Attachment_1_-_Specifications.pdf

Silt Pumping Plant Modernization Silt Project - Upper Colorado Region Solicitation No. R16PS00121

Table of Contents

00 01 10 - 1

SECTION C – DESCRIPTION / SPECIFICATIONS

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 14 10 Use of Site 01 14 12 Work Restrictions 01 32 20 Construction Program 01 33 00 Submittals 01 33 26 Electrical Drawings and Data 01 35 10 Safety Data Sheets 01 35 20 Safety and Health 01 35 22 First Aid 01 35 30 Contractor’s Onsite Safety Personnel 01 42 10 Reference Standards 01 46 00 Quality Procedures 01 51 00 Temporary Utilities 01 54 20 Use of Government Crane 01 55 00 Vehicular Access and Parking 01 55 20 Traffic Control 01 56 10 Protection of Existing Installations 01 56 20 Existing Fences 01 56 32 Temporary Safety Fence 01 57 20 Environmental Controls 01 57 30 Water Pollution Control 01 60 00 Product Requirements 01 74 00 Cleaning and Waste Management 01 78 30 Project Record Documents

DIVISION 02 - EXISTING CONDITIONS

02 42 00 Equipment Removal and Disposal 02 82 20 Removal and Disposal of Asbestos Containing Materials 02 83 20 Removal and Disposal of Coatings and Equipment with Coatings Containing

Heavy Metals

DIVISION 03 - CONCRETE

03 01 31 Concrete Removal 03 11 10 Concrete Forming 03 30 00 Cast-in-Place Concrete 03 48 00 Precast Concrete Structures 03 62 20 Nonshrink Grout

00 01 10 - 2

DIVISION 05 - METALS

05 50 00 Metal Fabrications

DIVISION 09 - FINISHES

09 96 20 Coatings

DIVISION 22 - PLUMBING

22 11 19 Automatic Vacuum Priming System

DIVISION 23 - HEATING, VENTILATING, AND AIR-CONDITIONING (HVAC)

23 00 00 Heating, Ventilating, and Air-Conditioning (HVAC) System 23 09 00 Instrumentation And Control For HVAC 23 37 00 Air Outlets 23 82 39 Electric Unit Heater

DIVISION 25 - INTEGRATED AUTOMATION

25 01 01 System Monitoring

DIVISION 26 - ELECTRICAL

26 05 02 Basic Electrical Materials and Methods 26 05 04 Removal of Existing Electrical Equipment and Cable 26 05 10 Conductors and Cables 26 05 13 Medium-Voltage Power Cable System 26 05 20 Grounding and Bonding 26 05 33 Electrical Conduit and Raceways 26 05 36 Cable Tray System 26 05 90 Wiring Checkout and Tests 26 09 10 Sump Water Level Detection Equipment 26 13 15 Outdoor Medium-Voltage Metal-Clad Switchgear 26 18 42 Medium-Voltage Motor Control Equipment 26 18 42 Medium-Voltage Motor Control Equipment 26 22 20 Distribution Transformer 26 24 30 Pushbutton Station 26 24 42 Distribution Panelboard 26 25 10 Metal Enclosed Bus 26 27 40 Wiring Devices 26 40 40 Refurbishment of Existing Motors

00 01 10 - 3

DIVISION 31 - EARTHWORK

31 03 33 Removal and Control of Water 31 23 02 Compacting Earth Materials 31 23 11 Earthwork for Structures 31 23 39 Disposal of Excavated Materials

DIVISION 33 - UTILITIES

33 09 10 Propeller Meter 33 12 73 Horizontal Centrifugal Pumping Units

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 21 94 Steel Piping 35 22 11 Hydraulically Operated Cylinder Actuator 35 22 14 Valves and Equipment 35 22 15 Hydraulic Power Unit

DIVISION 51 - INFORMATION AVAILABLE TO OFFERORS

51 00 00 Information Available to Offerors 51 00 10 Photographs 51 00 20 Analytic Test Results

DIVISION 52 - DRAWINGS

52 00 00 Drawings

END OF CONTENTS

00 01 10 - 4

This page intentionally left blank.

Summary of Work

01 11 00 - 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.01 LOCATION

A. Work is located approximately 1 mile east of Silt, Colorado in Garfield, County.

1.02 DEFINITIONS

A. When specifications use a word or term defined in Federal Acquisition Regulations (FAR), definition of the word or term shall be in accordance with FAR sections in effect at the time solicitation was issued.

B. When these specifications use the word “provide” in regards to a specified item, the intent and requirement is for the contractor to all also install the item, unless otherwise stated or it is a spare.

1.03 PRINCIPAL COMPONENTS OF WORK

A. Remove and replace:

1. 2,300 volt motor control center, and associated plant low voltage power distribution system.

2. Vent fan control panel, associated power and control wiring.

3. Existing power and control wiring for:

a. Vacuum priming system,

b. Hydraulic power unit,

c. Hydraulic operated discharge ball valves.

4. 5 kV power cables, and 600 volt control and instrumentation cables for pumping units 1 through 4.

B. Abandon in place:

1. Conductors for embedded conduits being abandoned. Plug conduit with grout with conductors in place. Removal of conductors from conduit should be avoided because this action could scrape insulation with asbestos from the wire.

