AMD 02 22R1322.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04 EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

RFP N62742-22-R-1322, PAF 198127 TACMOR UTILITIES AND INFRASTRUCTURE SUPPORT

Amendment No. 0002 is continued on page 2.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 7

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA 15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer) (Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X N62742-22-R-1322

X 9B. DATED (SEE ITEM 11)

05 JAN 2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

07 MAR 2022

CODE

NAVFAC PACIFIC

CONSTRUCTION CONTRACTS BR (CON33)

4256 RADFORD DR., BLDG 62

HONOLULU, HI 96818-3296

N62742 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

FACILITY CODECODE

EMAIL:TEL:

x

N62742-22-R-1322 Amendment No. 0002

SF 30 BLOCK 14 CONTINUATION PAGE

This amendment is issued to revise the following:

1. SF 1442, REV 1, dated 08 FEB 2022 is deleted in its entirety and replaced with the attached SF 1442, REV 2 dated 07 March 2022.

2. Document 00 21 16, Instructions to Proposers, Paragraph 1.1. Number of Copies/Time of Receipt is revised as follows:

a. Subparagraph a., delete 21 March 2022, 2:00 p.m. HST and replace it with 05 April 2022, 2:00 p.m. HST.

b. Subparagraph b., delete 21 March 2022, 2:00 p.m. HST and replace it with 05 April 2022, 2:00 p.m. HST.

3. Document 00 70 00, Paragraph 1.82 FAR 236-4, PHYSICAL DATE (APR 1984), last paragraph, “MEC probability has been….Public Works.” is deleted in its entirety and not replaced.

4. Document 00 73 00, Paragraph 1.4 Utilities for Construction and Testing (JUN 1994) and Paragraph 1.5 Compact of Free Association (COFA) and Subsidiary Agreement of the COFA (SOFA) Between the United States and the Government of Palau are deleted in their entirety and replaced with the following:

1.4 UTILITIES FOR CONSTRUCTION AND TESTING (JUN 1994)

No utilities are available on the Rx site. The Contractor is responsible for providing all temporary utilities required for construction. Materials may be new or used, must be adequate for the required usage, not create unsafe conditions, and shall not violate applicable codes and standards.

For the Tx site, electricity connections are close by, however, water and sewer services are not available. The Contractor is responsible for providing all temporary utilities required for construction. The cost for these utilities shall be borne by the Contractor. If obtained from the local utility companies, the expense shall be paid for at the current utility rate delivered to the job site. The Contractor shall provide and maintain all temporary utility connections and distribution lines, and all meters required to measure the amount of each utility used. Materials may be new or used, must be adequate for the required usage, not create unsafe conditions, and shall not violate applicable codes and standards.

1.5 COMPACT OF FREE ASSOCIATION (COFA) AND SUBSIDIARY AGREEMENT OF THE COFA (SOFA)

BETWEEN THE UNITED STATES AND THE GOVERNMENT OF PALAU

It is the Offeror’s/Contractor’s responsibility to ensure that all requirements of the COFA and SOFA are adhered to.

The following website provides a listing of the major U.S. Palau international agreements:

The SOFA is available at: https://www.doi.gov/sites/doi.gov/files/uploads/ROP-COFA-Subsidiary-Agreements.pdf

The COFA can be found at: https://www.govinfo.gov/content/pkg/STATUTE-100/pdf/STATUTE-100-Pg3672.pdf.

5. DOCUMENT 00 01 15, LIST OF DRAWINGS, paragraph 1.3 SUPPLEMENTARY DRAWINGS is revised to delete the 6th paragraph in its entirety and replace it with:

Anchor hardware and templates to be supplied by others. Coordinate procuring (anchor hardware and templates) and placement of anchors with Contracting Officer.

6. SECTION 01 11 00 SUMMARY OF WORK is revised as follows:

a. Paragraph 1.2.1 Project Description is deleted in its entirety and replaced with the following:

The work includes the construction of one approximately 50.54 acre Transmit Antenna site on Babeldaob Island and one approximately 96.22 acre Receive Antenna site on Angaur Island. Each site will require demolition of existing facilities, clearing and grubbing, excavation and embankment, temporary and permanent BMPs, drainage basins, plumbing, rainwater water catchment system, septic tanks, leach fields, site access roads, site and antenna array area fencing, foundations for antennas, portable building and support equipment (e.g. generators, fuel tanks, amplifiers, satellite dishes, and connex boxes/enclosures), and electrical conduits with conductors for power, empty conduit system for telecommunications and/security and incidental related work.

For Tx Site: Transport and dispose of excavated material that is not needed for the project to an approved offsite disposal site; construct MSE walls; provide hydroseed on antenna earth mat subgrade for erosion control purposes; furnish and stockpile onsite 1,530 cubic meters of topsoil for future placement by others;

topsoil stockpile location and BMPs to be coordinated/approved by the Contracting Officer; and provide hydroseed stockpile for the earth mat for future placement by others.

b. Paragraph 1.3 Work Covered by the UXO/MEC Contract (Rx Site Only) is deleted in its entirety and replaced with the following:

1.3 Work Covered by the MEC/Environmental Contract (Rx Site Only)

The MEC removal/Environmental Contractor will be responsible for removal and offsite disposal of MEC;

drums containing bitumen and other substances; onsite treatment and placement of non-MEC metals in deposit cells; and containment of lead contaminated soil in lead soil deposit cells. MEC removal/Environmental work will be performed under a separate contract. See Section 02 612 13 EXCAVATION AND HANDLING OF

CONTAMINATED MATERIALS.

