B08_Solicitation_140P2020R0054-CHRI 217021-S.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

NPS, DSC Contracting Services Div

12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Address listed in Box 7

Kurt Ulmer 303 969-2587

CHRI 217021

x 07/02/2020

140P2020R0054

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

CHRI 217021 Construct new bulkhead at harbor wharf at Christiansted National

Historic Site St. Croix, VI NOTE: This is a Delayed Start Project, see descriptive Project Schedule Note on page 3 below

a) This acquisition is being provided for full and open competition. The North

American Industrial Classification System (NAICS) code and the associated small business size standard are noted in clause 52.204-8 in section "K" of this solicitation.

b) Estimated Price Range: Between $5,000,000 - $10,000,000.

c) Refer to section "L" for information regarding a "remote" pre-proposal site visit.

d) Information and requirements stated in sections "B" through "J" & attachments noted in section "J" apply to this solicitation and the subsequent contract.

e) Refer to section "L" for proposal submittal requirements.

f) This is currently an unfunded requirement with a high expectation that funds will be available. When and if funds become available a contract will be awarded at that time.

g) Do NOT use FedConnect for any correspondence; the government cannot receive or respond to communications through FedConnect. Offerors shall submit proposals and questions, and acknowledge solicitation amendments as stated in section "L" of this solicitation.

Continued ...

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

14 365 calendar days and complete it within ________________ ________________ calendar days after receiving

_07/31/2020

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time

________ ___ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected .

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

DOI, NPS, DSC Contracting Services 12795 W. Alameda Pkwy

P.O. Box 25287 Denver CO 80225-0287

PDS

Dale Brown

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 166

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140P2020R0054

Legacy Doc #: NPS

Period of Performance: 08/13/2020 to 02/28/2022

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

PROJECT SCHEDULE NOTE: The Performance of this project is being delayed by factors including environmental conditions and COVID-19 impacts.

Please project a DELAYED NOTICE TO PROCEED TO

MARCH 1,2021 AND A PERFORMANCE PERIOD FROM

MARCH 1, 2021 THROUGH FEBRUARY 28, 2022.

Pricing and Scheduling for this proposal should reflect this time frame.

Solicitation 4/29/2019

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

TABLE OF CONTENTS

PART I – THE SCHEDULE

SECTION A -- SOLICITATION, OFFER, & AWARD

SECTION B – SUPPLIES OR SERVICES AND PRICES

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

SECTION D – PACKAGING AND MARKING

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

52.211-13 TIME EXTENSIONS (SEPT 2000)

52.242-14 SUSPENSION OF WORK (APR 1984)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM

(APR 2013)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL CLAUSE 1: KEY PERSONNEL

SPECIAL CLAUSE 2: SMALL BUSINESS PARTICIPATION

LIABILITY INSURANCE REQUIREMENTS

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

52.202-1 DEFINITIONS (NOV 2013)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBONTRACTOR SALES TO THE GOVERNMENT (SEPT 2006)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

52.203-7 ANTI-KICKBACK PROCEDURES (MAY 2014)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER

ACTIVITY (MAY 2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (OCT

2010)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (OCT 2015)

52.203-14 DISPLAY OF HOTLINE POSTER(S) (OCT 2015)

52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM

EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR 2014)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS

OR STATEMENTS (JAN 2017)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER FIBER CONTENT PAPER

(MAY 2011)

52.204-9 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)

52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(OCT 2018)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016)

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (JUL 2016)

52.204-21 BASIC SAFEGUARDING OF COVERED CONTRACTOR INFORMATION SYSTEMS (JUN

2016)

52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES

DEVELOPED OR PROVIDED BY KASPERSKY LAB AND OTHER COVERED ENTITIES (JUL 2018)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES AND EQUIPMENT (AUG 2019)

52.209-6 PROTECTING THE GOVERNMENT’S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (OCT 2015)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY

MATTERS (OCT 2018)