C. Remove existing:

1. Surface mounted conduit with conductors inside conduit as shown. Avoid removing conductors from conduit because this action could scrape insulation with asbestos from the wire.

2. Remove, refurbish and reuse existing motors for Pumping Unit Nos. 1, 2, 3 and 4.

01 11 00 - 2

a. Send to motor maintenance facility for evaluation, overhaul and rehabilitation.

b. After overhaul and rehabilitation, deliver motors to pump supplier for installation on pump and motor base frames and factory testing.

D. Provide:

1. New exposed conduit systems for rerouted conduit systems.

2. New cable tray systems for routing of overhead cables.

3. Provide new conduits, cables and conductors for new and existing electrical installations.

4. Incoming power service to the plant from switchyard utilizing underground conduits containing 5 kV incoming power cable.

5. Outdoor metal clad switchgear to serve as main plant disconnect.

6. Metal enclosed bus for incoming power entering plant.

7. New receptacles and ball valve pushbutton stations.

8. Low sump intake float switch.

E. Remove and replace:

1. Pumping Unit Nos. 1, 2, 3 and 4.

2. Suction and discharge piping and valves for Pumping Unit Nos. 1, 2, 3 and 4.

3. Hydraulic Power Unit and piping.

4. Vacuum priming system and piping.

F. Provide propeller flow meter for 30-inch discharge pipeline.

G. Provide precast concrete oil/water separator in existing pumping plant drain line.

H. Minor Civil yard improvements including oil/water precast separator, concrete door pad, concrete switchgear foundation, buried conduit trench from existing switchyard to switchgear, I. Remove and replace 4-inch buried gate valve in drain line of discharge manifold.

J. Paint new and existing Pumping Unit discharge piping. Coating system of existing pipe contains hazardous materials that will be covered with modern coatings.

K. Provide monitoring system.

L. Provide structural modifications for electrical and mechanical work.

M. Dispose of equipment that contains hazardous materials.

01 11 00 - 3

N. Upgrades to existing venting and heating system.

1.04 SPECIFICATIONS REQUIREMENTS

A. Requirements in Division 1, General Requirements, apply to Divisions 2 through 52.

B. Imperative statements in these specifications are Contractor requirements, unless otherwise stated.

C. Where specifications are written in streamlined form, words “shall be” are included by inference where a colon (:) is used within sentence or phrase.

1.05 ACRONYMS

A. The following acronyms apply to specifications Divisions 1 through 52:

1. CO: Contracting Officer.

2. COR: Contracting Officer’s Representative.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

END OF SECTION

01 11 00 - 4

Use of Site 01 14 10 - 1

SECTION 01 14 10

USE OF SITE

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the price schedule for other items of work.

1.02 REFERENCE STANDARDS

A. Bureau of Reclamation (USBR)

1. Cleaning Manual Inspection and Cleaning Manual for Equipment and Vehicles to Prevent the Spread of Invasive Species (Technical memorandum No. 86-68220-07-05) 2012 Edition, available online at:

http://www.usbr.gov/mussels/prevention

1.03 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 14 10-1, Land Use and Landscape Rehabilitation Plan:

1. For each Contractor use site on Government land.

a. Show use location and extent of impact. Uses include but are not limited to the following:

1) Buildings and service areas including offices, shops, warehouses, storage areas, fuel and oil storage areas, and fabrication yards.

2) Parking areas, temporary roads, and haul routes.

3) Utilities including air, power, and water lines; fire hydrants; and compressor station.

4) First-aid and medical facilities.

5) Areas for processing, storing, and disposing of waste materials from construction operations.

6) Temporary fences.

b. Describe methods to preserve, protect, and repair, vegetation (such as trees, shrubs, and grass) and other landscape features on or adjacent to jobsite, which are not to be removed and which do not interfere with work

01 14 10 - 2 required under this contract. Include methods to mark work area limits, protect disturbed areas, and prevent erosion.

c. Describe methods to protect, and repair if damaged, existing improvements and utilities at or near jobsite.

d. Describe methods for removing temporary structures and facilities, cleanup, and rehabilitating site after completion of construction activities.

2. Submit revised drawings of changes in use of Government land made during design and erection stages or after use of Government land is in operation.

1.04 PROJECT CONDITIONS

A. Government land as shown on drawings may be used for required construction facilities.

B. When private land is used for construction facilities, or other construction purposes, make necessary arrangements associated with use of private land.

C. Location, construction, operation, maintenance, and removal of construction facilities on Government land will be subject to approval of COR.

D. Do not interfere with work of other contractors or the Government in vicinity, or with reservations made by the Government for use of such land.

E. Housing for construction personnel will not be permitted on Government land, except housing for guards or watchmen as may be approved by COR.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.01 CLEANING

A. Construction equipment:

1. Before bringing on site, clean construction equipment to remove dirt, vegetation, and other organic material to prevent introduction of noxious weeds, and invasive plant and animal species.

2. Contractor cleaning procedures shall result in equipment being cleaned as well or better than procedures described in Cleaning Manual.

3. COR will inspect construction equipment following procedures described in Cleaning Manual before allowing equipment onsite.