The Contractor will not be allowed to access the Rx project site during the MEC removal/Environmental work without prior written approval of the Contracting Officer and the MEC removal/Environmental Contractor.

Upon completion of the MEC removal/Environmental work and/or acceptance of the Rx project site by the Contracting Officer, a clean project site will be made available to the Construction Contractor. Turnover of the Rx site to the Construction Contractor is anticipated to be no later than June 30, 2023.

c. Paragraph 1.7 Salvage Material and Equipment is deleted in its entirety and replaced with the following:

Items designated by the Contracting Officer to be salvaged remain the property of the Government. Segregate, itemize, and stockpile the salvaged property at the Government designated storage area within project site.

Provide a salvage plan, listing material and equipment to be salvaged and their storage location. Maintain property control records for material or equipment designated as salvage. Use a system of property control that is approved by the Contracting Officer. Store and protect salvaged materials and equipment until disposition by the Contracting Officer. Contractor will be required to salvage and stockpile timber and compost; items that may have historic or cultural value.

7. SECTION 01 14 00 WORK RESTRICTION, paragraph 1.3, SPECIAL SCHEDULING REQUIREMENTS, subparagraph f., is deleted in its entirety and replaced with the following:

Contractor to coordinate the interruption of utility service; removal and relocation of the existing utility poles and overhead electrical system at the Tx Site with the Palau Public Utilities Corporation (PPUC). Contractor is not responsible for PPUC costs to remove and relocate existing utility poles and overhead electrical system.

8. SECTION 01 57 19 – TEMPORARY ENVIRONMENTAL CONTROLS is deleted in its entirety and replaced with the attached SECTION 01 57 19 - TEMPORARY ENVIRONMENTAL CONTROLS. Revisions are shown in bold face type.

9. SECTION 01 57 19 – TEMPORARY ENVIRONMENTAL CONTROLS is revised as follows:

Insert the attached other background documents at the end of this section.

20. Memorandum of Agreement Between the Office of the Vice President of the Republic of Palau Represented by the Vice President Raynold B. Oilouch (Applicant) and Bureau of Cultural and Historical Preservation/Palau Historic Preservation Office (BCHP) Regarding Boring Holes Testing for U.S. Department of Defense Project at Ngerbelau Region, Angaur State, Republic of Palau, signed 12 February 2018

21. Memorandum of Agreement Between the Office of the Vice President of the Republic of Palau Represented by the Vice President Raynold B. Oilouch (Applicant) and Bureau of Cultural and Historical Preservation/Palau Historic Preservation Office (BCHP) Regarding the Test Pits Excavation for U.S. Department of Defense Project at Chol Area, Ngaraard State, Republic of Palau, signed 12 February 2018

22. Addendum to the MOA Between the Ministry of Public Infrastructure and Industries and BCHP Regarding Construction of the TACMOR Facilities in ROP, signed 11 November 2021

23. Application for Historic Clearance, signed by the Ministry of Public Infrastructure & Industry on 09 November 2021

10. SECTION 02 61 13 – EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL is deleted in its entirety and replaced with the attached SECTION 02 61 13 – EXCAVATION AND HANDLING OF CONTAMINATED MATERIAL. Revisions are shown in bold face type.

11. SECTION 03 30 00 – CAST-IN-PLACE CONCRETE, paragraph 2.5.1, Properties and Requirements, subparagraph h. Table is deleted in its entirety and replaced with the following:

Minimum f’c

MPa Exposure Categories

Miscellaneous Requirements

Slabs-on-ground 35 C2 Air Content: 5% +/- 1.5% Max w/c Ratio = 0.40 Corrosion Inhibitor Required Minimum Cementitious Material = 400 kg/ cubic meter

Concrete Coping 35 C2 Air Content: 5% +/- 1.5% Max w/c Ratio = 0.40 Corrosion Inhibitor Required Minimum Cementitious Material = 400 kg/ cubic meter

Leveling Pad 28 C2 Air Content: 3% +/- 1.5% Max w/c Ratio = 0.50 Corrosion Inhibitor Required Minimum Cementitious Material = 300 kg/ cubic meter

Concrete Header, Survey Monument

28 C2 Air Content: 3% +/- 1.5% Max w/c Ratio = 0.50 Corrosion Inhibitor Required Minimum Cementitious Material = 300 kg/ cubic meter

12. The following revisions to the indicated drawings are made narratively.

Drawing No.

NAVFAC

No. Revision

CS110

CG110

17267914 17267951

Revise "Data Center" to "Amenity"

CF510 17267934 Delete DWG CF510 in its entirety.

CG303 17267954 Note 2, delete "C1/CE502" and replace it with "C1/CE503"

Add Note 7 as follows:

“Provide hydroseed on antenna earth mat subgrade for erosion control purpose.

Furnish and stockpile onsite 1,530 cubic meters of topsoil for future placement by others. Topsoil stockpile location and BMPs to be coordinated/approved by the Contracting Officer.”