52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (NOV

2015)

52.210-1 MARKET RESEARCH (APR 2011)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

52.215-2 AUDIT AND RECORDS—NEGOTIATION (OCT 2010)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR 1984) .. 48

52.215-8 ORDER OF PRECEDENCE—UNIFORM CONTRACT FORMAT (OCT 1997)

52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)

52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS

CONCERNS (DEVIATION 2019-01)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (OCT 2018)

52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (AUG 2018) ALTERNATE II (NOV 2016)

52.219-16 LIQUIDATED DAMAGES—SUBCONTRACTING PLAN (JAN 1999)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JUL 2013)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS—OVERTIME COMPENSATION

(MAR 2018)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (AUG 2018)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (AUG 2018)

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION—DEBARMENT (MAY 2014)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIREMENTS AND RELATED

REGULATIONS (MAY 2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APRIL 2015)

52.222-26 EQUAL OPPORTUNITY (SEPT 2016)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (APRIL

2015)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (OCT 2015)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUL 2014)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (FEB 2016)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT

(DEC 2010)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

52.222-50 COMBATING TRAFFICKING IN PERSONS (JAN 2019)

2.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (OCT 2015)

52-222-55 MINIMUM WAGES UNDER EXECUTIVE ORDER 13658 (DEC 2015)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2017)

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND

CONSTRUCTION (SEP 2013)

52.223-3 HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA (JAN 1997)—

ALTERNATE I (JULY 1995)

52.223-5 POLLUTION PREVENTION AND RIGHT-TO-KNOW INFORMATION (MAY 2011)

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED PRODUCTS (MAY 2008)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED PRODUCTS—ALTERNATE I (MAY 2008)

52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (DEC 2007)

52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND

CONSTRUCTION CONTRACTS (AUG 2018)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING

(AUG 2011)

52.223-21 FOAMS (JUN 2016)

52.224-1 PRIVACY ACT NOTIFICATION (APR 1984)

52.224-2 PRIVACY ACT (APR 1984)

52.224-3 PRIVACY TRAINING (JAN 2017)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (DEC

2007)

52.227-4 PATENT INDEMNITY—CONSTRUCTION CONTRACTS (DEC 2007)

52.227-17 RIGHTS IN DATA – SPECIAL WORKS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE—WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 PLEDGES OF ASSETS (AUG 2018)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (MAY 2014)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS—CONSTRUCTION (OCT 2010)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

2.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2014)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER—SYSTEM FOR AWARD MANAGEMENT

(OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS

(DEC 2013)

52.233-1 DISPUTES (MAY 2014)—ALTERNATE I (DEC 1991)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

52.236-14 AVAILABILITY AND USE OF UTILITY SERVICES (APR 1984)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-17 LAYOUT OF WORK. (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT (JUL 1996)

52.242-5 PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (JAN 2017

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (JUN 2007)

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (AUG 2019)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.248-3 VALUE ENGINEERING—CONSTRUCTION (OCT 2015)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012)—

ALTERNATE I (SEPT 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

PART III – LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS

SECTION J – LIST OF ATTACHMENTS

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K – REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS . 140

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

52.204-24 REPRESENTATIONS REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES AND EQUIPMENT (DEC 2019)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS-CERTIFICATION (JUN

2018)

52.222-22 PREVIOUS CONTRACTS AND COMPLIANCE REPORTS (FEB 1999)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

INSTRUCTIONS FOR THE SUBMISSION OF OFFERS AND OTHER INFORMATION

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016)

52.204-22 ALTERNATE LINE ITEM PROPOSAL (JAN 2017)

52.215-1 INSTRUCTIONS TO OFFERORS—COMPETITIVE ACQUISITION (JAN 2017

52.215-16 FACILITIES CAPITAL COST OF MONEY (JUN 2003)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

1452.215-71 USE AND DISCLOSURE OF PROPOSAL INFORMATION—DEPARTMENT OF THE

INTERIOR (APR 1984)