01 14 10 - 3

3.02 RESTORATION

A. Restore Contractor use areas to pre-construction condition.

01 14 10 - 4

Work Restrictions

01 14 12 - 1

SECTION 01 14 12

WORK RESTRICTIONS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for other items of work.

1.02 DEFINITIONS

A. 2016 Irrigation Season: April 11, 2016 to September 30, 2016.

B. 2017 Irrigation Season: April 10, 2017 to September 30, 2017.

C. 2018 Irrigation Season: April 9, 2018 to September 30, 2018.

1.03 WORK RESTRICTIONS AND LIMITATIONS

A. Schedule:

1. All work shall be completed and the pumping plant is fully operational by April 9, 2018, or earlier.

2. This project duration provides great flexibility and multiple scenarios for offerors’ construction schedules. The following are three possible scenarios that have been considered by the Government (other scenarios are possible):

a. Early completion:

1) Assuming shorter lead times for manufacturing the pumping units and refurbishing motors, all work is completed before April 10, 2017 and the 2017 Irrigation Season.

2) See work restrictions and limitations below.

b. Later completion, splitting work disciplines:

1) Manufacture pumping units is initiated as soon as possible.

2) Complete a majority of the electrical work, the civil work and minor mechanical work before April 10, 2017 and the 2017 Irrigation Season.

3) Refurbish motors and install pumping units after the 2017 Irrigation Season. Complete the remaining work before April 9, 2018, and the 2018 Irrigations Season.

4) See work restrictions and limitations below.

01 14 12 - 2

c. Later completion, majority of work concentrated after the 2017 Irrigation Season.

1) All work is completed before April 9, 2018 and the 2018 Irrigation Season.

2) See work restrictions and limitations below.

B. Work restrictions and limitations for the 2016 and 2017 Irrigation Seasons:

1. Do not interfere with District irrigation operations, as determined by COR.

2. Except for the following, all equipment necessary for the operation of the Silt Pumping Plant, whether it be new, refurbished or existing, shall be operational during the irrigation seasons.

a. Individual pumps and motors shall not be removed without a letter of commitment from the company manufacturing the pump or refurbishing the motor. The commitment letter should state when the work will begin and when the work will be completed.

b. Pump Motor No. 2 may be de-energized and removed early for refurbishment after July 31.

1) Do not disturb operation of pumping units 1, 3 or 4.

c. Pump Motor No. 4 may be de-energized and removed early for refurbishment after August 31.

1) Do not disturb operation of pumping units 1 or 3.

d. Early removal of Pump Motor Nos. 2 and 4 shall occur:

1) In presence of District staff.

2) District staff availability: Wednesdays, Thursdays and Fridays during irrigation season.

3. Due to a contract for power and water availability, testing and commissioning of new pumps units shall not occur sooner than 30 days before start of the irrigation season.

C. Work restrictions and limitations for the 2018 Irrigation Season:

1. Do not interfere with District irrigation operations.

2. Due to a contract for power and water availability, testing and commissioning of new pumps units shall not occur sooner than 30 days before start of the irrigation season.

1.04 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 14 12-1, Letters of commitment

01 14 12 - 3

1. At least 7 days before removal of each pumping unit and each pump motor, submit for approval. Similar equipment removed and worked on simultaneously can be on same letter of commitment.

2. Letters shall be the company manufacturing the pumping units or refurbishing motors

3. Letter shall state the date the work will begin, the duration, anticipated date for testing and the date the equipment will be shipped.

4. Equipment shall not be removed until the CO has received and approved the Letter of Commitment.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

01 14 12 - 4

Construction Program

01 32 20 - 1

SECTION 01 32 20

CONSTRUCTION PROGRAM

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Developing Baseline Schedule: Include in lump sum price offered in the Price Schedule for Mobilization and Preparatory Work.

2. Updating and Using Construction Program: Include as an element of Contractor’s overhead.

1.02 DEFINITIONS

A. Schedule: Critical Path Method (CPM) of planning and scheduling a construction project where activities are arranged based on activity relationships and network calculations determine when activities can be performed and critical path of the project.

B. Project Calendar(s): Cross reference of numerical work days with calendar days. Project calendar serves as the basis for the day/date conversion and assigns work days and non-workdays.

1.03 REFERENCE STANDARDS

A. Associated General Contractors of America (AGC)

1. AGC Manual-04 Construction Planning and Scheduling Manual

1.04 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

1. Furnish database files in format compatible with Microsoft Project, release 2010 or newer.

2. Furnish schedule and analysis data on CD or DVD disc.

3. Upon request, provide information and data used to develop and maintain the Construction Program to CO.

B. RSN 01 32 20-1, Baseline Schedule:

1. Include:

a. Construction Program/Schedule database.

b. Definition of project calendars.

01 32 20 - 2

c. Gantt chart (Bar chart) for project on 11 by 17-inch print(s) and in portable document format (.pdf).

d. Activity report including logic constraints consisting of predecessors, successors, and constraint dates.

C. RSN 01 32 20-2, Updated Schedule:

1. This submittal is required for a proper invoice for progress payments in accordance with the clauses at FAR 52.232-27 - Prompt Payment for Construction Contracts and WBR 1452.232-82 - Other Invoice Requirements.

2. Include:

a. Construction Program database with updated activity and milestone data.

b. Definition of project calendars when revised from baseline calendars.

c. Gantt chart for project.

d. Narrative report specifically stating status of project.

