Attachment__4_-_01_33_00_-_Submittals_page_5_and_6.pdf

Silt Pumping Plant Modernization Silt Project - Upper Colorado Region Solicitation No. R16PS00121

Submittals

01 33 00 - 5

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 28 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time.

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of 2 or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract, and.

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR 52.242-14, Suspension of Work, however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

C. Return of Submittals:

1. Action Submittals: One set of submittals required for action will be returned either approved, approved subject to identified changes, or not approved.

a. Revise and resubmit submittals not approved.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

2. Informational Submittals: Government will acknowledge Informational submittals.

a. Informational submittals will not be returned when they comply with specifications.

Silt Pumping Plant Modernization Silt Project - Upper Colorado Region Solicitation No. R16PS00121

Submittals

01 33 00 - 6

b. Informational submittals that do not comply with specifications may be returned for resubmittal or additional information may be requested.

1.07 TRANSMITTAL

A. Addresses for codes listed in Table 01 33 00A - List of Submittals:

1. Contracting Officer, Bureau of Reclamation, 125 South State Street, Room 8100, Salt Lake City, UT, 84138-1102.

2. Contracting Officer’s Representative, Bureau of Reclamation, Attention: Mark Wernke, Suite 221, 445 West Gunnison Avenue, Suite 221 Grand Junction, CO 81501.

3. Technical Service Center, Bureau of Reclamation, Attn: 86-68170, P.O. Box 25007, Denver CO 80225-0007; Express Mail: Sixth and Kipling, Building 67, Room 152.

B. Send original transmittal letter with appropriate number of sets to office listed in “Responsible Code” column in Table 01 33 00A - List of Submittals.

1. Responsible codes starting with “86-6” are located in Technical Service Center.

Send these submittals to TSC address shown above.

C. Send copy of transmittal letter with appropriate number of sets to offices that are not responsible code, but show “No. of sets to be sent to” in Table 01 33 00A - List of Submittals.

D. When “No. of sets to be sent to” is 0, send a copy of transmittal letter to that office.

E. Submittals required by specifications, but not listed in Table 01 33 00A - List of Submittals:

1. Submit in accordance with this section.

2. Submit to COR, unless otherwise specified.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used