W9115123B0020 IFB.pdf

R

0011951647

This is an "Invitation for Bids."

A Bid Bond is required (see section 00100, FAR Clause 52.228-1).

Performance and Payment Bonds are required (see section 00700, FAR Clause 52.228-15).

As required by FAR 36.204, the estimated magnitude of this project is betw een $250,000 and $500,000.

The NAICS for this acquisition is 236220 Commercial and Institutional Building Construction (Small Business Size Standard $45.0 Million).

This acquisition is 100% Small Business Set-Aside concerns only; no large business bids w ill be accepted for this procurement.

The aw ardee of this contract w ill be required to provide a Superintendent through completion of the project (see section 00700, FAR Clause 52.236-6). Project Manager, Quality Control and Superintendent Positions are considered key positions. These positions SHALL not be sub-contracted and must w ork directly for the prime contractor.

Bidders are required to provide a valid CAGE Code (Block 14 FACILITY), Point of Contact (POC) and email address w ith their bid.

X

JUSTIN J. MANSFIELD 254-277-3899

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

24-Jul-2023

(RFP)

(IFB)

CALL:

Renovate BLDG 32010

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________270 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________24 Aug 2023 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

MICC - FORT CAVAZOS (901ST CBN)

36000 SHOEMAKER LANE, ROOM 1300B

FORT CAVAZOS TX 76544-5025

W91151

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

AD210940PC

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W9115123B0020 70

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W9115123B0020

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

REPAIR FACILITY - BUILIDING 32010

FFP

The work shall be located at building 32010 at the intersection at W. Old Ironsides Ave. and New Dawn Dr.,Fort Hood, Texas. The exact location will be shown by the Contracting Officer. Building(s) will not be occupied during performance of work under this Contract. The purpose of this project is to renovate the existing facility to modern standards.

See Technical Exhibits for details.

FOB: Destination

PURCHASE REQUEST NUMBER: 0011951647

PSC CD: Z2JZ

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 270 dys. ANP 1 DIRECTORATE OF PUBLIC WORKS - FT

CAVAZOS

JUSTIN PETREE

SERVICES DIVISION

4612 ENGINEER DRIVE

FORT CAVAZOS TX 76544

254-287-4504 OR 254-432-1308 (

FOB: Destination

W45NQ9

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO BIDDERS

INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

1. INSTRUCTIONS TO BIDDERS:

1.1 You are invited to submit a bid in response to our Invitation for Bids (IFB) W91151‐23-B-0020 located at the Shoemaker Center, Bldg. 36000 Shoemaker Lane, 1st Floor, Room 1527, Main Conference Room, Fort Cavazos, TX 76544.

1.2 The Government intends to award a Firm Fixed Price (FFP) contract to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantage to the Government, considering only price.

1.3 This solicitation is 100% Small Business Set‐aside.

2. NOTICE OF PRE‐BID CONFERENCE AND SITE VISIT:

2.1 The Contracting Officer will conduct a site visit. All potential bidders attending the site visit are highly encouraged to attend the prebid conference. Information on the scheduled Site Visit is located in FAR Clause 52.236‐27 ALT I SITE VISIT (CONSTRUCTION) (FEB 1995) of this solicitation. The Contracting Officer will review solicitation submittal requirements, and other administrative matters critical for successful and timely performance of the work.

2.2. The Offeror shall attend a Government coordinated preconstruction conference within 10 calendar days of contract award. As a minimum, the conference shall be attended by the Offeror’s appointed project manager, the superintendent, the Quality Control Manager (QCM), and administrative personnel responsible for preparation of contract documents, certified payroll records and invoices. The Offeror shall deliver letter appointments of its key personnel that include each individual's duties, roles and responsibilities.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

Submit all questions in the format shown below by email to the contracting office to the addresses shown below. Do NOT contact Department of Public Works (DPW) directly. Doing so will only delay your answer. All questions must come through the Contracting Office.

Subject Line:

Reference NO.

SOLICITATION Number Emails: marquez.m.siler.mil@army.mil; justin.j.mansfield.mil@army.mil;

Date of Bid Inquiry:

From:

Address:

Phone Number:

Email address:

Company Name:

Fax Number:

Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

• Any explanation desired by bidder regarding the meaning or interpretation of the solicitation, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

• All questions and requests for information (RFI) must be received NO LATER THAN time specified in

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

BIDDERS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS EARLY IN THIS PROCESS.

**After the due date no additional RFI's will be answered**

• Any changes to the drawings, specifications, etc. will be issued in the form of an amendment. However, any answers that clarify or provide an interpretation to the drawings, specifications, etc. will NOT be posted via amendment but rather as a response to the RFI on SAM.gov website:

https://sam.gov/content/home

• Receipt by the bidder must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids.