V-051 17267988 Note 4 is deleted in its entirety and replaced with the following:

“The Rx site will be cleared of vegetation, MEC, lead contaminated soil, bitumen and bitumen drums, and non-MEC metals by the MEC/EV contractor

Note 5 is deleted in its entirety and replaced with the following:

“Clearing activities by the MEC/EV contractor will alter the topographic survey shown in the sheets V051 through V-164. A topographic survey will be conducted by others post clearance and will be provided to the Construction Contractor.

Base bids on the topographic survey provided in sheets V-051 through V-164.

Differences between the current topographic survey and the new topographic survey conducted after the MEC clearance is complete will be handled as a changed condition.

Delete Note 6 in its entirety.

V-151 V-152 V-153 V-154 V-155 V-156 V-157 V-158 V-159 V-160 V-161 V-162 V-163 V-164

17267989 17267990 17267991 17267992 17267993 17267994 17267995 17267996 17267997 17267998 17267999 17268000 17268001 17268002

Delete all Notes in their entirety

CD151

CD152

CD153

CD154

CD155

CD156

CD157

CD158

CD159

CD160

CD161

17268004 17268005 17268006 17268007 17268008 17268009 17268010 17268011 17268012 17268013 17268014

Note 1 is deleted in its entirety and replaced with “NOT USED”

Note 3 is deleted in its entirety and replaced with “NOT USED”

CD162

CD163

CD164

17268015 17268016 17268017

CG051 17268039 Note 5 is deleted in its entirety and replaced with the following:

“Borrow pits must not exceed limits shown on site plans. Borrow pit locations are shown for Construction Contractor information only. On-site manufactured fill material must conform with common fill as indicated in Section 32 23 00.00 20.

Borrow pit slopes must not be steeper than 4H:1V

CP151 17268609 Revise drawing scale under plan title to read "SCALE: 1:200"

13. The following revised drawings supersede and replace any previously issued drawing bearing the same number and title:

DRAWING

NUMBER

NAVFAC

DRAWING

NUMBER

REVISION

NUMBER DRAWING TITLE

V-111 17267870 A2 TX EXISTING CONDITIONS PLAN-11

CD109 17267886 A2 TX EROSION CONTROL AND DEMOLITION PLAN-9

CD110 17267887 A2 TX EROSION CONTROL AND DEMOLITION PLAN-10

CD113 17267890 A2 TX EROSION CONTROL AND DEMOLITION PLAN-13

CD114 17267891 A2 TX EROSION CONTROL AND DEMOLITION PLAN-14

CD115 17267892 A2 TX EROSION CONTROL AND DEMOLITION PLAN-15

CD117 17267894 A2 TX EROSION CONTROL AND DEMOLITION PLAN-17

CD119 17267896 A2 TX TREE TOPPING PLAN

CS501 17267916 A2 TX & RX MISCELLANEOUS SITE DETAILS

CF001 17267917 A2 TX OVERALL FENCING & GRASSING PLAN

CF101 17267918 A2 TX FENCING & GRASSING PLAN-1

CF102 17267919 A2 TX FENCING & GRASSING PLAN - 2

CF103 17267920 A2 TX FENCING & GRASSING PLAN - 3

CF104 17267921 A2 TX FENCING & GRASSING PLAN - 4

CF105 17267922 A2 TX FENCING & GRASSING PLAN - 5

CF106 17267923 A2 TX FENCING & GRASSING PLAN - 6

CF107 17267924 A2 TX FENCING & GRASSING PLAN - 7

CF502 17267926 A2 TX & RX CHAIN LINK FENCE DETAILS

CF505 17267929 A2 TX & RX CABLE REINF FENCE DETAILS - GATES

CF507 17267931 A2 TX & RX CABLE REINFORCING DETAILS

CF508 17267932 A2 TX & RX MISC CHAIN LINK FENCE DETAILS

CF511 17267935 A2 TX & RX FENCING SIGN DETAILS

CG301 17267952 A2 TX SITE SECTIONS - 1

CG302 17267953 A2 TX SITE SECTIONS - 2

CP501 17267966 A2 TX & RX PAVEMENT DETAILS

CD051 17268003 A2 RX OVERALL EROSION CONTROL AND DEMOLITION PLAN

CS155 17268027 A2 RX SITE PLAN - 5

CS161 17268033 A2 RX SITE PLAN - 11

S-520 17268096 A2 TYPICAL SLAB-ON-GRADE PLAN, SECTION, AND SCHEDULE

14. All other terms and conditions remain unchanged.

End of Amendment

1596606

RFP N62742-21-R-1322, PAF 198127 TACMOR UTILITIES AND INFRASTRUCTURE SUPPORT

GENERAL DESCRIPTION: SEE SECTION 01 11 00, SUMMARY OF WORK, PARAGRAPH 1.1.1, Project Description.

THIS PROCUREMENT IS UNRESTRICTED. North American Industry Classification System (NAICS) Code 237990, Other Heavy and Civil Engineering Construction , Average Annual Receipts for the Past 3 years $39.5M

ESTIMATED COST: BETWEEN $100,000,000 AND $250,000,000.

DPAS RATING: DO-C2

ENFORCEABILITY OF PROPOSAL: The proposal must set forth full, accurate and complete information as required by this solicitation. The Government will rely on such information in the award of a contract. The awardee’s proposal will be incorporated into the contract and all items proposed will become binding requirements of the contract. By submission of the offer, the offeror agrees that all items proposed (e.g., affiliates/subcontractors with teaming agreements, etc.) will be utilized for the duration of the contract and any substitutions must be equal or better and will require prior approval by the Contracting Officer.

