FA4855-18-R-0013_Rev._2_conformed_copy.pdf

F1L3J27339AW01

Project: Construction of Pad including all utilities described in the CZQZ 17-0014 SOW dated 18 Jan 18. (attachment 1) and the Specif ications

Site Visit: A site viste w ill be conducted on 23 Feb 2018 at 8:00 AM. For those that require a access email elric.manville@us.af.mil NLT 20 Feb 2017 w ith a list of names of those that w ill be attending

Disclosure of Magnitude: Estimated Magnitude for the total project is betw een $100,000 and $250,000.

Set-Aside: This acquisition is a Total Small Business Set-Aside, NAICS Code 238110, Size Standard $15.0M

NOTE: A Bid Bond is required in the amount of 20% and must be included w ith your proposal

ELRIC A. MANVILLE 575-784-1359

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

12-Feb-2018

(RFP)

(IFB)

X

CALL:

SOF Construct Pad for Training Sim

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______5 calendar days and complete it w ithin ________90 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________15 Mar 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

27 SOCONS/CC

110 E ALISON AVE, BLDG 600

CANNON AFB NM 88103-5321

FA4855

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

CZQZ17-0014

8. ADDRESS OFFER TO (If Other Than Item 7)

(575) 784-4791FAX:TEL: (575) 784-2321 TEL: FAX:

FA485518R0013 25

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA485518R0013

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job

SOF CONSTRUCT PAD FOR TRAINING

FFP

Contractor shall construct a concrete pad at Cannon AFB, NM IAW attached SOW and Specifications. This CLIN shall include New Mexico Gross Receipts Tax at the current rate of 6.125% for Curry County, per Taxation & Revenue New Mexico.

FOB: Destination

PURCHASE REQUEST NUMBER: F1L3J27339AW01

NET AMT

PSC Code: Y1EZ

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 90 dys. ANP 1 27 SOCES

JESSICA ELSIK

506 N AIR COMMANDO WAY

CANNON AFB NM 88103

575-784-2018 FOB: Destination

F1L3J2

Section G - Contract Administration Data

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-7 System for Award Management OCT 2016 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.224-1 Privacy Act Notification APR 1984 52.224-2 Privacy Act APR 1984 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General DEC 2012

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7002 Safety Precautions For Ammunition And Explosives MAY 1994 252.223-7003 Changes In Place Of Performance--Ammunition And

Explosives

DEC 1991

252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Alt I Prohibition on Storage, Treatment, and Disposal of Toxic or

Hazardous Materials - Alternate I

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 calendar days

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ 225.64 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code - assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

(a) “Irrevocable letter of credit” (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit.

(b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used.

(c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and--

(1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period;

(2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be:

(i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of--

(A) One year following the expected date of final payment;

(B) For performance bonds only, until completion of any warranty period; or

(C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment.

(ii) For contracts not subject to the Miller Act, the later of--

(A) 90 days following final payment; or

(B) For performance bonds only, until completion of any warranty period.

(d)(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC.

(2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year.

(3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC.

(4) The current rating for a financial institution is available through any of the following rating services registered with the U.S. Securities and Exchange Commission (SEC) as a Nationally Recognized Statistical Rating Organization (NRSRO). NRSRO's can be located at the Web site http://www.sec.gov/answers/nrsro.htm maintained by the SEC.

(e) The following format shall be used by the issuing financial institution to create an ILC:

[Issuing Financial Institution's Letterhead or Name and Address]

Issue Date _ ___

IRREVOCABLE LETTER OF CREDIT NO. ___

Account party's name ___ _

Account party's address ___ _

For Solicitation No. ___ _(for reference only)

TO: [ ___ U.S. Government agency]

[ ___ U.S. Government agency's address]

1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United States $ ___ . This Letter of Credit is payable at [issuing financial institution's and, if any, confirming financial institution's] office at [ ___ issuing financial institution's address and, if any, confirming financial institution's address] and expires with our close of business on ___ , or any automatically extended expiration date.

2. We hereby undertake to honor your or the transferee's sight draft(s) drawn on the issuing or, if any, the confirming financial institution, for all or any part of this credit if presented with this Letter of Credit and confirmation, if any, at the office specified in paragraph 1 of this Letter of Credit on or before the expiration date or any automatically extended expiration date.

3. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this Letter of Credit that it is deemed to be automatically extended without amendment for one year from the expiration date hereof, or any future expiration date, unless at least 60 days prior to any expiration date, we notify you or the transferee by registered mail, or other receipted means of delivery, that we elect not to consider this Letter of Credit renewed for any such additional period. At the time we notify you, we also agree to notify the account party (and confirming financial institution, if any) by the same means of delivery.

4. This Letter of Credit is transferable. Transfers and assignments of proceeds are to be effected without charge to either the beneficiary or the transferee/assignee of proceeds. Such transfer or assignment shall be only at the written direction of the Government (the beneficiary) in a form satisfactory to the issuing financial institution and the confirming financial institution, if any.

http://www.sec.gov/answers/nrsro.htm

5. This Letter of Credit is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. ___ -- (Insert version in effect at the time of ILC issuance, e.g., ``Publication 600, 2006 edition'') and to the extent not inconsistent therewith, to the laws of ___ --[State of confirming financial institution, if any, otherwise State of issuing financial institution].

6. If this credit expires during an interruption of business of this financial institution as described in Article 17 of the UCP, the financial institution specifically agrees to effect payment if this credit is drawn against within 30 days after the resumption of our business.

Sincerely, [ ___ Issuing financial institution]

(f) The following format shall be used by the financial institution to confirm an ILC:

___ [Confirming Financial Institution's Letterhead or Name and Address]

(Date) ___

Our Letter of Credit Advice Number ___

Beneficiary: ___ [U.S. Government agency]

Issuing Financial Institution: ___

Issuing Financial Institution's LC No.: ___

Gentlemen:

1. We hereby confirm the above indicated Letter of Credit, the original of which is attached, issued by ___ [name of issuing financial institution] for drawings of up to United States dollars ___ _/U.S. $ ___ and expiring with our close of business on ___ [the expiration date], or any automatically extended expiration date.

2. Draft(s) drawn under the Letter of Credit and this Confirmation are payable at our office located at ___ _.

3. We hereby undertake to honor sight draft(s) drawn under and presented with the Letter of Credit and this Confirmation at our offices as specified herein.

4. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this confirmation that it be deemed automatically extended without amendment for one year from the expiration date hereof, or any automatically extended expiration date, unless:

(a) At least 60 days prior to any such expiration date, we shall notify the Contracting Officer, or the transferee and the issuing financial institution, by registered mail or other receipted means of delivery, that we elect not to consider this confirmation extended for any such additional period; or

(b) The issuing financial institution shall have exercised its right to notify you or the transferee, the account party, and ourselves, of its election not to extend the expiration date of the Letter of Credit.

5. This confirmation is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. ___ -- (Insert version in effect at the time of ILC issuance, e.g., ``Publication 600, 2006 edition'') and to the extent not inconsistent therewith, to the laws of ___ --[State of confirming financial institution].

6. If this confirmation expires during an interruption of business of this financial institution as described in Article 17 of the UCP, we specifically agree to effect payment if this credit is drawn against within 30 days after the resumption of our business.

Sincerely, [Confirming financial institution]

(g) The following format shall be used by the Contracting Officer for a sight draft to draw on the Letter of Credit:

SIGHT DRAFT

[City, State]

(Date) ___

[Name and address of financial institution]

Pay to the order of ___ [Beneficiary Agency] ___ the sum of United States ___ This draft is drawn under Irrevocable Letter of Credit No. ___

___ [Beneficiary Agency]

By: ___

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/ http://farsite.hill.af.mil/vmdfara.htm http://farsite.hill.af.mil/vmaffara.htm

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

2 in 1 Invoice

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

F1L3J2

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F87700 Issue By DoDAAC FA4855 Admin DoDAAC FA4855 Inspect By DoDAAC F1L3J2 Ship To Code F1L3J2 Ship From Code ____

Mark For Code ____ Service Approver (DoDAAC) F1L3J2 Service Acceptor (DoDAAC) F1L3J2 Accept at Other DoDAAC ____ LPO DoDAAC ____ DCAA Auditor DoDAAC ____ Other DoDAAC(s) ____

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

elric.manville@us.af.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

See Below

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

5352.201-9101 OMBUDSMAN (APR 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, Lt Col Jason A. Whittle, AFICA/KO, 427 Cody Avenue (Bldg 90333), Hurlburt Field, FL 32544-5407, Phone: (850) 884- 3990, DSN: 579-3990, Fax: (850) 884-2476, Email: Jason.Whittle@us.af.mil. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/HQ AFICA/AFISRA/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330- 1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

http://www.whitehouse.gov/omb/circulars/a076/a76_rev2003.pdf

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.223-9001 HEALTH AND SAFETY ON GOVERNMENT INSTALLATIONS (NOV 2012)

(a) In performing work under this contract on a Government installation, the contractor shall:

(1) Take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(2) Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes.