• All technical data related to this solicitation will be distributed using the sam.gov Opportunities (https://sam.gov/) system. SAM is a web‐based dissemination tool designed to safeguard acquisition related information for all Federal agencies. Interested bidders/offerors must register with SAM before accessing the system.

• Amendments, if/when issued will be posted to https://sam.gov/ for electronic downloading. This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible due to various reasons.

4. SUBMISSION OF BIDS: ELECTRONIC SUBMISSION OF BIDS, TO INCLUDE EMAIL AND

FACSIMILE TRANSMISSIONS, IS NOT AUTHORIZED.

• The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids on its behalf as indicated below. Bids shall not be addressed to any specific person. Any bids hand‐ delivered prior to 1330 on the due date shall only be delivered to the MICC Fort Cavazos Contracting Office, Shoemaker Building, 36000 Shoemaker Lane, 1st Floor, Room 1535, Fort Cavazos, TX 76544.

*Note: Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer shall declare the bid "late" in accordance with FAR 14.304.

All bids must be clearly identified with the bidder's name, address, and UEI. To ensure timely and proper handling, the lower left comer of the outermost wrapper should indicate the following:

Invitation for Bid No: W91151-23-B-0020 Due Date of Bids: See Block 13 A, page 1.

Title of Project: The purpose of this project is to renovate building 32010.

Bidder’s submission shall consist of one (1) volume, physically separated with detachable parts, and individually titled. Please note no thumb drives will be accepted.

TAB TITLE ORIGINAL HARD COPY

A COVERSHEET 1

B SF1442 / AMMENDMENTS 1

C TOTAL CONTRACT PRICE 1

D LETTER FROM BONDING

COMPANY

E BID BOND GUARANTEE 1

F REPS & CERTS 1

Bids not hand carried must be delivered before bid opening only by mail, including, Federal Express or United Parcel Service to the address as indicated below. The date and time of delivery established by these carriers is not the official time of receipt by the Government. Bidders are responsible for allowing sufficient time for the bid to be processed for receipt and are cautioned that sufficient time may be as much as 24 hours prior to the date and time designated for receipt of bids. Bids sent by Federal Express and United Parcel Service are required to be sent to:

MICC‐Fort Cavazos Attention: MSG Justin Mansfield

W91151‐23-B-0020 36000 Shoemaker Lane, Fort Cavazos, TX 76544

OR

MICC‐Fort Cavazos Attention: SSG Marques Siler W91151‐23-B-0020 36000 Shoemaker Lane, Fort Cavazos, TX 76544

*Note if you will be mailing your bid please ensure you allow enough time due to possible shipping delays Bidders must allow sufficient time to complete security screening to gain admittance to Fort Cavazos, TX. The Government will not be responsible for bids delivered to any location or to anyone other than those designated to receive bids on its behalf. Bidders are responsible for ensuring bids are submitted so as to reach the location designated for receipt of bids.

5. PUBLIC BID OPENING:

The bid opening will occur at the time and date specified in Block 13, A of page 1: Shoemaker Center, Building 36000 Shoemaker Lane, Main Conference, Room 1527, 1st Floor, Fort Cavazos, TX.

6. WAGE DETERMINATION:

Construction Wage Rates are applicable to this Project# AD210940PC as shown in Section 00800.

7. BID PREPARATION EXPENSES AND PRE‐CONTRACT COSTS:

This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

8. BID CONTENT/OFFERORS QUALIFICATIONS:

IFB DOCUMENTS. Contract shall be awarded to the responsive /responsible prospective Offeror considering only price. Before award, to be determined responsive, a prospective Offeror must furnish the following information with their bid:

a. TAB A: Cover Sheet. Coversheet shall be on company letterhead and must contain your UEI number, CAGE code, Tax ID, and authorized representative(s) who can obligate your company contractually, sign the bid, and sign, other contract actions; include tele phone number with area code and complete email address for each authorized representative. Failure to provide all of the above requirements shall render your bid nonresponsive.

b. TAB B: Signed and completed SF 1442 along with any amendments. The SF1442 shall be submitted fully completed. The Offeror shall acknowledge any amendments to the IFB in accordance with the instructions on the SF1442. All bidders are cautioned to complete blocks 20a‐20c with an original signature in block 20b. Failure to provide all of the above requirements shall render your bid nonresponsive.

c. TAB C: CLIN Price and Total Contract Amount. The Bidders shall provide page 3 of the solicitation pricing each CLIN individually and include the OVERALL contract price.

d. TAB D: Letter from Bonding Company. Letter must indicate the bidder’s ability to obtain performance and payment bonds in the amount of their bid. Failure to provide this letter shall render your bid as nonresponsive.