AWARD RESULTING FROM THIS SOLICITATION IS SUBJECT TO RECEIPT OF CONGRESSIONAL/PRESIDENTIAL APPROVAL OF THE FY22 NATIONAL DEFENSE AUTHORIZATION ACT AND FY22 MILITARY CONSTRUCTION QUALITY OF LIFE AND VETERANS AFFAIRS

APPROPRIATIONS ACT

AWARD RESULTING FROM THIS SOLICITATION IS SUBJECT TO RECEIPT OF A SIGNED LEASE AGREEMENT WITH THE GOVERNMENT OF PALAU

Norine E. Horikawa (808) 471-2235

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFOMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

05 January 2022

08 FEB 2022 REV 1

07 MAR 2022, REV2 (RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

HAND DELIVER

NAVFAC PACIFIC

CONSTRUCTION CONTRACTS BR (CON33)

4256 RADFORD DR, BLDG 62

HONOLULU HI 96818-3296

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______ 15 calendar days and complete it within ________ 1,095 calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________ Document 00 70 00

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ copies to perform the work required are due at the place specified in Item 8 by 2:00 p.m. HST local time See Doc 002116 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 90 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVFAC PACIFIC

CONSTR CONTRACTS BRANCH (CODE CON33)

258 MAKALAPA DR STE 100

JBPHH HI 96860-3134

N62742

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX: TEL: TEL: FAX:

N6274222R1322 4

See Doc 00 21 16

N62742

20B. SIGNATURE

(REV. 4-85) STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE PRICE PROPOSAL SCHEDULE

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE 27. PAYMENT WILL BE MADE BY: 26. ADMINISTERED BY

(Include ZIP Code) 14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO.

Office: Fax:

(Include area code)

See Item 14

(Include only if different than Item 14) 16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this 28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror) OFFER

DUNS NO.:

TIN NO.: CAGE CODE:

SOLICITATION, OFFER AND AWARD (SF 1442), CONTINUED

PRICE PROPOSAL SCHEDULE

FOR

RFP NO. N62742-22-R-1322

PAF 198127 TACMOR UTILITIES AND INFRASTRUCTURE SUPPORT

SF 1442 (Continued), REV 2, Amd 02

ITEM

NO. DESCRIPTION

QTY

UNIT OF

ISSUE

UNIT

PRICE

AMOUNT

0001 BASE ITEM

0001AA

BASE ITEM: The basis for SLIN 0001AA is the price for all labor, material, and equipment for the entire work for WON 1596606 complete and in accordance with the drawings and specifications, but not including work under any other SLIN

Each

Lump Sum

0001AB Mobilization/Demobilization for WON 1596606, but not including work under any other SLIN.

Each

Lump Sum

0001AC Basalt Rock Removal, Tx site only. Work to remove basalt rock offsite to include excavating, removing, stockpiling and transporting, but not including work under any other SLIN.

49,600 M3 $________ $_________________

0001AD Surplus Soil Removal, Tx site only. Work to remove surplus soil to include excavation and removal off-site, but not including work under any other SLIN.

291,560 M3 $________ $_________________

TOTAL CLIN 0001

NOTES:

1. See Document 00 22 00 for the Price Evaluation.

2. A firm-fixed-price is required for all line items. ALL OR NONE OFFERS - Offers are solicited on an “all or none” basis and FAR 52.215-1, INSTRUCTIONS TO OFFERORS-COMPETITIVE ACQUISITION in Document 00 21 16, is hereby modified. Failure to submit offers for all line items listed shall be cause for rejection of the offer.

3. The Offeror SHALL include a price for ALL SLINs.

4. For SLINs 0001AC and 0001AD: In the event there is a difference between a unit price and the extended total, the unit price will be held to be the intended offer and the total will be recomputed accordingly. If an offer provides a total but fails to enter a unit price, the total divided by the specified quantity will be held to be the intended unit price.

5. For SLINs 0001AC and 0001AD: Measurement for SLIN 0001AC and 0001AD

Contractor shall perform a topographic survey of the disposal site(s) prior to disposal of basalt/surplus soil, and the contractor shall perform a second topographic survey of the disposal site(s) after disposal of basalt/surplus soil is completed. The topographic survey of the disposal site(s) must be performed by a licensed surveyor in accordance with the National Society of Professional Surveyors (NSPS) Model Standards for Topographic Surveys and in Metric units. The contractor shall use commercial software, such as AutoCAD Civil 3D to calculate the volume of disposed basalt rock/surplus soil and submit the results in the form of a report to the Contracting Officer for approval.

Contractor may perform additional surveys and calculations to support progress payments.

SOLICITATION, OFFER AND AWARD (SF 1442), CONTINUED

PRICE PROPOSAL SCHEDULE

FOR

RFP NO. N62742-22-R-1322

PAF 198127 TACMOR UTILITIES AND INFRASTRUCTURE SUPPORT

SF 1442 (Continued), REV 2, Amd 02

5. Multiple awards will not be made.

6. 7FARS 252.236-7004, PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC 1991)

(a) The Government will pay all costs for the mobilization and demobilization of all of the Contractor's plant and equipment at the contract lump sum price for this item.

(1) 60 percent of the lump sum price upon completion of the contractor's mobilization at the work site.

(2) The remaining 40 percent upon completion of demobilization.