1) If negative float exists, cite specific actions and conditions which caused the "behind schedule" condition and provide proposed course of action to complete the project within the specified delivery time.

2) List of Contractor-initiated changes to the current schedule stating the reason for the action taken and unresolved issues relating to the Construction Program. Government reserves the right to reject Contractor-initiated changes to the current schedule which negatively impact any Government action which was initiated on the basis of the current schedule.

1.05 SCHEDULE

A. Develop, maintain, and use approved Construction Program to plan, monitor, report, and evaluate accomplishment of work.

B. Prepare construction schedules using Critical Path Method outlined in AGC Manual.

C. Failure to include any element of the work will not release Contractor from completing required work under the contract.

D. Construction Program:

1. Prepare detailed activity network for accomplishing required work organized by work breakdown structure.

2. Prepare schedule based on required sequence and interdependence of activities.

3. Include work of subcontractors, Government interfaces, and contract milestones.

4. Include contract title, contract number, and Contractor's name on each sheet.

01 32 20 - 3

5. Adjust Construction Program/schedule for seasonal weather conditions.

6. Define activities to a level of detail resulting in their durations being no greater than 20 workdays unless otherwise accepted by CO.

a. Durations for administrative activities (e.g., submittals and reviews, fabrication, manufacturing), or other specific activities identified in the contract will not be subject to the workday limitation.

7. Use durations in units of whole workdays.

8. Include activities for Government reviews and approvals of submittals that are critical to the project completion data.

9. Update schedule with changes directed by contract modifications or approved changes to sequencing.

E. Baseline Schedule:

1. Represents Contractor’s as-planned approach to accomplishing the work.

2. Include planned start and completion dates for features of work.

F. Updated Schedule:

1. Enter actual progress.

2. Assign a unique project file name for each schedule update.

G. Contract Change or Delay:

1. Submit a time impact evaluation within 14 days of contract change or delay, showing effects of change order or delay on the progress schedule.

2. Time extensions for performance will be considered only to the extent that Contractor’s current scheduled milestone dates exceed the contract milestone dates.

H. Float is not for the exclusive use by or benefit of either Government or Contractor.

1.06 UPDATED SCHEDULE:

A. Meet monthly with COR at Government’s project office or at a location approved by the COR, to review progress made to end date of progress payment period. Establish dates that activities were started and completed and remaining duration for each activity started but not completed during the period.

1. Discuss and mutually agree upon changes to the schedule.

2. Out-of-sequence activities are not allowed. Revise logic to reflect change in work plan.

3. Finalize updated Construction Program database with mutually agreed upon changes.

01 32 20 - 4

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Submittals

01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the price schedule for other items of work.

1.02 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittal Types, as listed in Table 01 33 00A - List of Submittals:

1. A - Action:

a. Government will respond as to adequacy of submittal.

b. Action submittals are considered to be “shop drawings” within terms of clause at FAR 52.236-21, Specifications and Drawings for Construction.

2. I - Informational:

a. Government will acknowledge receipt of Informational submittals.

b. Government may reject an Informational submittal when submittal does not comply with contract. Correct mistakes or deficiencies in rejected Informational submittals and resubmit.

c. Informational submittals are considered to be “shop drawings” within terms of clause at FAR 52.236-21, Specifications and Drawings for Construction, except that approval by Government is not required.

1.03 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-12 Decimal Inch Drawing Sheet Size and Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-14 United States National CAD Standards, Version 6

01 33 00 - 2

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included elsewhere take precedence.

B. General:

1. Prepare in English.

2. Label with contract number and title, and RSN.

3. Measurement units: US Customary Units.

C. Drawings:

1. Minimum Identification in Title Block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3- by 3-inch space next to title block for review stamps.

3. Print Size: D size (22 inches by 34 inches).

4. Draw to scale using computer drafting or drafting equipment, unless otherwise specified.

a. Computer drafted drawings:

1) In accordance with NIBS NCS.

2) Electronic file format: Compatible with AutoCAD, Version 2007 or later.

3) Compile using “eTransmit” utility in AutoCAD.

b. Drawing prepared with drafting equipment, when allowed: Lettering shall be neat.

5. Drawings Designated as “Government Format” in Specifications:

a. Computer drafted.

b. Government will provide electronic AutoCAD format template.

c. Title block and sheet format:

1) As shown on standard drawing 40-D-7102.

2) Government will supply template.

3) Government will supply specific title block information to be used.

6. Final Drawings:

a. Computer drafted.

b. Government will supply electronic AutoCAD format template.

01 33 00 - 3

c. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

7. Electronic Files: On CD or DVD discs.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets.

a. Identify manufacturer's name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a registered professional: Signed and sealed by registered professional.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

F. Manuals:

1. Copies:

a. Printed copies: Bound and indexed.

b. Electronic copies: Adobe pdf on CD or DVD discs.

1) Bookmark longer files to assist in navigating file.

2. Contents:

a. Parts identification lists, lists of special tools, and accessories.

b. Schematics and wiring diagrams.

c. Detailed instructions for installing, operating, lubricating, and maintaining equipment.

d. As-built drawings, photographs, and test records or reports if required by the specifications.