e. TAB E: Bid Bond Guarantee. Per FAR 52.228‐1, failure to provide a bid bond guarantee per FAR 52.228‐1 shall render your bid nonresponsive.

f. TAB F: REPRESENTATIONS, CERTIFICATIONS. The bidder shall ensure that their business has completed an online Representations and Certifications at the System and Awards Management (SAM) website, which may be found at https://www.sam.gov/portal/public/SAM/. It is the bidder’s responsibility to ensure that the information provided in each representation and certification is completed truthfully and completely. A bidder' s failure to complete the online representations and certifications prior to the close of the Solicitation (to include listing of the applicable NAICS code and applicable size standards) will result in their bid being deemed nonresponsive and eliminated from further consideration. Bidders shall submit the representations and certifications listed in Section 00600 or provide a printed version of the documents from their corporate SAM profile. Bidder must be registered in the database IAW FAR 52.204‐7 in order to be awarded a contract and have the applicable NAICS code listed in FAR 52.219‐1(c), Small Business Program Representations (Alternate I), Representations.

9. JOINT VENTURES OR TEAMING AGREEMENTS:

Contractors proposing Joint Venture (JV) and/or Teaming Agreements (TA) shall submit a copy of the JV and/or TA with the specified Subcontractor to include the Subcontractor’s proposal. In order for your joint venture to be able to bid on contracts reserved for small businesses, you must follow the requirements for receiving an exclusion of affiliation for contracting purposes. To receive an exclusion from affiliation the mentor-protégé agreement must be approved before a mentor and its protégé submit an offer for a small business contract as a joint venture. The certificate should also be emailed to mppjvreporting@sba.gov.The KO will validate with the SBA that the JV/TA Subcontractor is determined eligible for award under the size standard assigned to the contract.

10. ANTITERRORISM / OPERATIONAL SECURITY REQUIRMENTS:

AT Level I Training. This provision/contract text is for contractor employees with an area of performance within an Army controlled installation, facility or area. All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities, controlled access areas, or require network access, shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. Upon request, the contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at the following website:

http://jko.jten.mil/courses/atl1/launch.html or it can be provided by the RA ATO in presentation form which will be documented via memorandum.

Access and General Protection/Security Policy and Procedures. Contractor employees with an area of performance within an Army controlled installation, facility or area. All contractor and all associated sub-contractors employees shall comply with applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation/facility access requirements to be accomplished by installation Provost Marshal Office, Director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9, Personal Identity Verification of Contractor Personnel) as directed by DOD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any installation or facility change, the Government may require changes in contractor security matters or processes.

For contractors who do not require CAC, but require access to a DoD facility or installation. Contractor and all associated sub-contractors employees shall comply with adjudication standards and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05 / AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (provided by government representative, as NCIC and TSDB are available), or, at OCONUS locations, in accordance with status of forces agreements and other theater regulations.

Suspicious Activity Reporting Training (e.g. iWATCH, CorpsWatch, or See Something, Say Something).

Contractor employees with an area of performance within an Army controlled installation, facility or area.

Contractor and all associated sub-contractors shall receive a brief/training (provided by the RA) on the local suspicious activity reporting program. This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the project manager, security representative or law enforcement entity. This training shall be completed within 30 calendar days of contract award and within 30 calendar days of new employees commencing performance with the results reported to the COR NLT 5 calendar days after the completion of the training.

For Contracts that Require OPSEC Training. Per AR 530-1, (Operations Security) contractor employees must complete Level I OPSEC Training within 30 calendar days of contract award. All new contractor employees will complete Level I OPSEC Training within 30 calendar days of their reporting for duty. Additionally, all contractor employees must complete annual OPSEC awareness training. The contractor shall submit certificates of completion for each affected contractor and subcontractor employee, to the COR or to the contracting officer (if a COR is not assigned), within 5 calendar days after completion of training. OPSEC awareness training is available at the following websites: https://www.iad.gov/ioss/ or http://www.cdse.edu/catalog/operations-security.html; or it can be provided by the RA OPSEC Officer in presentation form which will be documented via memorandum.

Will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas. The contractor will coordinate with the COR and/or the facility security office for access when required. (Use when security clearances are not required, i.e. facility repair or construction). All contract employees, including subcontractor employees who are not in possession of the appropriate security clearance or access privileges, will be escorted in areas where they may be exposed to classified and/or sensitive materials and/or sensitive or restricted areas.