(b) The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a)(1) and (2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of—

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization; and

(iii) The remainder of this item in the final payment under this contract.

(2) The Contracting Officer's determination of the actual costs in paragraph (b)(1)of this clause is not subject to appeal.

8. The following FAR clause applies to SLINs 0001AC and 0001AD. At the end of the contract work, should there be any remaining quantities, these quantities will be deobligated via modification to the contract.

FAR 52.211-18, VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

9. DFARS 252.247-7023, TRANSPORTATION OF SUPPLIES BY SEA. Within 30 days of each shipment, the Contractor is required to provide an electronic copy of the carrier’s bill of lading to the Contracting Officer and to MARAD via email at cargo.MARAD@dot.gov (attn.: MIL Team). In addition, the Contractor shall notify the Contracting Officer when oceanic shipments have been initiated within 3 working days of shipment.

PAF 198127 TACMOR UTILITES AND INFRASTRUCTURE SUPPORT 1596606

SECTION 01 57 19

TEMPORARY ENVIRONMENTAL CONTROLS

11/15

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

REPUBLIC OF PALAU (ROP) Regulation (www.palaugov.pw/eqpb)*

2401-01 Earthmoving Regulations

2401-11 Marine and Freshwater Quality Regulations

2401-13 Wastewater Treatment and Disposal Regulations

2401-31 Solid Waste Management Regulations

2401-33 Pesticide Regulations

2401-71 Air Pollution Control Regulations

2401-81 Ozone Layer Protection Regulations

*As may be amended; regulations on the ROP Environmental Quality Protection Board (EQPB) website may not be current. It is the Contractor's responsibility to obtain and comply with the most current regulations.

ROP National Code

Title 19 Cultural Resources

Title 24 Environmental Protection

U.S. DEPARTMENT OF DEFENSE (DOD)

DoDM 4715.05 Overseas Environmental Baseline Guidance Document (OEBGD), Volume 5 Waste, Section 5 Hazardous Waste and Appendix 5A Characteristics of Hazardous Wastes and Lists of Hazardous Wastes and Hazardous Substances (January 29, 2020 or most current revision)**

(https://www.esd.whs.mil/Portals/54/Documents/DD/issuances/dodm/471505_vol05.pdf?ver=2020-06-29-155017-350)

**Comply with the DoD Manual OEBGD, Volume 5, Section 5 and Appendix 5A (hereafter, DoDM 4715.05-V5, Sect.5 & Appx.5A) for hazardous materials and/or hazardous wastes that will be shipped out of the Republic of Palau (ROP) or evaluated for shipment or disposal outside the ROP.

SECTION 01 57 19 Page 1

AMENDMENT NO. 0002

DoDI 4715.08 (2018) Remediation of Environmental Contamination Outside the United States

DoDI 4160.2M (2017) Defense Material Disposition Manual

DoDI 6050.05 (2006)DoD Hazard Communication Program

OTHER BACKGROUND DOCUMENTS

1. Argonne National Laboratory, Monitoring - Archaeological Monitoring, Ngaraard, Republic of Palau, Draft Monitoring Plan (March 2021)

2. Argonne National Laboratory, Monitoring - Archaeological Monitoring, Angaur, Republic of Palau, Draft Monitoring Plan (November 2019)

3. TACMOR Soil and Waste Management Evaluation, TACMOR Project, Babeldaob and Angaur Islands, Palau, Final (January 2021)

4. Environmental Baseline Survey Ngaraard and Angaur, Republic of Palau, Final (October 2018)

5. Supplemental Environmental Baseline Survey Ngaraard and Angaur, Republic of Palau, Final (March 2020)

6. Phase II Environmental Baseline Survey Ngaraard and Angaur, Republic of Palau, Final (March 2020)

7. Megapode Nest Location Map

8. Natural and Cultural Resource Investigations to Support Construction of Air Domain Awareness Radar Facilities in the Republic of Palau, Natural Resource Surveys, Final Survey Report (June 2020)

9. Letter Report: Cultural and Natural Resource Assessment of Proposed Soil Disposal Areas 1 and 2 for the Tactical Multi-Mission Over-the-Horizon Radar Facilities in Chol, Ngaraard, Republic of Palau (20 November 2020)

10. Memorandum of Understanding between Ngaraard State Governor Benjamin Iskawa and the Ngaraard State Public Land Authority (March 2020)

11. Tx Cultural Resources Sensitivity Area Map

12. Biomass Management Report (August 2020)

13. Stormwater Protection Report (September 2020)

14. Volume I Palau Stormwater Management Manual, Final (May 2010)

15. Volume II Palau Stormwater Management Manual, Final (May 2010)

16. Palau Erosion and Sediment Control Field Guide (2010)

17. Letter Report Cultural and Natural Resource Assessment Proposed Fence Line Construction, Ngaraard, Palau (Tx Site) (September 2020)

18. Coconut Rhinoceros Beetle (CRB)Brochure, American Samoa Community College Community & Natural Resources Cooperative Research & Extension (2005)

