to reject any and all proposals, remove scope, or terminate the solicitation if the final Guaranteed Maximum Price exceeds the budget or is not in the public interest.
Opportunity text
Notice is hereby given that City of Orlando (City) is accepting sealed responses for RFP26-0434 Design-Build Services at Grove Park Garage and they must be submitted electronically by 2:00 pm local time on Friday, September 4, 2026, in order for a Respondent to be considered for award of a contract.
Respondents are solely responsible for ensuring that their submittals are complete, uploaded, and submitted electronically via OpenGov by the due date and time. The City shall not be responsible for any submission delays or failures caused by any occurrence. Respondents are expected to examine this solicitation, specifications, associated drawings, if any, and all instructions. Failure to do so will be at the Respondent's risk.
Each Respondent shall furnish the information required on each submittal form and each accompanying sheet thereof on which an entry is made.
Files
On GovTribe
Work this opportunity
- Track it in your pipeline
- Similar opportunities
- Ask GovTribe AI about this opportunity