G. Photographs:

1. Prints: Professional quality 8-inch by 10-inch color for each listed view.

a. Identify with adhesive labels on back.

1) Include contract number, name of equipment and view title.

2) Do not type directly on back of photograph.

01 33 00 - 4

2. Include negatives, or digital files on CD or DVD in .jpeg or similar format.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A - List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit number of sets specified in “No. of sets to be sent to:” columns in Table 01 33 00A - List of Submittals. A complete set includes listed items for RSNs with multiple parts.

1. Electronic (Elect) submittals:

a. In Portable Document Format (PDF).

b. Include RSN transmittal letter.

c. Do not include Personally Identifiable Information (PII) in electronic submittals.

2. Submit electronic submittals via email or CD/DVD based on size:

a. Government can receive e-mails up to 25MB. However, e-mails over 10MB should be considered extra-large. E-mailing of electronic submittals exceeding 10MB should only occur after transmittal of extra-large size e-mail has been verified.

b. Include electronic submittals that are too large to e-mail with paper copy of submittal. These electronic submittals shall be on CD or DVD.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 7 days after receiving comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

01 33 00 - 5

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 28 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time.

a. Rime extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of 2 or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract, and.

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR 52.242-14, Suspension of Work, however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

C. Return of Submittals:

1. Action Submittals: One set of submittals required for action will be returned either approved, approved subject to identified changes, or not approved.

a. Revise and resubmit submittals not approved.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been approved.

2. Informational Submittals: Government will acknowledge Informational submittals.

a. Informational submittals will not be returned when they comply with specifications.

01 33 00 - 6

b. Informational submittals that do not comply with specifications may be returned for resubmittal or additional information may be requested.

1.07 TRANSMITTAL

A. Addresses for codes listed in Table 01 33 00A - List of Submittals:

1. Contracting Officer, Bureau of Reclamation, 125 South State Street, Room 8100, Salt Lake City, UT, 84138-1102.

2. Contracting Officer’s Representative, Bureau of Reclamation, Attention: Mark Wernke, Suite 221, 445 West Gunnison Avenue, Suite 221 Grand Junction, CO 81501.

3. Technical Service Center, Bureau of Reclamation, Attn: 86-68170, P.O. Box 25007, Denver CO 80225-0007; Express Mail: Sixth and Kipling, Building 67, Room 152.

B. Send original transmittal letter with appropriate number of sets to office listed in “Responsible Code” column in Table 01 33 00A - List of Submittals.

1. Responsible codes starting with “86-6” are located in Technical Service Center.

Send these submittals to TSC address shown above.

C. Send copy of transmittal letter with appropriate number of sets to offices that are not responsible code, but show “No. of sets to be sent to” in Table 01 33 00A - List of Submittals.

D. When “No. of sets to be sent to” is 0, send a copy of transmittal letter to that office.

E. Submittals required by specifications, but not listed in Table 01 33 00A - List of Submittals:

1. Submit in accordance with this section.

2. Submit to COR, unless otherwise specified.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

01 33 00 - 7

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

I-1 Bonds 52.228-15

Performance and Payment Bonds

Within 10 calendar days after award

A CO 1

paper

0 0

I-2 Insurance-work on a Government Installation 1452.228-70

1) Written certification that the required insurance has been obtained

2) Current certification of insurance for each subcontractor

Before commencing onsite work

A

CO 1

paper

I-3 Liability Insurance 1452.228-70

Acceptable Certificate of Liability Insurance

Prior to commencement of work under the contract

A CO 1

paper

0 0

I-4 Equal Opportunity 52.222-26

Information required by Executive Order

112246 (SF-100)

Within 30 days following award

A CO 1

paper

0 0

I-5 Release of Claims 1452.204-70

Release of Claims (DI-137) against the Government

After completion of the work and prior to final payment

A CO 1

paper

0 0

I-6 Labor Standards Data 52.222-11

1) List of subcontractors

2) Statement and acknowledgement Form (SF-1413) for each subcontract

Within 14 days after award of contract

COR

paper elect elect

I-7 Payrolls 52.222-08

Copies of all payrolls

Statement of Compliance

Weekly for each week of contract performance

Weekly for each week of contract performance paper

01 33 00 - 8

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

I-8 Safety and Health (WBR 1452.223-81)

Safety Program Submitted and accepted before commencing onsite work. See section 3 of RSHS

A COR 1

paper paper elect

I-9 Safety and Health (WBR 1452.223-81)

Monthly Accident Summary Report

First day of each month.

See paragraph 3.8 of

RSHS.

I CO 1

paper paper elect

01 14 10-1 Use of Site Land Use and Landscape Rehabilitation Plan

At least 28 days before use of Government land

A COR 1

paper paper elect

01 14 12-1 Work Restrictions

Letters of Commitment

At least 7 days before removing a pumping unit or pump motor

A COR 1

paper paper elect paper

01 32 20-1 Construction Program

Baseline Schedule Within 14 days after receipt of Notice to Proceed

A COR 1

paper paper elect paper

01 32 20-2 Construction Program

Updated Schedule With monthly requests for progress payments.