SECTION 01 57 19 Page 2

19. Coconut Rhinoceros Beetle (CRB) and Little Fire Ant (LFA) Management Procedures, Ver3. (Revised 27 January 2020)

20. Memor andum of Agr eement Bet ween t he Of f i ce of t he Vi ce Pr esi dent of t he Republ i c of Pal au Repr esent ed by t he Vi ce Pr esi dent Raynol d B. Oi l ouch ( Appl i cant ) and Bur eau of Cul t ur al and Hi st or i cal Pr eser vat i on/ Pal au Hi st or i c Pr eser vat i on Of f i ce ( BCHP) Regar di ng Bor i ng Hol es Test i ng f or U. S. Depar t ment of Def ense Pr oj ect at Nger bel au Regi on, Angaur St at e, Republ i c of Pal au, s i gned 12 Febr uar y 2018

21. Memor andum of Agr eement Bet ween t he Of f i ce of t he Vi ce Pr esi dent of t he Republ i c of Pal au Repr esent ed by t he Vi ce Pr esi dent Raynol d B. Oi l ouch ( Appl i cant ) and Bur eau of Cul t ur al and Hi st or i cal Pr eser vat i on/ Pal au Hi st or i c Pr eser vat i on Of f i ce ( BCHP) Regar di ng t he Test Pi t s Excavat i on f or U. S. Depar t ment of Def ense Pr oj ect at Chol Ar ea, Ngar aar d St at e, Republ i c of Pal au, s i gned 12 Febr uar y 2018

22. Addendum t o t he MOA Bet ween t he Mi ni st r y of Publ i c I nf r ast r uct ur e and I ndust r i es and BCHP Regar di ng Const r uct i on of t he TACMOR Faci l i t i es i n ROP, s i gned 11 November 2021

23. Appl i cat i on f or Hi st or i c Cl ear ance, s i gned by t he Mi ni st r y of Publ i c I nf r ast r uct ur e & I ndust r y on 09 November 2021

ASTM INTERNATIONAL (ASTM)

E2590-15 Standard Guide for Conducting Hazard Analysis-Critical Control Point (HACCP) Evaluations

1.2 ROP NATIONAL CODE AND ADDITIONAL REQUIREMENTS

1.2.1 ROP National Code and Permit Requirements

Comply with all applicable ROP laws, regulations, standards, and permits.

The applicable ROP regulations include but are not limited to ROP Ch.

2401-01 , ROP Ch. 2401-11 , ROP Ch. 2401-13 , ROP Ch. 2401-31 , ROP Ch. 2401-33 , ROP Ch. 2401-71 , and 2401-81 .

Comply with all conditions of any permit applicable to the project regardless of whether the permit is issued directly to the Contractor and regardless of whether the Contractor is named in the permit.

Where these specifications call for submittal of a permit application to the Contracting Officer, no action requiring the applicable permit may be taken until after approval by the Contracting Officer. Upon approval by the Contracting Officer, submit permit applications to the ROP Ministry of Public Infrastructure and Industry (MPII) for its review and submittal to appropriate agency.

Submit permit applications to Contracting Officer at least 120 days prior to anticipated need for permits and allow at least 30 days for U.S.

Government review. The Government shall not be responsible for any delay in ROP permit issuance after permit submittal and the Contractor shall bear any costs of such delay.

SECTION 01 57 19 Page 3

1.2.2 U.S. DoD and International Requirements

Comply with the DoDM 4715.05 -V5, Sect.5 & Appx.5A, and all applicable international requirements for managing, transporting, disposing of hazardous materials and hazardous materials that will be shipped into or out of the ROP. In addition, comply with applicable provisions of the DoD Instructions (DoDI) as follows:

- DoDI 4160.2M : Defense Material Disposition Manual

- DoDI 6050.05 DoD Hazard Communication (HAZCOM) Program: Hazardous material handling and labeling

- DoDI 4715.08 Remediation of Environmental Contamination outside the United States: Si t e cont ami nat i on wi t hi n t he pr oj ect s i t es wi l l be handl ed under a separ at e cont r act by ot her s. In addition to compliance with ROP requirements, ensure that any i nadver t ent l y enount er ed addi t i onal existing contamination is addressed to prevent substantial impact to human health and safety.

1.2.3 Cultural and Natural Resource Monitoring

The U.S. Government will retain a biologist(s) and an archaeologist(s) for the project. Comply with all requirements to protect natural and cultural resources specified in this section and other background documents.

1.3 DEFINITIONS

1.3.1 Ozone Depleting Substance (ODS)

Ozone depleting controlled substances are defined under ROP Ozone Layer Protection Regulations, Chapter 2401-81 . The appendix contains a list of ozone depleting controlled substances in the ROP.

1.3.2 Contractor Generated Hazardous Waste

Contractor generated hazardous waste is materials that, if abandoned or disposed of, meets the definition of a hazardous waste. These waste streams would typically consist of material brought on site by the Contractor to execute work, but are not fully consumed during the course of construction. Examples include, but are not limited to, excess paint thinners (i.e. methyl ethyl ketone, toluene), waste thinners, excess paints, excess solvents, waste solvents, excess pesticides, and contaminated pesticide equipment rinse water.

1.3.3 Environmental Damage

Environmental damage is the presence of chemical, physical, or biological elements or agents which adversely affect human health or welfare;

unfavorably alter ecological balances of importance to human life; affect other species of importance to humankind; or degrade the environment aesthetically, culturally, or historically.

1.3.4 Environmental Protection

Environmental protection is the prevention/control of pollution and habitat disruption that may occur to the environment during construction.