52.216-1 TYPE OF CONTRACT (APR 1984)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY

2014)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS (MAY 2014)

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT – CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

52.228-1 PROPOSAL GUARANTEE (SEP 1996)

52.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (SEPT 2006) (DEVIATION) (JUL 1996)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

52.236-28 PREPARATION OF PROPOSALS—CONSTRUCTION (OCT 1997)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

SECTION M – EVALUATION FACTORS FOR AWARD

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

PART I – THE SCHEDULE

SECTION A -- SOLICITATION, OFFER, & AWARD

Solicitation, Offer, and Award (SF-1442) - pages 1- 3 of this package

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

SECTION B – SUPPLIES OR SERVICES AND PRICES

CONTRACT PRICE SCHEDULE

SOLICITATION NUMBER: 140P2020R0054

PARK - PMIS: CHRI 201021

DEVELOPED AREA: Wharf Bulkhead 217021 and Apron 244555 (sidewalk) PROJECT TITLE: Repair Wharf Bulkhead and Repair to Wharf Apron Notice: Offerors are required to submit, at a minimum, an offer that conforms to the solicitation documents with pricing for all CLIN line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of summation error, the total corrected amounts govern. Round totals & extended prices to whole dollars.

CONTRACT

LINE ITEM

NUMBER

(CLIN)

CONTRACT LINE ITEM (CLI)

TITLE QUANTITY UNIT OF

MEASURE UNIT PRICE TOTAL PRICE

1 LIC: General Conditions 1 LS $ _____________

2 LIC: Site Protection 1 LS $ _____________

3 LIC: Demolition and Removal 1 LS $ _____________

4 LIC: Steel Sheet Pile Bulkhead Predrilling 1 LS $ ____________

5 LIC: Steel Sheet Pile Bulkhead (Sta 0+00 to 4+97) 497 LF $ _____________

6 LIC: Concrete Cap and Fascia (Sta 0+00 to 4+97) 497 LF $ ____________

7 LIC: Granular Backfill Between Existing/Proposed Bulkhead 475 CY $ ____________

8 LIC: Concrete Gravity Wall Extension 200 LF $ _____________

9 LIC: Mooring Cleats 32 EA $ _____________

10 LIC: Sacrificial Aluminum Anodes 26 EA $ _____________

11 LIC: Timber Boardwalk Reconstruction 1 LS $ _____________

12 LIC: Site Furnishings 17 EA $ _____________

13 LIC: Vibration Monitoring 1 EA $ _____________

14 LIC: Landscape Repairs 1 LS $ _____________

TOTAL LIC PRICE (Contract Line Item Number 1 through 14) --------------------------------- $ _____________

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

15 HIM: General Conditions 1 LS $ _____________

16 HIM: Concrete Overlay Slab 11,440 SF $ _____________

17 HIM: Curb Repairs 2 EA $ _____________

18 HIM: Drainage Pipe Repairs 1 EA $ _____________

TOTAL HIM PRICE (Contract Line Item Numbers 15 through 18) ------------------------------------ $ _____________

TOTAL PROPOSED PRICE – LIC PLUS HIM (Contract Line Item Numbers 1 through 18) ----------- $ _____________

All measurement and payment information is included in the project specifications, Section 012700.

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

The work of this contract is for the construction of a new bulkhead seaward of the existing Christiansted Harbor bulkhead. One portion of the new bulkhead will consist of new cantilever steel sheet piles with reinforced concrete cap, and a second portion of the new bulkhead will consist of a new cast-in-place concrete bulkhead. The existing bulkhead will be enclosed and left in place. The bulkhead runs from the city’s boardwalk to Fort Christiansvaern on NPS property. The project will also include repairs to the existing concrete wharf apron and installation of new docking cleats. The bulkhead is approximately 730 feet long and depth of water averages approximately 10 feet.