(b) The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH) Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract.

(c) Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract.

Section J - List of Documents, Exhibits and Other Attachments

LIST OF ATTACHMENTS

ATTACHMENT LIST

DOCUMENT DESCRIPTION PAGES DATE

Attachment 1 Statement of Work (SOW) 11 18 Jan 2018 Attachment 2 Specifications 267 No Date Attachment 3 Schedule of Materials 2 No Date Attachment 4 One Line Electrical 1 No Date Attachment 5 Comm Inputs 4 03 Oct 2017 Attachment 6 Enviromental Guide 46 02 Jul 2015 Attachment 7 Design Standards 49 02 Feb 2012 Attachment 8 Electrical standards 15 30 Apr 2014 Attachment 9 Landscape Dev Plan 39 03 Feb 2012 Drawing 1.0 Floorplan (373765-S1.01) 20171213 Drawing 2.0 Structure (373765-S.01) 20171213 Drawing 2.1 Truss System (373765-S1.01) 20171213 Drawing 2.2 Structure (373765) StructuralCalculations Drawing 3.0 Concrete Pad (373765-S.01) 20171213 Drawing 4.0 Mechanical (373765-H.101) 20171213 Drawing 5.0 COM (373765-C.101) Updated-20171213 Drawing 6.0 Electrical (373765-E.000) Updated-20171213 Drawing 7.0 Fire Alarm Supression (373765-FA1.1) Update-20171128 Drawing 8.0 IDS (373765-E104) Updated-20171213

Section K - Representations, Certifications and Other Statements of Offerors

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.236-28 Preparation of Proposals--Construction OCT 1997 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

Section L - Instructions, Conditions and Notices to Bidders

52.204-7 System for Award Management OCT 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.216-1 Type Of Contract APR 1984 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction

FEB 1999

52.233-2 Service Of Protest SEP 2006 252.204-7004 Alt A System for Award Management Alternate A FEB 2014

INSTRUCTION TO OFFERORS

Section L - Instructions, Conditions, and Notices to Offerors

L-001. PROPOSAL PREPARATION INSTRUCTIONS

A. To assure timely and equitable evaluation of qualifications and proposals, offerors must follow the instructions contained herein. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements, in addition to those identified as evaluation factors or subfactors. Offerors must clearly identify any exception to the solicitation terms and conditions and provide complete accompanying rationale.

B. The contracting officer has determined there is a high probability of adequate price competition in this acquisition. Upon examination of the offers, the contracting officer will review this determination and if, in the contracting officer's opinion, adequate price competition exists no additional data will be requested and certification under FAR 15.406-2 will not be required. However, if at any time during this competition the contracting officer determines that adequate price competition no longer exists; offerors may be required to submit cost data to the extent necessary for the contracting officer to determine the reasonableness and affordability of the price.

C. Documents submitted in response to this RFP must be fully responsive to and consistent with the following:

1. Evaluation Factors for Award in Section M of this RFP.

2. Any limitation on the number of proposal pages. Pages exceeding the page limitations set forth in this Section L will not be read or evaluated, and will be removed from the proposal.

D. Format for proposal Parts I and II shall be as follows:

1. Electronic copies of both volumes shall emailed to the POC listed on Page 1 of the solicitation. Each Volume shall be its own file, to include the Redacted Volume II.

2. Print-outs from each file should print, by default, hardcopies that match the following criteria: proposal will be 8 1/2” x 11” paper except for fold-outs used for charts, tables, or diagrams, which may not exceed 11” x 17”.

3. A page is defined as one face of a sheet of paper containing information.

4. Typing shall not be less than 12 pitch.

5. Elaborate formats, bindings or color presentations are not desired or required.

https://cs.eis.af.mil/airforcecontracting/knowledge_center/Documents/AFFARS_Library/5315/templates/AppData/Local/Microsoft/Windows/Temporary%20Internet%20Files/Content.Outlook/far/FAR15.DOC#b154062

6. Ensure the files clearly identify Volume I, Volume II, and Volume II Redacted Copy with the proper documents filed appropriately.