The control of environmental damage requires consideration of land, water, and air; biological and cultural resources; and includes management of

SECTION 01 57 19 Page 4 visual aesthetics; noise; solid, chemical, gaseous, and liquid waste;

radiant energy and radioactive material as well as other contaminants.

1.3.5 Hazardous Debris

Debris that contains listed hazardous waste (either on the debris surface, or in its interstices, such as pore structure) as defined by ROP law, regulation, or permit conditions. Additionally, hazardous debris shall be defined using the standards identified in DoDM 4715.05-V5, Sect.5, Appx.5A for materials/wastes to be shipped out of the ROP, or evaluated for shipment or disposal outside the ROP.

1.3.6 Hazardous Materials

Any material that is regulated as a hazardous material; or requires a Safety Data Sheet (SDS); or during end use, treatment, handling, packaging, storage, transportation, or disposal meets or has components that meet or have potential to meet the definition of a hazardous waste as defined by Palauan law, regulation, or permit conditions. Designation of a material by this definition, when separately regulated or controlled by other sections or directives, does not eliminate the need for adherence to that hazard-specific guidance which takes precedence over this section for "control" purposes. Such material includes those materials that cause physical, health, asphyxiant, combustible dust, or phyrophoric gas hazards, or are regulated as hazardous under the ROP regulations or DoDM 4715.05-V5, Sect.5 & Appx.5A.

1.3.7 Hazardous Waste

Hazardous waste is any material that meets the definition of a hazardous waste as defined by ROP law, regulation, or permit conditions. Wastes classified and listed as Persistent Organic Pollutants (PoPs) under the Stockholm Convention are considered hazardous wastes. Additionally, for materials to be shipped out of the ROP, or evaluated for shipment or disposal outside the ROP, hazardous waste shall be defined using the standards identified in DODM 4715.05-V5, Sect.5 & Appx.5A.

1.3.8 Land Application

Land application means spreading or spraying discharge water at a rate that allows the water to percolate into the soil. No sheeting action, soil erosion, discharge into storm sewers, discharge into defined drainage areas, or discharge into the "Waters of Palau" must occur. Comply with ROP laws and regulations.

1.3.9 Oily Waste

Oily wastes are those materials that are, or were, mixed with Petroleum, Oils, and Lubricants (POLs) and have become separated from those POLs.

Oily waste also means materials, including wastewaters, centrifuge solids, filter residues or sludges, bottom sediments, tank bottoms, and sorbents which have come into contact with and have been contaminated by, POLs and may be appropriately tested and discarded in a manner which is in compliance with ROP law, regulation, or permit conditions.

This definition includes materials such as oily rags, "kitty litter" sorbent clay and organic sorbent material. These materials may be land filled provided that: the amount generated is "de minimus" (a small amount); it is the result of minor leaks or spills resulting from normal

SECTION 01 57 19 Page 5 process operations; and free-flowing oil has been removed to the practicable extent possible, and does not contain listed hazardous wastes as defined in the Palauan law, regulation, or permit condition. Large quantities of this material, generated as a result of a major spill or in lieu of proper maintenance of the processing equipment, are a solid waste.

As a solid waste, perform a hazardous waste determination prior to disposal.

1.3.10 Regulated Waste

Regulated waste are solid wastes that have specific ROP required controls for handling, storage, or disposal and in addition, for wastes to be shipped out of the ROP, or evaluated for shipment or disposal outside the ROP, are solid wastes that are specified in DoDM 4715.05-V5, Sect.5 & Appx.5A required controls for handling, storage, or disposal.

1.3.11 Sediment

Sediment is soil and other debris that have eroded and have been transported by runoff water or wind.

1.3.12 Solid Waste

Solid waste is a solid, liquid, semi-solid or contained gaseous waste. A solid waste can be a hazardous waste, non-hazardous waste, or non-regulated waste. Types of solid waste typically generated at construction sites may include: solid waste as defined in ROP Solid Waste Regulations, Chapter 2401-31-03, construction and demolition debris, hazardous waste, or other such wastes as defined elsewhere in Section 1.3 of this specification.

1.3.12.1 Debris

Debris is non-hazardous solid material generated during the construction, demolition, or renovation of a structure that exceeds 60mm particle size that is: a manufactured object; plant or animal matter; or natural geologic material (for example, cobbles and boulders), broken or removed concrete, masonry, and rock asphalt paving; ceramics; roofing paper and shingles. Inert materials may be reinforced with or contain ferrous wire, rods, accessories and weldments. A mixture of debris and other material such as soil or sludge is also subject to regulation as debris if the mixture is comprised primarily of debris by volume, based on visual inspection.

1.3.12.2 Green Waste

Green waste is the vegetative matter from landscaping, land clearing and grubbing, including, but not limited to, grass, bushes, scrubs, small trees and saplings, tree stumps and plant roots. Marketable trees, grasses and plants that are indicated to remain, be re-located, or be re-used are not included. A Biomass Management Plan including a plan for green and brown waste management and disposal must be prepared in accordance with Section 3.11. The Biomass Management Report may be referenced for estimated quantities.

1.3.12.3 Material not Regulated as Solid Waste

Material not regulated as solid waste is suspended or dissolved materials in domestic sewage effluent or irrigation return flows, or other regulated

SECTION 01 57 19 Page 6 point source discharges; regulated air emissions; and fluids or wastes associated with natural gas or crude oil exploration or production.