Project Location: Christiansted National Historic Site, Christiansted, St. Croix, VI

Include brief project description: The scope of work includes the installation of a new bulkhead approximately 700 feet long that will lie waterward of the existing bulkhead. The new bulkhead will consist of steel sheet pile and concrete construction. The work also includes restoration/repair of the existing concrete wharf apron.

SPECIFICATIONS AND DRAWINGS ARE ATTACHED AND INCORPORATED HEREIN BY REFERENCE, SEE

SECTION J, AND ATTACHMENT(S)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

SECTION D – PACKAGING AND MARKING

No clauses included.

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 14 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365 days after the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the Period of Performance (POP) of 365 days as specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,621.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(End of clause)

SECTION G – CONTRACT ADMINISTRATION DATA

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the

Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING

SYSTEM (DEC 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2042_15.html https://www.cpars.gov/ https://www.cpars.csd.disa.mil/ https://www.cpars.gov/

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

(End of Notice)

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM

(APR 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract. The IPP website address is: https://www.ipp.gov.

The contractor shall submit a draft Invoice Package, including copies of the following documents, to the National Park Service’s (NPS) Construction Management Representative (CMR) a minimum of 5 working days prior to submittal of the formal Invoice through IPP. Within 5 working days of receipt, the CMR shall provide an acceptability recommendation to both the NPS Contracting Officer’s Representative (COR) and the contractor. If the CMR recommends acceptance, the contractor shall submit a copy of the final version of the CMR’s checklist and the Invoice Package to the NPS through IPP.

1. Completed copy of the CMR’s final Construction Payment Request Checklist (Submit only with the formal submittal to IPP)

2. Completed copy of the Pay Estimate Form (including signed certification of subcontractor payments)

3. Completed copy of the Limitations on Subcontracting Report

4. Certified copies of Payroll Reports per Contract clause 52.222-8 Payrolls and Basic Records.

5. Completed copy of the Payroll Report PII Certification

6. Information required by contract clause 52.232-27, Prompt Payment for Construction Contracts

7. A copy of the current construction schedule (refer to project specification section 013216)

8. A copy of the current Schedule of Values. (refer to project specification section 013216)

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause) https://www.ipp.gov/ mailto:ippgroup@bos.frb.org

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL CLAUSE 1: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Manager:

Job-site Superintendent:

Quality Control Manager:

Safety Manager:

Note: Project Manager and Superintendent roles cannot be performed by the same person, and the QC Manager and Superintendent roles cannot be performed by the same person.

(b) During the first 60 days of performance, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the initial 60-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer.

Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

(End of clause)

SPECIAL CLAUSE 2: SMALL BUSINESS PARTICIPATION

(a) Definitions. As used in this clause— “Subcontract” means any agreement (other than one involving an employer-employee relationship) entered into by a Federal Government prime Contractor calling for supplies or services required for performance of the contract.

(b) The contractor shall ensure a minimum 15% of the total contract value is performed by Small Business. This requirement may be met by

i. Self-performance by small business prime contractors and / or

ii. Subcontracting portions of the work to small businesses

(c) Prior to submittal of their initial invoice the contractor shall submit a small business participation plan that demonstrates compliance with the requirements noted in (b) above. The plan shall include:

i. A listing of anticipated subcontracts to small businesses including the following information for each subcontract:

Subcontractor name Description of supply or service

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

Subcontract dollar value

ii. If the prime contractor is a small business then also list the dollar value of the work the prime contractor will self-perform.

iii. Total dollar value for all small business subcontracts + dollar value of work to be self-performed by small business prime contractors.

iv. The total prime contract dollar value.

v. Small business participation expressed as a percentage of the total contract value contracted to small businesses and self-performed by small business prime contractors.

(d) Failure of the contractor to meet the minimum required small business participation shall be reflected in the Government’s evaluation of the contractor’s performance upon contract completion.