A COR 1

paper paper elect paper

01 35 10-1 Safety Data Sheets

Complete LHM and

SDS

At least 14 days before jobsite delivery of hazardous material

I COR 1

paper paper elect

01 35 10-2 Safety Data Sheets

Updated LHM and

SDS

At least 14 days before jobsite delivery of hazardous material not previously listed

I COR 1

paper paper elect

01 35 22-1 First-Aid Medical Facilities Plan

Submitted and approved before start of operations

A COR 1

paper paper

01 33 00 - 9

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

01 54 20-1 Use of Government Crane

Qualifications At least 14 days use of crane

A COR 1

paper paper elect

01 55 20-1 Traffic Control Traffic Control Plan At least 14 days before affecting public traffic.

A COR 1

paper paper elect

01 55 20-2 Traffic Control Permits At least 14 days before affecting public traffic.

A COR 1

paper paper elect

01 57 30-1 Water Pollution Control

Water Management Plan

At least 14 days before commencing construction activities

A COR 1

paper paper elect

01 57 30-2 Water Pollution Control

Spill Prevention Control and Countermeasure (SPCC) Plan

At least 14 days before delivery or storage of oil

A COR 1

paper paper elect

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

Within 7 days of waste disposal

I COR 1

paper paper elect

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of hazardous waste disposal

I COR 1

paper paper elect

01 74 00-3 Cleaning and Waste Management

Environmental Consultant Resume

At least 35 days before beginning environmental assessment

I COR 1

paper paper elect

01 74 00-4 Cleaning and Waste Management

Environmental Site Assessment

Within 14 days of completion of work

I COR 1

paper paper

01 33 00 - 10

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

01 78 30-1 Project Record Documents

Final As-built Drawings

Within 14 days of completion of work

I COR 1

paper paper elect paper

01 78 30-2 Project Record Documents

Extra Materials Within 14 days of completion of work

I COR 1

paper paper elect paper

01 78 30-3 Project Record Documents

Warranties Within 14 days of completion of work

I COR 1

paper paper elect paper

02 42 00-1 Equipment Removal and Disposal

Removal Plan At least 14 days before commencing construction activities

A COR 1

paper paper elect paper

02 82 20-1 Removal and Disposal of Asbestos Containing Materials

Contractor and Asbestos Abatement Subcontractors History

At least 30 days before asbestos removal starts

I 86-68220 1 paper paper elect paper

02 82 20-2 Removal and Disposal of Asbestos Containing Materials

Resumes, Certificates, and Qualifications

At least 30 days before asbestos removal starts

A 86-68220 1 paper paper elect paper

02 82 20-3 Removal and Disposal of Asbestos Containing Materials

Asbestos Hazard Abatement Plan

At least 30 days before asbestos removal starts

A 86-68220 1 paper paper elect paper

02 82 20-4 Removal and Disposal of Asbestos Containing Materials

Working Level Test Results

Within 2 days after tests completed

I 86-68220 1 paper paper elect paper

02 82 20-5 Removal and Disposal of Asbestos Containing Materials

Certificate Of Disposal

Within 14 days after disposal

I 86-68220 1 paper paper elect

01 33 00 - 11

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

02 83 20-1 Removal and Disposal of Coatings and Equipment With Coatings Containing Heavy Metals

Resumes At least 30 days before removal starts

A 86-68220 1 paper paper elect paper

02 83 20-2 Removal and Disposal of Coatings and Equipment With Coatings Containing Heavy Metals

Written Compliance Program for Worker Protection

At least 30 days before removal starts

A 86-68220 1 paper paper elect paper

02 83 20-3 Removal and Disposal of Coatings and Equipment With Coatings Containing Heavy Metals

Plans At least 30 days before removal starts

A 86-68220 1 paper paper elect paper

02 83 20-4 Removal and Disposal of Coatings and Equipment With Coatings Containing Heavy Metals

Certificate of Disposal or Recycling Documentation

Within 14 days after disposal

I 86-68220 1 paper paper elect paper

03 01 31-1 Concrete Removal

Concrete Removal Plan

At least 28 days before beginning removal work

A COR 1

paper paper elect

03 30 00-1 Cast-In-Place Concrete

Mix Design At least 28 days before beginning removal work

A COR 1

paper paper elect

03 48 00-1 Precast Concrete Structures

Product Approval Drawings and Data

At least 35 days before beginning removal work

A COR 1

paper paper

01 33 00 - 12

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

03 48 00-2 Precast Concrete Structures

Handling and Storage Requirements

At least 35 days before beginning removal work

A COR 1

paper paper elect

03 62 20-1 Nonshrink Grout

Packaged Nonshrink Grout Data

At least 28 days before beginning removal work

A COR 1

paper paper elect

03 62 20-2 Nonshrink Grout

Grouting Plan At least 28 days before beginning removal work

A COR 1

paper paper elect

09 96 20-1 Coatings Approval Data At least 28 days prior to procurement

A 86-68180 1 paper paper elect paper

09 96 20-2 Coatings Final Approval Data At least 28 days prior to procurement

A 86-68180 1 paper paper elect paper

09 96 20-3 Coatings Certifications At least 28 days prior to procurement

A 86-68180 1 paper paper elect paper

09 96 20-4 Coatings Documentation At least 28 days prior to procurement

A 86-68180 1 paper paper elect paper

09 96 20-5 Coatings Contractor Quality Testing Data for “Shop or Field Applied” Coatings