1.3.12.4 Non-Hazardous Waste

Non-hazardous waste is waste that is excluded from, or does not meet, hazardous waste criteria.

1.3.12.5 Recyclables

Recyclables are materials, equipment and assemblies such as doors, windows, door and window frames, plumbing fixtures, glazing and mirrors that are recovered and sold as recyclable, wiring, insulated/non-insulated copper wire cable, wire rope, and structural components. It also includes commercial-grade refrigeration equipment with Freon removed, household appliances where the basic material content is metal, clean polyethylene terephthalate bottles, cooking oil, used fuel oil, textiles, high-grade paper products and corrugated cardboard, stackable pallets in good condition, clean crating material, and clean rubber/vehicle tires. Metal meeting the definition of lead contaminated or lead-based paint (LBP) contaminated may not be included as recyclable if sold to a scrap metal company. Paint cans may be included as recyclable if sold to a scrap metal company.

1.3.12.6 Surplus Soil

Surplus soil is existing soil that is in excess of what is required for this work, including aggregates intended, but not used, for on-site mixing of concrete, mortars, and paving. Contaminated soil meeting the definition of hazardous material or hazardous waste is not included and must be managed in accordance with paragraph HAZARDOUS MATERIAL MANAGEMENT, and paragraph 3.7.3 CONTROL AND MANAGEMENT OF HAZARDOUS WASTE, as appropriate.

1.3.12.7 Scrap Metal

This includes scrap and excess ferrous and non-ferrous metals such as reinforcing steel, structural shapes, pipe, wire, and remnant mining equipment, aircraft, vehicles, and miscellaneous metals that are recovered or collected and disposed of as scrap.

Scrap metal meeting the definition of hazardous material or hazardous waste or munitions and explosives of concern (MEC) are not included.

1.3.12.8 Wood

Wood is dimension and non-dimension lumber, plywood, chipboard, hardboard.

Treated or painted wood that meets the definition of lead contaminated or LBP contaminated is not included. Treated wood includes, but is not limited to, lumber, utility poles, crossties, and other wood products with chemical treatment.

1.3.13 Surface Discharge

Surface discharge means discharge of water into drainage ditches, storm sewers, creeks or "Waters of Palau." Surface discharges are discrete, identifiable sources and require a permit from the governing agency.

Comply with ROP laws and regulations.

SECTION 01 57 19 Page 7

1.3.14 Wastewater

Wastewater is the used water and solids from a community that flow to a treatment plant.

1.3.14.1 Stormwater

Stormwater is any precipitation in an urban or suburban area that does not evaporate or soak into the ground, but instead collects and flows into storm drains, rivers, and streams.

1.3.15 Waters of Palau

Waters of Palau means Palauan jurisdictional waters, including wetlands, that are subject to ROP Marine and Fresh Water Quality regulation 2401-11 .

1.3.16 Wetlands

Wetlands are those areas that are inundated or saturated by surface or groundwater at a frequency and duration sufficient to support, and that under normal circumstances do support, a prevalence of vegetation typically adapted for life in saturated soil conditions.

1.4 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submit the following:

SD-01 Preconstruction Submittals

Preconstruction Survey; G

Solid Waste Management Permit; G

Solid Waste Management Plan (IAW ROP Reg. 2401-31-12); G

Hazardous Waste Management Plan (IAW ROP Reg. 2401-31-27); G

Regulatory Notifications; G

Environmental Protection Plan; G

Stormwater Pollution Prevention Plan (SWPPP); G

Employee Training Records; G

Environmental Manager Qualifications; G

Erosion and Sedimentation Control Plan; G

Earthmoving Permit Application; G

Biomass Management Plan; G

Hazard Analysis and Critical Control Point Plan; G

Supporting Documentation for HACCP Plan; G

SECTION 01 57 19 Page 8

Wastewater Disposal System Permit Application; G

Spill Prevention Control and Countermeasures (SPCC) Plan; G

Pest Management Plan; G

Site Specific Best Management Practices Plan; G

Pesticide Import Permit Application; G

Ozone Depleting Substances (ODS) Import Permit; G

Application for Quarantine Import Permit; G

ODS Storage and Use Permit Application; G

Point-Source Discharge Permit Application; G

SD-06 Test Reports

Laboratory Analysis

Monthly Solid Waste Disposal Report; G

Erosion and Sediment Control Inspection Reports; G

BMP Daily Inspection Reports; G

Field Equipment Validation; G

SD-07 Certificates

Employee Training Records; G

Erosion and Sediment Control Inspector Qualifications

SD-11 Closeout Submittals

Waste Determination Documentation; G

Disposal Documentation for Hazardous and Regulated Waste; G

Assembled Employee Training Records; G

Sales Documentation; G

Contractor Hazardous Material Inventory Log; G

Project Solid Waste Management & Disposal Documentation; G

Hazardous Waste/Debris Management Report; G

1.5 ENVIRONMENTAL PROTECTION REQUIREMENTS

Provide all necessary plans and implement/maintain the plans during the life of the contract to protect the environment as defined in the plans.

Provide environmental protective measures to control pollution that develops during the construction project. Provide environmental protective

SECTION 01 57 19 Page 9 measures required to correct conditions that develop during the construction of permanent or temporary environmental features associated with the project. Protect the environmental resources within the project boundaries and those affected outside the limits of permanent work.

Special precautions are required at areas identified as avoidance, High and Moderate Sensitivity areas,…