(End of clause)

LIABILITY INSURANCE REQUIREMENTS

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

Employer's liability $100,000

General liability $500,000

Construction Per person $100,000 Per occurrence $500,000 Property damage $1,000,000

Architect-Engineer Per person $200,000 Per occurrence $500,000 Property damage $ 20,000

Automobile liability Per person $200,000 Per occurrence for bodily injury $500,000 (other than passenger liability) Per occurrence for property damage $20,000

Aircraft public and passenger liability, when aircraft used in connection with the performing this contract Per person $200,000 Per occurrence for bodily injury $500,000 Per occurrence for property damage $200,000 Passenger liability bodily injury $200,000 multiplied by number of seats or passengers, whichever is greater

If this is a construction contract, the Contractor shall maintain compensation insurance, for employees engaged in the work, complying with the workmen's compensation laws of the State in which the work is to be performed and shall maintain liability insurance protecting the Contractor from claims because of bodily injury (including death) and property damage arising under this Contract.

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead well as the insured, the policy number and a brief description of contract services to be performed. The Contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

52.202-1 DEFINITIONS (NOV 2013)

When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR 2.101 in effect at the time the solicitation was issued, unless—

(a) The solicitation, or amended solicitation, provides a different definition;

(b) The contracting parties agree to a different definition;

(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning; or

(d) The word or term is defined in FAR Part 31, for use in the cost principles and procedures.

(End of clause)

52.203-3 GRATUITIES (APR 1984)

(a) The right of the Contractor to proceed may be terminated by written notice if, after notice and hearing, the agency head or a designee determines that the Contractor, its agent, or another representative—

(1) Offered or gave a gratuity (e.g., an entertainment or gift) to an officer, official, or employee of the Government;

and

(2) Intended, by the gratuity, to obtain a contract or favorable treatment under a contract.

(b) The facts supporting this determination may be reviewed by any court having lawful jurisdiction.

(c) If this contract is terminated under paragraph (a) of this clause, the Government is entitled—

(1) To pursue the same remedies as in a breach of the contract; and

(2) In addition to any other damages provided by law, to exemplary damages of not less than 3 nor more than 10 times the cost incurred by the Contractor in giving gratuities to the person concerned, as determined by the agency head or a designee. (This paragraph (c)(2) is applicable only if this contract uses money appropriated to the Department of Defense.)

(d) The rights and remedies of the Government provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or under this contract.

(End of clause)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

(a) The Contractor warrants that no person or agency has been employed or retained to solicit or obtain this contract upon an agreement or understanding for a contingent fee, except a bona fide employee or agency. For breach or violation of this warranty, the Government shall have the right to annul this contract without liability or, to deduct from the contract price or consideration, or otherwise recover, the full amount of the contingent fee.

(b) “Bona fide agency,” as used in this clause, means an established commercial or selling agency, maintained by a contractor for the purpose of securing business, that neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds itself out as being able to obtain any Government contract or contracts through improper influence.

https://acquisition.gov/far/current/html/Subpart%202_1.html#wp1145508 https://acquisition.gov/far/current/html/FARTOCP31.html#wp253693

Document No.

140P2020R0054

Document Title CHRI 201021 – Replace Wharf Bulkhead

“Bona fide employee,” as used in this clause, means a person, employed by a contractor and subject to the contractor’s supervision and control as to time, place, and manner of performance, who neither exerts nor proposes to exert improper influence to solicit or obtain Government contracts nor holds out as being able to obtain any Government contract or contracts through improper influence.

“Contingent fee,” as used in this clause, means any commission, percentage, brokerage, or other fee that is contingent upon the success that a person or concern has in securing a Government contract.

“Improper influence,” as used in this clause, means any influence that induces or tends to induce a Government employee or officer to give consideration or to act regarding a Government contract on any basis other than the merits of the matter.

(End of clause)

52.203-6 RESTRICTIONS ON SUBONTRACTOR SALES TO THE GOVERNMENT…