Pre-screen candidates using E-Verify Program. The Contractor must pre-screen Candidates using the E-verify Program (http://www.uscis.gov/e-verify) website to meet the established employment eligibility requirements. The Vendor must ensure that the Candidate has two valid forms of Government issued identification prior to enrollment to ensure the correct information is entered into the E-verify system. An initial list of verified/eligible Candidates must be provided to the COR no later than 3 business days after the initial contract award." *When contracts are with individuals, the individuals will be required to complete a Form I-9, Employment Eligibility Verification, with the designated Government representative. This Form will be provided to the Contracting Officer and shall become part of the official contract file.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-22 Alternative Line Item Proposal JAN 2017 52.204-27 Prohibition on a ByteDance Covered Application JUN 2023 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.219-2 Equal Low Bids OCT 1995 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.232-13 Notice Of Progress Payments APR 1984 52.236-4 Physical Data APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed Price contract resulting from this solicitation.

(End of provision)

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (MAR 2023)

(a) Definitions. As used in this provision--

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR 127.300. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern--

(1) Means a concern, including its affiliates, that is independently owned and operated, not dominant in its field of operation, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph

(b) of this provision.

(2) Affiliates, as used in this definition, means business concerns, one of whom directly or indirectly controls or has the power to control the others, or a third party or parties control or have the power to control the others. In determining whether affiliation exists, consideration is given to all appropriate factors including common ownership, common management, and contractual relationships. SBA determines affiliation based on the factors set forth at 13

CFR 121.103.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned small business concern means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127) means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States, and the concern is certified by SBA or an approved third-party certifier in accordance with 13 CFR 127.300.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $45,000,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce (i.e., nonmanufacturer), is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(c) Representations.

(1) The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not a small business concern; or

(ii) It [ ___ ] is, [ ___ ] is not a small business joint venture that complies with the requirements of 13 CFR 121.103(h) and 13 CFR 125.8(a) and (b). [The offeror shall enter the name and unique entity identifier of each party to the joint venture: ___ .]

(2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) joint venture eligible under the WOSB Program. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The offeror shall enter the name and unique entity identifier of each party to the joint venture: ___ .]

(5) Economically disadvantaged women-owned small business (EDWOSB) joint venture. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR 127.506(a) through (c). [The offeror shall enter the name and unique entity identifier of each party to the joint venture: ___ .]

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(6) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern; or

(ii) It [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned joint venture that complies with the requirements of 13 CFR 125.18(b)(1) and (2). [The offeror shall enter the name and unique entity identifier of each party to the joint venture: ___ .] Each service-disabled veteran-owned small business concern participating in the joint venture shall provide representation of its service-disabled veteran-owned small business concern status.

(8) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, as having been certified by SBA as a HUBZone small business concern in the Dynamic Small Business Search and SAM, and will attempt to maintain an employment rate of HUBZone residents of 35 percent of its employees during performance of a HUBZone contract (see 13 CFR 126.200(e)(1)); and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR 126.616(a) through (c). [The offeror shall enter the name and unique entity identifier of each party to the joint venture: ___ .] Each HUBZone small business concern participating in the HUBZone joint venture shall provide representation of its HUBZone status.

(d) Notice. Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall—

(1) Be punished by imposition of fine, imprisonment, or both;

(2) Be subject to administrative remedies, including suspension and debarment; and

(3) Be ineligible for participation in programs conducted under the authority of the Act.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

The offeror represents that --

(a) ( ) It has, ( ) has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation;

(b) ( ) It has, ( ) has not, filed all required compliance reports; and

(c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

16.4% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Bell County, Fort Cavazos, Texas.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Mission and Installation Contracting Command - Fort Cavazos Installation Support Division, Construction Team ATTN: MSG Justin Mansfield, Contracting Officer 36000 Shoemaker Lane, Room 1300B Fort Cavazos, Texas 76544-5045

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Participants will meet on 9 August 2023 at 10:00 AM CDT for scheduled site visit/pre-bid conference at Building 32010, Fort Cavazos, TX:

Building 32010 Fort Cavazos, Texas 76544

(c) Fort Cavazos is a closed access installation. All visitors must obtain a visitors’ pass at the Main Gate Visitors’Center before being allowed on post. Consequently, participants should allow at least one hour prior to the site visit for obtaining this pass.

(d) All questions resulting from the site visit must be submitted electronically to the email below prior to 4:00 PM CDT on 11 August 2023.

SSG Marquez Siler marquez.m.siler.mil@army.mil

All contractors are highly encouraged to have a prime representative at the scheduled briefing and site visit. This will be the only site visit conducted.

(e) Remarks and explanations made by the government representative during the course of the site visit shall not change or qualify any of the terms or conditions of the solicitation. The solicitation can only be changed by a written amendment issued by a warranted contracting officer. All RFIs and clarifications considered as a result of inquiries from contractors at the site visit will be incorporated in one or more amendments to the solicitation, all of which will be provided to the contractor and or posted to Sam.gov in sufficient time to allow contractors to finalize bids prior to submission.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

NONE

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Department of Defense FAR Supplement (DFARS) (48 CFR Chapter 2) provision with…