E. Proposal Preparation format and Instructions - Contractor will submit two separate volumes as follows:

1. VOLUME I – PRICE PROPOSAL / Reps & Certs – Submit in electronic format via Email.

(a) Complete blocks 14, thru 20C, of the RFP Section A, SF1442. In doing so, the offeror accedes to the contract terms and conditions as written in the RFP Sections A through K. These sections constitute the model contract.

(b) Insert proposed unit and extended prices in Section B for each Contract Line Item Number (CLIN) or Sub CLIN (SCLIN). The extended amount must equal the whole dollar unit price multiplied by the number of units. Complete Block 22 of SF1442 with total price.

(c) Complete the necessary fill-ins and certifications in Sections I through K. Section K shall be returned in its entirety. For Sections C through I, the offeror shall submit only those pages that require a fill-in.

F. VOLUME II – TECHNICAL PROPOSAL - Limited to no more than 30 pages. Two copies of Volume II shall be submitted. One of the file copies submitted shall be redacted of all company information to include names, addresses, logos, etc. that can identify your proposal.

1. Past performance

(a) Recency and Relevancy: The government will evaluate the quality and extent of offeror's performance deemed relevant to the requirements of this RFP. Relevant contracts include demolition/deconstruction and asbestos abatement of facilities. Provide any information currently available (letters, metrics, customer surveys, independent surveys, etc.) Limit to no more than three (3) per contractor or subcontractor which demonstrates customer satisfaction with overall job performance and quality of completed product for relevant past efforts/contracts (similar in scope and magnitude of effort and complexities this solicitation requires) within the last 5 years.

In addition, explain corrective actions taken in the past, if any, for substandard performance and any current performance problems such as cost overruns, extended performance periods, numerous warranty calls, etc.

(b) The evaluation of past performance information will take into account past performance information regarding predecessor companies, key personnel who have relevant experience, or subcontractors that will perform major or critical aspects of the requirement when such information is relevant to the instant acquisition. Furnish the following information for each contract listed:

(i) Company/Division name

(ii) Product/Service

(iii) Contracting Agency/Customer

(iv) Contract Number

(v) Contract Dollar Value

(vi) Period of Performance

(vii) Verified, up-to-date name, address, FAX & telephone number of the contracting officer

(viii) Comments regarding compliance with contract terms and conditions

(ix) Comments regarding any known performance deemed unacceptable to the customer, or not in accordance with the contract terms and conditions.

(x) Subcontractor Consent: Past performance information pertaining to a subcontractor cannot be disclosed to the prime offeror without the subcontractor’s consent. Provide with the proposal a letter from all subcontractors that will perform major or critical aspects of the requirement, consenting to the release of their past performance information to the prime contractor.

http://www.gsa.gov/Portal/gsa/ep/formslibrary.do?viewType=DETAIL&formId=4E179AB32AF6652285256A260054D101

2. Technical Approach/Schedule

a) - Technical/Management Approach/Capabilities

Offerors will provide a schedule on a AF3064. For the purposes of the proposal the contractor’s will use a Notice to Proceed start date 12 April 2018 with a 90 Day period of perfomance.

Offerors shall schedule will have the following critical path items in a sequencial order of how items will be constructed.

Division 01 General requirements

- Mobilization

- Include equipment/materials delivery deadline.

Division 02 Existing Conditions

- Demolition of existing asphalt.

Division 03 Concrete

- Concrete reinforcing -Cast in place -Concrete finishing -Concrete curing, which includes stub ups, and air content/slump test. (7 day break and 28 day break)

Division 26 Electrical

- Install Conduit/pull strings from transformer to site stub up.

- Installation of electrical equipment disconnect, wiring, terminations from transformer to site stub up.

- installation of concrete handholes/pullbox for electrical lines.

- Grounding and bonding -Perform acceptance tests for electrical lines.

Division 33 Utilities (Communication)

- Telecommunications Outside Plant to site location

- Install Conduit/pull strings from Communication main to site stub up.

- Installation of copper, terminations, from Communication box to site stub up.

- Installation of concrete handholes/pullbox for comm. Lines.

- Install fiber cable from Comm. Box

- Grounding and bonding.

- perform acceptance tests for comm. Line.

Division 31 Earthwork

- Prep site for concrete placement by excavated, scarifying, and compacting.

- Hand dig to trench for utility lines, backfill, and compact while avoiding damaging existing utility lines.

- Prep and place concrete for electrical duct banks.