Within 14 days after test A 86-68180 1 paper paper elect paper

22 11 19-1 Automatic Vacuum Priming System

Commercial Product Data

At least 42 days before fabrication or procurement

A 86-68420 1 paper paper elect

01 33 00 - 13

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

22 11 19-2 Automatic Vacuum Priming System

Hydraulic Calculations

At least 42 days before installation, fabrication, or procurement

A 86-68420 1 paper paper elect paper

22 11 19-3 Automatic Vacuum Priming System

Field Installation Procedure

At least 42 days before installation, fabrication, or procurement

A 86-68420 1 paper paper elect paper

22 11 19-4 Automatic Vacuum Priming System

Documentation of Installation and Operation

Within 14 days after installation

I 86-68420 1 paper paper elect paper

22 11 19-5 Automatic Vacuum Priming System

Final Drawings and Data

Within 14 days after installation

I 86-68420 1 paper paper elect paper

23 09 00-1 Instrumentatio n and Control for HVAC

Approval Data At least 14 days before procurement

A COR 1

paper paper elect

23 09 00-2 Instrumentatio n and Control for HVAC

Final Data Within 14 days of completion of work

I COR 1

paper paper elect

23 37 00-1 Air Outlets Approval Data At least 14 days before procurement

A COR 1

paper paper elect

23 37 00-2 Air Outlets Final Data Within 14 days of completion of work

I COR 1

paper paper elect

23 82 39-1 Electric Unit Heater

Approval Data At least 14 days before procurement

A COR 1

paper paper

01 33 00 - 14

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

23 82 39-2 Electric Unit Heater

Final Data Within 14 days of completion of work

I COR 1

paper paper elect

25 01 01-1 System Monitoring

Approval Drawings At least 42 days before procurement

A 86-68450 1 paper paper elect paper

25 01 01-2 System Monitoring

Approval Data At least 42 days before procurement

A 86-68450 1 paper paper elect paper

25 01 01-3 System Monitoring

Final Drawings and Data

Within 35 days after System Performance Availability Test.

I 86-68450 1 paper paper elect paper

25 01 01-4 System Monitoring

Operations and Maintenance Instruction Manuals

Within 35 days after System Performance Availability Test

I 86-68450 1 paper paper elect paper

25 01 01-5 System Monitoring

FAT Test Procedure and FAT Start Date

At least 28 days before

FAT

A 86-68450 1 paper paper elect paper

25 01 01-6 System Monitoring

FAT Test Report Within 14 days of completing tests

I 86-68450 1 paper paper elect paper

25 01 01-7 System Monitoring

Approval Data At least 28 days before

FOC

A 86-68450 1 paper paper elect paper

25 01 01-8 System Monitoring

FOC Test Report Within 14 days of completing tests

I 86-68450 1 paper paper elect

01 33 00 - 15

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

25 01 01-9 System Monitoring

Approval Data At least 28 days before

SPAT

A 86-68450 1 paper paper elect paper

25 01 01-

System Monitoring

SPAT Test Report Within 14 days of completing tests.

I 86-68450 1 paper paper elect paper

25 01 01-

System Monitoring

Training Materials and Training Start Date

At least 28 days before training.

A 86-68450 1 paper paper elect

26 05 04-1 Removal of Existing Electrical Equipment and Cable

Electrical Equipment Removal Request

At least 56 days before removal of existing electrical equipment

A COR 1

paper paper elect

26 05 10-1 Conductors and Cables

Approval Data and Installation Plan

At least 56 days before procurement

A COR 1

paper paper elect

26 05 10-2 Conductors and Cables

Field Test Reports Within 14 days after tests are completed

A COR 1

paper paper elect

26 05 10-3 Conductors and Cables

Final Drawings Within 28 days after installation

A COR 1

paper paper elect

26 05 13-1 Medium Voltage Power Cable System

Approval Drawings and Data

At least 56 days before procurement

A COR 1

paper paper elect

26 05 13-2 Medium Voltage Power Cable

New 5 kV Cable Field Test Plan

At least 56 days before procurement

I COR 1

paper paper

01 33 00 - 16

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

26 05 13-3 Medium Voltage Power Cable System

Factory Production Test Certifications

Within 14 days after tests are completed

I COR 1

paper paper elect

26 05 13-4 Medium Voltage Power Cable System

Field Test Reports Within 30 days after tests are completed

A COR 1

paper paper elect

26 05 20-1 Grounding and Bonding

Test Reports Within 30 days after tests are completed

A COR 1

paper paper elect

26 05 33-1 Electrical Conduit and Raceways

Approval Drawings and Data

At least 56 days before procurement

A COR 1

paper paper elect

26 05 33-2 Electrical Conduit and Raceways

Final Drawings Within 28 days after installation of conduit

A COR 1

paper paper elect

26 05 36-1 Cable Tray System

Manufacturer’s Approval Data and Design Data

At least 42 days before procurement

A COR 1

paper paper elect

26 05 36-2 Cable Tray System

Approval Layout Drawings and Bill of Materials (Manufacturer’s Format)

