Exhibit_A_-_Company_Experience_Statement.docx
DOCX document 45 KB Posted
- Attached to
- Anacostia II WWPS Electrical Updates
- Solicitation number
- 107592
- Issued by
- Prince George's County, Maryland
About this file
This is a Company Experience Statement exhibit submitted in response to Solicitation No. CP6901A20 for Anacostia II WWPS Electrical Upgrades issued by the Washington Suburban Sanitary Commission (WSSC) in Maryland. The statement serves as a template for contractors to document their relevant completed project experience as part of their proposal submission. Responses were due by 2:00 pm on Wednesday, July 22, 2026, via WSSC's eProcurement Portal. The project scope encompasses replacement and upgrade of the Anacostia II Wastewater Pumping Station electrical system, including replacement of large and medium voltage transformers, switchgear line ups, 13.8kV and 4.16kV switchgear with associated electrical protection systems, backup battery systems, underground feeders and cables, electrical manholes, HVAC systems, structures and foundations, new paving, stormwater control devices, and temporary power provisions.
The Company Experience Statement requires contractors to provide detailed information on a minimum of five completed projects, including contract bid and final prices, original and actual completion dates, change order amounts categorized by source (owner request, differing site conditions, A/E errors and omissions, or contractor-initiated), subcontracting breakdowns by trade and percentage of work performed, minority and small local business enterprise utilization (goals versus actual), shutdown and tie-in coordination summaries where applicable, claims and disputes documentation, and liquidated damages assessments. The form requires contractors to identify project owners, construction managers, and designer/consultant contacts for reference verification purposes.
View the file
Other files
Show all 14
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SOLICITATION NO. CP6901A20
ANACOSTIA II WWPS ELECTRICAL UPGRADES
Exhibit A – Company Experience Statement
1. COMPLETED Projects – Contractor
| Project Information |
| Project Description |
| Subcontracting |
1. Trades and % of Work Performed by Subcontractors
2. Goals vs. Actual % Minority & % Small Local Business Enterprise Utilization Shutdown/Tie-in Coordination Summary (if applicable)
| Claims/Disputes (Information Required)* |
| Liquidated Damages Assessed? |
Yes/No
Project Name
Owner Name and Contact Information
Construction Manager Contact Information
Designer/Consultant Contact Information
Contract Bid Price
Contract Final Price
Original Contract Completion Date
Date of Substantial Completion
Final Contract Completion Date
| Approx. $ Amount of Change Orders |
| Other - At Owner’s Request |
| Due to Differing Site Conditions |
| Due to A/E Errors and Omissions |
| Other - Contractor Initiated |
| *Information Required: a) Number of Claims/Disputes b) How was each Claim/Dispute resolved? (negotiation at project level, decision by Contracting Officer, arbitration, mediation, litigation, etc. c) What was the resolution in terms of contract price and time? |
Direct ($)
Indirect ($)
2. COMPLETED Projects – Contractor
| Project Information |
| Project Description |
| Subcontracting |
3. Trades and % of Work Performed by Subcontractors
4. Goals vs. Actual % Minority & % Small Local Business Enterprise Utilization Shutdown/Tie-in Coordination Summary (if applicable)
| Claims/Disputes (Information Required)* |
| Liquidated Damages Assessed? |
Project Name
Owner Name and Contact Information
Construction Manager Contact Information
Designer/Consultant Contact Information
Contract Bid Price
Contract Final Price
Original Contract Completion Date
Date of Substantial Completion
Final Contract Completion Date
| Approx. $ Amount of Change Orders |
| Other - At Owner’s Request |
| Due to Differing Site Conditions |
| Due to A/E Errors and Omissions |
| Other - Contractor Initiated |
| *Information Required: a) Number of Claims/Disputes b) How was each Claim/Dispute resolved? (negotiation at project level, decision by Contracting Officer, arbitration, mediation, litigation, etc. c) What was the resolution in terms of contract price and time? |
Direct ($)
Indirect ($)
3. COMPLETED Projects – Contractor
| Project Information |
| Project Description |
| Subcontracting |
5. Trades and % of Work Performed by Subcontractors
6. Goals vs. Actual % Minority & % Small Local Business Enterprise Utilization Shutdown/Tie-in Coordination Summary (if applicable)
| Claims/Disputes (Information Required)* |
| Liquidated Damages Assessed? |
Project Name
Owner Name and Contact Information
Construction Manager Contact Information
Designer/Consultant Contact Information
Contract Bid Price
Contract Final Price
Original Contract Completion Date
Date of Substantial Completion
Final Contract Completion Date
| Approx. $ Amount of Change Orders |
| Other - At Owner’s Request |
| Due to Differing Site Conditions |
| Due to A/E Errors and Omissions |
| Other - Contractor Initiated |
| *Information Required: a) Number of Claims/Disputes b) How was each Claim/Dispute resolved? (negotiation at project level, decision by Contracting Officer, arbitration, mediation, litigation, etc. c) What was the resolution in terms of contract price and time? |
Direct ($)
Indirect ($)
4. COMPLETED Projects – Contractor
| Project Information |
| Project Description |
| Subcontracting |
7. Trades and % of Work Performed by Subcontractors
8. Goals vs. Actual % Minority & % Small Local Business Enterprise Utilization Shutdown/Tie-in Coordination Summary (if applicable)
| Claims/Disputes (Information Required)* |
| Liquidated Damages Assessed? |
Project Name
Owner Name and Contact Information
Construction Manager Contact Information
Designer/Consultant Contact Information
Contract Bid Price
Contract Final Price
Original Contract Completion Date
Date of Substantial Completion
Final Contract Completion Date
| Approx. $ Amount of Change Orders |
| Other - At Owner’s Request |
| Due to Differing Site Conditions |
| Due to A/E Errors and Omissions |
| Other - Contractor Initiated |
| *Information Required: a) Number of Claims/Disputes b) How was each Claim/Dispute resolved? (negotiation at project level, decision by Contracting Officer, arbitration, mediation, litigation, etc. c) What was the resolution in terms of contract price and time? |
Direct ($)
Indirect ($)
5. COMPLETED Projects – Contractor
| Project Information |
| Project Description |
| Subcontracting |
9. Trades and % of Work Performed by Subcontractors
10. Goals vs. Actual % Minority & % Small Local Business Enterprise Utilization Shutdown/Tie-in Coordination Summary (if applicable)
| Claims/Disputes (Information Required)* |
| Liquidated Damages Assessed? |
Project Name
Owner Name and Contact Information
Construction Manager Contact Information
Designer/Consultant Contact Information
Contract Bid Price
Contract Final Price
Original Contract Completion Date
Date of Substantial Completion
Final Contract Completion Date
| Approx. $ Amount of Change Orders |
| Other - At Owner’s Request |
| Due to Differing Site Conditions |
| Due to A/E Errors and Omissions |
| Other - Contractor Initiated |
| *Information Required: a) Number of Claims/Disputes b) How was each Claim/Dispute resolved? (negotiation at project level, decision by Contracting Officer, arbitration, mediation, litigation, etc. c) What was the resolution in terms of contract price and time? |
Direct ($)
Indirect ($)
Rev No. ____________________ (Commission Use Only) Proposer Name _______________________________
File details come from the government source that posted it. Updated .