Repair TACAN Electrical Feed
Closed Solicitation Posted
This opportunity was awarded. See the award notice from .
- Solicitation number
- FA6670-20-B-0002
- Agency
- Reserve Command Air Force, Department of Defense
- Responses due
- Set-aside
- HUBZone
Opportunity facts
- NAICS code
- 236220 Commercial and Institutional Building Construction
- Place of performance
- Niagara Falls NY 14304 USA
Notice details come from SAM.gov. Updated .
About this opportunity
This solicitation seeks a firm fixed-price construction contract to replace an underground primary electrical feeder line and associated equipment at Niagara Falls Air Reserve Station in New York. The Department of the Air Force Reserve Command is procuring these services to repair the electrical feed for the base's TACAN system. Offerors must complete the work within 120 calendar days and furnish all labor, materials, equipment, and supervision. Questions regarding the solicitation are due by August 31, 2020. Proposals must include bid, payment, and performance bonds and will be evaluated without discussions.
The procurement is set aside 100% for historically underutilized business zone concerns under NAICS code 236220 with a size standard of $39.5 million. The estimated value of the contract is between $500,000 to $1,000,000 to be performed over 120 calendar days at Niagara Falls Air Reserve Station in Niagara County, New York. Electronic submissions will not be accepted. Offerors must register in the System for Award Management and Wide Area Workflow to receive the full solicitation available on beta.SAM.gov and be eligible for award.
Notice text
2 versions
Update #2 · Latest ·
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair TACAN Electrical Feed.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 19-0734 Repair TACAN Electrical Feed, to include the following: replace the existing underground primary feeder electrical line on the west end of the airfield connecting the TACAN, ILS and fire training areas to the existing base electrical system. Work will include the replacement of the existing pad mounted transformers, switching equipment and other related equipment and parts to be compatible with the new circuit.
Notice to Offerors: Funds are not presently available for this project. No award will be made until funds are available to make payment under a contract. The Government reserves the right to cancel this solicitation, either before or after Bid closing, with no obligation to the Offeror by the Government.
Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 180 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Historically Underutilized Business Zone, (HUBZone), concerns IAW FAR Subpart 19.15.
The estimated magnitude of construction is between $500,000 and $1,000,000.
The NAICS code is 236220 and the Small Business Size Standard is $39,500,000.
Electronic bid submissions will not be accepted or returned
Bid, Payment and Performance Bonds will be required.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
Site visit information is provided in the solicitation, see FAR Clause 52.236-27; prime contractors, subcontractors and/or suppliers may attend the site visit. There will NOT be additional Site Visits.
All questions regarding this solicitation and any questions generated from the site visit must be submitted in writing to Mary Pyle Platts at mary.pyleplatts@us.af.mil , NLT 31 August 2020 at 3:00 pm. Answers will be posted out under the solicitation on FBO.gov approximately 4 days later. The Contracting Officer will provide clarification through amendment to the solicitation following receipt of any questions. Submission of questions prior to the site visit is strongly encouraged.
Due to the current COVID-19 situation, all participants are required to wear Personnel Protection Equipment (PPE) while attending the site visit. All individuals on DOD property, installations and facilities are required to wear a cloth face covering when he/she cannot maintain social distancing of at least six feet in public areas or work centers per DOD guidance on the use of cloth face coverings. It is the sole responsibility of each attendee to wear any PPE in accordance with the latest Federal, State and Local Departments of Health, and DoD Public Health Emergency Management policies appropriate for the site visit. The Government will not provide any PPE for persons attending the site visit. If proper PPE is not used, the individual will not be allowed to participate in the site visit.
The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized. For questions, please contact Mary Pyle Platts at mary.pyleplatts@us.af.mil
Update #1 ·
Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair TACAN Electrical Feed.
Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 19-0734 Repair TACAN Electrical Feed, to include the following: replace the existing underground primary feeder electrical line on the west end of the airfield connecting the TACAN, ILS and fire training areas to the existing base electrical system. Work will include the replacement of the existing pad mounted transformers, switching equipment and other related equipment and parts to be compatible with the new circuit.
Notice to Offerors: Funds are not presently available for this project. No award will be made until funds are available to make payment under a contract. The Government reserves the right to cancel this solicitation, either before or after Bid closing, with no obligation to the Offeror by the Government.
Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY.
Performance time is 120 calendar days.
A single Firm Fixed-Price construction contract will be awarded.
This solicitation is set-aside 100% Historically Underutilized Business Zone, (HUBZone), concerns IAW FAR Subpart 19.15.
The estimated magnitude of construction is between $500,000 and $1,000,000.
The NAICS code is 236220 and the Small Business Size Standard is $39,500,000.
Electronic bid submissions will not be accepted or returned
Bid, Payment and Performance Bonds will be required.
Liquidated damages will be identified in the solicitation and placed under the proposed contract.
All applicable provisions and clauses will be included in the actual solicitation.
Site visit information is provided in the solicitation, see FAR Clause 52.236-27; prime contractors, subcontractors and/or suppliers may attend the site visit. There will NOT be additional Site Visits.
All questions regarding this solicitation and any questions generated from the site visit must be submitted in writing to Mary Pyle Platts at mary.pyleplatts@us.af.mil , NLT 31 August 2020 at 3:00 pm. Answers will be posted out under the solicitation on FBO.gov approximately 4 days later. The Contracting Officer will provide clarification through amendment to the solicitation following receipt of any questions. Submission of questions prior to the site visit is strongly encouraged.
Due to the current COVID-19 situation, all participants are required to wear Personnel Protection Equipment (PPE) while attending the site visit. All individuals on DOD property, installations and facilities are required to wear a cloth face covering when he/she cannot maintain social distancing of at least six feet in public areas or work centers per DOD guidance on the use of cloth face coverings. It is the sole responsibility of each attendee to wear any PPE in accordance with the latest Federal, State and Local Departments of Health, and DoD Public Health Emergency Management policies appropriate for the site visit. The Government will not provide any PPE for persons attending the site visit. If proper PPE is not used, the individual will not be allowed to participate in the site visit.
The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates.
Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities.
Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil
This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned.
Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized. For questions, please contact Mary Pyle Platts at mary.pyleplatts@us.af.mil
Attachments
Show all 11
Notice history
| Notice | Type | Posted |
|---|---|---|
| Repair TACAN Electrical Feed | Award Notice | |
| Repair TACAN Electrical Feed | Solicitation | |
| Repair TACAN Electrical Feed | Pre-Solicitation |
On GovTribe
Work this opportunity on GovTribe
- Track it in your pipeline
- Find teaming partners
- Similar opportunities
- Ask GovTribe AI about this opportunity