Closeout will be 10% As-builts/Warranty/Final Inspection

Section M - Evaluation Factors for Award

EVALUATION FACTORS FOR AWARD

Section M - Evaluation Factors for Award

M001 - SOURCE SELECTION

1. Basis for Contract Award This is a Lowest Price Technically Acceptable (LPTA) source selection conducted in accordance with Federal Acquisition Regulation (FAR) 15, Contracting by Negotiation, as supplemented by the Defense Federal Acquisition Regulation Supplement (DFARS), the Air Force Federal Acquisition Regulation Supplement (AFFARS), DoD Source Selection Procedures, Appendix A, 04 March 2011 and Air Force Mandatory Procedures 5315.3 27 March 2013. These regulations are available electronically at the Air Force (AF) FARSite, http://farsite.hill.af.mil. The Government will select the proposal with the lowest evaluated price from among those meeting the acceptability standards for non-price factors. Contract(s) may be awarded to the offeror who is deemed responsible in accordance with the FAR Part 9.1, as supplemented, whose proposal conforms to the solicitation’s requirements (to include all stated terms, conditions, representations, certifications, and all other information required by Section L of this solicitation) and is judged, based on the evaluation factors and subfactors, to represent the lowest price technically acceptable proposal. While the Government will strive for maximum objectivity, the source selection process, by its nature, is subjective; and therefore, professional judgment is implicit throughout the entire process.

2. Number of Contracts to be Awarded The Government intends to award one (1) contract for this requirement.

3. Discussions If, during the evaluation period, it is determined to be in the best interest of the Government to hold discussions, offeror responses to Evaluation Notices (ENs) and the Final Proposal Revision (FPR) will be considered in making the source selection decision. If the offeror’s proposal has been evaluated as acceptable at the time discussions are closed, any changes or exceptions in the Final Proposal Revision are subject to evaluation and may introduce risk that the offeror’s proposal be determined unacceptable and ineligible for award.

4. Solicitation Requirements, Terms and Conditions Offerors are required to meet all solicitation requirements, such as terms and conditions, representations and certifications, and technical requirements, in addition to those identified as factors or subfactors.

Failure to comply with the terms and conditions of the solicitation may result in the offeror being ineligible for award. Offerors must clearly identify any exception to the solicitation terms and conditions and must provide complete supporting rationale. The Government reserves the right to determine any such exceptions unacceptable.

M002 EVALUATION FACTORS

Factor Identification. The evaluation team will evaluate the proposals using the following factors:

1. Volume I - Price Evaluation

(a) Offerors whose price is determined to be unreasonable, unbalanced, or unaffordable may not be considered for award. Furthermore, all proposals will be reviewed to ensure a bid bond was received.

http://farsite.hill.af.mil/

(b) The offeror’s Price proposal will be evaluated, for award purposes, based upon the available funds for the base bid and any separately priced prioritized line items.

(c) Evaluation of offers will be conducted as follows:

(i) All offers will be evaluated for compliance with instructions in section L for responsiveness.

(ii) Responsive offers will be ranked according to price from lowest to highest.

(iii) The lowest price offer will be forwarded to the Source Selection Evaluation Board (SSEB) and evaluated for technical acceptability.

(d) If the lowest priced proposal is determined to be technically acceptable no further evaluations will be conducted and award shall be made. If the lowest priced evaluation is not determined to be technically acceptable the evaluation team will be forwarded the next lowest priced proposal for evaluation and will follow the same example until a lowest priced technically acceptable offer is made.

2. Volume II - Technical Evaluation Factor 1. Recent and Relevant Past Performance.

The past performance evaluation considers each offeror’s demonstrated recent and relevant record of performance in supplying products and services that meet the solicitation requirements. In conducting the Recent and Relevant Performance Evaluation, the Government reserves the right to use both the information provided in the offeror’s Volume II - Technical and information and from other sources available to the Government, to include, but not limited to: the Past Performance Information Retrieval System (PPIRS); Federal Awardee Performance and Integrity Information System (FAPIIS); Electronic Subcontract Reporting System (eSRS), or other databases; and interviews/questionnaires with Program Managers, Contracting Officers and Fee Determining Officials, the Defense Contract Management Agency (DCMA), and commercial sources.

Subfactor 1. Recency Assessment An assessment of the past performance information will be made to determine if it is recent. To be recent, the effort must be ongoing or must have been performed during the past 5 years from the date of issuance of this solicitation. Past performance information that fails this condition will not be evaluated.

Subfactor 2. Relevancy Assessment The Government will conduct an evaluation of all recent performance information obtained to determine whether the products provided/services performed under those contracts relate to the Technical subfactors and Price factor.