At least 42 days before procurement

A COR 1

paper paper elect

26 05 90-1 Wiring Checkout and Tests

Test Notification and Plan

Within at least 14 days prior to checkout and test

I COR 1

paper paper elect

26 05 90-2 Wiring Checkout and Tests

Test Reports Within 28 days after tests are completed

A COR 1

paper paper

01 33 00 - 17

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

26 09 10-1 Sump Water Level Detection Equipment

Approval Data At least 56 days before fabrication or procurement

A COR 1

paper paper elect

26 09 10-2 Sump Water Level Detection Equipment

Shop Drawings and Manufacturer’s Data

At least 56 days before fabrication or procurement

A COR 1

paper paper elect

26 13 15-1 Outdoor Medium- Voltage Metal- Clad Switchgear

Approval Drawings and Data

At least 56 days before fabrication or procurement

A COR 1

paper paper elect

26 13 15-2 Outdoor Medium- Voltage Metal- Clad Switchgear

Factory Test Notification

At least 14 days before testing

I COR 1

paper paper elect

26 13 15-3 Outdoor Medium- Voltage Metal- Clad Switchgear

Factory Test Reports Within 14 days after tests are completed

I COR 1

paper paper elect

26 13 15-4 Outdoor Medium- Voltage Metal- Clad Switchgear

Field Test Reports Within 14 days after tests are completed

I COR 1

paper paper elect

26 13 15-5 Outdoor Medium- Voltage Metal- Clad Switchgear

Final Documentation Within 14 days after installation

A COR 1

paper paper elect

26 18 42-1 Medium- Voltage Motor Control Equipment

Approval Data At least 56 days before procurement

A COR 1

paper paper elect

26 18 42-2 Medium- Voltage Motor Control Equipment

Approval Layouts At least 56 days before procurement

I COR 1

paper paper

01 33 00 - 18

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

26 18 42-3 Medium- Voltage Motor Control Equipment

Schematic Diagrams At least 56 days before procurement

I COR 1

paper paper elect

26 18 42-4 Medium- Voltage Motor Control Equipment

Time-Current Characteristic Curves

At least 30 days before procurement

A COR 1

paper paper elect

26 18 42-5 Medium- Voltage Motor Control Equipment

Sample Wiring and Interconnection Diagrams

At least 30 days before procurement

I COR 1

paper paper elect

26 18 42-6 Medium- Voltage Motor Control Equipment

Schematic, Wiring, and Interconnection Diagram Check Prints

At least 14 days before equipment is shipped

A COR 1

paper paper elect

26 18 42-7 Medium- Voltage Motor Control Equipment

Factory Test Report Within 14 days after tests are completed

A COR 1

paper paper elect

26 18 42-8 Medium- Voltage Motor Control Equipment

Operation and Maintenance Instruction Book

Within 30 days after installation

A COR 1

paper paper elect

26 22 20-1 Distribution Transformer

Approval Data At least 56 days before procurement

A COR 1

paper paper elect

26 22 20-2 Distribution Transformer

Approval Layout At least 56 days before procurement

A COR 1

paper paper elect

26 22 20-3 Distribution Transformer

Factory Test Reports Within 14 days after tests are completed

A COR 1

paper paper

01 33 00 - 19

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

26 22 20-4 Distribution Transformer

Operations and Maintenance Instruction Book

Within 30 days after installation

A COR 1

paper paper elect

26 24 30-1 Pushbutton Station

Approval Drawings and Data

At least 56 days before procurement

A COR 1

paper paper elect

26 24 30-2 Pushbutton Station

Factory Test Report Within 14 days after tests are completed

A COR 1

paper paper elect

26 24 30-3 Pushbutton Station

Final Drawings Within 30 days after installation

A COR 1

paper paper elect

26 24 42-1 Distribution Panelboard

Approval Drawings and Data

At least 56 days before procurement

A COR 1

paper paper elect

26 24 42-2 Distribution Panelboard

Test Reports Within 30 days after installation

A COR 1

paper paper elect

26 25 10-1 Metal Enclosed Bus

Approval Drawings and Data

At least 56 days before procurement

A COR 1

paper paper elect

26 25 10-2 Metal Enclosed Bus

Factory Test Report Within 14 days after tests are completed

A COR 1

paper paper elect

26 25 10-3 Metal Enclosed Bus

Field Test Reports Within 14 days after tests are completed

A COR 1

paper paper

01 33 00 - 20

Table 01 33 00A. - List of Submittals

* Submittal Types: A - Action, I - Information ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative , and TSC indicates Technical Service Center.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Type

Respon-sible code

No. of sets to be sent to: **

CO COR TSC

26 27 40-1 Wiring Devices

Approval Data At least 56 days before procurement

A COR 1

paper paper elect

26 40 40-1 Refurbishment of Existing Motors

Removal Plan At least 56 days before removal of motors

I 86-68430 1 paper paper elect paper

26 40 40-2 Refurbishment of Existing Motors

Motor Disassembly Inspection Report

Within 14 days after motor disassembly

A 86-68430 1 paper paper elect paper

26 40 40-3 Refurbishment of Existing Motors

Refurbishment Plan At least 30 days before equipment is refurbished

I 86-68430 1 paper paper elect paper

26 40 40-4 Refurbishment of Existing Motors

Motor Approval Data and Drawings

Within 14 days after tests are completed

A 86-68430 1 paper paper elect paper

26 40 40-5…